UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, DC 20549

FORM 10-K

þ

Annual Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934.1934

For the fiscal year ended December 31, 2018.2019

o

Transition Report Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934.1934

For the transition period from-to-

Commission File No. 1-6314

Tutor Perini Corporation

(Exact name of registrant as specified in its charter)

Massachusetts

04-1717070

(State of Incorporation) Massachusetts 

 04-1717070 

(State or Other Jurisdiction of Incorporation or Organization)

(IRS Employer Identification No.)

15901 Olden Street, Sylmar, California

91342

(Address of principal executive offices)

(Zip Code)

(818) 362-8391

(818) 362-8391

(Registrant’s telephone number, including area code)

Securities registered pursuant to Section 12(b) of the Act:

Title of Each Classeach class

Trading Symbol(s)

Name of each exchange on which registered

Common Stock, $1.00 par value

 TPC 

The New York Stock Exchange

Securities registered pursuant to Section 12(g) of the Act: None

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes þ  No o

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act. Yes o  No  þ

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes þ  No o

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). Yes þ  No o

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K (§ 229.405 of this chapter) is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See definitionthe definitions of “accelerated filer,” “large accelerated filer,” “accelerated filer,” “smaller reporting company”company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer

Accelerated filer

Non-accelerated filer

 Large accelerated filer þ

Accelerated filer o

Non-accelerated filer o

Smaller reporting companyo

Emerging growth companyo

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act  o

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes o  No þ

The aggregate market value of voting Common Stock held by non-affiliates of the registrant was $725,059,982$549,519,663 as of June 29, 2018,28, 2019, the last business day of the registrant’s most recently completed second fiscal quarter.

The number of shares of Common Stock, $1.00 par value per share, outstanding at February 21, 20192020 was 50,103,445.50,298,607.

Documents Incorporated by Reference

The information required by Part III of this Annual Report on Form 10-K, to the extent not set forth herein, is incorporated herein by reference to the registrant’s definitive proxy statement relating to the Annual Meeting of Shareholders to be held in 2019,2020, which definitive proxy statement shall be filed with the Securities and Exchange Commission within 120 days after the end of the fiscal year to which this Annual Report on Form 10-K relates.

��


TUTOR PERINI CORPORATION

20182019 ANNUAL REPORT ON FORM 10-K

TABLE OF CONTENTS

PAGE

PART I.

Item 1.

Business

3

Item 1A.

Risk Factors

Item 1B.

Unresolved Staff Comments

13 

Item 2.

Properties

13 

Item 3.

Legal Proceedings

13 

Item 4.

Mine Safety Disclosures

13 

PART II.Item 1A.

Risk Factors

9

Item 5.1B.

Unresolved Staff Comments

13

Item 2.

Properties

14

Item 3.

Legal Proceedings

14

Item 4.

Mine Safety Disclosures

14

PART II.

Item 5.

Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

14 

15

Item 6.

Selected Financial Data

16 

17

Item 7.

Management’s Discussion and Analysis of Financial Condition and Results of Operations

17 

18

Item 7A.

Quantitative and Qualitative Disclosures About Market Risk

26 

28

Item 8.

Financial Statements and Supplementary Data

26 

28

Item 9.

Changes in and Disagreements with Accountants on Accounting and Financial Disclosure

26 

Item 9A.

Controls and Procedures

26 

Item 9B.

Other Information

28

PART III.Item 9A.

Controls and Procedures

29

Item 10.9B.

Other Information

31

PART III.

Item 10.

Directors, Executive Officers and Corporate Governance

28 

31

Item 11.

Executive Compensation

28 

31

Item 12.

Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

28 

31

Item 13.

Certain Relationships and Related Transactions, and Director Independence

28 

Item 14.

Principal Accountant Fees and Services

28 

31

PART IV.Item 14.

Principal Accounting Fees and Services

31

PART IV.

Item 15.

Exhibits and Financial Statement Schedules

28 

31

Item 16.

Form 10-K Summary

30 

33

Signatures

31 

34

2

2


PART I.

Forward-Looking Statements

The statements contained in this Annual Report on Form 10-K that are not purely historical are forward-looking statements within the meaning of Section 27A of the Securities Act of 1933 (the “Securities Act”) and Section 21E of the Securities Exchange Act of 1934 (the “Exchange Act”), including without limitation, statements regarding our management’s expectations, hopes, beliefs, intentions or strategies regarding the future and statements regarding future guidance or estimates and non-historical performance. These forward-looking statements are based on our current expectations and beliefs concerning future developments and their potential effects on us. Our expectations, beliefs and projections are expressed in good faith, and we believe there is a reasonable basis for them. There can be no assurance that future developments affecting us will be those that we have anticipated. These forward-looking statements involve a number of risks, uncertainties (some of which are beyond our control) or other assumptions that may cause actual results or performance to be materially different from those expressed or implied by such forward-looking statements. These risks and uncertainties are listed and discussed in Item 1A. Risk Factors, below. We undertake no obligation to update or revise any forward-looking statements, whether as a result of new information, future events or otherwise, except as may be required under applicable securities laws.

ITEM 1. BUSINESS

General

Tutor Perini Corporation, formerly known as Perini Corporation (“Perini”), was incorporated in 1918 as a successor to businesses that had been engaged in providing construction services since 1894. Tutor Perini Corporation (together with its consolidated subsidiaries, “Tutor Perini,” the “Company,” “we,” “us,” and “our,” unless the context indicates otherwise) is a leading construction company, based on revenue as ranked by Engineering News-Record (“ENR”), offering diversified general contracting, construction management and design-build services to private customers and public agencies throughout the world. Our corporate headquarters are in Los Angeles (Sylmar), California, and we have various other principal offices throughout the United States and its territories (see Item 2. Properties for a listing of our major facilities). Our common stock is listed on the New York Stock Exchange under the symbol “TPC.” We are incorporated in the Commonwealth of Massachusetts.

We have established a strong reputation within our markets for executing large, complex projects on time and within budget while adhering to strict quality control measures. We offer general contracting, pre-construction planning and comprehensive project management services, including the planning and scheduling of the manpower, equipment, materials and subcontractors required for a project. We also offer self-performed construction services including site work; concrete forming and placement; steel erection; electrical, mechanical, plumbing, heating, ventilation and air conditioning (HVAC), and fire protection. During 2018,2019, we performed work on approximately 1,4001,300 construction projects.

In 2018, 2019, ENR ranked Tutor Perini as the tenth12th largest domestic contractor. We are recognized as one of the leading civil contractors in the United States, as evidenced by our performance on several of the country’s largest mass-transit and transportation projects, such as Newark Liberty International Airport Terminal One (“Newark Airport Terminal One”), the East Side Access project in New York City, the California High-Speed Rail System, the Alaskan Way Viaduct Replacement (SR 99) project in Seattle, major portions of the Red Line and Purple Line segments of the Los Angeles subway system, and the San Francisco Central Subway extension to Chinatown. We are also recognized as one of the leading building contractors in the United States, as evidenced by our performance on several of the country’s largest building development projects, including CityCenter and the Cosmopolitan Resort and Casino in Las Vegas, and Hudson Yards in New York City.

SinceAs a result of the 2008 merger between our predecessor companies, Tutor-Saliba Corporation (“Tutor-Saliba”) and Perini, Corporation,and the subsequent acquisitions that we made in 2010 and 2011, we have experienced significant growth supported by our increased size, scale, bonding capacity, access to broader geographic regions, expanded management capabilities, complementary assets and particular expertise in large, complex projects. In 2010 and 2011, we expanded vertically and geographically through the strategic acquisitions of seven companies with demonstrated success in their respective markets. These acquisitions further strengthened our geographic presence in our Building and Civil segments and also significantly increased our specialty contracting capabilities.

Our acquisitions have enabled us to provide customers with a vertically integrated service offering. This vertical integration is a unique capability and competitive advantage that allows us to self-perform a greater amount of work than our competitors. Our vertical integration increases our competitiveness in bidding and our efficiency in managing and executing large, complex projects. It also provides us with significant cross-selling opportunities across a broad geographic footprint.

Business Segment Overview

Our business is conducted through three segments: Civil, Building and Specialty Contractors.

Civil Segment

Our Civil segment specializes in public works construction and the replacement and reconstruction of infrastructure across most of the major geographic regions of the United States. Our civil contracting services include construction and rehabilitation of highways, bridges, tunnels, mass-transit systems, military defense facilities, and water management and wastewater treatment facilities.

The Civil segment is comprised of the Company’s legacy heavy civil construction operations (civil operations of our predecessors, Tutor-Saliba, its subsidiary Black Construction, and Perini Corporation)Perini), as well as our acquired companies, Frontier-Kemper, Lunda Construction and Becho. The Company’s legacy heavy civil units operate primarily on the West and East Coasts of the United States and are engaged in a variety of large mass-transit, transportation,tunneling, bridge and highway projects.Black Construction is the largest contractor in Guam and provides a variety of heavy, civil, building, mechanical and electrical construction services throughout the Western Pacific region and in other strategic military locations. Frontier-Kemper is a heavy civil contractor engaged in the construction of tunnels for highways, railroads, subways and rapid transit systems; the construction of shafts and other facilities for water supply, wastewater transport and hydroelectric projects; and the development and equipping of mines with innovative hoisting, elevator and vertical conveyance systems. Lunda Construction is a heavy civil contractor specializing in the construction, rehabilitation and maintenance of bridges, railroads and other civil structures throughout the United States. Becho is engaged in drilling, foundation and excavation support for shoring, bridges, piers, roads and highway projects, primarily in the southwestern United States. We believe that the Company has benefitted from these acquisitions by an expanded geographic presence, enhanced civil construction capabilities and the addition of experienced management with proven, successful track records.

Our Civil segment’s customers primarily award contracts through one of two methods: the traditional public “competitive bid” method, in which price is the major determining factor, or through a request for proposal, where contracts are awarded based on a combination of technical qualifications, proposed project team, schedule, past performance on similar projects and price.

Traditionally, our Civil segment’s customers require each contractor to pre-qualify for construction business by meeting criteria that include technical capabilities and financial strength. Our financial strength and outstanding record of performance on challenging civil works projects often enable us to pre-qualify for projects in situations where smaller, less diversified contractors are unable to meet the qualification requirements. We believe this is a competitive advantage that makes us an attractive partner on the largest, most complex infrastructure projects and on prestigious design-build, DBOM (design-build-operate-maintain)design-build-operate-maintain and P3 (public-private partnership)public-private partnership projects.

In its 20182019 rankings, ENR ranked us as the nation’s secondthird largest contractor in the transportation market and thirdfifth largest domestic heavy contractor.

We believe the Civil segment provides us with significant opportunities for growth due to the age and condition of existing infrastructure coupled with large government funding sources dedicated to the replacement and reconstruction of aging U.S. infrastructure. In addition, infrastructure improvement programs frequently enjoy popular, bipartisan support from the public and elected officials. Funding for major civil infrastructure projects is typically provided through a combination of one or more of the following: local, regional, state and federal loans and grants; other direct allocations sourced through tax revenue; bonds; user fees; and, for certain projects, private capital.

We have been active in civil construction since 1894 and believe we have a particular expertise in large, complex civil construction projects. We have completed, or are currently working on, some of the most significant civil construction projects in the United States. For example, we are currently working on Newark Airport Terminal One, various portions of the East Side Access project in New York City, the first phase of the California High-Speed Rail project, the Purple Line Segments 2 and 3 expansion projects in Los Angeles, and the San Francisco Central Subway extension to Chinatown.Chinatown and the Minneapolis Southwest Light Rail Transit project. We have also completed major projects such as the Alaskan Way Viaduct Replacement (SR 99) in Seattle; the platform over the eastern rail yard at Hudson Yards in New York City; the rehabilitation of the Verrazano-Narrows Bridge in New York; and multiple runway reconstruction projects, including the John F. Kennedy International Airport in New York, Los Angeles International Airport and Fort Lauderdale-Hollywood International Airport.

Building Segment

Our Building segment has significant experience providing services to a number of specialized building markets for private and public works customers, including hospitality and gaming, transportation, health care, commercial offices, government facilities, sports and entertainment, education, correctional facilities, biotech, pharmaceutical, industrial and high-tech. We believe the success of the Building segment results from our proven ability to manage and perform large, complex projects with aggressive fast-track schedules, elaborate designs, and advanced mechanical, electrical and life safety systems, while providing accurate budgeting and strict quality

4


control. Although price is a key competitive factor, we believe our strong reputation, long-standing customer relationships and significant level of repeat and referral business have enabled us to achieve a leading position in the marketplace.

4


In its 20182019 rankings, ENR ranked us as the 1117th largest domestic building contractor. We are a recognized leader in the hospitality and gaming market, specializing in the construction of high-end resorts and casinos. We work with hotel operators, Native American tribal councils, developers and architectural firms to provide diversified construction services to meet the challenges of new construction and renovation of hotel and resort properties. We believe that our reputation for completing projects on time is a significant competitive advantage in this market, as any delay in project completion could result in significant loss of revenue for the customer.

The Building segment is comprised of several operating units that provide general contracting, design-build, preconstruction and construction services in various regions of the United States. Tutor Perini Building Corp.Corporation focuses on large, complex building projects nationwide, including significant projects in the hospitality and gaming, commercial office, education, government facilities, and multi-unit residential markets. Rudolph and Sletten focuses on large, complex projects in California in the health care, commercial office, technology, industrial, education, and government facilities markets. Roy Anderson Corp. provides general contracting services, including major disaster response support, to public and private customers primarily throughout the southeastern United States. Perini Management Services provides diversified construction and design-build services internationally to U.S. government agencies, as well as to surety companies and multi-national corporations.

We have recently completed, or are currently working on, large private and public building projects across a wide array of building end markets, including commercial offices, multi-unit residential, health care, hospitality and gaming, transportation, education and entertainment. Specific projects include Newark Airport Terminal One in Newark, New Jersey; twothree large corporate office buildings in northern California for differentdistinct confidential technology customers; a commercial office tower at 10 Hudson Yards and a multi-unit residential tower at 15 Hudson Yards in New York City; the WashingtonEl Camino Hospital expansionIntegrated Medical Office Building in Fremont,El Camino, California; Kaiser Hospital Buildings in San Leandro, Redwood City and Roseville, California; the Graton RancheriaChoctaw Casino and Resort and Casino in Rohnert Park, California;Durant, Oklahoma; the Pechanga Resort and Casino expansion in Temecula, California; the Maryland Live! Casino expansionO Street Government Office Building in Hanover, Maryland; Kaiser Hospital Buildings in San Leandro and Redwood City,Sacramento, California; and courthouses in San Bernardino and San Diego, California and Broward County, Florida. As a result of our reputation and track record, we were previously awarded and completed contracts for several marquee projects in the hospitality and gaming market,projects in Las Vegas, including the Resorts World New York Casino in Jamaica, New York, as well as CityCenter, the Cosmopolitan Resort and Casino and the Wynn Encore Hotel, Trump International Hotel and Tower, Paris Las Vegas and Planet Hollywood in Las Vegas.Hotel. These projects span a wide array of building end markets and illustrate our Building segment’s résumé of successfully completed large-scale public and private projects.

Specialty Contractors Segment

Our Specialty Contractors segment specializes in electrical, mechanical, plumbing, HVAC, fire protection systems and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming, and mass-transit end markets. This segment provides unique strengths and capabilities that position us as a full-service contractor with greater control over project bids and costs, scheduled work, project delivery and risk management. The majority of work performed by the Specialty Contractors segment is contracted directly with state and local municipal agencies, real estate developers, school districts and other commercial and industrial customers. A growingsignificantportion of its work is expected to be performed for our Civil and Building segments in future years.

The Specialty Contractors segment is comprised of several operating units that provide unique services in various regions of the United States. Five Star Electric has established itself as an industry leader and is one of the largest electrical contractors in New York City. Five Star Electric provides construction services in the electrical sector, including power, lighting, fire alarm, security, telecommunications, low voltage and wireless systems to both the public and private sectors. These services are provided across end markets that include multi-unit residential, hotels, commercial offices, industrial, mass transit, education, retail, sports and entertainment, health care and water treatment. Fisk Electric (“Fisk”) covers many of the major commercial, transportation and industrial electrical construction markets in California and the southern United States, with the ability to cover other attractive markets nationwide. Fisk’s expertise is in technology design and the development of electrical and technology systems for major projects spanning a broad variety of project types, including commercial office buildings, sports arenas, hospitals, research laboratories, hotels and casinos, convention centers, manufacturing plants, refineries, and water and wastewater treatment facilities. WDF, Nagelbush and Desert Mechanical each provide mechanical, plumbing, HVAC and fire protection services to a range of customers in a wide variety of markets, including transportation, commercial/industrial, schools and universities and residential. WDF is one of the largest mechanical contractors servicing the New York City metropolitan region. Nagelbush operates primarily in Florida and Desert Mechanical operates primarily in the western United States. Superior Gunite specializes in pneumatically placed structural concrete utilized in infrastructure projects nationwide, such as bridges, dams, tunnels and retaining walls.

5


In its 20182019 rankings, ENR ranked us as the fifth13th largest electrical contractor1, 1418th largest mechanical contractor1 and 1418th largest specialty contractor1 in the United States. Through Five Star Electric and WDF, collectively, we are also the largest specialty contractor in the New York City metropolitan area.

1This ranking represents the collective revenue of the Company’s specialty contracting subsidiaries as reported to ENR.

5


Our Specialty Contractors business units have completed, or are currently working on, various portions of the East Side Access project in New York City, various projects at the World Trade Center and at Hudson Yards in New York City, upgrades and rehabilitations at various New York City public housing facilities, and electrical work for the new hospital at the University of Texas Southwestern Medical Center in Dallas. The Specialty Contractors segment has also supported, or is currently supporting, several large projects in our Civil and Building segments, including the Alaskan Way Viaduct Replacement (SR 99) project in Seattle; the San Francisco Central Subway extension to Chinatown; the Purple Line SegmentSegments 2 and 3 expansion projectprojects in Los Angeles; Newark Airport Terminal One in Newark, New Jersey; McCarran International Airport Terminal 3 in Las Vegas; and several marquee projects in the hospitality and gaming market,projects in Las Vegas, including CityCenter, the Cosmopolitan Resort and Casino, and the Wynn Encore Hotel in Las Vegas.Hotel.

Backlog

Backlog in our industry is a measure of the total value of work that is remaining to be performed on projects that have been awarded. We include a construction project in our backlog when a contract is awarded or when we have otherwise received written definitive notice that the project has been awarded to us and there are no remaining major uncertainties that the project will proceed (e.g., adequate funding is in place). As a result, we believe our backlog is firm, and although cancellations or scope adjustments may occur, historically they have not been material. We estimate that approximately $4$5 billion, or 45%44%, of our backlog as of December 31, 20182019 will be recognized as revenue in 2019.2020. Our backlog by segment, end market and customer type is presented in the following tables:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Backlog by business segment:

 

 

 

 

 

 

 

 

 

 

 

Civil

$

5,141,863 

 

55 

%

 

$

4,118,243 

 

57 

%

$

6,037,195

54

%

$

5,141,863

55

%

Building

 

2,333,127 

 

25 

%

 

1,701,378 

 

23 

%

2,790,289

25

%

2,333,127

25

%

Specialty Contractors

 

1,821,701 

 

20 

%

 

 

1,463,813 

 

20 

%

2,393,626

21

%

1,821,701

20

%

Total backlog

$

9,296,691 

 

100 

%

 

$

7,283,434 

 

100 

%

$

11,221,110

100

%

$

9,296,691

100

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Civil segment backlog by end market:

 

 

 

 

 

 

 

 

 

 

 

Mass transit

$

3,710,354 

 

72 

%

 

$

2,565,066 

 

63 

%

$

4,628,664

77

%

$

3,710,354

72

%

Military defense facilities

369,647

6

%

189,004

4

%

Bridges

 

513,839 

 

10 

%

 

617,084 

 

15 

%

364,992

6

%

513,839

10

%

Highways

 

348,589 

 

%

 

471,706 

 

11 

%

229,851

4

%

348,589

7

%

Tunneling

 

168,113 

 

%

 

266,727 

 

%

83,551

1

%

168,113

3

%

Other

 

400,968 

 

%

 

 

197,660 

 

%

360,490

6

%

211,964

4

%

Total Civil segment backlog

$

5,141,863 

 

100 

%

 

$

4,118,243 

 

100 

%

$

6,037,195

100

%

$

5,141,863

100

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Building segment backlog by end market:

 

 

 

 

 

 

 

 

 

 

 

Hospitality and gaming

$

793,624

28

%

$

26,866

1

%

Municipal and government

584,444

21

%

499,288

21

%

Commercial and industrial facilities

578,852

21

%

518,880

22

%

Mass transit

$

678,371 

 

29 

%

 

$

5,923 

 

 —

%

345,462

12

%

678,371

29

%

Commercial and industrial facilities

 

518,880 

 

22 

%

 

353,387 

 

21 

%

Municipal and government

 

499,288 

 

21 

%

 

332,073 

 

20 

%

Education facilities

233,551

8

%

177,402

8

%

Health care facilities

 

280,354 

 

12 

%

 

377,768 

 

22 

%

92,913

3

%

280,354

12

%

Education facilities

 

177,402 

 

%

 

105,585 

 

%

Mixed use

 

61,746 

 

%

 

162,291 

 

10 

%

Hospitality and gaming

 

26,866 

 

%

 

229,220 

 

13 

%

Other

 

90,220 

 

%

 

 

135,131 

 

%

161,443

7

%

151,966

7

%

Total Building segment backlog

$

2,333,127 

 

100 

%

 

$

1,701,378 

 

100 

%

$

2,790,289

100

%

$

2,333,127

100

%

1This ranking represents the collective revenue of the Company’s specialty contracting subsidiaries as reported to ENR.

6

6




As of December 31,

(in thousands)

2018

 

2017

Specialty Contractors segment backlog by end market:

 

 

 

 

 

 

 

 

 

 

 

Mass transit

$

1,132,158 

 

62 

%

 

$

780,457 

 

53 

%

Multi-unit residential

 

278,602 

 

15 

%

 

 

85,339 

 

%

Commercial and industrial facilities

 

100,163 

 

%

 

 

127,964 

 

%

Education facilities

 

95,360 

 

%

 

 

96,533 

 

%

Mixed use

 

60,159 

 

%

 

 

128,669 

 

%

Transportation

 

44,178 

 

%

 

 

68,990 

 

%

Health care facilities

 

25,296 

 

%

 

 

66,537 

 

%

Other

 

85,785 

 

%

 

 

109,324 

 

%

Total Specialty Contractors segment backlog

$

1,821,701 

 

100 

%

 

$

1,463,813 

 

100 

%

As of December 31,

(in thousands)

2019

2018

Specialty Contractors segment backlog by end market:

Mass transit

$

1,406,047

59

%

$

1,132,158

62

%

Multi-unit residential

307,009

13

%

278,602

15

%

Water

278,788

12

%

69,373

4

%

Commercial and industrial facilities

115,742

5

%

100,163

6

%

Education facilities

48,741

2

%

95,360

5

%

Other

237,299

9

%

146,045

8

%

Total Specialty Contractors segment backlog

$

2,393,626

100

%

$

1,821,701

100

%

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

2018

 

2017

2019

2018

Backlog by customer type:

 

 

 

 

 

State and local agencies

72 

%

 

66 

%

69

%

72

%

Private owners

25

%

20

%

Federal agencies

%

 

%

6

%

8

%

Private owners

20 

%

 

26 

%

Total backlog

100 

%

 

100 

%

100

%

100

%

Fixed price contracts are expected to continue to represent a sizeable percentage of total backlog. Fixed price contracts as a percentage of total backlog grew in 2018 compared to 2017. The composition of backlog by type of contract for 20182019 and 20172018 is as follows:

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

2018

 

2017

2019

2018

Backlog by contract type:

 

 

 

 

 

Fixed price

80 

%

 

67 

%

76

%

80

%

Guaranteed maximum price

%

 

12 

%

11

%

5

%

Unit price

%

 

13 

%

5

%

8

%

Cost plus fee and other

%

 

%

8

%

7

%

Total backlog

100 

%

 

100 

%

100

%

100

%

For additional information on customer types and contract types, see Note 3of the Notes to Consolidated Financial Statements.

Competition

While the construction markets include numerous competitors, especially for small to mid-sized projects, much of the work that we target is for larger, more complex projects where there are typically fewer active market participants due to the greater capabilities and resources required to perform the work. In addition to domestic competitors, we have seen certain foreign competitors attempting to grow their presence in the United States over the past several years, particularly through the pursuit of large civil projects. More recently,In recent years, however, the numberwe have observed a diminished presence from some of these foreign competitors appears to be diminishingin the bidding for manyseveral of the larger U.S. projects.project opportunities. We believe price, experience, reputation, responsiveness, customer relationships, project completion track record, schedule control, risk management and quality of work are key factors customers consider when awarding contracts.

In our Civil segment, we compete principally with large civil construction firms, including (alphabetically) Dragados USA; Fluor Corporation; Granite Construction; Kiewit Corporation; Skanska USA; Traylor Bros., Inc.; and The Walsh Group. In our Building segment, we compete with a variety of national and regional contractors, including (alphabetically) AECOM (through its acquisitions of Tishman Construction and Hunt Construction Group); Balfour Beatty Construction; Clark Construction Group; DPR Construction; Gilbane, Inc.; Hensel Phelps Construction Co.; McCarthy Building Companies, Inc.; Skanska USA; Suffolk Construction; and Turner Construction Company. In our Specialty Contractors segment, we compete principally with various regional and local electrical, mechanical and plumbing subcontractors.

Construction Costs

If prices for materials, labor or equipment increase excessively, provisions in certain types of contracts often shift all or a major portion of any adverse impact to the customer. In our fixed price contracts, we attempt to insulate ourselves from the unfavorable effects of inflation, when possible, by incorporating escalating wage and price assumptions into our construction cost estimates, by

7

7


obtaining firm fixed price quotes from major subcontractors and material suppliers, and by entering into purchase commitments for materials early in the project schedule. Construction and other materials used in our construction activities are generally available locally from multiple sources and have been in adequate supply during recent years. Labor resources for our domestic projects are largely obtained through various labor unions. We have not experienced significant labor shortages in recent years, nor do we expect to in the near future, although a significant, rapid growth in our backlog may lead to situations in which labor resources become constrained. We employ expatriate and local labor in selected overseas areas.

Environmental Matters

Our properties and operations are subject to federal, state and municipal laws and regulations relating to the protection of the environment, including requirements for water discharges; air emissions; the use, management and disposal of solid or hazardous materials or wastes; and the cleanup of contamination. In certain circumstances, we may also be required to hire subcontractors to dispose of hazardous materials encountered on a project in accordance with a plan approved in advance by the owner. We continually evaluate our compliance with all applicable environmental laws and regulations, and believe that we are in substantial compliance with those laws and regulations. However, future requirements or amendments to current laws or regulations imposing more stringent requirements could require us to incur additional costs to maintain or achieve compliance.

In addition, some environmental laws, such as the U.S. federal “Superfund” law and similar state statutes, can impose liability for the entire cost of cleanup of contaminated sites upon any of the current or former owners or operators or upon parties who generated waste at, or sent waste to, these sites, regardless of who owned the site at the time of the release or the lawfulness of the original disposal activity. Contaminants have been detected at some of the sites that we own and where we have worked as a contractor in the past, and we have incurred costs for the investigation and remediation of hazardous substances. We believe that our liabilities for these sites are not material, either individually or in the aggregate. We have pollution liability insurance coverage for such matters, and if applicable, we seek indemnification from customers to cover the risks associated with environmental remediation.

Insurance and Bonding

All of our properties and equipment, as well as those of our joint ventures, are covered by insurance in amounts that we believe are consistent with our risk of loss and industry practice. Our wholly owned subsidiary, PCR Insurance Company, issues policies for default insurance for our subcontractors, auto liability, general liability and workers’ compensation insurance, allowing us to centralize our claims and risk management functions to reduce our insurance-related costs.

As a normal part of the construction business, we are often required to provide various types of surety bonds as an additional level of security for our performance. We also require many of our higher-risk subcontractors to provide surety bonds as security for payment of subcontractors and suppliers and to guarantee their performance. As an alternative to traditional surety bonds, we also have purchased subcontractor default insurance for certain construction projects to insure against the risk of subcontractor default.

Employees

The number of our employees varies based on the number of active projects, the type and magnitude of those projects, as well as our position within the lifecycle of those projects. Our total number of employees as of December 31, 20182019 was approximately 8,200.9,100.

We are signatory to numerous local and regional collective bargaining agreements, both directly and through trade associations, as a union contractor. These agreements cover all necessary union crafts and are subject to various renewal dates. Estimated amounts for wage escalation related to the expiration of union contracts are included in our bids on various projects; accordingly, the expiration of any union contract in the next year is not expected to have any material impact on us. During the past several years, we have not experienced any significant work stoppages caused by our union employees.

Financial information about geographic areas is discussed in Note 1415 to the Consolidated Financial Statements under the heading “Geographic Information.”

Available Information

Our investor website address is http://investors.tutorperini.com. In the “Financial Reports” portion of our investor website, under the subsection “SEC Filings,” you may obtain free electronic copies of our annual reports on Form 10-K, quarterly reports on Form 10‑10-Q, current reports on Form 8-K, proxy statements, and allany amendments to thosethese reports. These reports, as well as reports under Section 16 of the Exchange Act of transactions in our stock by our directors and executive officers. These reportsany amendments to them, are made available on our website as soon as reasonably practicable after we electronically file them with the Securities and Exchange Commission (“SEC”). These reports, and any amendments to them, are also available at the Internet website of the SEC, www.sec.gov. We also maintain various documents, including our Code of Business Conduct and Ethics, Corporate Governance Guidelines and the charters of the Committees of our Board of Directors in the “Corporate Governance” portion of our investor website.

ITEM 1A. RISK FACTORS

We are subject to a number of known and unknown risks and uncertainties that could have a material adverse effect on our operations. Set forth below, and elsewhere in this report, are descriptions of the risks and uncertainties that could cause our actual results to differ materially from the results contemplated by the forward-looking statements contained in this report and could have a material adverse effect on our financial condition, results of operations and cash flows.

If we are unable to accurately estimate contract risks, revenue or costs, the timing of new awards, or the pace of project execution, we may incur a loss or achieve lower than anticipated profit.

Accounting for contract-related revenue and costs requires management to make significant estimates and assumptions that may change significantly throughout the project lifecycle, which could result in a material impact to our consolidated financial statements. In addition, cost overruns, including unanticipated cost increases on fixed price and guaranteed maximum price contracts, may result in lower profits or losses.Changes in laws, policies or regulations, including tariffs and taxes, could impact the prices for materials or equipment. Further, our results of operations can fluctuate quarterly and annually depending on when new awards occur and the commencement and progress of work on projects already awarded.

We are subject toinvolved in a significant number of legal proceedings which, if determined adversely to us, could adversely affect our financial results and/or cash flows, harm our reputation and/or preclude us from bidding on future projects and/or have a material effect on us.projects. We also may invest significant working capital on projects while legal proceedings are being settled.

We are involved in various lawsuits, including the legal proceedings described under Note 8 of the Notes to Consolidated Financial Statements. Litigation is inherently uncertain, and it is not possible to accurately predict what the final outcome will be of any legal proceeding. We must make certain assumptions and rely on estimates, which are inherently subject to risks and uncertainties, regarding potential outcomes of legal proceedings in order to determine an appropriate contingent liability and charge to income. Any result that is materially different thanfrom our expectations and estimates could have a material adverse effect on our financial condition, results of operations and cash flows. This may include requiring us to record an expense or reduce revenue that we previously recorded, based on our expectations or estimates, requiring us to pay damages or reducing cash collections that we had expected to receive. For example, on December 13, 2019, we received an adverse jury verdict in the case related to the construction of the Alaskan Way Viaduct Replacement Project (“SR 99”) by a joint venture for which the Company holds a 45% share as a minority partner. As a result of the unexpected adverse jury verdict, we recorded in a pre-tax charge of $166.8 million in 2019. Refer to the Alaskan Way Viaduct Matter in Note 8 of the Notes to Consolidated Financial Statements for further discussion. In addition, any adverse judgments could harm our reputation and preclude us from bidding on future projects.

We may bring claims against project owners for additional cost exceeding the contract price or for amounts not included in the original contract price. When these types of events occur and unresolved claims are pending, we may invest significant working capital in projects to cover cost overruns pending the resolution of the relevant claims. A failure to promptly recover on these types of claims could have a material effect on our liquidity and financial results.

Our contracts require us to perform extra, or change order, work which can result in disputes or claims and adversely affect our working capital, profits and cash flows.

Our contracts generally require us to perform extra, or change order, work as directed by the customer even if the customer has not agreed in advance on the scope and/or price of the work to be performed. This process may result in disputes or claims over whether the work performed is beyond the scope of work directed by the customer and/or exceeds the price the customer is willing to pay for the work performed. To the extent we do not recover our costs for this work or there are delays in the recovery of these costs, our working capital, profits and cash flows could be adversely impacted.

Our actual results could differ from the assumptions and estimates used to prepare our financial statements.

In preparing our financial statements, we are required under generally accepted accounting principles in the United States (“GAAP”) to make estimates and assumptions as of the date of the financial statements. These estimates and assumptions affect the reported values of assets, liabilities, revenue and expenses, and the disclosure of contingent assets and liabilities. Areas requiring significant estimates by our management include, but are not limited to:

• recognition of contract revenue, costs, profits or losses in applying the principles of revenue accounting;

• recognition of revenue related to project incentives or awards we expect to receive;

• recognition of recoveries under contract change orders or claims;

• estimated amounts for expected project losses, warranty costs, contract closeout or other costs;

• collectability of billed and unbilled accounts receivable;

9


• asset valuations;

• income tax provisions and related valuation allowances;

• determination of expense and potential liabilities under pension and other post-retirement benefit programs; and

• accruals for other estimated liabilities, including litigation and insurance revenue/reserves.

9


Our actual business and financial results could differ from our estimates of such results, which could have a material negative impact on our financial condition and reported results of operations.

A significant slowdown or decline in economic conditions could adversely affect our operations.

Any significant decline in economic conditions in any of the markets we serve or uncertainty regarding the economic outlook, could result in a decline in demand for infrastructure projects and commercial building developments. In addition, any instability in the financial and credit markets could negatively impact our customers’ ability to pay us on a timely basis, or at all, for work on projects already under construction, could cause our customers to delay or cancel construction projects in our backlog or could create difficulties for customers to obtain adequate financing to fund new construction projects. Such consequences could have an adverse impact on our future operating results. Lastly, we are more susceptible to adverse economic conditions in New York and California, as a significant portion of our operations are concentrated in those states.

We may not fully realize the revenue value reported in our backlog due to cancellations or reductions in scope.

As of December 31, 2018, our backlog of uncompleted construction work was approximately $9.3 billion. The revenue projected in our backlog may not be fully realized and, in some cases, if realized, may not result in profits or may be less profitable than expected. The cancellation or reduction in scope of significant projects included in our backlog could have a material adverse effect on our financial condition, results of operations and cash flows.

Competition for new project awards is intense, and our failure to compete effectively could reduce our market share and profits.

New project awards are determined through either a competitive bid basis or on a negotiated basis. Projects may be awarded based solely upon price, but often take into account other factors, such as technical qualifications, proposed project team, schedule and past performance on similar projects. Within our industry, we compete with many international, regional and local construction firms. Some of these competitors have achieved greater market penetration than we have in the markets in which we compete, and some have greater resources than we do. If we are unable to compete successfully in such markets, our relative market share and profits could be reduced.

The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability.

Many of our contracts are subject to specific completion schedule requirements. Any failure to meet contractual schedule requirements could subject us to liquidated damages, liability for our customer’s actual cost arising out of our delay and damage to our reputation.

In connection with mergers and acquisitions, we have recorded goodwill and other intangible assets that could become impaired and adversely affect our operating results. Assessing whether impairment has occurred requires us to make significant judgments and assumptions about the future, which are inherently subject to risks and uncertainties, and if actual events turn out to be materially less favorable than the judgments we make and the assumptions we use, we may be required to record impairment charges in the future.

We had $635.4 million of goodwill and indefinite-lived intangible assets recorded on our Consolidated Balance Sheet as of December 31, 2018. We assess these assets for impairment annually, or more often if required. Our assessments involve a number of estimates and assumptions that are inherently subjective, require significant judgment and involve highly uncertain matters that are subject to change. The use of different assumptions or estimates could materially affect the determination as to whether or not an impairment has occurred. In addition, if future events are less favorable than what we assumed or estimated in our impairment analysis, we may be required to record an impairment charge, which could have a material impact on our consolidated financial statements.

We require substantial personnel, including construction and project managers and specialty subcontractor resources to execute and perform our contracts in backlog. The successful execution of our business strategies is also dependent upon our ability to attract and retain our key officers, as well as adequately plan for their succession.

Our ability to execute and perform on our contracts in backlog depends in large part upon our ability to hire and retain highly skilled personnel, including project and construction management and trade labor resources, such as carpenters, masons and other skilled workers. In the event we are unable to attract, hire and retain the requisite personnel and subcontractors necessary to execute and perform our backlog, we may experience delays in completing projects in accordance with project schedules or an increase in expected costs, both of which could have a material adverse effect on our financial results, our reputation and our relationships. In addition, if we lack the personnel and specialty subcontractors necessary to perform on our current contract backlog, we may find it necessary to curtail our pursuit of new projects. A significant, rapid growth in our backlog may lead to situations in which labor resources become constrained.

10


The execution of our business strategies also substantially depends on our ability to retain several key members of our management. Losing any of these individuals could adversely affect our business. The majority of these key individuals are not bound by employment agreements. Volatility or lack of positive performance in our stock price may adversely affect our ability to retain key individuals to whom we have provided share-based compensation. Additionally, because a substantial portion of our key officers' compensation is placed "at risk" and linked to the performance of our business, when our operating results are negatively impacted, we are at greater risk of employee turnover. If we lose our key officers and do not have qualified successors in place, our operating results would likely be harmed.

The construction services industry is highly schedule driven, and our failure to meet the schedule requirements of our contracts could adversely affect our reputation and/or expose us to financial liability.

Many of our contracts are subject to specific completion schedule requirements. Any failure to meet contractual schedule requirements could subject us to liquidated damages, liability for our customer’s actual cost arising out of our delay and damage to our reputation.

A significant slowdown or decline in economic conditions could adversely affect our operations.

Any significant decline in economic conditions in any of the markets we serve or uncertainty regarding the economic outlook, could result in a decline in demand for infrastructure projects and commercial building developments. In addition, any instability in the financial and credit markets could negatively impact our customers’ ability to pay us on a timely basis, or at all, for work on projects already under construction, could cause our customers to delay or cancel construction projects in our backlog or could create difficulties for customers to obtain adequate financing to fund new construction projects. Such consequences could have an adverse impact on our future operating results. Lastly, we are more susceptible to adverse economic conditions in New York and California, as a significant portion of our operations are concentrated in those states.

We have a substantial amount of indebtedness which could adversely affect our financial position and prevent us from fulfilling our obligations under our debt agreements.

We currently have, and expect to continue to have, a substantial amount of indebtedness. As of December 31, 2018, we had2019, our total debt of $761.5 million.was $834.5 million, with $124.1 million classified as current debt. If we are unable to meet the terms of the financial covenants or fail to comply with any of the other restrictions contained in the agreements governing our indebtedness, an event of default could occur, causing the debt related to such agreements to become immediately due. If such acceleration occurs, we may not be able to repay such indebtedness as required. Since indebtedness under our credit agreement entered into on April 20, 2017 (the “2017 Credit FacilityFacility”) with SunTrust Bank, now known as Truist Bank, as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders is secured by substantially all of our assets, acceleration of this debt could result in foreclosure of those assets and a negative impact on our operations. In addition, a failure to meet the terms of our 2017 Credit Facility could result in a reduction of future borrowing capacity under the 2017 Credit Facility, causing a loss of liquidity. A loss of liquidity could adversely impact our ability to execute projects in our backlog, obtain new projects, engage subcontractors, and attract and retain key employees. Lastly, the 2017 Credit Facility includes a spring-forward provision whereby the facility will mature on December 17, 2020 if the 2.875% Convertible Senior Notes due June 15, 2021 (the “Convertible Notes”) remain outstanding at that time. While we do not have call rights that allow us to unilaterally redeem the Convertible Notes, we intend to repurchase or exchange the Convertible Notes and/or modify or replace

10


Table of Contents

The level of federal, state

the 2017 Credit Facility during 2020. Various alternatives are under consideration to determine the financing arrangement that is best suited to our needs and local government spending for infrastructure and other public projects could adversely affectprovides the number of projects available to usmost favorable terms. We are currently in the future.

The civil construction and public-works building markets are dependent on the amount of work funded by various government agencies, which depends on many factors, including the condition of the existing infrastructure and buildings; the need for new or expanded infrastructure and buildings; and federal, state and local government spending levels.discussions with lenders regarding our options. As a result our future operating results could be negatively impacted by any decrease in demand for public projects or decrease or delay in government funding, which could result from a variety of factors, including extended government shutdowns, delaysthe aforementioned spring-forward provision in the sale2017 Credit Facility, all borrowings under the facility are included in current debt on our balance sheet as of voter-approved bonds, budget shortfalls, credit rating downgradesDecember 31, 2019. If we are unable to repurchase or long-term impairmentexchange the Convertible Notes in 2020 and/or modify or replace the 2017 Credit Facility, all outstanding borrowings under our 2017 Credit Facility will mature and become immediately due and payable on December 17, 2020.

Weather can significantly affect our revenue and profitability.

Inclement weather conditions, such as significant storms and unusual temperatures, can impact our ability of stateto perform work. Adverse weather conditions can cause delays and local governments to raise capitalincreases in the municipal bond market.project costs, resulting in variability in our revenue and profitability.

Our participation in construction joint ventures exposes us to liability and/or harm to our reputation for failures by our partners.

As part of our business, we enter into joint venture arrangements typically to jointly bid on and execute particular projects, thereby reducing our risk profile while enhancing the execution capability and financial reward of project teams. Success on these joint projects depends in large part on whether our joint venture partners satisfy their contractual obligations. Generally, we and our joint venture partners are jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partner’s shortfall. Further, if we are unable to adequately address our partner’s performance issues, the customer may terminate the project, which could result in legal liability to us, harm our reputation, reduce our profit on a project or, in some cases, result in a loss.

We may not fully realize the revenue value reported in our backlog due to cancellations or reductions in scope.

As of December 31, 2019, our backlog of uncompleted construction work was approximately $11.2 billion. The revenue projected in our backlog may not be fully realized and, in some cases, if realized, may not result in profits or may be less profitable than expected. The cancellation or reduction in scope of significant projects included in our backlog could have a material adverse effect on our financial condition, results of operations and cash flows.

The level of federal, state and local government spending for infrastructure and other public projects could adversely affect the number of projects available to us in the future.

The civil construction and public-works building markets are dependent on the amount of work funded by various government agencies, which depends on many factors, including the condition of the existing infrastructure and buildings; the need for new or expanded infrastructure and buildings; and federal, state and local government spending levels. As a result, our future operating results could be negatively impacted by any decrease in demand for public projects or decrease or delay in government funding, which could result from a variety of factors, including extended government shutdowns, delays in the sale of voter-approved bonds, budget shortfalls, credit rating downgrades or long-term impairment in the ability of state and local governments to raise capital in the municipal bond market.

Competition for new project awards is intense, and our failure to compete effectively could reduce our market share and profits.

New project awards are determined through either a competitive bid basis or on a negotiated basis. Projects may be awarded based solely upon price, but often take into account other factors, such as technical qualifications, proposed project team, schedule and past performance on similar projects. Within our industry, we compete with many international, regional and local construction firms. Some of these competitors have achieved greater market penetration than we have in the markets in which we compete, and some have greater resources than we do. If we are unable to compete successfully in such markets, our relative market share and profits could be reduced.

In connection with mergers and acquisitions, we have recorded goodwill and other intangible assets that could become impaired and adversely affect our operating results. Assessing whether impairment has occurred requires us to make significant judgments and assumptions about the future, which are inherently subject to risks and uncertainties, and if actual events turn out to be materially less favorable than the judgments we make and the assumptions we use, we may be required to record impairment charges in the future.

We had $255.5 million of goodwill and indefinite-lived intangible assets recorded on our Consolidated Balance Sheet as of December 31, 2019. We assess these assets for impairment annually, or more often if required. Our assessments involve a number of estimates

11


and assumptions that are inherently subjective, require significant judgment and involve highly uncertain matters that are subject to change. The use of different assumptions or estimates could materially affect the determination as to whether or not an impairment has occurred. In addition, if future events are less favorable than what we assumed or estimated in our impairment analysis, we may be required to record an impairment charge, which could have a material impact on our consolidated financial statements.

Systems and information technology interruption and breaches in data security could adversely impact our ability to operate and negatively impact our operating results.

We rely on computer, information and communication technology and other related systems, some of which are hosted by third party providers, for various business processes and activities, including project management, accounting, financial reporting and business development. These systems may be subject to interruptions or damage by a variety of factors including, but not limited to, cyber-attacks, natural disasters, power loss, telecommunications failures, acts of war, computer viruses, obsolescence and physical damage. Such interruptions could result in a loss of critical data, a delay in operations or an unintentional disclosure of client confidential or personally identifiable information, any of which could have a material impact to us and our consolidated financial statements.

In addition, various privacy and security laws require us to protect sensitive and confidential information from disclosure. We dedicate considerable attention and resources to the safeguarding of our information technology systems. Our systems may, nevertheless, continue to be at risk for cyber-attacks. Consequently, we may need to engage significant resources in the future to remediate the impact of, or further mitigate the risk of, such an attack. Any successful cyber-attack could result in the criminal, or otherwise

11


illegitimate use of, confidential data, including our data or third-party data for which we have the responsibility for safekeeping. Additionally, such an attack could adversely affect our operations, reputation and financial results.

Weather can significantly affect our revenue and profitability.

Inclement weather conditions, such as significant storms and unusual temperatures, can impact our ability to perform work. Adverse weather conditions can cause delays and increases in project costs, resulting in variability in our revenue and profitability.

We are subject to a number of risks as a U.S. government contractor, which could harm our reputation, result in fines or penalties against us and/or adversely impact our financial condition.

Failure to comply with laws and regulations related to government contracts and related procurement regulations.

Our contracts with U.S. federal, as well as state, local and foreign, government entities are subject to various procurement regulations and other requirements relating to their formation, administration and performance. We are subject to audits and investigations relating to our government contracts, and any violations could result in various civil and criminal penalties and administrative sanctions, including termination of contract, termination,refunding or suspending of payments, forfeiture of profits, payment of fines and suspension or debarment from contracting with the U.S.future government civil fines and criminal prosecution, any of which could adversely affect our operations, reputation and financial results.

Conversion of our outstanding Convertible Notes could dilute ownership interests of existing stockholders and could adversely affect the market price of our common stock.

Based on the terms of the indenture for our 2.875% Convertible Senior Notes due June 15, 2021 (the “Convertible Notes”), we may redeem the Convertible Notes in cash, shares of our common stock or a combination of the two. As a result, a conversion of some or all of the Convertible Notes may dilute the ownership interests of existing stockholders. Any sales in the public market of our common stock issuable upon such conversion of the Convertible Notes could cause the price of our common stock to decline.business. In addition, some of these contracts provide for termination by the existence of the Convertible Notes may encourage short selling by market participants because a conversion of the Convertible Notes could depress the price of our common stock.government at any time, without cause.

We may need to include the potential dilutive impact of our Convertible Notes in our diluted earnings per share calculation.

We currently intend to pay the principal amount of our Convertible Notes in cash; therefore, we have not included the potential dilutive effect of our Convertible Notes in our diluted earnings per share calculations. If, however, there is a change in future circumstances as a result of a decline in our projected cash flow, available cash/liquidity or other reasons, we may conclude at such time that it will be preferable to use shares to satisfy the Convertible Notes. Such a change in our intentions would result in the inclusion of the potential dilutive impact of the Convertible Notes in our diluted earnings per share calculation, which would result in a decrease in our diluted earnings per share.

Our international operations expose us to economic, political and other risks, as well as uncertainty related to U.S. Government funding, which could adversely affect our revenue and earnings. In addition, we could be adversely affected by violations of the U.S. Foreign Corrupt Practices Act and similar worldwide anti-bribery laws.

For the year ended December 31, 2018,2019, we derived $274.5$377.1 million of revenue from our work on projects located outside of the United States. Our international operations expose us to risks inherent in doing business in certain hostile regions outside the United States, including political risks; risks of loss due to acts of war; unstable economic, financial and market conditions; potential incompatibility with foreign subcontractors and vendors; foreign currency controls and fluctuations; trade restrictions; logistical challenges; variations in taxes; and changes in labor conditions, labor strikes and difficulties in staffing and managing international operations. Failure to successfully manage risks associated with our international operations could result in higher operating costs than anticipated or could delay or limit our ability to generate revenue and income from construction operations in key international markets.

The U.S. federal government has approved various spending bills for the construction of defense- and diplomacy-related projects and has allocated significant funds to the defense of U.S. interests around the world from the threat of terrorism. The federal government has also approved funds for development in conjunction with the relocation of military personnel into Guam. However, federal government funding levels for construction projects in the Middle East have decreased significantly over the past several years as the U.S. government has reduced the number of military troops and support personnel in the region. As a result, we have seen a decrease in the number and size of federal government projects available to us in this region. Any decrease in U.S. federal government funding for projects in Guam or in other U.S. Territories or countries in which we are pursuing work may result in project delays or cancellations, which could reduce our revenue and earnings.

12


Finally, the U.S. Foreign Corrupt Practices Act, the U.K. Bribery Act of 2010, and similar anti-bribery laws in other jurisdictions generally prohibit companies and their intermediaries from making improper payments for the purpose of obtaining or retaining business. While our policies mandate compliance with these anti-bribery laws, there is no assurance that our policies and procedures will protect us from circumstances or actions that could result in possible criminal penalties or other sanctions, including contract cancellations or debarment and loss of reputation, any of which could have a material adverse impact on our business, financial condition, and results of operations.

12Adverse health events, such as an epidemic or a pandemic, could adversely impact our business.


Downgrades in our credit ratings could have a material adverse effect on our business and financial condition.

The Company’s debt rating was downgraded by a major credit rating agency on May 17, 2019. The credit ratings assigned to us and our debt are subject to ongoing evaluation by credit rating agencies and could change based upon, among other things, our results of operations and financial condition. Actual or anticipated changes or downgrades in our credit ratings, including any announcement that our ratings are under review for a downgrade, could have a material adverse effect on our costs and availability of capital, which could in turn have a material adverse effect on our financial condition, results of operations, cash flows and our ability to satisfy our debt service obligations. Negative changes in our credit ratings could also result in more stringent covenants and higher interest rates with regard to any new debt.

The phase-out of the London Interbank Offered Rate (“LIBOR”), or the replacement of LIBOR with a different reference rate, may adversely affect interest rates paid on some of our loans and consequently, our earnings and cash flows.

Borrowings under our revolving credit facility and the variable portion of our equipment financing and mortgages use interest rates in relation to LIBOR. In 2017, the United Kingdom’s Financial Conduct Authority, which regulates LIBOR, announced that it intends to phase out LIBOR by the end of 2021. It is unclear if LIBOR will cease to exist at that time or if new methods of calculating LIBOR will be established such that it continues to exist after 2021. The expected phase out of LIBOR could cause market volatility or disruption and may adversely affect our access to the capital markets and cost of funding.

Conversion of our outstanding Convertible Notes could dilute ownership interests of existing stockholders and could adversely affect the market price of our common stock.

Based on the terms of the indenture for our Convertible Notes, we may redeem the Convertible Notes in cash, shares of our common stock or a combination thereof. Should we redeem the Convertible Notes for shares of our common stock, the ownership interests of existing stockholders may be diluted and any subsequent sales in the public market of our common stock issued upon such conversion could cause the price of our common stock to decline. In addition, the existence of the Convertible Notes may encourage short selling by market participants because a conversion of the Convertible Notes could depress the price of our common stock.

Our chairman and chief executive officer could exert influence over the Company due to his position and significant ownership interest.

As of December 31, 2018,2019, our chairman and chief executive officer, Ronald N. Tutor, and three trusts controlled by Mr. Tutor (the “Tutor Group”) owned approximately 17%16% of the outstanding shares of our common stock. Additionally, one of our current directors was appointed by Mr. Tutor pursuant to his right to nominate one member to our Board of Directors, so long as the Tutor Group owns at least 11.25% of the outstanding shares of our common stock. Accordingly, Mr. Tutor could exert influence over the outcome of a range of corporate matters, including the election of directors and the approval or rejection of other extraordinary transactions, such as a takeover attempt or sale of the Company or its assets.

ITEM 1B. UNRESOLVED STAFF COMMENTS

None.

13


ITEM 2. PROPERTIES

We have office facilities and equipment yards in the following locations, which we believe are suitable and adequate for our current needs:

Offices

Owned or Leased by Tutor Perini

Business Segment(s)

Los Angeles (Sylmar), CA

Leased

Corporate, Civil & Specialty Contractors

Barrigada, Guam

Owned

Civil

Black River Falls, WI

Owned

Civil

Evansville, IN

Owned

Civil

Fort Lauderdale, FL

Leased

Building & Specialty Contractors

Framingham, MA

Owned

Building

Gulfport, MS

Owned

Building

Henderson, NV

Owned

Building & Specialty Contractors

Houston, TX

Owned

Specialty Contractors

Jessup, MD

Owned

Civil

Lakeview Terrace, CA

Leased

Specialty Contractors

Mount Vernon, NY

Leased

Specialty Contractors

New Rochelle, NY

Owned

Civil

Ozone Park, NY

Leased

Specialty Contractors

Philadelphia, PA

Leased

Building

San Carlos, CA

Leased

Building

Equipment Yards

Owned or Leased by Tutor Perini

Business Segment(s)

Black River Falls, WI

Owned

Civil

Evansville, IN

Owned

Civil

Fontana, CA

Leased

Civil

Jessup, MD

Owned

Civil

Lakeview Terrace, CA

Leased

Specialty Contractors

Peekskill, NYStockton, CA

Owned

Civil

San Leandro, CA

Leased

Specialty Contractors

Stockton, CA

Owned

Building

ITEM 3. LEGAL PROCEEDINGS

Legal Proceedings are set forth in Note 8 of the Notes to Consolidated Financial Statements and are incorporated herein by reference.

ITEM 4. MINE SAFETY DISCLOSURES

We do not own or operate any mines; however, we may be considered a mine operator under the Federal Mine Safety and Health Act of 1977 because we provide construction services to customers in the mining industry. Accordingly, we provide information regarding mine safety violations and other mining regulation matters in Exhibit 95 to this Form 10-K.

PART II.

ITEM 5. MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

Market Information

Our common stock is traded on the New York Stock Exchange under the symbol “TPC.”

Holders

At February 21, 2019,2020, there were 381363 holders of record of our common stock, including holders of record on behalf of an indeterminate number of beneficial owners.

Dividends and Issuer Purchases of Equity Securities

We did not repurchase any of our common stock during the fourth quarter of 2018.2019. We have not historically paid dividends on our common stock and have no immediate plans to do so.

Issuance of Unregistered Securities

None.

Performance Graph

The following graph compares the cumulative five-year total return to shareholders on our common stock relative to the cumulative total returns of the NYSE Composite Index and the Dow Jones U.S. Heavy Construction Index. We selected the Dow Jones U.S. Heavy Construction Index because we believe the index reflects the market conditions within the industry in which we primarily operate. The comparison of total return on investment, defined as the change in year-end stock price plus reinvested dividends, for each of the periods assumes that $100 was invested on December 31, 20132014 in each of our common stock, the NYSE Composite Index and the Dow Jones U.S. Heavy Construction Index, with investment weighted on the basis of market capitalization.

The comparisons in the following graph are based on historical data and are not intended to forecast the possible future performance of our common stock.

Picture 2Picture 1

COMPARISON OF CUMULATIVE TOTAL RETURN

Tutor Perini Corp NYSE Composite Index Dow Jones U.S. Heavy Construction Index

$225 $220 $175 $150 $125 $100 $75 $50 $25 $0

2012 2013 2014 2015 20

16 2017

ITEM 6. SELECTED FINANCIAL DATA

Selected Consolidated Financial Information

The following tables present selected financial data for the last five years. This selected financial data should be read in conjunction with Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations, Item 15. Exhibits andFinancial Statement Schedules, and the other information included elsewhere inthis Annual Report.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

CONSOLIDATED OPERATING RESULTS

Year Ended December 31,

Year Ended December 31,

(In thousands, except per common share data)

2018

 

2017

 

2016

 

2015

 

2014

2019

2018

2017

2016

2015

Revenue:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Civil

$

1,586,093 

 

$

1,602,175 

 

$

1,668,963 

 

$

1,889,907 

 

$

1,687,144 

$

1,779,352 

$

1,586,093 

$

1,602,175 

$

1,668,963 

$

1,889,907 

Building

 

1,861,699 

 

 

1,941,325 

 

 

2,069,841 

 

 

1,802,535 

 

 

1,503,837 

1,742,040 

1,861,699 

1,941,325 

2,069,841 

1,802,535 

Specialty Contractors

 

1,006,870 

 

 

1,213,708 

 

 

1,234,272 

 

 

1,228,030 

 

 

1,301,328 

929,440 

1,006,870 

1,213,708 

1,234,272 

1,228,030 

Total

 

4,454,662 

 

 

4,757,208 

 

 

4,973,076 

 

 

4,920,472 

 

 

4,492,309 

4,450,832 

4,454,662 

4,757,208 

4,973,076 

4,920,472 

Cost of operations

 

(4,000,209)

 

 

(4,302,803)

 

 

(4,515,886)

 

 

(4,564,219)

 

 

(3,986,867)

(4,209,060)

(4,000,209)

(4,302,803)

(4,515,886)

(4,564,219)

Gross profit(a)

 

454,453 

 

 

454,405 

 

 

457,190 

 

 

356,253 

 

 

505,442 

241,772 

454,453 

454,405 

457,190 

356,253 

General and administrative expenses(b)

 

(262,577)

 

 

(274,928)

 

 

(255,270)

 

 

(250,840)

 

 

(263,752)

(226,916)

(262,577)

(274,928)

(255,270)

(250,840)

Income from construction operations(a)

 

191,876 

 

 

179,477 

 

 

201,920 

 

 

105,413 

 

 

241,690 

Other income (expense), net(b)

 

4,256 

 

 

43,882 

 

 

6,977 

 

 

13,569 

 

 

(8,217)

Goodwill impairment(c)

(379,863)

Income (loss) from construction operations

(365,007)

191,876 

179,477 

201,920 

105,413 

Other income, net(d)

6,667 

4,256 

43,882 

6,977 

13,569 

Interest expense

 

(63,519)

 

 

(69,384)

 

 

(59,782)

 

 

(45,143)

 

 

(46,035)

(67,494)

(63,519)

(69,384)

(59,782)

(45,143)

Income before income taxes

 

132,613 

 

 

153,975 

 

 

149,115 

 

 

73,839 

 

 

187,438 

Income tax (expense) benefit(c)

 

(34,832)

 

 

569 

 

 

(53,293)

 

 

(28,547)

 

 

(79,502)

Net income

 

97,781 

 

 

154,544 

 

 

95,822 

 

 

45,292 

 

 

107,936 

Income (loss) before income taxes

(425,834)

132,613 

153,975 

149,115 

73,839 

Income tax benefit (expense)(e)

65,609 

(34,832)

569 

(53,293)

(28,547)

Net income (loss)

(360,225)

97,781 

154,544 

95,822 

45,292 

Less: Net income attributable to noncontrolling interests

 

14,345 

 

 

6,162 

 

 

 —

 

 

 —

 

 

 —

27,465 

14,345 

6,162 

Net income attributable to Tutor Perini Corporation

$

83,436 

 

$

148,382 

 

$

95,822 

 

$

45,292 

 

$

107,936 

Net income (loss) attributable to Tutor Perini Corporation

$

(387,690)

$

83,436 

$

148,382 

$

95,822 

$

45,292 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per common share:(a)(b)(c)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings (loss) per common share:(a)(b)(c)(d)(e)

Basic

$

1.67 

 

$

2.99 

 

$

1.95 

 

$

0.92 

 

$

2.22 

$

(7.72)

$

1.67 

$

2.99 

$

1.95 

$

0.92 

Diluted

$

1.66 

 

$

2.92 

 

$

1.92 

 

$

0.91 

 

$

2.20 

$

(7.72)

$

1.66 

$

2.92 

$

1.92 

$

0.91 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted-average common shares outstanding:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

49,952 

 

 

49,647 

 

 

49,150 

 

 

48,981 

 

 

48,562 

50,220 

49,952 

49,647 

49,150 

48,981 

Diluted

 

50,301 

 

 

50,759 

 

 

49,864 

 

 

49,666 

 

 

49,114 

50,220 

50,301 

50,759 

49,864 

49,666 

(a)

During the year ended December 31, 2018, the Company recorded a charge of $17.8 million in income from construction operations ($0.25 per diluted share), which was primarily non-cash, as a result of the unexpected adverse outcome of an arbitration decision related to a subcontract back charge dispute on a Civil segment project in New York that was completed in 2013.

_____________________________________________________________________________________________________________

(a)During the year ended December 31, 2019, the Company recorded a charge of $166.8 million in gross profit ($2.38 per diluted share) as a result of the adverse jury verdict in the case related to the construction of SR 99 by a joint venture for which the Company holds a 45% share as a minority partner. Refer to the Alaskan Way Viaduct Matter discussion in Note 8 of the Notes to Consolidated Financial Statements for further discussion of this item.

During the year ended December 31, 2018, the Company recorded a charge of $17.8 million in gross profit ($0.25 per diluted share), which was primarily non-cash, as a result of the unexpected adverse outcome of an arbitration decision related to a subcontract back charge dispute on a Civil segment project in New York that was completed in 2013.

During the year ended December 31, 2015, the Company recorded unfavorable adjustments totaling $45.6 million to income from construction operationsgross profit ($0.53 per diluted share) for various Five Star Electric projects in the Specialty Contractors segment. In addition, that same year there was a decrease of $24.3 million in income from construction operationsgross profit ($0.28 per diluted share) due to unfavorable adjustments to the estimated cost to complete a Building segment project in New York. The Company’s 2015 results were also impacted by an unfavorable adjustment for an adverse legal decision related to a long-standing litigation matter in the Civil segment, which resulted in a decrease of $23.9 million in income from construction operationsgross profit ($0.28 per diluted share). Furthermore, the Company recorded favorable adjustments for a Civil segment runway reconstruction project, which resulted in an increase of $13.7 million in income from construction operationsgross profit ($0.16 per diluted share) in 2015.

The Company's results for(b)During the year ended December 31, 2014 included2019, the Company recognized a positive impactone-time gain of $37.8 million ($0.54 per diluted share) related to changesthe Company’s acquisition of an additional 25% interest in a Civil segment joint venture for which the Company gained a controlling financial interest. The gain resulted from the remeasurement to fair value of the Company’s existing investment in the estimated recoveries for two Civil segment projectsjoint venture. For further discussion on the acquisition and the related remeasurement, see Note 13 of the Notes to Consolidated Financial Statements.

(c)During the year ended December 31, 2019, the Company recorded a Building segment hospitality and gaming project. With respect to the two Civil segment projects, there was an increasenon-cash goodwill impairment charge of $25.9$379.9 million in income (loss) from construction operations ($0.306.58 per diluted share) resulting from an interim impairment test the Company

17


performed as of June 1, 2019. For further information and a $9.4breakdown of the goodwill impairment charge by segment, see Note 6 of the Notes to Consolidated Financial Statements.

(d)On June 6, 2017, the Company received $37.0 million decrease in income from construction operations ($0.110.43 per diluted share) in a cash settlement with Merrill Lynch, Pierce, Fenner & Smith Incorporated (“Merrill Lynch”), as successor in interest to Banc of America Securities LLC and Bank of America, N.A. (collectively “BofA”). The Building project changesettlement pertained to litigation, which was filed by the Company in estimate resulted2011, and related to the purchase by the Company of certain auction-rate securities from BofA. The Company recognized the settlement as a gain during the second quarter of 2017. For additional information, see Note 10 of the Notes to Consolidated Financial Statements.

(e)As mentioned above in an $11.4footnote (c), the Company recorded a $379.9 million increase ingoodwill impairment charge during 2019, of which approximately $209.5 million is not deductible for income from construction operationstax purposes. The Company recognized a tax benefit totaling $49.4 million ($0.140.98 per diluted share). as a result of the impairment charge.

In December 2017, the Tax Cuts and Jobs Act of 2017 (“TCJA”) was enacted reducing the U.S. corporate income tax rate from 35% to 21%, effective in 2018. As a result, tax expense in 2019 and 2018 was positively impacted and in 2017 the Company recognized a favorable tax adjustment of $53.3 million ($1.05 per diluted share) primarily due to a one-time revaluation of its deferred tax assets and liabilities in connection with the adoption of the TCJA. For a further discussion of the effect of the TCJA, see Note 5 of the Notes to Consolidated Financial Statements.

(b)

On June 6, 2017, the Company received $37.0 million ($0.43 per diluted share) in a cash settlement with Merrill Lynch, Pierce, Fenner & Smith Incorporated (“Merrill Lynch”), as successor in interest to Banc of America Securities LLC and Bank of America, N.A. (collectively “BofA”). The settlement pertained to litigation, which was filed by the Company in 2011, and related to the purchase by the Company of certain auction-rate securities from BofA. The Company recognized the settlement as a gain during the second quarter of 2017. For additional information, see Note 9 of the Notes to Consolidated Financial Statements.

As of and For the Year Ended December 31,

(In thousands, except ratios and percentages)

2019

2018

2017

2016

2015

CONSOLIDATED FINANCIAL POSITION

Current assets

$

3,510,986 

$

3,175,643 

$

3,074,392 

$

2,837,756 

$

2,608,939 

Current liabilities

2,109,856 

1,597,966 

1,581,846 

1,518,943 

1,448,819 

Working capital

$

1,401,130 

$

1,577,677 

$

1,492,546 

$

1,318,813 

$

1,160,120 

Current ratio

1.66 

1.99 

1.94 

1.87 

1.80 

Property and equipment, net of accumulated depreciation

$

509,685 

$

490,669 

$

467,499 

$

477,626 

$

523,525 

Total assets

4,485,777 

4,387,752 

4,264,123 

4,038,620 

3,861,300 

Capitalization:

Total debt

834,476 

761,504 

736,276 

759,519 

817,684 

Stockholders’ equity

1,440,142 

1,809,177 

1,713,275 

1,553,023 

1,420,227 

Total capitalization

$

2,274,618 

$

2,570,681 

$

2,449,551 

$

2,312,542 

$

2,237,911 

Total debt as a percentage of total capitalization

37 

%

30 

%

30 

%

33 

%

37 

%

Ratio of debt to equity

0.58 

0.42 

0.43 

0.49 

0.58 

Stockholders' equity per common share

$

28.64 

$

36.16 

$

34.42 

$

31.56 

$

28.94 

OTHER DATA

Backlog at year end

$

11,221,110 

$

9,296,691 

$

7,283,434 

$

6,227,137 

$

7,465,129 

New awards

6,375,262 

6,467,918 

5,813,505 

3,735,084 

4,553,877 

Capital expenditures

84,196 

77,069 

30,280 

15,743 

35,912 

Net cash provided by operating activities

136,530 

21,402 

163,550 

113,336 

14,072 

Net cash used in investing activities

(76,055)

(70,208)

(87,133)

(13,844)

(30,932)

Net cash provided by (used in) financing activities

21,763 

(28,979)

(75,376)

(24,190)

(41,788)

_____________________________________________________________________________________________________________

16


(c)

In December 2017, the Tax Cuts and Jobs Act of 2017 (“TCJA”) was enacted reducing the U.S. corporate income tax rate from 35% to 21%, effective in 2018. As a result, tax expense in 2018 was positively impacted and in 2017 the Company recognized a favorable tax adjustment of $53.3 million ($1.05 per diluted share) primarily due to a one-time revaluation of its deferred tax assets and liabilities in connection with the adoption of the TCJA. For a further discussion of the effect of the TCJA, see Note 5 of the Notes to Consolidated Financial Statements.



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



As of and For the Year Ended December 31,

 

(In thousands, except ratios and percentages)

2018

 

2017

 

2016

 

2015

 

2014

 

CONSOLIDATED FINANCIAL POSITION

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Current assets

$

3,175,643 

 

$

3,074,392 

 

$

2,837,756 

 

$

2,608,939 

 

$

2,454,594 

 

Current liabilities

 

1,597,966 

 

 

1,581,846 

 

 

1,518,943 

 

 

1,448,819 

 

 

1,344,447 

 

Working capital

$

1,577,677 

 

$

1,492,546 

 

$

1,318,813 

 

$

1,160,120 

 

$

1,110,147 

 

Current ratio

 

1.99 

 

 

1.94 

 

 

1.87 

 

 

1.80 

 

 

1.83 

 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Property and equipment, net of accumulated depreciation

$

490,669 

 

$

467,499 

 

$

477,626 

 

$

523,525 

 

$

527,602 

 

Total assets

 

4,387,752 

 

 

4,264,123 

 

 

4,038,620 

 

 

3,861,300 

 

 

3,711,450 

 

Capitalization:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total debt

 

761,504 

 

 

736,276 

 

 

759,519 

 

 

817,684 

 

 

857,791 

 

Stockholders’ equity

 

1,809,177 

 

 

1,713,275 

 

 

1,553,023 

 

 

1,420,227 

 

 

1,365,505 

 

Total capitalization

$

2,570,681 

 

$

2,449,551 

 

$

2,312,542 

 

$

2,237,911 

 

$

2,223,296 

 

Total debt as a percentage of total capitalization

 

30 

%

 

30 

%

 

33 

%

 

37 

%

 

39 

%

Ratio of debt to equity

 

0.42 

 

 

0.43 

 

 

0.49 

 

 

0.58 

 

 

0.63 

 

Stockholders' equity per common share

$

36.16 

 

$

34.42 

 

$

31.56 

 

$

28.94 

 

$

28.06 

 

OTHER DATA

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Backlog at year end

$

9,296,691 

 

$

7,283,434 

 

$

6,227,137 

 

$

7,465,129 

 

$

7,831,725 

 

New awards

 

6,467,918 

 

 

5,813,505 

 

 

3,735,084 

 

 

4,553,877 

 

 

5,369,747 

 

Capital expenditures

 

77,069 

 

 

30,280 

 

 

15,743 

 

 

35,912 

 

 

75,829 

 

Net cash provided by (used in) operating activities

 

21,402 

 

 

163,550 

 

 

113,336 

 

 

14,072 

 

 

(56,678)

 

Net cash used in investing activities(a)

 

(70,208)

 

 

(87,133)

 

 

(13,844)

 

 

(30,932)

 

 

(25,181)

 

Net cash provided by (used in) financing activities

 

(28,979)

 

 

(75,376)

 

 

(24,190)

 

 

(41,788)

 

 

99,295 

 

(a)

Prior years were adjusted retrospectively to exclude changes in restricted cash from investing activities in accordance with Accounting Standards Update 2016-18, Statement of Cash Flows,as discussed in Note 1 of the Notes to Consolidated Financial Statements.

ITEM 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our Consolidated Financial Statements and the accompanying Notes to Consolidated Financial Statements included in Item 15. Exhibits and Financial Statement Schedules in this Annual Report. This discussion contains forward-looking statements, which involve risks and uncertainties. For cautions about relying on such forward-looking statements, please refer to the section entitled “Forward-Looking Statements”Forward-Looking Statements at the beginning of this Annual Report immediately prior to Item 1. Our actual results could differ materially from those anticipated in the forward-looking statements as a result of certain factors, including, but not limited to, those discussed in Item 1A. Risk Factors and elsewhere in this Annual Report.

18


Comparison of Fiscal Years 2018 and 2017

For a discussion comparing our fiscal 2018 results to fiscal 2017, refer to Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations in our Form 10-K for the fiscal year ended December 31, 2018, as filed with the Securities and Exchange Commission on February 27, 2019.

Executive Overview

Consolidated revenue for 20182019 was $4.5 billion, comparedwhich is comparable to $4.8 billion for 2017. The decreaserevenue in 2018. Revenue in 2019 was primarily driven by a mix of Building segment projects in California, including a large technology project that completed in the second quarter of 2018, and various electrical projects in New York within the Specialty Contractors segment, as revenue generated from project execution activities for certain new projects starting up did not fully offset reduced revenue from projects that have completed or are nearing completion.

Consolidated revenue for 2017 was $4.8 billion compared to $5.0 billion for 2016. The slight reduction was primarily due to decreased volume in our Building and Civil segments attributed to various projects that were completed or nearing completion. The decrease was partially offsetfavorably impacted by higher volume on certain Civil segment projects, which was mostly offset by a $123.9 million reduction in California and New York, as well as certain Building segment projectsrevenue associated with the SR 99-related charge discussed in California and Maryland. In addition, revenue in 2017 was negatively impacted by the timingfollowing paragraph.

For the year ended December 31, 2019, the Company reported a loss from construction operations of certain Building and Civil projects that were in ramp-up stages.

17


Despite the volume reduction,$365.0 million compared to income from construction operations increased 7% in 2018 toof $191.9 million comparedin 2018. The loss was primarily driven by the $379.9 million pre-tax non-cash goodwill impairment charge recorded in 2019 (see Note 6 of the Notes to $179.5 millionConsolidated Financial Statements). Adjusted income from construction operations for 2019, which is a non-GAAP financial measure and excludes the non-cash goodwill impairment charge, was $14.9 million. (For a discussion of non-GAAP financial measures, including a reconciliation of non-GAAP financial measures to the most nearly comparable GAAP financial measures, see the section below titled Non-GAAP Financial Measures.) The decrease in 2017. The increaseadjusted income from construction operations was primarily due to unfavorable adjustments that occurred in 2017 on certain mechanical projects in New York ($13.1a $166.8 million in the aggregate, none of which were individually material) and California (which were not material individually or in the aggregate), as well as general and administrative expense savings in 2018 largelypre-tax charge related to lower compensation costs.the adverse SR 99 jury verdict. The increase was partially offset by a pre-taxSR 99-related charge inprincipally impacted the first quarter of 2018 totaling $17.8 million, which was attributableCivil segment. For additional information, refer to the unexpected adverse outcomeAlaskan Way Viaduct Matter discussion in Note 8 of an arbitration decision on a completed Civil segment project in New York.the Notes to Consolidated Financial Statements.

Income from construction operations for 2017 was $179.5 million compared to $201.9 million for 2016. The decrease was driven by the unfavorable adjustments in 2017 related to certain mechanical projects mentioned in the preceding paragraph, the lower volume in 2017 relative to 2016 and higher compensation-related general and administrative expenses in 2017. The decrease was partially offset by work performed on certain higher margin Civil and Building projects.

The effective tax rate for 2019 was 15.4% compared to 26.3%, (0.4)% for 2018. During 2019, the Company recognized an income tax benefit of $65.6 million as a result of the pre-tax loss primarily related to the goodwill impairment and 35.7%SR 99 charges mentioned above. The goodwill impairment charge was not fully deductible for 2018, 2017income taxes, which significantly reduced the tax benefit and 2016, respectively. The effective tax ratesrate for 2018 and 2017 were favorably impacted by the enactment of the TCJA, which was signed into law on December 22, 2017.year. For a further discussion of the effect of the TCJA,goodwill impairment charge, see Note 5 of the Notes to Consolidated Financial Statements.

EarningsDiluted loss per share for 2019 was $7.72 compared to diluted earnings per share wasof $1.66 $2.92 and $1.92 in 2018, 2017 and 2016, respectively.for 2018. The decreasedsubstantially reduced earnings in 20182019 were primarily attributable to the $17.8 million charge mentioned above. The higher earnings in 2017 compared to 2016 were primarily due to the above-mentioned tax benefit of $53.3 milliongoodwill impairment ($1.056.58 per diluted share), as well as the 2017 gain on a $37.0 million and SR 99-related ($0.432.38 per diluted share) legal settlement mentioned above (also see Note 9 of the Notes to Consolidated Financial Statements).charges.

Consolidated new awards in 20182019 were $6.5$6.4 billion compared to $5.8$6.5 billion in 2017 and $3.7 billion in 2016.2018. The Civil and Building segments were the predominant contributors of new awards during 20182019 and 2016. The Civil segment was the major contributor of new awards during 2017.2018.

Consolidated backlog as of December 31, 2019 was $9.3$11.2 billion $7.3 billion and $6.2compared to $9.3 billion as of December 31, 2018, 2017 and 2016, respectively.2018. The Company experienced backlog growth of 28%21% in 2018,2019, driven by various large awards in the Civil and Building segments. As of December 31, 2018,2019, the mix of backlog by segment was 55%54% for Civil, 25% for Building and 20%21% for Specialty Contractors. The Company experienced backlog growth of 17% in 2017, driven by various awards in the Civil segment.

Most projects in the Civil segment’s backlog typically convert to revenue over a period of three to five years and in the Building and Specialty Contractors segments over a period of one to three years. We estimate that approximately $4$5 billion, or 45%44%, of our backlog as of December 31, 20182019 will be recognized as revenue in 2019.2020.

The following table presents the changes in backlog in 2018:2019:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Backlog at

 

 

 

Revenue

 

Backlog at

Backlog at

Revenue

Backlog at

December 31,

 

New Awards

 

Recognized

 

December 31,

December 31,

New Awards

Recognized

December 31,

(in millions)

2017

 

in 2018 (a)

 

in 2018

 

in 2018 (b)

2018

in 2019 (a)

in 2019

2019(b)

Civil

$

4,118.2 

 

$

2,609.8 

 

$

(1,586.1)

 

$

5,141.9 

$

5,141.9

$

2,674.7

$

(1,779.4)

$

6,037.2

Building

 

1,701.4 

 

 

2,493.4 

 

 

(1,861.7)

 

2,333.1 

2,333.1

2,199.2

(1,742.0)

2,790.3

Specialty Contractors

 

1,463.8 

 

 

1,364.8 

 

 

(1,006.9)

 

1,821.7 

1,821.7

1,501.3

(929.4)

2,393.6

Total

$

7,283.4 

 

$

6,468.0 

 

$

(4,454.7)

 

$

9,296.7 

$

9,296.7

$

6,375.2

$

(4,450.8)

$

11,221.1

_____________________________________________________________________________________________________________

(a)New awards consist of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

(b)Backlog may differ from the transaction prices allocated to the remaining performance obligations as disclosed in Note 3 of the Notes to Consolidated Financial Statements. Such differences relate to the timing of executing a formal contract or receiving a notice to proceed. More specifically, backlog sometimes may include awards for which a contract has not yet been executed or a notice to proceed has not been issued, but for which there are no remaining major uncertainties that the project will proceed (e.g., adequate funding is in place).

(a)

New awards consist of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

19


(b)

Backlog may differ from the transaction prices allocated to the remaining performance obligations as disclosed in Note 3 of the Notes to the Consolidated Financial Statements. Such differences relate to the timing of executing a formal contract or receiving a notice to proceed. More specifically, backlog sometimes may include awards for which a contract has not yet been executed or a notice to proceed has not been issued, but for which there are no remaining major uncertainties that the project will proceed (e.g., adequate funding is in place).

The outlook for ourthe Company’s growth over the next several years remains favorable, particularly in the Civil and Specialty Contractors segments, although the pace of growth could continue to be moderatedimpacted by project delays or the timing of project completionscommencements, ramp-up activities and project ramp-up activities.completions. We anticipate that additionalwe will continue to win our share of significant new awards should benefit these segments based onresulting from long-term capital spending plans by state, local and federal customers, as well as bipartisan support for infrastructure investments.investments and limited competition for some of the largest project opportunities. In recent years, voters in numerous states approved dozens of long-term transportation funding measures totaling approximately $200 billion in long-term funding. The largest of these were in Los Angeles County, where Measure M, a half-cent sales tax increase, was approved and is expected to generate $120 billion of funding over 40 years, and in Seattle, Washington, where Sound Transit 3 was passed and is expected to generate $54 billion of funding over 25 years. Recently, there has been renewed interest at the federal government level in passing budgetary measures that would provide significant long-term funding for infrastructure investments. In addition, the Trump Administration previously proposed a significant infrastructure investment program. Furthermore, several large, long-duration civil infrastructure programs with which we are already involved are progressing, such as the Purple Line Extension projects in Los Angeles and New York City’s East Side Access project.

18


Planning and permitting activities continue on Amtrak’s Northeast Corridor Improvements, including the Gateway Program, which is expected to rehabilitate an existing tunnel and construct a new rail tunnel beneath the Hudson River to connect service between New Jersey and New York’s Penn Station.Angeles. Finally, while interest rates have climbed modestly from their historical low levels, they remain relatively low and generally favorableconducive to sustain continued demand and spending by public and private customers on infrastructure projects.customer spending.

For a more detailed discussion of operating performance of each business segment, corporate general and administrative expenses and other items, see Results of Segment Operations, Corporate, Tax and Other Matters and Liquidity and Capital Resources below.

Non-GAAP Financial Measures

To supplement our consolidated financial statements presented under generally accepted accounting principles in the United States (“GAAP”), we are presenting certain non-GAAP financial measures. We are providing these non-GAAP financial measures to disclose additional information to facilitate the comparison of past and present operations, and they are among the indicators management uses as a basis for evaluating the Company’s financial performance as well as for forecasting future periods. We believe that these non-GAAP financial measures, when considered together with our GAAP financial results, provide management and investors with an additional understanding of our business operating results, including underlying trends.

These non-GAAP financial measures, which exclude the non-cash goodwill impairment charge (as well as the tax benefit associated with this charge), include adjusted income (loss) from construction operations, adjusted net income (loss) attributable to Tutor Perini Corporation, adjusted diluted earnings (loss) per common share and adjusted effective income tax rate. We also reference adjusted operating margin for each segment, which is a non-GAAP financial measure that we define as adjusted income (loss) from construction operations as a percentage of revenue. These non-GAAP financial measures are not intended to replace the presentation of our financial results in accordance with GAAP, and they may not be comparable to other similarly titled non-GAAP financial measures presented by other companies. Reconciliations of these non-GAAP financial measures to the most nearly comparable GAAP financial measures are presented below. For the year ended December 31, 2018, there are no non-GAAP financial measures presented or included in the reconciliation tables below because the non-GAAP financial measures, as defined by the Company, do not differ from GAAP results in those periods, as the only adjustment occurred in 2019.

Reconciliation of Non-GAAP Financial Measures

Specialty

Consolidated

(in millions)

Civil

Building

Contractors

Corporate

Total

Year Ended December 31, 2019

Income (loss) from construction operations, as reported

$

(150.9)

$

23.7

$

(172.6)

$

(65.2)

$

(365.0)

Plus: Goodwill impairment charge

210.2

13.5

156.2

379.9

Adjusted income (loss) from construction operations

$

59.3

$

37.2

$

(16.4)

$

(65.2)

$

14.9

Year Ended December 31,

(in millions, except per common share amounts and percentages)

2019

2018

Net income (loss) attributable to Tutor Perini Corporation, as reported

$

(387.7)

$

83.4

Plus: Goodwill impairment charge

379.9

Less: Tax benefit provided on goodwill impairment charge

(49.4)

Adjusted net income (loss) attributable to Tutor Perini Corporation

$

(57.2)

$

83.4

Diluted earnings (loss) per common share, as reported

$

(7.72)

$

1.66

Plus: Goodwill impairment charge

7.56

Less: Tax benefit provided on goodwill impairment charge

(0.98)

Adjusted diluted earnings (loss) per common share

$

(1.14)

$

1.66

Effective income tax rate, as reported

15.4

%

26.3

%

Tax effect of goodwill impairment charge

19.9

%

%

Adjusted effective income tax rate

35.3

%

26.3

%

20


Results of Segment Operations

The results of our Civil, Building and Specialty Contractors segments are discussed below:

Civil Segment

Revenue, income (loss) from construction operations and adjusted income from construction operations for the Civil segment are summarized as follows:

Year Ended December 31,

(in millions)

2019

2018

Revenue

$

1,779.4

$

1,586.1

Income (loss) from construction operations, as reported

(150.9)

168.3

Plus: Goodwill impairment charge

210.2

Adjusted income from construction operations

59.3

168.3



 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 



Year Ended December 31,

(in millions)

2018

 

2017

 

2016

Revenue

$

1,586.1 

 

$

1,602.2 

 

$

1,669.0 

Income from construction operations

 

168.3 

 

 

192.2 

 

 

172.7 

Revenue for 2018 decreased slightly2019 increased 12% compared to 2017, as the impact of certain large projects that completed or are nearing completion2018. The growth was approximately offset by projects that started or experienced higher volume during 2018. Revenue for 2017 decreased 4% compared to 2016 primarily due to the impact of certain projects in New York, Washington and the Midwest that were completed or nearing completion in 2017. The decrease was partially offsetprincipally driven by increased activityproject execution activities on certain mass-transit projects in California and New YorkMinnesota that were ramping up.are early in their project life cycles, as well as increased activities on the Newark Airport Terminal One project. The growth was partially offset by the revenue reduction associated with the adverse SR 99 jury verdict discussed in the section entitled Executive Overview.

Income (loss) from construction operations decreased 12%significantly in 20182019 compared to 2017,2018, mainly due to the goodwill impairment charge. Despite the strong revenue growth, adjusted income from construction operations for 2019 decreased 65% compared to 2018, primarily due to the impact of the SR 99-related charge ($155.8 million of the $166.8 million impacted the Civil segment), partially offset by the $37.8 million reduction in general and administrative expenses associated with the remeasurement gain that resulted from the Company increasing its ownership interest in a joint venture (see Note 13 of the Notes to Consolidated Financial Statements) and income contributions related to the volume increase mentioned above.

Operating margin was (8.5)% and adjusted operating margin was 3.3% for 2019 compared to 10.6% in 2018. The reduction in operating margin for 2019 was driven by the goodwill impairment and SR 99 charges mentioned above. The decrease in adjusted operating margin for 2019 was principally due to the $17.8 million charge in the first quarter of 2018 discussed above in the Executive Overview. Income from construction operations increased 11% in 2017 compared to 2016, principally due to increased project execution activity on certain higher-margin projects in California and New York.

Operating margin was 10.6% in 2018 compared to 12.0% in 2017 and 10.3% in 2016. The operating margin changes in 2018 and 2017 were primarily due to the reasons discussedfactors mentioned above that impacteddrove the changes to revenue and adjusted income from construction operations.

New awards in the Civil segment totaled $2.7 billion in 2019 compared to $2.6 billion in 2018, $3.02018. New awards in 2019 included the $1.4 billion Purple Line Section 3 Stations project and the $432 million Division 20 Portal Widening and Turnback Facility project, both in 2017California; the $253 million Culver Line Communications-Based Train Control project in New York; and $1.6 billiona $178 million military facilities project and a $122 million wastewater treatment project, both in 2016. Guam.

New awards in 2018 included the $800 million Minneapolis Southwest Light Rail Transit project in Minnesota; the Civil segment’s 50% share of the $1.4 billion Newark Airport Terminal One project, net of subcontracts awarded to Five Star Electric and WDF in the Specialty Contractors segment (with the remaining 50% share of the project booked in the Building segment’s backlog); a $410 million mass-transit project in California; a $121 million water tunnel project in California; a $93 million bridge project in New York; and an $82 million aircraft maintenance facility and hangar project in Guam.

New awards in 2017 included a $1.4 billion joint venture mass-transit project in California; a bridge project in Iowa valued at $323 million; a mass-transit project in New York worth $292 million; a joint venture tunnel project for a hydroelectric generating station in British Columbia valued at $274 million; a bridge project in New York valued at $189 million; $97 million of additional scope for a platform project in New York; a joint venture bridge project in Minnesota, for which the Company’s portion is valued at $90 million; a bridge project in New York valued at $82 million; a highway project in Maryland worth $78 million; and a military training range project in Guam worth $78 million. New awards in 2016 included a $663 million mass-transit project in New York, approximately $277 million of new bridge projects in the Midwest, the Company’s share of $244 million of additional contract scope for a mass-transit project in California, a $107 million highway project in Virginia and a $97 million airport terminal expansion project in Guam.

Backlog for the Civil segment was $6.0 billion as of December 31, 2019, an increase of 17% compared to $5.1 billion as of December 31, 2018, compared to $4.1 billion as of December 31, 2017 and $2.7 billion as of December 31, 2016. Civil segment2018. The strong backlog grew 25% year-over-year in 2018 as a result ofgrowth was driven by the significant new award activity discussed above. The segment continues to experience strong demand reflected in a large pipeline of prospective projects that are supported by substantial anticipated funding from various voter-approved transportation measures and public agencies’ long-term spending plans. The Civil segment is well-positioned to capturecontinue capturing its share of these prospective projects. The segment, however, continues to face considerable competition, including periodic aggressive bids from competitors.

Building Segment

Revenue, income from construction operations and adjusted income from construction operations for the Building segment are summarized as follows:

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in millions)

2018

 

2017

 

2016

2019

2018

Revenue

$

1,861.7 

 

$

1,941.3 

 

$

2,069.8 

$

1,742.0

$

1,861.7

Income from construction operations

 

43.9 

 

34.2 

 

51.6 

Income from construction operations, as reported

23.7

43.9

Plus: Goodwill impairment charge

13.5

Adjusted income from construction operations

37.2

43.9

Revenue for 20182019 decreased modestly6% compared to 2017. The decrease was2018 primarily driven by the net impact of the completion and ramp-up of various large projects in California, with the biggest contributor being a large technology project that was completed in the second quarter of 2018. Revenue for 2017 decreased slightly compared to 2016, principally due to decreaseda reduction in project execution activityactivities on certainhealth care projects in California and Florida that were substantially complete, partially offset by increased activity on certain hospitality and gaming projects and a large technology project.

Despite the slight volume reduction, income from construction operations increased 28% in 2018 compared to 2017, largely due to contributions from the Newark Airport Terminal One project and a favorable closeout adjustment on a courthouse project in California. Income from construction operations decreased 34% in 2017 compared to 2016, primarily due to favorable closeout activities in 2016 on two projects in New York and the volume changes mentioned above.various states. The decrease was partially offset by improved performanceincreased activities on a large technologythe Newark Airport Terminal One project and an industrial revitalization project in California that was nearing completion.Mississippi.

Income from construction operations decreased 46% in 2019 compared to 2018, primarily due to the goodwill impairment charge recorded in 2019. Adjusted income from construction operations for 2019 decreased 15% compared to 2018 mainly due to the absence of prior-year project closeout adjustments, none of which were individually material, partially offset by increased project contributions from other projects, including Newark Airport Terminal One, in the current year.

Operating margin was 1.4% and adjusted operating margin was 2.1% in 2019 compared to 2.4% in 2018 compared to 1.8%2018. The reduction in 2017 and 2.5% in 2016. The operating margin changesfor 2019 was driven by the aforementioned goodwill impairment charge recorded. The slight reduction in 2018 and 2017 were due toadjusted operating margin for 2019 was primarily driven by the factors mentioned above that drove the changes in revenue and adjusted income from construction operations.

New awards in the Building segment totaled $2.2 billion in 2019 compared to $2.5 billion in 2018, $1.7 billion2018. New awards in 20172019 included the Choctaw Casino and $1.3 billionResort project in 2016. Oklahoma; a large hospitality and gaming project in California; a $263 million courthouse project in Florida; a technology campus tenant improvement project in California valued at more than $200 million; and the $200 million Southland Gaming Casino and Hotel project in Arkansas.

New awards in 2018 included the Building segment’s 50% share of the $1.4 billion Newark Airport Terminal One project, net of subcontracts awarded to Five Star Electric and WDF in the Specialty Contractors segment; $311 million of additional funding for a technology project in California; a government office building project in California valued at $215 million; a $100 million military facility project in Saudi Arabia; an $88 million airport parking garage project in South Carolina; and incremental funding of $90 million and $82 million, respectively, for another technology office project and a health care project, both in California.

New awards in 2017 included four health care projects in California collectively worth $328 million; $250 million of initial funding for a technology office building in California; additional scope of work valued at $121 million for another technology office project in California; a U.S. embassy renovation project in Uruguay valued at $87 million; and an $80 million military facility project in Saudi Arabia. New awards in 2016 included a hospitality and gaming project in California and another in Maryland, collectively valued at $372 million; a hospitality project in California valued at $120 million; and a multi-unit residential project in Florida valued at $72 million.

Backlog for the Building segment was $2.8 billion as of December 31, 2019, an increase of 20% compared to $2.3 billion as of December 31, 2018, compared to $1.7 billion as of December 31, 2017 and $2.0 billion as of December 31, 2016.2018. The strong backlog growth in 2018 was primarily due todriven by the new award of the Newark Airport Terminal One project. The decline in backlog for 2017 was due to revenue burn that outpaced new awards.activity discussed above. The Building segment continues to have a large volume of prospective projects some of which have already been bidacross various end markets and are expected to be selected and awarded by customers in 2019. Demand for our building servicesgeographic locations. Strong demand is expected to remain stablecontinue due to ongoing customer spending supported by a still favorable economic environment and low interest rate environment.rates that have persisted.

Specialty Contractors Segment

Revenue, income (loss) from construction operations and adjusted income (loss) from construction operations for the Specialty Contractors segment are summarized as follows:

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in millions)

2018

 

2017

 

2016

2019

2018

Revenue

$

1,006.9 

 

$

1,213.7 

 

$

1,234.3 

$

929.4

$

1,006.9

Income from construction operations

 

43.4 

 

18.9 

 

37.9 

Income (loss) from construction operations, as reported

(172.6)

43.4

Plus: Goodwill impairment charge

156.2

Adjusted income (loss) from construction operations

(16.4)

43.4

Revenue for 20182019 decreased 17%8% compared to 2017 primarily2018 due to reduced project execution activities on variouscertain completed electrical projects in New York and a mass-transit project in California. Revenue for 2017 decreased modestly compared to 2016, as decreased activity on various electrical projects in New York was largely offset by increased activity on various electrical projects in the southern U.S. and California.

Despite the volume reduction, income from construction operations increased 130% in 2018 compared to 2017, principally due to the absence of prior year unfavorable adjustments on certain mechanical projects in California, Washington and New York ($13.1 million in the aggregate, none of which were individually material) and California (which were not material individually or in the aggregate). Overall improvement in

20


the performance of other mechanical projects in New York also contributed to the increase. Income from construction operations decreased 50% in 2017 compared to 2016, principally due to the impact of the above-mentioned unfavorable project adjustments on certain mechanical projects in New York and California.York. The decrease was partially offset by improved profitabilityincreased activity on variousa mechanical project in New York and an electrical project in California.

Income (loss) from construction operations decreased substantially in 2019 compared to 2018, mainly due to the goodwill impairment charge mentioned above. Adjusted income (loss) from construction operations for 2019 also decreased substantially due primarily to

22


net unfavorable adjustments totaling $41.5 million on certain electrical and mechanical projects in New York, andnone of which were individually material. The Specialty Contractors segment was also impacted by $11.0 million of the increased activity mentioned above on various electrical projects.$166.8 million SR 99 charge in 2019.

Operating margin was (18.6)% and adjusted operating margin was (1.8)% in 2019 compared to 4.3% in 2018 compared to 1.6%2018. The reduction in 2017 and 3.1%operating margin for 2019 was driven by the aforementioned goodwill impairment charge. The reduction in 2016. Theadjusted operating margin changes in both 2018 and 2017 were due tofor 2019 was primarily driven by the factors mentioned above that impacteddrove the changes in revenue and adjusted income (loss) from construction operations for both years.operations.

New awards in the Specialty Contractors segment totaled $1.5 billion in 2019 compared to $1.4 billion in 2018, $1.1 billion2018. New awards in 20172019 included, among others, electrical and $867mechanical subcontracts valued at $216 million for the Purple Line Section 3 Stations project and an electrical subcontract valued at $140 million for the Division 20 Portal Widening and Turnback Facility project, both in 2016. California; and three mechanical projects collectively valued at $192 million and an electrical subcontract valued at $140 million for a mass-transit project, all in New York.

New awards in 2018 included $364 million of electrical and mechanical subcontracts for the Newark Airport Terminal One project; $294 million for various electrical projects in New York; $248 million for various electrical projects in the southern United States and California; and $243 million for two large mechanical projects in New York.

New awards in 2017 included approximately $426 million for various electrical projects in the southern United States and California, two electrical subcontracts for mass-transit projects in New York collectively valued at $158 million, and four mechanical contracts in New York with a total value of $131 million. New awards in 2016 included various mechanical projects in New York collectively valued at approximately $146 million, several electrical projects in the southern United States totaling approximately $93 million and an electrical subcontract for a mass-transit project in New York valued at $86 million.

Backlog for the Specialty Contractors segment was $2.4 billion as of December 31, 2019, an increase of 31% compared to $1.8 billion as of December 31, 2018 compared to $1.5 billion2018. The robust backlog growth was driven by strong demand as of December 31, 2017 and $1.6 billion as of December 31, 2016. The Specialty Contractors segment continues to have a substantial volume of prospective projects with demand increasing because of strongevidenced by public and private sectorcustomer spending on numerous civil and building projects. The Specialty Contractors segment iscontinues to be increasingly focused on servicing ourthe Company’s growing backlog of large Civil and Building segment projects, but it also remains well-positioned to capture its share of new projects for external customers, leveraging the size and scale of our business units that operate in New York, Texas, Florida and California and the strong reputation held by these business units for high-quality work on large, complex projects.

Corporate, Tax and Other Matters

Corporate General and Administrative Expenses

Corporate general and administrative expenses were $65.5 million in 2019 compared to $63.8 million in 2018, $65.9 million in 2017 and $60.2 million in 2016. The 2017 increase in corporate general and administrative expenses compared to 2016 was predominantly due to higher compensation-related expenses pertaining to the employment and retention of certain key executives.2018.

Other Income, Net, Interest Expense and Income Tax Benefit (Expense) Benefit

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in millions)

2018

 

2017

 

2016

2019

2018

Other income, net

$

4.3 

 

$

43.9 

 

$

7.0 

$

6.7

$

4.3

Interest expense

 

(63.5)

 

(69.4)

 

 

(59.8)

(67.5)

(63.5)

Income tax (expense) benefit

 

(34.8)

 

0.6 

 

 

(53.3)

Income tax benefit (expense)

65.6

(34.8)

Other income, net, decreased by $39.6increased $2.4 million in 20182019 compared to 2017, and increased by $36.9 million in 2017 compared to 2016. The higher balance in 2017 relative to the other years presented was2018, primarily due to a $37.0 millionnet gain associated with a legal settlementon the sale of property and equipment in 2017, as discussed in Note 9 of the Notes to Consolidated Financial Statements.2019.

Interest expense decreased $5.9increased $4.0 million in 20182019 compared to the prior year,2018, principally due to non-cash extinguishment costs recognized in 2017 related toa higher average balance on our debt restructuring transactions in April 2017. Interest expense increased $9.6 million in 2017 compared to 2016 principally due to non-cash extinguishment costs recognized in 2017 related to our debt restructuring transactions, as well as increased non-cash interest charges from the amortizationline of debt discount and issuance costs.credit.

The effective income tax rate for 2019 was 15.4% compared to 26.3% for 2018, (0.4)% for 2017 and 35.7% for 2016. As discussed in2018. During 2019, the Executive Overview, the effectiveCompany recognized a tax rates for 2018 and 2017 were positively impacted by the enactmentbenefit of the TCJA. The TCJA included$65.6 million on a numberloss before income taxes of provisions including, but not limited to, the reduction of the U.S. corporate tax rate from 35% to 21%, effective January 1, 2018.$425.8 million. As a result our tax expense in 2018 was lower due toof the U.S. statutory rate reduction and we$379.9 million goodwill impairment charge discussed above, the Company recognized a one-time federaltax benefit totaling $49.4 million. Approximately $209.5 million of the charge is not deductible for income tax purposes, which significantly reduced the tax benefit of $53.3 million in 2017 primarily related to the required remeasurement of deferred tax assets and liabilities as of December 31, 2017 with the enactment of the TCJA. Excluding the benefit resulting from the enactment of the TCJA, the effective income tax rate for 2017 would have been 34.3%the year. The adjusted effective income tax rate for 2019, which excludes the tax benefit from the goodwill impairment charge and which is a non-GAAP financial measure, was 35.3%. For a further discussionThe adjusted effective income tax rate for 2019 was higher than the U.S. federal statutory rate primarily due to earnings attributable to noncontrolling interests for which income taxes are not the responsibility of the effect ofCompany, which increased the TCJA, see Note 5 ofeffective rate due to the Notespre-tax loss for the period, U.S. federal research and development tax credits, and state income taxes, partially offset by foreign tax impacts. The 2018 effective tax rate was higher than the U.S. federal rate primarily due to Consolidated Financial Statements.state income taxes.

21


Table of Contents

Liquidity and Capital Resources

Liquidity is provided by available cash and cash equivalents, cash generated from operations, credit facilities and access to capital markets. We have a committed line of credit totaling $350 million, which may be used for revolving loans, letters of credit and/or general purposes. We believe that cash generated from operations, along with our unused credit capacity of $309$236 million and available

23


Table of Contents

cash positionbalances as of December 31, 2018,2019, will be sufficient to fund any working capital needs for the next 12 months. As discussed in the section entitled Debt below, the Company intends to modify or replace the 2017 Credit Facility and/or repurchase or exchange the Convertible Notes in 2020.

Cash and Working Capital

Cash and cash equivalents were $193.7 million as of December 31, 2019 compared to $116.1 million as of December 31, 2018 compared to $192.9 million as of December 31, 2017.2018. Cash immediately available for general corporate purposes was $51.7$43.8 million and $94.7$51.7 million as of December 31, 20182019 and 2017,2018, respectively, with the remainder being amounts held by our consolidated joint ventures and also our proportionate share of cash held by our unconsolidated joint ventures and also amountsventures. Cash held by our consolidated joint ventures which, in both cases, werewas available only for joint venture-related uses, including distributions to joint venture partners. In addition, our restricted cash and restricted investments, held primarily to secure insurance-related contingent obligations, totaled $79.4 million as of December 31, 2019 compared to $61.9 million as of December 31, 2018 compared to $57.8 million as of2018.

During the year ended December 31, 2017.

2019, net cash provided by operating activities was $136.5 million (with $248.0 million provided in the second half of 2019), due primarily to changes in net investment in working capital and cash generated from income sources. The change in working capital primarily reflects an increase in billings in excess of costs and estimated earnings (“BIE”), partially offset by increases in accounts receivable and retainage receivable. During the year ended December 31, 2018, net cash provided by operating activities was $21.4 million due primarily to cash generated from income sources mostly offset by changes in net investment in working capital. The change in working capital primarily reflectsreflected an increase in costs and estimated earnings in excess of billings (“CIE”), which was partially offset by an increase in billingsBIE.

The $115.1 million increase in excess of costs and estimated earnings. During the year ended December 31, 2017, net cash provided by operating activities was $163.6 million also duewhen comparing 2019 with 2018 primarily reflects a current year decrease in CIE compared to cash generated from income sources partially offset by changesan increase in net investmentthe prior year, a larger increase in working capital. The changeBIE in working capital primarily reflectsthe current year and an increase in accounts payable compared to a decrease in the prior year. These current year improvements were partially offset by increases in retainage receivable and costs and estimated earningsaccounts receivable in excess of billings, which was mostly offset by an increase in billings in excess of costs and estimated earnings.

Cash flow from operations for 2018 was $21.4 million2019 compared to $163.6 milliondecreases in 2017 (which was a record high for the Company since the 2008 merger). The decrease primarily reflects a higher net investment in working capital, as costs2018.

During 2019 and estimated earnings in excess of billings increased $108.6 million more in 2018, than in 2017. In addition, cash flows from operations for 2017 benefited from a $37.0 million cash settlement associated with a legal matter, as discussed in Note 9 of the Notes to Consolidated Financial Statements. Cash flow from operations for 2017 improved $50.2 million compared to 2016 and was due to a lower net investment in working capital.

During 2018 and 2017, we used $70.2$76.1 million and $87.1$70.2 million of cash from investing activities, respectively. The net cash used in investing activities in 2019 was primarily due to $84.2 million of expenditures for the acquisition of property and equipment. The majority of our capital expenditures was for project-specific equipment purchased by our joint ventures and funded directly by our customers. The net cash used in investing activities in 2018 was primarily due to $77.1 million of expenditures for the acquisition of property and equipment. The net cash used in investing activities for 2017 was attributable to investments in securities of $61.0 million and the acquisition of property and equipment of $30.3 million.

During 2018,2019, we utilized $29.0generated $21.8 million of cash from financing activities principally due to increased net borrowings of $61.3 million and contributions from noncontrolling interests of $9.8 million, partially offset by distributions to noncontrolling interests of $46.5 million. Net cash used in financing activities for 2018 was $29.0 million, primarily due to distributions to noncontrolling interests of $29.0 million and an earn-out payment related to a 2011 acquisition of $16.0 million, partially offset by increased net borrowings of $14.8 million. Net cash used in financing activities for 2017 was $75.4 million, primarily due to the net paydown of debt, distributions paid to noncontrolling interests of $17.5 million and the payment of $15.3 million in debt issuance and extinguishment costs related to debt restructuring transactions.

As of December 31, 2018,2019, we had working capital of $1.4 billion, a ratio of current assets to current liabilities of 1.66 and a ratio of debt to equity of 0.58 compared to working capital of $1.6 billion, a ratio of current assets to current liabilities of 1.99 and a ratio of debt to equity of 0.43 compared to working capital of $1.5 billion, a ratio of current assets to current liabilities of 1.94 and a ratio of debt to equity of 0.43 at December 31, 2017.2018.

Debt

Summarized below are the key terms of our debt as of December 31, 2018.2019. For additional information, refer to Note 7 of the Notes to Consolidated Financial Statements, as applicable.

2017 Credit Facility

On April 20, 2017, wethe Company entered into a credit agreement (the “2017the 2017 Credit Facility”)Facility with SunTrust Bank, now known as Truist Bank, as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The 2017 Credit Facility provides for a $350 million revolving credit facility (the “2017 Revolver”) and a sublimit for the issuance of letters of credit and swingline loans up to the aggregate amount of $150 million and $10 million, respectively, both maturing on April 20, 2022 unless any of the Convertible Notes are outstanding on December 17, 2020, in which case all such borrowings will mature on December 17, 2020, (subjectprovided that (i) if the Convertible Notes are refinanced in full with the proceeds of permitted refinancing indebtedness in accordance with the terms of the 2017 Credit Facility, the maturity date for the 2017 Credit Facility will remain April 20, 2022 and (ii) if the Company issues “New Convertible Notes” (as defined in the 2017 Credit Facility), the maturity date for the 2017 Credit Facility will be the earlier of (x) April 20, 2022 or December 17, 2020 if Convertible Notes are outstanding on December 17, 2020 and (y) 90 days prior to certain further exceptions).the maturity date for such New Convertible Notes. In addition, the 2017 Credit Facility permits additional borrowings in an aggregate amount of $150 million, which can be in the form of increased capacity on the 2017 Revolver or the establishment of one or more term loans. On May 7, 2019, certain provisions of the 2017 Credit Facility were amended, including setting the maximum leverage ratio at 3.50:1.00

24


Table of Contents

for the remainder of its term, thus eliminating the step down from 3.50:1.00 to 3.25:1.00. For additional information regarding the terms of our 2017 Credit Facility, refer to Note 7 of the Notes to Consolidated Financial Statements.

22


Table of Contents

The table below presents our actual and required consolidated fixed charge coverage ratio and consolidated leverage ratio under the 2017 Credit Facility for the period, which are calculated on a rolling four-quarter basis:

Twelve Months Ended December 31, 20182019

Actual

Required

Fixed charge coverage ratio

3.193.57 to 1.00

> or = 1.25 : 1.00

Leverage ratio

2.742.60 to 1.00

< or = 3.50 : 1.00

As of the filing date of this Form 10-K,December 31, 2019, we arewere in compliance and expect to continue to be in compliance with the financial covenants under the 2017 Credit Facility.

As a result of the aforementioned provision in the 2017 Credit Facility whereby the maturity date of the 2017 Credit Facility may be moved forward from April 20, 2022, the facility will mature on December 17, 2020 if the Convertible Notes remain outstanding at that time (the “spring-forward” provision). While the Company does not have call rights that allow it to unilaterally redeem the Convertible Notes, it intends to repurchase or exchange the Convertible Notes and/or modify or replace the 2017 Credit Facility during 2020. Various alternatives are under consideration to determine the financing arrangement that is best suited to the Company’s needs and provides the most favorable terms. The Company is currently in discussions with lenders regarding its options. Due to the spring-forward provision in the 2017 Credit Facility, all borrowings under the facility are included in “Current maturities of long-term debt” on the Consolidated Balance Sheet as of December 31, 2019.

2017 Senior Notes

On April 20, 2017, we issued $500 million in aggregate principal amount of 6.875% Senior Notes due 2025 (the “2017 Senior Notes”) in a private placement.placement offering. Interest on the 2017 Senior Notes is payable in arrears semi-annually onin May 1 and November 1 of each year, beginning onin November 1, 2017.

Repurchase and Redemption of Notes and Termination of Credit Facility

We used proceeds from the 2017 Senior Notes and 2017 Revolver to repurchase or redeem our previously outstanding senior notes, to pay off and terminate our previous credit facility which included a term loan and revolver, as well as to pay accrued but unpaid interest and fees.

Convertible Notes

On June 15, 2016, we completed an offering ofthe Company issued $200 million of our Convertible Notes.Notes in a private placement offering. The Convertible Notes are senior unsecured obligations of the Company. InterestCompany and do not contain any financial covenants or restrictions on the payments of dividends, the incurrence of indebtedness or the issuance or repurchase of securities by the Company. The Convertible Notes isbear interest at a rate of 2.875% per year, payable onin cash semi-annually in June 15 and December 15 of each year, commencing on December 15, 2016, until the maturity date.December. Upon conversion, and at the Company’s election, the Company may satisfy its conversion obligation with cash, shares of its common stock or a combination thereof. As of December 31, 2018, none of2019, the conversion provisions of our Convertible Notes have not been triggered.

Equipment financingFinancing and mortgagesMortgages

We haveThe Company has certain loans entered into for the purchase of specific property, plant and equipment and secured by the assets purchased. The aggregate balance of equipment financing loans was approximately $38.6$27.7 million and $61.1$38.6 million at December 31, 20182019 and 2017,2018, respectively, with interest rates ranging from 2.19%2.62% to 3.38%3.89% with equal monthly installment payments over periods up to ten years with additional balloon payments of $12.4 million in 2021 and $6.3 million in 2022 on the remaining loans outstanding at December 31, 2018.2019. The aggregate balance of mortgage loans was approximately $12.3$11.5 million and $15.7$12.3 million at December 31, 20182019 and 2017,2018, respectively, with interest rates ranging from a fixed 3.50% to London Interbank Offered Rate (“LIBOR”)LIBOR plus 3% and equal monthly installment payments over periods up to ten years with additional balloon payments of $2.9 million in 2021 and $7.0 million in 2023.

25


Table of Contents

Contractual Obligations

Our outstanding contractual obligations as of December 31, 20182019 are summarized in the following table:



 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

Payments Due

(in thousands)

Total

 

1 year or less

 

2-3 years

 

4-5 years

 

Over 5 years

Debt(a)

$

796,502 

 

$

16,817 

 

$

265,150 

 

$

14,535 

 

$

500,000 

Interest on debt(a)

 

240,283 

 

 

43,804 

 

 

81,339 

 

 

69,307 

 

 

45,833 

Operating leases

 

56,025 

 

 

14,039 

 

 

18,170 

 

 

12,154 

 

 

11,662 

Pension benefit payments(b)

 

6,162 

 

 

4,862 

 

 

1,300 

 

 

 —

 

 

 —

Other

 

7,388 

 

 

747 

 

 

540 

 

 

48 

 

 

6,053 

Total

$

1,106,360 

 

$

80,269 

 

$

366,499 

 

$

96,044 

 

$

563,548 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

(a)

Debt and interest on debt exclude unamortized debt discount and deferred debt issuance costs. Amounts for interest on debt are based on interest rates in effect as of December 31, 2018.

(b)

The Company utilizes current actuarial assumptions in determining the expected minimum contributions to fund our defined benefit pension and other post-retirement plans. Estimated contributions for periods beyond the scope of the actuarial assumptions have not been included because, in management’s judgment, such estimates may not be reliable.

Payments Due

(in thousands)

Total

Less than 1 year

1-3 years

3-5 years

More than 5 years

Debt(a)

$

857,819

$

124,054

$

226,513

$

7,252

$

500,000

Interest on debt(a)

200,107

47,040

72,743

68,866

11,458

Operating leases

50,379

13,564

17,344

11,853

7,618

Pension benefit payments(b)

5,322

4,387

935

Other

8,064

1,353

1,043

17

5,651

Total

$

1,121,691

$

190,398

$

318,578

$

87,988

$

524,727

_____________________________________________________________________________________________________________

(a)Debt and interest on debt exclude unamortized debt discount and deferred debt issuance costs. Amounts for interest on debt are based on interest rates in effect as of December 31, 2019.

23(b)The Company utilizes current actuarial assumptions in determining the expected minimum contributions to fund our defined benefit pension and other post-retirement plans. Estimated contributions for periods beyond the scope of the actuarial assumptions have not been included because, in management’s judgment, such estimates may not be reliable.


Table of Contents

Off-Balance Sheet Arrangements

None.

Critical Accounting Policies

Our discussion and analysis of our financial condition and results of operations is based upon our Consolidated Financial Statements, which have been prepared in accordance with GAAP. Our significant accounting policies are described in Note 1 of the Notes to Consolidated Financial Statements. The preparation of the Consolidated Financial Statements requires us to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. Estimates are based on information available through the date of the issuance of the financial statements; accordingly, actual results in future periods could differ from these estimates. Effective January 1, 2018, the Company adopted Accounting Standards Codification (“ASC”) 606, Revenue from Contracts with Customers (“ASC 606”). See Note 1(d), Note 3 and Note 4 of the Notes to Consolidated Financial Statements for more information. Significant judgments and estimates used in the preparation of the Consolidated Financial Statements apply to the following critical accounting policies:

Method of Accounting for Contracts — Contract revenue is recognized over time using the cost-to-cost method which measures progress towards completion based on the ratio of contract costs incurred to date compared to total estimated costs for each performance obligation. The estimates used in accounting for contracts with customers require judgment and assumptions regarding both future events and the evaluation of contingencies such as the impact of change orders, liability claims, other contract disputes, the achievement of contractual performance standards and potential variances in project schedule and costs. Changes to the total estimated contract cost, either due to unexpected events or revisions to management’s initial estimates, for a given project are recognized in the period in which they are determined.

In certain instances, we provide guaranteed completion dates and/or achievement of other performance criteria. Failure to meet schedule or performance guarantees could result in unrealized incentive fees and/or liquidated damages. In addition, depending on the type of contract, unexpected increases in contract cost may be unrecoverable, resulting in total cost exceeding revenue realized from the projects. The Company generally provides limited warranties for work performed, with warranty periods typically extending for a limited duration following substantial completion of the Company’s work on a project. Historically, warranty claims have not resulted in material costs incurred.

Claims arising from construction contracts have been made against the Company by customers, and the Company has made claims against customers for costs incurred in excess of current contract provisions. The Company recognizes revenue for claims as variable consideration in accordance with ASC 606. Assumptions as to the occurrence of future events and the likelihood and amount of variable consideration are made during the contract performance period. Estimates of variable consideration and determination of whether to include estimated amounts in the transaction price are based largely on an assessment of anticipated performance and all information (historical, current and forecasted) that is reasonably available to management. Estimated amounts are only included in the transaction price to the extent it is probable that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is resolved. Back charges to suppliers or subcontractors are recognized as a reduction of cost when it is determined that recovery of such cost is probable and the amounts can be reliably estimated. Disputed back charges are recognized when the same requirements described above for variable consideration have been satisfied.

26


Construction Joint Ventures Certain contracts are executed through joint ventures. The arrangements are often formed for the execution of single contracts or projects and allow the Company to share risks and secure specialty skills required for project execution.

In accordance with ASC 810, Consolidation (“ASC 810”) the Company assesses its joint ventures at inception to determine if any meet the qualifications of a variable interest entity (“VIE”). The Company considers a joint venture a VIE if either (a) the total equity investment is not sufficient to permit the entity to finance its activities without additional subordinated financial support, (b) characteristics of a controlling financial interest are missing (either the ability to make decisions through voting or other rights, the obligation to absorb the expected losses of the entity or the right to receive the expected residual returns of the entity), or (c) the voting rights of the equity holders are not proportional to their obligations to absorb the expected losses of the entity and/or their rights to receive the expected residual returns of the entity and substantially all of the entity’s activities either involve or are conducted on behalf of an investor that has disproportionately few voting rights. Upon the occurrence of certain events outlined in ASC 810, the Company reassesses its initial determination of whether the joint venture is a VIE.

The Company also evaluates whether it is the primary beneficiary of each VIE and consolidates the VIE if the Company has both (a) the power to direct the economically significant activities of the entity and (b) the obligation to absorb losses of, or the right to receive benefits from, the entity that could potentially be significant to the VIE. The Company considers the contractual agreements that define the ownership structure, distribution of profits and losses, risks, responsibilities, indebtedness, voting rights and board representation of the respective parties in determining whether it qualifies as the primary beneficiary. The Company also considers all parties that have direct or implicit variable interests when determining whether it is the primary beneficiary. When the Company is determined to be the primary beneficiary, the VIE is consolidated. In accordance with ASC 810, management’s assessment of whether the Company is the primary beneficiary of a VIE is performed continuously.

24


Table of Contents

For construction joint ventures that do not need to be fully consolidated, the Company accounts for its interest in the joint ventures using the proportionate consolidation method, whereby the Company’s proportionate share of the joint ventures’ assets, liabilities, revenue and cost of operations are included in the appropriate classifications in the Company’s consolidated financial statements. Intercompany balances and transactions have been eliminated. See Note 1(b) and Note 1314 of the Notes to Consolidated Financial Statements for additional discussion regarding VIEs.

Recoverability of Goodwill — Goodwill represents the excess of amounts paid over the fair value of net assets acquired from an acquisition. In order to determine the amount of goodwill resulting from an acquisition, we perform an assessment to determine the value of the acquired company's tangible and identifiable intangible assets and liabilities. In our assessment, we determine whether identifiable intangible assets exist, which typically include backlog, customer relationships and trade names.

We test goodwill for impairment annually as of October 1 of each year for our Civil, Building and Specialty Contractors operating segments, which are the same as our reporting units for goodwill impairment analysis.year. This test requires us to estimate the fair value of each reporting unit carrying goodwill, using income and market approaches and to compare the calculated fair value of each reporting unit to its carrying value, which is equal to the reporting unit’s net assets. If the calculated fair value of a reporting unit is less than its carrying value, we recognize an impairment charge equal to the difference.

The impairment evaluation process requires assumptions that are subject to a high degree of judgment such as revenue growth rates, profitability levels, discount rates, industry market multiples and weighted averageweighted-average cost of capital (WACC)(“WACC”). Changes in these assumptions would impact the results of our impairment tests.

As part of our annual impairment test, we also assess the reasonableness of the estimated fair value of our reporting units by comparing the sum of our reporting units’ fair values to our market capitalization and calculating an implied control premium (the excess of the aggregate fair values of our reporting units over our market capitalization). The reasonableness of this implied control premium is evaluated by considering a number of factors including, but not limited to, the following:

·

Market control premium: We compare our implied control premium to those observed in industry-specific mergers and acquisition transactions over a sustained period of time with an emphasis on more recent transactions.

·

Sensitivity analysis: We perform a sensitivity analysis to determine the minimum control premium required to recover our carrying value as of our testing date. The minimum control premium required is then compared to the observable market information.

·

Other entity-specific factors: A significant portion of our common stock is owned by our Chairman and CEO. As a result, our public float, which represents the percentage of our total outstanding shares of common stock that are freely traded by public investors, is significantly lower relative to that of our peers. While this circumstance does not impact the fair value of our reporting units, we believe it leads to an inherent marketability discount impacting our stock price.

During interim periods, including those subsequent to the Company’s October 1 annual test date, we evaluate events and circumstances, including, but not limited to, an examination of macroeconomic conditions, cost factors, overall financial performance by each reporting unit, other relevant entity-specific events, and trends in the stock prices of our Company and peers to determine if such factors indicate that it is likely that the goodwill for one or more of our reporting units is impaired, thus warranting the performance of the annuala quantitative impairment test sooner than the fourth quarter of the year. The Company performed an interim impairment test as of June 1, 2019 and recognized a non-cash impairment loss totaling $379.9 million, which eliminated the carrying value of goodwill for the Building and Specialty Contractors reporting units. See Note 1(g) and Note 6 of the Notes to Consolidated Financial Statements.

During the fourth quarter of 2018,2019, we conducted our annual goodwill impairment test and determined that goodwill was not impaired since the estimated fair value for each of our reporting units exceeded their respective net book values. Further, the implied control premium was consistent with or within a reasonable range of actual premiums paid in industry-specific merger and acquisition transactions observed over a sustained period of time. The estimated fair value of the Civil and Building reporting units were substantially in excess of their carrying value. The estimated fair value of our Specialty Contractors reporting unit exceeded its carryingnet book value, but not by a significant amount. As such, there is a risk of goodwill impairment if future events are less favorable than what we assumed or estimated in our impairment analysis.

The Company considered relevant events and circumstances since the annual goodwill impairment test, including, but not limited to, an examination of macroeconomic conditions, industry and market conditions, cost factors, overall financial performance by each reporting unit, other relevant entity-specific events, and trends in the stock prices of the Company and its peers. The Company has continued to observe significant opportunities in a robust marketplace which have led to sizable new awards and significant growth in backlog for each of the Company’sCivil reporting units, including the Specialty Contractors reporting unit, which has backlog margins in excess of historical averages.unit. In considering the totality of qualitative factors known as of the reporting date, we determined that

27


Table of Contents

no triggering events occurred or circumstances changed since the date of our October 1 annual test that would more likely than not reduce the fair value of the Company’sCivil reporting unitsunit below theirits carrying amounts. Accordingly, an interim impairment test was not required. However, weamount. We will continue to monitor events occurring or circumstances such aschanging which may suggest that goodwill should be reevaluated. These events and circumstances include, but are not limited to, a sustained decline in our stock price and market capitalization, or other factors, as well as consider entity specific quantitative and qualitative factors specific to identifythe Civil reporting unit which indicate potential triggering events that would more likely than not reduce the fair value of the Company’sCivil reporting unitsunit below theirits carrying amounts.amount.

25


Table of Contents

New Accounting Pronouncements — For discussion of recently adopted accounting standards and updates, see Note 1 of the Notes to Consolidated Financial Statements.

ITEM 7A. QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

Interest rate risk isWe do not enter into derivative financial instruments for trading, speculation or other purposes that would expose the Company to market risk. In the normal course of business, our primaryresults of operations are exposed to certain market risk exposure. Borrowingrisks, primarily associated with fluctuations in interest rates. Borrowings under our 2017 Credit Facility and certain other debt obligations have variable interest rates subject to interest rate risk. AsSee Note 7 of December 31, 2018, wethe Notes to Consolidated Financial Statements for further discussion of our 2017 Credit Facility. We had approximately $121.9 million and $49.1 million of net borrowings with variable interest rates.rates as of December 31, 2019 and 2018. If short-term floating interest rates were to increase by 0.50%, the change in interest on these borrowings were to change by 0.50% and our variable indebtedness were to remain unchanged, interest expense would increase or decrease by approximately $250,000.$610,000 for the next twelve months.

ITEM 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

The Report of Independent Registered Public Accounting Firm and Consolidated Financial Statements and Supplementary Schedules are set forth in Item 15 in this Annual Report on Form 10-K and are incorporated herein by reference.

ITEM 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE

None.


28


ITEM 9A. CONTROLS AND PROCEDURES

Evaluation of Disclosure Controls and Procedures — An evaluation of the effectiveness of the design and operation of our disclosure controls and procedures as defined by Rule 13a-15(e) under the Exchange Act, as of December 31, 20182019 was made under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that, as of December 31, 2018,2019, our disclosure controls and procedures were effective, in that they provide reasonable assurance that information required to be disclosed in our reports filed or submitted under the Exchange Act were recorded, processed, summarized and reported within the time periods specified in the SEC’s rules. Our disclosure controls and procedures are designed to ensure that information we are required to disclose in such reports is accumulated and communicated to management, including our Chief Executive Officer and Chief Financial Officer, as appropriate, to allow timely decisions regarding required disclosures.

Management’s Report on Internal Control over Financial Reporting — Our management, under the supervision of our Chief Executive Officer and Chief Financial Officer, is responsible for establishing and maintaining an adequate system of internal control over financial reporting as such term is defined in Exchange Act Rules 13a-15(f). In designing and evaluating our system of internal control over financial reporting, we recognize that inherent limitations exist in any control system no matter how well designed and operated, and we can only provide reasonable, not absolute, assurance of achieving the desired control objectives. In making this assessment, management utilized the criteria issued in Internal Control — Integrated Framework (2013) issuedby the Committee of Sponsoring Organizations of the Treadway Commission. Based on this assessment, management concluded that, as of December 31, 2018,2019, our internal control over financial reporting was effective based on those criteria.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. In addition, projections of any evaluation of the effectiveness to future periods are subject to the risk that controls may become inadequate due to changes in conditions, or that the degree of compliance with policies and procedures may deteriorate.

Deloitte & Touche LLP, the independent registered public accounting firm that audited our consolidated financial statements included in this Annual Report on Form 10-K, has issued an attestation report on the Company’s internal control over financial reporting as of December 31, 2018.2019.

Changes in Internal Control over Financial Reporting — There were no changes in our internal control over financial reporting for the quarter ended December 31, 20182019 that have materially affected, or are reasonably likely to materially affect, our internal control over financial reporting.

29

26


REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Stockholders and the Board of Directors of

Tutor Perini Corporation

Sylmar, California

Opinion on Internal Control over Financial Reporting

We have audited the internal control over financial reporting of Tutor Perini Corporation and subsidiaries (the “Company”) as of December 31, 2018,2019, based on criteria established in Internal Control — Integrated Framework (2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO). In our opinion, the Company maintained, in all material respects, effective internal control over financial reporting as of December 31, 2018,2019, based on criteria established in Internal Control — Integrated Framework (2013) issued by COSO.

We have also audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States) (PCAOB), the consolidated financial statements as of and for the year ended December 31, 2018,2019, of the Company and our report dated February 27, 2019,26, 2020, expressed an unqualified opinion on those financial statements.

Basis for Opinion

The Company’s management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Report on Internal Control over Financial Reporting. Our responsibility is to express an opinion on the Company’s internal control over financial reporting based on our audit. We are a public accounting firm registered with the PCAOB and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audit in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects. Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.

Definition and Limitations of Internal Control over Financial Reporting

A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the financial statements.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

/s/ Deloitte & Touche LLP

Los Angeles, CaliforniaCA

February 26, 2020

February 27, 2019

ITEM 9B. OTHER INFORMATION

None.

PART III.

ITEM 10. DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

The information required by this Item 10 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2018.2019.

We have adopted a Code of Business Conduct and Ethics that applies to all of our directors, officers and employees, including our principal executive, principal financial and principal accounting officers. Our Code of Business Conduct and Ethics is posted on our website located at http://investors.tutorperini.com/corporate-governance/overview/default.aspx. We intend to disclose future amendments to certain provisions of the Code of Business Conduct and Ethics, and waivers of the Code of Business Conduct and Ethics granted to executive officers and directors, on the website within four business days following the date of the amendment or waiver.

ITEM 11. EXECUTIVE COMPENSATION

The information required by this Item 11 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2018.2019.

ITEM 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

The information required by this Item 12 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2018.2019.

ITEM 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

The information required by this Item 13 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2018.2019.

ITEM 14. PRINCIPAL ACCOUNTANTACCOUNTING FEES AND SERVICES

The information required by this Item 14 is hereby incorporated by reference from our definitive proxy statement to be filed within 120 days after the end of 2018.2019.

PART IV.

ITEM 15. EXHIBITS AND FINANCIAL STATEMENT SCHEDULES

Tutor Perini Corporation and Subsidiaries

(a) List of Documents Filed as a Part of This Report.

1.           Financial Statements:

Our consolidated financial statements as of December 31, 20182019 and 20172018 and for each of the three years in the period ended December 31, 20182019 and the Notes thereto, together with the report of the independent registered public accounting firm on those consolidated financial statements are hereby filed as part of this Annual Report on Form 10-K, beginning on page F-1.

2.           Financial Statement Schedules:

All consolidated financial statement schedules are omitted because of the absence of the conditions under which they are required or because the required information is included in the Consolidated Financial Statements and in the Notes thereto.

3.           Exhibits:

See exhibits listed under Part (b) below.

(b) Exhibits.

EXHIBIT INDEX

The following designated exhibits are, as indicated below, either filed herewith or have heretofore been filed with the SEC under the Securities Act or the Exchange Act and are referred to and incorporated herein by reference to such filings.

Exhibit 3.

Articles of Incorporation and By-laws

3.1

Restated Articles of Organization (incorporated by reference to Exhibit 3.1 to Form 10-K (File No. 001-06314) filed on March 31, 1997).

3.2

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on April 12, 2000).

3.3

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.1 to Form 8-K filed on September 11, 2008).

3.4

Articles of Amendment to the Restated Articles of Organization of Tutor Perini Corporation (incorporated by reference to Exhibit 3.5 to Form 10-Q filed on August 10, 2009).

3.5

Third Amended and Restated By-laws of Tutor Perini Corporation (incorporated by reference to Exhibit 3.5 to Form 10-Q filed on August 2, 2016).

Exhibit 4.

Instruments Defining the Rights of Security Holders, Including Indentures

4.1

Shareholders Agreement, dated April 2, 2008, by and among Tutor Perini Corporation, Ronald N. Tutor and the shareholders of Tutor-Saliba Corporation signatory thereto (incorporated by reference to Exhibit 4.1 to Form 8-K filed on April 7, 2008).

4.2

Amendment No. 1 to the Shareholders Agreement, dated September 17, 2010, by and between Tutor Perini Corporation and Ronald N. Tutor, as shareholder representative (incorporated by reference to Exhibit 4.1 to Form 8-K filed on September 20, 2010).

4.3

Amendment No. 2 to the Shareholders Agreement, dated June 2, 2011, by and between Tutor Perini Corporation and Ronald N. Tutor, as shareholder representative (incorporated by reference to Exhibit 4.1 to Form 8-K filed on June 6, 2011).

4.4

Amendment No. 3 to the Shareholders Agreement, dated September 13, 2011, by and between Tutor Perini Corporation and Ronald N. Tutor, as shareholder representative (incorporated by reference to Exhibit 4.1 to Form 8-K filed on September 16, 2011).

4.5

Registration Rights Agreement, dated October 20, 2010, by and among Tutor Perini Corporation, certain subsidiary guarantors named therein and the initial purchasers named therein (incorporated by reference to Exhibit 4.2 to Form 8-K filed on October 21, 2010).

4.6

Indenture, dated June 15, 2016, by and between Tutor Perini Corporation and Wilmington Trust, National Association (incorporated by reference to Exhibit 4.1 to Form 8-K filed on June 16, 2016).

4.7

Indenture, dated April 20, 2017, among Tutor Perini Corporation, the guarantors named therein and Wilmington Trust, National Association, as trustee (incorporated by reference to Exhibit 4.1 to Form 8-K filed on April 25, 2017).

Exhibit 10.4.8

Material ContractsDescription of Securities

Exhibit 10.

Material Contracts

10.1*

Form of Director and Officer Indemnification Agreement (incorporated by reference to Exhibit 10.19 to Amendment No. 1 to Form S-1 (File No. 333-111338) filed on February 10, 2004).

10.2*

2009 General Incentive Compensation Plan (incorporated by reference to Annex B to the Company’s Definitive Proxy Statement on Form DEF 14A filed on April 17, 2009).

10.3*

Amended and Restated Tutor Perini Corporation Long-Term Incentive Plan (as amended on October 2, 2014 and included as Exhibit A to the Company’s Definitive Proxy Statement on Schedule 14A, filed with the SEC on October 2, 2014 and incorporated herein by reference.

10.4*

Tutor Perini Corporation Incentive Compensation Plan (incorporated by reference to Exhibit 10.1 to Form 8-K filed on May 26, 2017).

10.5*

Amended and Restated Employment Agreement, dated December 22, 2014, by and between Tutor Perini Corporation and Ronald N. Tutor (incorporated by reference to Exhibit 10.1 to Form 8-K filed on December 24, 2014).

10.6*

Amendment No. 1 to Amended and Restated Employment Agreement, dated January 5, 2018, by and between Tutor Perini Corporation and Ronald N. Tutor (incorporated by reference to Exhibit 10.1 to Form 8-K filed on January 8, 2018).

10.7

Commercial Lease Agreement, dated April 18, 2014, by and among Tutor Perini Corporation and Ronald N. Tutor (incorporated by reference to Exhibit 10.1 to Form 10-Q filed on May 7, 2014).

10.8

Industrial Lease Agreement, dated April 18, 2014, by and among Tutor Perini Corporation and Kristra Investments, Ltd. (incorporated by reference to Exhibit 10.2 to Form 10-Q filed on May 7, 2014).

2932


10.9*

Amended and Restated Employment Agreement, dated November 1, 2016, by and between James A. Frost and Tutor Perini Corporation (incorporated by reference to Exhibit 10.1 to Form 10-Q filed on November 2, 2016).

10.10*

Employment Agreement, dated September 6, 2017, by and between Tutor Perini Corporation and Gary G. Smalley (incorporated by reference to Exhibit 10.1 to Form 8-K filed on September 8, 2017).

10.11

Credit Agreement, dated April 20, 2017, by and among Tutor Perini Corporation, the subsidiaries of Tutor Perini Corporation identified therein, SunTrust Bank, now known as Truist Bank, as Administrative Agent, Swing Line Lender and L/C Issuer, and the other lenders from time to time party thereto (incorporated by reference to Exhibit 10.1 to Form 8-K filed on April 25, 2017).

10.12*

Employment Offer Letter, dated May 9, 2017, by and between Tutor Perini Corporation and Leonard J. Rejcek (incorporated by reference to Exhibit 10.1 to Form 10-Q filed on May 9, 2018).

10.13*

Amendment to Employment Offer Letter, dated August 11, 2017, by and between Tutor Perini Corporation and Leonard J. Rejcek (incorporated by reference to Exhibit 10.2 to Form 10-Q filed on May 9, 2018).

10.14*

Tutor Perini Corporation Omnibus Incentive Plan (incorporated by reference to Exhibit 10.1 to Form 8-K filed on May 25, 2018).

10.15*

Employment Offer Letter, dated June 12, 2018, by and between Tutor Perini Corporation and Wendy A. Hallgren (incorporated by reference to Exhibit 10.1 to Form 10-Q filed on November 7, 2018).

Exhibit 2110.16

First Amendment to Credit Agreement dated as of May 7, 2019 (incorporated by reference to Exhibit 10.1 to Form 10-Q filed on May 8, 2019).

10.17*

Separation Benefits Agreement, dated September 17, 2019, by and between Tutor Perini Corporation and Wendy A. Hallgren (incorporated by reference to Exhibit 10.1 to Form 8-K filed on September 20, 2019).

10.18

Form of Restricted Stock Unit Award Agreement (incorporated by reference to Exhibit 10.2 to Form 10-Q filed on November 6, 2019).

10.19

Form of Restricted Stock Unit Award Agreement with Guarantee (incorporated by reference to Exhibit 10.3 to Form 10-Q filed on November 6, 2019).

10.20

Form of Stock Option Agreement (incorporated by reference to Exhibit 10.4 to Form 10-Q filed on November 6, 2019).

Exhibit 21

Subsidiaries of Tutor Perini Corporation.

Exhibit 23

Consent of Independent Registered Public Accounting Firm.

Exhibit 24

Power of Attorney executed by members of the Company’s Board of Directors allowing Management to sign the Company’s Form 10-K on their behalf.

Exhibit 31.1

Certification of Principal Executive Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.

Exhibit 31.2

Certification of Principal Financial Officer Pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.

Exhibit 32.1

Certification of Principal Executive Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

Exhibit 32.2

Certification of Principal Financial Officer Pursuant to 18 U.S.C. Section 1350, As Adopted Pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.

Exhibit 95

Mine Safety Disclosure.

Exhibit 101.INS

XBRL Instance Document.Document – The instance document does not appear in the Interactive Data File because its XBRL tags are embedded within the Inline XBRL document.

Exhibit 101.SCH

XBRL Taxonomy Extension Schema Document.

Exhibit 101.CAL

XBRL Taxonomy Extension Calculation Linkbase Document.

Exhibit 101.LAB

XBRL Taxonomy Extension Label Linkbase Document.

Exhibit 101.PRE

XBRL Taxonomy Extension Presentation Linkbase Document.

Exhibit 101.DEF

XBRL Taxonomy Extension Definition Linkbase Document.

Exhibit 104

The cover page from the Company’s Annual Report on Form 10-K for the year ended December 31, 2019, formatted in Inline XBRL (included as Exhibit 101).


_________________________________________________________________________________________

*Management contract or compensatory arrangement required to be filed as an exhibit pursuant to Item 15(a)(3) of Form 10-K

ITEM 16. FORM 10-K SUMMARY

None.

SIGNATURES

SIGNATURES

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

5

Tutor Perini Corporation

(Registrant)

Dated: February 27, 201926, 2020

By:

/s/ Gary G. Smalley

Gary G. Smalley

Executive Vice President and Chief Financial Officer

Pursuant to the requirements of the Securities Exchange Act of 1934, this report has been signed below by the following persons on behalf of the Company and in the capacities and on the dates indicated.

Signature

Title

Date

Principal Executive Officer and Director

/s/ Ronald N. Tutor

Ronald N. Tutor

Chairman and Chief Executive Officer

February 27, 201926, 2020

Principal Financial Officer

/s/ Gary G. Smalley

Gary G. Smalley

Executive Vice President and Chief Financial Officer

February 27, 201926, 2020

Principal Accounting Officer

/s/ Ryan J. Soroka

Ryan J. Soroka

Vice President and Chief Accounting Officer

February 27, 201926, 2020

Other Directors

Peter Arkley

)

Sidney J. Feltenstein

)

James A. Frost

)

Michael F. Horodniceanu

)

/s/ Gary G. Smalley

Michael R. Klein

)

Gary G. Smalley

Robert C. Lieber

)

Attorney in Fact

Dennis D. Oklak

)

Raymond R. Oneglia

)

Dale A. Reiss

)

Donald D. Snyder

)

Dickran M. Tevrizian, Jr.

)

Dated: February 27, 201926, 2020

TUTOR PERINI CORPORATION AND SUBSIDIARIES

INDEX TO CONSOLIDATED FINANCIAL STATEMENTS

TABLE OF CONTENTS

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

To the Stockholders and the Board of Directors of

Tutor Perini Corporation

Sylmar, California

Opinion on the Financial Statements

We have audited the accompanying consolidated balance sheets of Tutor Perini Corporation and subsidiaries (the "Company") as of December 31, 20182019 and 2017,2018, the related consolidated statements of income,operations, comprehensive income (loss), changes in equity, and cash flows, for each of the three years in the period ended December 31, 2018,2019, and the related notes (collectively referred to as the "financial statements"). In our opinion, the financial statements present fairly, in all material respects, the financial position of the Company as of December 31, 20182019 and 2017,2018, and the results of its operations and its cash flows for each of the three years in the period ended December 31, 2018,2019, in conformity with accounting principles generally accepted in the United States of America.

We have also audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States) (PCAOB), the Company's internal control over financial reporting as of December 31, 2018,2019, based on criteria established in Internal Control — Integrated Framework (2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission and our report dated February 27, 2019,26, 2020, expressed an unqualified opinion on the Company's internal control over financial reporting.

Basis for Opinion

These financial statements are the responsibility of the Company's management. Our responsibility is to express an opinion on the Company's financial statements based on our audits. We are a public accounting firm registered with the PCAOB and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audits in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement, whether due to error or fraud. Our audits included performing procedures to assess the risks of material misstatement of the financial statements, whether due to error or fraud, and performing procedures that respond to those risks. Such procedures included examining, on a test basis, evidence regarding the amounts and disclosures in the financial statements. Our audits also included evaluating the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the financial statements. We believe that our audits provide a reasonable basis for our opinion.

Critical Audit Matters

The critical audit matters communicated below are matters arising from the current-period audit of the financial statements that were communicated or required to be communicated to the audit committee and that (1) relate to accounts or disclosures that are material to the financial statements and (2) involved our especially challenging, subjective, or complex judgments. The communication of critical audit matters does not alter in any way our opinion on the financial statements, taken as a whole, and we are not, by communicating the critical audit matters below, providing separate opinions on the critical audit matters or on the accounts or disclosures to which they relate.

Revenue, Accounts Receivable, Contract Assets and Liabilities — Accounting for Construction Contracts– Refer to Notes 1, 3, 4, and 8 to the financial statements

Critical Audit Matter Description

The Company recognizes revenue for construction contracts over the contract term (“over time”) as construction work progresses. The accounting for these contracts involves judgment, particularly as it relates to the process of determining total estimated revenue (transaction price) and estimating total costs to be incurred at contract completion. Costs of operations are typically recognized as incurred, and the Company’s revenues, including estimated profits, are recorded proportionately as costs are incurred based on the ratio of costs incurred to date to the total estimated costs at completion for the respective performance obligations. Assumptions as to the occurrence of future events and the likelihood and amount of variable consideration, including the impact of change orders, claims, contract disputes and the achievement of contractual performance criteria, and award or other incentive fees are made during the contract performance period (collectively referred to as “variable consideration”). The Company estimates variable consideration at the most likely amount it expects to receive, and includes estimated amounts in the transaction price to the extent it is probable that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is resolved. Also, the Company often engages subcontractors, suppliers, or vendors, to provide underlying materials or services, or a combination of both. Judgment is involved in determining estimated recoveries from disputes regarding performance under these contracts (“back charges”), which are a reduction in costs and are recorded as a receivable on the consolidated balance sheet.

Given the significant judgment necessary to account for the Company’s construction contracts including the use of estimates, such as total estimated revenue, total costs to be incurred at contract completion, variable consideration and back charges, which are complex

and subject to many variables, auditing the corresponding balances and related accounting estimates required extensive audit effort due to the complexity of these estimates, and a high degree of auditor judgment when performing audit procedures and evaluating the results of those procedures.

How the Critical Audit Matter Was Addressed in the Audit

Our audit procedures related to management’s estimates and judgments included within the Company’s total estimated revenues, total costs to be incurred at contract completion, variable consideration, and back charges included the following, among others:

We tested the effectiveness of controls over revenues, including those over the determination of estimated costs at completion of the contract, total estimated revenue (including the estimated percentage of completion), variable consideration (including significant change orders and claims), and back charges.

We selected a sample of construction contracts and performed the following:

oCompared the total estimated revenue (transaction price), including estimated variable consideration, to the consideration expected to be received based on current rights and obligations under the contracts and any modifications that were agreed upon with the customers.

oWe evaluated the reasonableness of the estimated variable consideration by 1) evaluating the information supporting management’s judgment as to the cause and contractual rights and 2) testing the accuracy of the identification of the underlying costs.

oTested the accuracy and completeness of costs incurred to date.

oEvaluated the reasonableness of management’s estimates of total cost and profit at completion by:

Evaluating management’s ability to achieve the estimates of total cost and profit by performing corroborating inquiries with the Company’s project managers, and comparing the estimates to management’s work plans, engineering specifications, and supplier contracts.

Comparing management’s estimates to supporting documents for those estimates, when applicable.

Evaluating management’s ability to accurately estimate total costs and profits at completion by comparing actual costs and profits to management’s historical estimates for performance obligations that have been fulfilled.

Evaluating trends on changes in estimates and obtaining evidence on timing and amounts supporting these changes in estimates.

oTested the mathematical accuracy of management’s calculation of revenue recognized.

We evaluated selected quarter over quarter changes in contract profit estimates by obtaining explanations from the Company’s project managers regarding timing and amount and corroborating these inquiries by reading documents such as management work plans, customer communications, invoices and supplier communications.

Performed procedures on recorded back charges to evaluate the reasonableness of the estimated recovery by 1) evaluating the information supporting management’s judgment as to the cause and contractual rights and 2) testing the accuracy of the identification of the underlying costs.

Goodwill – Refer to Notes 1 and 6 to the financial statements

Critical Audit Matter Description

The Company’s evaluation of goodwill for impairment involves the comparison of the fair value of each reporting unit (which correspond to the Company’s operating segments) to its carrying value. The Company determines the fair value of its reporting units using the income approach and market approach valuation methodologies. The determination of fair value using the income-based approach requires management to make significant estimates and assumptions related to projected operating margins, cash flows generated from existing work and new awards, and projected investments in working capital (collectively, the “forecasted financial information”), as well as the discount rates and weighted-average cost of capital (“WACC”). The determination of fair value using the market-based approach requires management to make significant assumptions, including those related to the forecasted financial information referred to above and the industry-comparable multiples to be used for each of its reporting units. The Company determines the valuation of each reporting unit based upon a weighted-average value of the income approach and market approach valuation methods. As appropriate, the Company also assesses the reasonableness of the estimated fair value of the reporting units by comparing the sum of the reporting units’ fair values to the Company’s market capitalization and calculating an implied control premium (the excess of the aggregate fair values of the reporting units over the Company’s market capitalization). In evaluating the results there are various quantitative and qualitative factors that need to be considered and could involve subjective judgment. During the second quarter of 2019, the Company identified an interim impairment indicator in its goodwill balance. The Company performed an interim impairment test and determined that the fair value of each of the reporting units was below the carrying value, leading to a pre-tax impairment charge of $379.9 million and leaving a $205.1 million post-impairment goodwill balance solely attributable to the Civil reporting unit.

We identified goodwill as a critical audit matter because small changes to valuation assumptions, specifically the forecasted financial information, discount rates, WACC, and industry-comparable multiples, could have a significant impact on the reporting unit concluded value for both the interim and annual impairment tests, and changes to the reporting unit concluded value impacts the implied control premium calculated from the reconciliation between the reporting unit’s fair values and the Company’s market

capitalization, which was performed during the interim impairment test. Auditing these assumptions involved extensive audit effort, including the need to involve our fair value specialists, due to the complexity of these assumptions and a high degree of auditor judgment when performing audit procedures and evaluating the results of those procedures.

How the Critical Audit Matter Was Addressed in the Audit

Our audit procedures related to the forecasted financial information, discount rates, WACC, and industry-comparable multiples for the reporting units, for both the interim and the annual impairment tests, included the following, among others:

We tested the effectiveness of controls within the goodwill impairment test process, including those over the forecasted financial information, the selection of the industry-comparable multiples, WACC, and discount rates, as well as the identification of interim impairment indicators.

We evaluated management’s historical ability to accurately forecast by comparing actual results to management’s previous forecasted financial information for the same period.

We evaluated the reasonableness of management’s forecasted financial information by comparing the forecasted financial information to (1) historical results, (2) internal communications to management and the Board of Directors, (3) reporting units’ backlog, and (4) forecasted financial information included in the Company’s press releases, as well as analyst and industry reports of the Company and companies in its peer group.

We considered the impact of circumstances affecting the industry including, but not limited to, changes in the legal and business environment.

With the assistance of our fair value specialists, we evaluated the WACC and discount rates, including testing the underlying source information and the mathematical accuracy of the calculations, and developing a range of independent estimates of the discount rates and comparing those to the WACC and discount rates selected by management.

With the assistance of our fair value specialists, we evaluated the industry-comparable multiples, including testing the underlying source information and mathematical accuracy of the calculations, the acceptability of the selected companies within the Company’s peer group, and comparing the multiples selected by management to companies in the engineering and construction industry.

With the assistance of our fair value specialists, we evaluated the reasonableness of the quantitative and qualitative factors considered in the reconciliation between the reporting units’ fair values and the Company’s market capitalization and implied control premium as of the interim impairment test date. We evaluated factors such as implied control premiums in other mergers and acquisition transactions in the industry, ownership of the Company’s common stock, market trends, and vertical-integration between reporting units.

We evaluated the selected industry-comparable multiples by comparing to those used in the prior year, those used in the different reporting units and to current facts and circumstances affecting the reporting unit.

/s/ Deloitte & Touche LLP

Los Angeles, CaliforniaCA

February 26, 2020

February 27, 2019

We have served as the Company's auditor since 2002.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF INCOMEOPERATIONS

Year Ended December 31,

(in thousands, except per common share amounts)

2019

2018

2017

REVENUE

$

4,450,832

$

4,454,662

$

4,757,208

COST OF OPERATIONS

(4,209,060)

(4,000,209)

(4,302,803)

GROSS PROFIT

241,772

454,453

454,405

General and administrative expenses

(226,916)

(262,577)

(274,928)

Goodwill impairment

(379,863)

INCOME (LOSS) FROM CONSTRUCTION OPERATIONS

(365,007)

191,876

179,477

Other income, net

6,667

4,256

43,882

Interest expense

(67,494)

(63,519)

(69,384)

INCOME (LOSS) BEFORE INCOME TAXES

(425,834)

132,613

153,975

Income tax benefit (expense)

65,609

(34,832)

569

NET INCOME (LOSS)

(360,225)

97,781

154,544

LESS: NET INCOME ATTRIBUTABLE TO NONCONTROLLING INTERESTS

27,465

14,345

6,162

NET INCOME (LOSS) ATTRIBUTABLE TO TUTOR PERINI CORPORATION

$

(387,690)

$

83,436

$

148,382

BASIC EARNINGS (LOSS) PER COMMON SHARE

$

(7.72)

$

1.67

$

2.99

DILUTED EARNINGS (LOSS) PER COMMON SHARE

$

(7.72)

$

1.66

$

2.92

WEIGHTED-AVERAGE COMMON SHARES OUTSTANDING:

BASIC

50,220

49,952

49,647

DILUTED

50,220

50,301

50,759



 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 



Year Ended December 31,

(in thousands, except per common share amounts)

2018

 

2017

 

2016

REVENUE

$

4,454,662 

 

$

4,757,208 

 

$

4,973,076 

COST OF OPERATIONS

 

(4,000,209)

 

 

(4,302,803)

 

 

(4,515,886)

GROSS PROFIT

 

454,453 

 

 

454,405 

 

 

457,190 

General and administrative expenses

 

(262,577)

 

 

(274,928)

 

 

(255,270)

INCOME FROM CONSTRUCTION OPERATIONS

 

191,876 

 

 

179,477 

 

 

201,920 

Other income, net

 

4,256 

 

 

43,882 

 

 

6,977 

Interest expense

 

(63,519)

 

 

(69,384)

 

 

(59,782)

INCOME BEFORE INCOME TAXES

 

132,613 

 

 

153,975 

 

 

149,115 

Income tax (expense) benefit

 

(34,832)

 

 

569 

 

 

(53,293)

NET INCOME

 

97,781 

 

 

154,544 

 

 

95,822 

LESS: NET INCOME ATTRIBUTABLE TO NONCONTROLLING INTERESTS

 

14,345 

 

 

6,162 

 

 

 —

NET INCOME ATTRIBUTABLE TO TUTOR PERINI CORPORATION

$

83,436 

 

$

148,382 

 

$

95,822 

BASIC EARNINGS PER COMMON SHARE

$

1.67 

 

$

2.99 

 

$

1.95 

DILUTED EARNINGS PER COMMON SHARE

$

1.66 

 

$

2.92 

 

$

1.92 

WEIGHTED-AVERAGE COMMON SHARES OUTSTANDING:

 

 

 

 

 

 

 

 

BASIC

 

49,952 

 

 

49,647 

 

 

49,150 

DILUTED

 

50,301 

 

 

50,759 

 

 

49,864 

The accompanying notes are an integral part of these consolidated financial statements.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME (LOSS)

Year Ended December 31,

(in thousands)

2019

2018

2017

NET INCOME (LOSS)

$

(360,225)

$

97,781

$

154,544

OTHER COMPREHENSIVE INCOME (LOSS), NET OF TAX:

Defined benefit pension plan adjustments

844

771

1,424

Foreign currency translation adjustments

1,337

(2,945)

1,273

Unrealized gain (loss) in fair value of investments

1,561

(778)

(2)

TOTAL OTHER COMPREHENSIVE INCOME (LOSS), NET OF TAX

3,742

(2,952)

2,695

COMPREHENSIVE INCOME (LOSS)

(356,483)

94,829

157,239

LESS: COMPREHENSIVE INCOME ATTRIBUTABLE TO NONCONTROLLING INTERESTS

27,858

14,124

6,162

COMPREHENSIVE INCOME (LOSS) ATTRIBUTABLE TO TUTOR PERINI CORPORATION

$

(384,341)

$

80,705

$

151,077



 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 



Year Ended December 31,

(in thousands)

2018

 

2017

 

2016

NET INCOME

$

97,781 

 

$

154,544 

 

$

95,822 



 

 

 

 

 

 

 

 

OTHER COMPREHENSIVE INCOME (LOSS), NET OF TAX:

 

 

 

 

 

 

 

 

Defined benefit pension plan adjustments

 

771 

 

 

1,424 

 

 

(2,623)

Foreign currency translation adjustments

 

(2,945)

 

 

1,273 

 

 

(261)

Unrealized loss in fair value of investments

 

(778)

 

 

(2)

 

 

(340)

Unrealized loss in fair value of interest rate swap

 

 —

 

 

 —

 

 

(24)

TOTAL OTHER COMPREHENSIVE INCOME (LOSS), NET OF TAX

 

(2,952)

 

 

2,695 

 

 

(3,248)



 

 

 

 

 

 

 

 

COMPREHENSIVE INCOME

 

94,829 

 

 

157,239 

 

 

92,574 

LESS: COMPREHENSIVE INCOME ATTRIBUTABLE TO NONCONTROLLING INTERESTS

 

14,124 

 

 

6,162 

 

 

 —

COMPREHENSIVE INCOME ATTRIBUTABLE TO TUTOR PERINI CORPORATION

$

80,705 

 

$

151,077 

 

$

92,574 

The accompanying notes are an integral part of these consolidated financial statements.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED BALANCE SHEETS

As of December 31,

(in thousands, except share and per share amounts)

2019

2018

ASSETS

CURRENT ASSETS:

Cash and cash equivalents ($103,850 and $43,131 related to VIEs)

$

193,685

$

116,075

Restricted cash

8,416

3,788

Restricted investments

70,974

58,142

Accounts receivable ($91,090 and $62,482 related to VIEs)

1,354,519

1,261,072

Retainage receivable ($89,132 and $36,724 related to VIEs)

562,375

478,744

Costs and estimated earnings in excess of billings ($22,764 and $0 related to VIEs)

1,123,544

1,142,295

Other current assets ($58,128 and $30,185 related to VIEs)

197,473

115,527

Total current assets

3,510,986

3,175,643

PROPERTY AND EQUIPMENT:

Land

39,047

41,599

Building and improvements

115,041

125,193

Construction equipment

560,547

486,034

Other equipment

183,197

181,578

897,832

834,404

Less accumulated depreciation

(388,147)

(343,735)

Total property and equipment, net ($49,919 and $51,508 related to VIEs)

509,685

490,669

GOODWILL

205,143

585,006

INTANGIBLE ASSETS, NET

155,270

85,911

OTHER ASSETS

104,693

50,523

TOTAL ASSETS

$

4,485,777

$

4,387,752

LIABILITIES AND EQUITY

CURRENT LIABILITIES:

Current maturities of long-term debt

$

124,054

$

16,767

Accounts payable ($93,848 and $18,070 related to VIEs)

682,699

621,728

Retainage payable ($13,967 and $0 related to VIEs)

252,181

211,956

Billings in excess of costs and estimated earnings ($422,847 and $263,764 related to VIEs)

844,389

573,190

Accrued expenses and other current liabilities ($25,402 and $34,828 related to VIEs)

206,533

174,325

Total current liabilities

2,109,856

1,597,966

LONG-TERM DEBT, less current maturities, net of unamortized discount and debt issuance costs totaling $23,343 and $34,998

710,422

744,737

DEFERRED TAX LIABILITIES

35,686

105,521

OTHER LONG-TERM LIABILITIES

199,288

151,639

TOTAL LIABILITIES

3,055,252

2,599,863

COMMITMENTS AND CONTINGENCIES (Note 8)

 

 

EQUITY

Stockholders' equity:

Preferred stock – authorized 1,000,000 shares ($1 par value), NaN issued

Common stock – authorized 75,000,000 shares ($1 par value), issued and outstanding 50,278,816 and 50,025,996 shares

50,279

50,026

Additional paid-in capital

1,117,972

1,102,919

Retained earnings

313,991

701,681

Accumulated other comprehensive loss

(42,100)

(45,449)

Total stockholders' equity

1,440,142

1,809,177

Noncontrolling interests

(9,617)

(21,288)

TOTAL EQUITY

1,430,525

1,787,889

TOTAL LIABILITIES AND EQUITY

$

4,485,777

$

4,387,752



 

 

 

 

 



 

 

 

 

 



As of December 31,

(in thousands, except share and per share amounts)

2018

 

2017

ASSETS

CURRENT ASSETS:

 

 

 

 

 

Cash and cash equivalents ($43,131 and $53,067 related to VIEs)

$

116,075 

 

$

192,868 

Restricted cash

 

3,788 

 

 

4,780 

Restricted investments

 

58,142 

 

 

53,014 

Accounts receivable ($62,482 and $30,003 related to VIEs)

 

1,261,072 

 

 

1,265,717 

Retainage receivable ($36,724 and $12,410 related to VIEs)

 

478,744 

 

 

535,939 

Costs and estimated earnings in excess of billings

 

1,142,295 

 

 

932,758 

Other current assets ($30,185 and $0 related to VIEs)

 

115,527 

 

 

89,316 

Total current assets

 

3,175,643 

 

 

3,074,392 

PROPERTY AND EQUIPMENT:

 

 

 

 

 

Land

 

41,599 

 

 

41,382 

Building and improvements

 

125,193 

 

 

125,029 

Construction equipment

 

486,034 

 

 

477,988 

Other equipment

 

181,578 

 

 

182,288 



 

834,404 

 

 

826,687 

Less accumulated depreciation

 

(343,735)

 

 

(359,188)

Total property and equipment, net ($51,508 and $11,641 related to VIEs)

 

490,669 

 

 

467,499 

GOODWILL

 

585,006 

 

 

585,006 

INTANGIBLE ASSETS, NET

 

85,911 

 

 

89,454 

OTHER ASSETS

 

50,523 

 

 

47,772 

TOTAL ASSETS

$

4,387,752 

 

$

4,264,123 

LIABILITIES AND EQUITY

CURRENT LIABILITIES:

 

 

 

 

 

Current maturities of long-term debt

$

16,767 

 

$

30,748 

Accounts payable ($18,070 and $19,243 related to VIEs)

 

621,728 

 

 

699,971 

Retainage payable

 

211,956 

 

 

261,820 

Billings in excess of costs and estimated earnings ($263,764 and $120,952 related to VIEs)

 

573,190 

 

 

456,869 

Accrued expenses and other current liabilities ($34,828 and $0 related to VIEs)

 

174,325 

 

 

132,438 

Total current liabilities

 

1,597,966 

 

 

1,581,846 

LONG-TERM DEBT, less current maturities, net of unamortized discounts and debt issuance costs totaling $34,998 and $45,631

 

744,737 

 

 

705,528 

DEFERRED TAX LIABILITIES

 

105,521 

 

 

108,504 

OTHER LONG-TERM LIABILITIES

 

151,639 

 

 

163,465 

TOTAL LIABILITIES

 

2,599,863 

 

 

2,559,343 

COMMITMENTS AND CONTINGENCIES (Note 8)

 

 

 

 

 

EQUITY

 

 

 

 

 

Stockholders' equity:

 

 

 

 

 

Preferred stock – authorized 1,000,000 shares ($1 par value), none issued

 

 —

 

 

 —

Common stock – authorized 75,000,000 shares ($1 par value), issued and outstanding 50,025,996 and 49,781,010 shares

 

50,026 

 

 

49,781 

Additional paid-in capital

 

1,102,919 

 

 

1,084,205 

Retained earnings

 

701,681 

 

 

622,007 

Accumulated other comprehensive loss

 

(45,449)

 

 

(42,718)

Total stockholders' equity

 

1,809,177 

 

 

1,713,275 

Noncontrolling interests

 

(21,288)

 

 

(8,495)

TOTAL EQUITY

 

1,787,889 

 

 

1,704,780 

TOTAL LIABILITIES AND EQUITY

$

4,387,752 

 

$

4,264,123 

The accompanying notes are an integral part of these consolidated financial statements. 

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF CASH FLOWS

Year Ended December 31,

(in thousands)

2019

2018

2017

Cash Flows from Operating Activities:

Net income (loss)

$

(360,225)

$

97,781

$

154,544

Adjustments to reconcile net income (loss) to net cash provided by operating activities:

Goodwill impairment

379,863

Depreciation

58,818

43,724

48,387

Amortization of intangible assets

6,226

3,543

3,543

Share-based compensation expense

19,143

22,782

21,174

Change in debt discount and deferred debt issuance costs

13,207

12,072

17,595

Deferred income taxes

(71,609)

(449)

(23,096)

Gain on remeasurement of investment in joint venture

(37,792)

(Gain) loss on sale of property and equipment

(4,688)

402

1,131

Changes in other components of working capital, net of balances acquired

131,257

(156,844)

(60,214)

Other long-term liabilities

1,863

(2,007)

3,656

Other, net

467

398

(3,170)

NET CASH PROVIDED BY OPERATING ACTIVITIES

136,530

21,402

163,550

Cash Flows from Investing Activities:

Business acquisition, cash balance acquired net of cash paid

6,607

Acquisition of property and equipment

(84,196)

(77,069)

(30,280)

Proceeds from sale of property and equipment

12,581

6,387

2,744

Investments in securities

(35,167)

(20,848)

(60,967)

Proceeds from maturities and sales of investments in securities

24,120

21,322

1,370

NET CASH USED IN INVESTING ACTIVITIES

(76,055)

(70,208)

(87,133)

Cash Flows from Financing Activities:

Proceeds from debt

931,594

1,753,160

2,161,384

Repayment of debt

(870,277)

(1,738,314)

(2,195,068)

Business acquisition related payment

(15,951)

Cash payments related to share-based compensation

(2,363)

(2,671)

(11,769)

Distributions paid to noncontrolling interests

(46,500)

(29,000)

(17,499)

Contributions from noncontrolling interests

9,813

3,797

2,842

Debt issuance and extinguishment costs

(504)

(15,266)

NET CASH PROVIDED BY (USED IN) FINANCING ACTIVITIES

21,763

(28,979)

(75,376)

Net increase (decrease) in cash, cash equivalents and restricted cash

82,238

(77,785)

1,041

Cash, cash equivalents and restricted cash at beginning of year

119,863

197,648

196,607

Cash, cash equivalents and restricted cash at end of year

$

202,101

$

119,863

$

197,648



 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 



Year Ended December 31,

(in thousands)

2018

 

2017

 

2016

Cash Flows from Operating Activities:

 

 

 

 

 

 

 

 

Net income

$

97,781 

 

$

154,544 

 

$

95,822 

Adjustments to reconcile net income to net cash provided by operating activities:

 

 

 

 

 

 

 

 

Depreciation

 

43,724 

 

 

48,387 

 

 

63,759 

Amortization of intangible assets

 

3,543 

 

 

3,543 

 

 

3,543 

Share-based compensation expense

 

22,782 

 

 

21,174 

 

 

13,423 

Excess income tax benefit from share-based compensation

 

 —

 

 

 —

 

 

(269)

Change in debt discounts and deferred debt issuance costs

 

12,072 

 

 

17,595 

 

 

10,968 

Deferred income taxes

 

(449)

 

 

(23,096)

 

 

(10,169)

Loss on sale of property and equipment

 

402 

 

 

1,131 

 

 

453 

Changes in other components of working capital 

 

(156,844)

 

 

(60,214)

 

 

(90,530)

Other long-term liabilities

 

(2,007)

 

 

3,656 

 

 

28,210 

Other, net

 

398 

 

 

(3,170)

 

 

(1,874)

NET CASH PROVIDED BY OPERATING ACTIVITIES

 

21,402 

 

 

163,550 

 

 

113,336 



 

 

 

 

 

 

 

 

Cash Flows from Investing Activities:

 

 

 

 

 

 

 

 

Acquisition of property and equipment

 

(77,069)

 

 

(30,280)

 

 

(15,743)

Proceeds from sale of property and equipment

 

6,387 

 

 

2,744 

 

 

1,899 

Investments in securities

 

(20,848)

 

 

(60,967)

 

 

 —

Proceeds from maturities and sales of investments in securities

 

21,322 

 

 

1,370 

 

 

 —

NET CASH USED IN INVESTING ACTIVITIES

 

(70,208)

 

 

(87,133)

 

 

(13,844)



 

 

 

 

 

 

 

 

Cash Flows from Financing Activities:

 

 

 

 

 

 

 

 

Proceeds from debt

 

1,753,160 

 

 

2,161,384 

 

 

1,353,895 

Repayment of debt

 

(1,738,314)

 

 

(2,195,068)

 

 

(1,562,684)

Business acquisition related payment

 

(15,951)

 

 

 —

 

 

 —

Issuance of convertible notes

 

 —

 

 

 —

 

 

200,000 

Cash payments related to share-based compensation

 

(2,671)

 

 

(11,769)

 

 

(584)

Excess income tax benefit from share-based compensation

 

 —

 

 

 —

 

 

269 

Distributions paid to noncontrolling interests

 

(29,000)

 

 

(17,499)

 

 

 —

Contributions from noncontrolling interests

 

3,797 

 

 

2,842 

 

 

 —

Debt issuance and extinguishment costs

 

 —

 

 

(15,266)

 

 

(15,086)

NET CASH USED IN FINANCING ACTIVITIES

 

(28,979)

 

 

(75,376)

 

 

(24,190)



 

 

 

 

 

 

 

 

Net increase (decrease) in cash, cash equivalents and restricted cash

 

(77,785)

 

 

1,041 

 

 

75,302 

Cash, cash equivalents and restricted cash at beginning of year

 

197,648 

 

 

196,607 

 

 

121,305 

Cash, cash equivalents and restricted cash at end of year

$

119,863 

 

$

197,648 

 

$

196,607 

The accompanying notes are an integral part of these consolidated financial statements.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

CONSOLIDATED STATEMENTS OF CHANGES IN EQUITY

Accumulated

Additional

Other

Common

Paid-in

Retained

Comprehensive

Noncontrolling

(in thousands)

Stock

Capital

Earnings

Loss

Interests

Total

Balance - December 31, 2016

$

49,211

$

1,075,600

$

473,625

$

(45,413)

$

$

1,553,023

Net income

148,382

6,162

154,544

Other comprehensive income

2,695

2,695

Share-based compensation

20,877

20,877

Issuance of common stock, net

570

(12,272)

(11,702)

Contributions from noncontrolling interests

2,842

2,842

Distributions to noncontrolling interests

(17,499)

(17,499)

Balance - December 31, 2017

$

49,781

$

1,084,205

$

622,007

$

(42,718)

$

(8,495)

$

1,704,780

Cumulative effect of accounting change

(3,762)

(1,714)

(5,476)

Net income

83,436

14,345

97,781

Other comprehensive loss

(2,731)

(221)

(2,952)

Share-based compensation

21,544

21,544

Issuance of common stock, net

245

(2,830)

(2,585)

Contributions from noncontrolling interests

3,797

3,797

Distributions to noncontrolling interests

(29,000)

(29,000)

Balance - December 31, 2018

$

50,026

$

1,102,919

$

701,681

$

(45,449)

$

(21,288)

$

1,787,889

Net income (loss)

(387,690)

27,465

(360,225)

Other comprehensive income

3,349

393

3,742

Share-based compensation

17,571

17,571

Issuance of common stock, net

253

(2,518)

(2,265)

Contributions from noncontrolling interests

9,813

9,813

Distributions to noncontrolling interests

(46,500)

(46,500)

Recognized fair value of noncontrolling interest in joint venture upon consolidation

20,500

20,500

Balance - December 31, 2019

$

50,279

$

1,117,972

$

313,991

$

(42,100)

$

(9,617)

$

1,430,525



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

Accumulated

 

 

 

 

 

 



 

 

 

Additional

 

 

 

 

Other

 

 

 

 

 

 



Common

 

Paid-in

 

Retained

 

Comprehensive

 

Noncontrolling

 

 

 

(in thousands)

Stock

 

Capital

 

Earnings

 

Loss

 

Interests

 

Total

Balance - December 31, 2015

$

49,073 

 

$

1,035,516 

 

$

377,803 

 

$

(42,165)

 

$

 —

 

$

1,420,227 

Net income

 

 —

 

 

 —

 

 

95,822 

 

 

 —

 

 

 —

 

 

95,822 

Other comprehensive loss

 

 —

 

 

 —

 

 

 —

 

 

(3,248)

 

 

 —

 

 

(3,248)

Tax effect of share-based compensation

 

 —

 

 

(457)

 

 

 —

 

 

 —

 

 

 —

 

 

(457)

Share-based compensation

 

 —

 

 

13,423 

 

 

 —

 

 

 —

 

 

 —

 

 

13,423 

Issuance of common stock, net

 

138 

 

 

676 

 

 

 —

 

 

 —

 

 

 —

 

 

814 

Convertible note proceeds allocated to conversion option, net

 

 —

 

 

26,442 

 

 

 —

 

 

 —

 

 

 —

 

 

26,442 

Balance - December 31, 2016

$

49,211 

 

$

1,075,600 

 

$

473,625 

 

$

(45,413)

 

$

 —

 

$

1,553,023 

Net income

 

 —

 

 

 —

 

 

148,382 

 

 

 —

 

 

6,162 

 

 

154,544 

Other comprehensive income

 

 —

 

 

 —

 

 

 —

 

 

2,695 

 

 

 —

 

 

2,695 

Share-based compensation

 

 —

 

 

20,877 

 

 

 —

 

 

 —

 

 

 —

 

 

20,877 

Issuance of common stock, net

 

570 

 

 

(12,272)

 

 

 —

 

 

 —

 

 

 —

 

 

(11,702)

Contributions from noncontrolling interests

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

2,842 

 

 

2,842 

Distributions to noncontrolling interests

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

(17,499)

 

 

(17,499)

Balance - December 31, 2017

$

49,781 

 

$

1,084,205 

 

$

622,007 

 

$

(42,718)

 

$

(8,495)

 

$

1,704,780 

Cumulative effect of accounting change

 

 —

 

 

 —

 

 

(3,762)

 

 

 —

 

 

(1,714)

 

 

(5,476)

Net income

 

 —

 

 

 —

 

 

83,436 

 

 

 —

 

 

14,345 

 

 

97,781 

Other comprehensive loss

 

 —

 

 

 —

 

 

 —

 

 

(2,731)

 

 

(221)

 

 

(2,952)

Share-based compensation

 

 —

 

 

21,544 

 

 

 —

 

 

 —

 

 

 —

 

 

21,544 

Issuance of common stock, net

 

245 

 

 

(2,830)

 

 

 —

 

 

 —

 

 

 —

 

 

(2,585)

Contributions from noncontrolling interests

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

3,797 

 

 

3,797 

Distributions to noncontrolling interests

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

(29,000)

 

 

(29,000)

Balance - December 31, 2018

$

50,026 

 

$

1,102,919 

 

$

701,681 

 

$

(45,449)

 

$

(21,288)

 

$

1,787,889 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

The accompanying notes are an integral part of these consolidated financial statements.

F-9

F-7


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

1.     Summary of Significant Accounting Policies

(a) Basis of Presentation

The accompanying consolidated financial statements have been prepared in compliance with generally accepted accounting principles in the United States (“GAAP”) as codified in the Financial Accounting Standards Board’s (“FASB”) Accounting Standards Codification (“ASC”).

(b) Principles of Consolidation

The consolidated financial statements include the accounts of Tutor Perini Corporation and its wholly owned subsidiaries (the “Company”). The Company occasionally forms joint ventures with unrelated third parties for the execution of single contracts or projects. The Company assesses its joint ventures at inception to determine if they meet the qualifications of a variable interest entity (“VIE”) in accordance with ASC 810, Consolidation (“ASC 810”). If a joint venture is a VIE and the Company is the primary beneficiary, the joint venture is fully consolidated (See Note 13 below)14). If a joint venture is not a VIE, it may be consolidated under the voting interest method if the Company holds a controlling financial interest in the joint venture. The Company is considered to hold a controlling financial interest when it is able to exercise control over the joint venture’s operating and financial decisions. For construction joint ventures that do not need to be consolidated, the Company accounts for its interest in the joint ventures using the proportionate consolidation method, whereby the Company’s proportionate share of the joint ventures’ assets, liabilities, revenue and cost of operations are included in the appropriate classifications in the Company’s consolidated financial statements. Intercompany balances and transactions have been eliminated.

(c) Use of Estimates

The preparation of financial statements in accordance with GAAP requires management to make estimates and assumptions that affect reported amounts. These estimates are based on information available through the date of the issuance of the financial statements; therefore, actual results could differ from those estimates.

(d) Revenues

Revenue Recognition

Implementation of New Revenue Recognition Guidance

In May 2014, the FASB issued Accounting Standards Update (“ASU”) 2014-09, Revenue from Contracts with Customers (Topic 606), as amended by subsequent ASUs (collectively, “ASC 606”) which amends the existing accounting standards for revenue recognition and establishes principles for recognizing revenue upon the transfer of promised goods or services to customers based on the expected consideration to be received in exchange for those goods or services. The Company adopted this ASU effective January 1, 2018 using the modified retrospective transition method.The Company recognized the cumulative effect of initially applying the new revenue standard to all contracts not yet completed or substantially completed as of January 1, 2018 as an immaterial reduction to beginning retained earnings. The impact of adoption on the Company’s opening balance sheet was primarily related to the deferral of costs incurred to fulfill certain contracts that were previously recorded in income in the period incurred, but under the new standard are capitalized and amortized over the period of contract performance. The prior year comparative information has not been restated and continues to be reported under the accounting standards in effect for those periods; however, certain balances have been reclassified to conform to the current year presentation.

F-8


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The effect of the changes made to the Company’s consolidated January 1, 2018 balance sheet for the adoption of ASC 606 were as follows:



 

 

 

 

 

 

 

 



 

 

BALANCE SHEET

Balance as of

 

Adjustments due to

 

Balance as of

(in thousands)

December 31, 2017(a)

 

ASC 606

 

January 1, 2018

ASSETS

 

 

 

 

 

 

 

 

Accounts receivable(b)

$

1,801,656 

 

$

(535,939)

 

$

1,265,717 

Retainage receivable(b)

 

 —

 

 

535,939 

 

 

535,939 

Other current assets

 

89,316 

 

 

32,773 

 

 

122,089 



 

 

 

 

 

 

 

 

LIABILITIES

 

 

 

 

 

 

 

 

Accounts payable(b)

$

961,791 

 

$

(261,820)

 

$

699,971 

Retainage payable(b)

 

 —

 

 

261,820 

 

 

261,820 

Billings in excess of costs and estimated earnings

 

456,869 

 

 

39,785 

 

 

496,654 

Deferred income taxes

 

108,504 

 

 

(1,537)

 

 

106,967 



 

 

 

 

 

 

 

 

EQUITY

 

 

 

 

 

 

 

 

Retained earnings

$

622,007 

 

$

(3,762)

 

$

618,245 

Noncontrolling interests

 

(8,495)

 

 

(1,714)

 

 

(10,209)

(a)

Balances as previously reported on the Company’s Annual Report on Form 10-K for the year ended December 31, 2017.  

(b)

Prior to the adoption of ASC 606, retainage receivable and payable balances were included within accounts receivable and accounts payable, respectively.

In accordance with the new revenue standard requirements, the disclosure of the impacts of adoption on the Consolidated Statement of Income and Consolidated Balance Sheet were as follows:



 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 



 

Year Ended December 31, 2018



 

 

 

Balance Without

 

 

STATEMENT OF INCOME

 

 

 

Adoption of

 

Effect of

(in thousands)

 

As Reported

 

ASC 606

 

Change

REVENUE

 

$

4,454,662 

 

$

4,458,668 

 

$

(4,006)

COST OF OPERATIONS

 

 

(4,000,209)

 

 

(4,003,959)

 

 

3,750 

GROSS PROFIT

 

 

454,453 

 

 

454,709 

 

 

(256)

General and administrative expenses

 

 

(262,577)

 

 

(262,577)

 

 

 —

INCOME FROM CONSTRUCTION OPERATIONS

 

 

191,876 

 

 

192,132 

 

 

(256)

Other income, net

 

 

4,256 

 

 

4,256 

 

 

 —

Interest expense

 

 

(63,519)

 

 

(63,519)

 

 

 —

INCOME BEFORE INCOME TAXES

 

 

132,613 

 

 

132,869 

 

 

(256)

Income tax (expense) benefit

 

 

(34,832)

 

 

(34,939)

 

 

107 

NET INCOME

 

 

97,781 

 

 

97,930 

 

 

(149)

LESS: NET INCOME ATTRIBUTABLE TO NONCONTROLLING INTERESTS

 

 

14,345 

 

 

14,212 

 

 

133 

NET INCOME ATTRIBUTABLE TO TUTOR PERINI CORPORATION

 

$

83,436 

 

$

83,718 

 

$

(282)

F-9


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)



 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 



 

As of December 31, 2018



 

 

 

Balance Without

 

 

BALANCE SHEET

 

 

 

Adoption of

 

Effect of

(in thousands)

 

As Reported

 

ASC 606

 

Change

ASSETS

 

 

 

 

 

 

 

 

 

Accounts receivable(a)

 

$

1,261,072 

 

$

1,735,414 

 

$

(474,342)

Retainage receivable(a)

 

 

478,744 

 

 

 —

 

 

478,744 

Costs and estimated earnings in excess of billings

 

 

1,142,295 

 

 

1,148,216 

 

 

(5,921)

Other current assets

 

 

115,527 

 

 

79,004 

 

 

36,523 



 

 

 

 

 

 

 

 

 

LIABILITIES

 

 

 

 

 

 

 

 

 

Accounts payable(a)

 

$

621,728 

 

$

833,684 

 

$

(211,956)

Retainage payable(a)

 

 

211,956 

 

 

 —

 

 

211,956 

Billings in excess of costs and estimated earnings

 

 

573,190 

 

 

530,918 

 

 

42,272 

Accrued expenses and other current liabilities

 

 

174,325 

 

 

174,824 

 

 

(499)

Deferred income taxes

 

 

105,521 

 

 

106,665 

 

 

(1,144)



 

 

 

 

 

 

 

 

 

EQUITY

 

 

 

 

 

 

 

 

 

Retained earnings

 

$

701,681 

 

$

705,725 

 

$

(4,044)

Noncontrolling interests

 

 

(21,288)

 

 

(19,707)

 

 

(1,581)

(a)

Prior to the adoption of ASC 606, retainage receivable and payable balances were included within accounts receivable and payable, respectively.

The adoption of ASC 606 had no impact on the cash flows provided by operating activities in the Company’s Consolidated Statement of Cash Flows.

Revenue Recognition Policy

The Company derives revenue from long-term construction contracts with public and private customers primarily in the United States and its territories and in certain other international locations. The Company’s construction contracts are generally each accounted for as a single unit of account (i.e., as a single performance obligation).

Throughout the execution of construction contracts, the Company and its affiliated entities recognize revenue with the continuous transfer of control to the customer. The customer typically controls the asset under construction by either contractual termination clauses or by the Company’s rights to payment for work already performed on the asset under construction that does not have an alternative use for the Company.

Because control transfers over time, revenue is recognized to the extent of progress towards completion of the performance obligations. The selection of the method to measure progress towards completion requires judgment and is based on the nature of the products or services provided. The Company generally uses the cost-to-cost method for its contracts, which measures progress towards completion for each performance obligation based on the ratio of costs incurred to date to the total estimated costs at completion for the respective performance obligation. Incurred cost represents work performed, which corresponds with, and thereby best depicts, the transfer of control to the customer. Revenue, including estimated fees or profits, is recorded proportionately as costs are incurred. Cost of operations includes labor, materials, subcontractor costs, and other direct and indirect costs, including depreciation and amortization.

Due to the nature of the work required to be performed on many of the Company’s performance obligations, estimating total revenue and cost at completion is complex, subject to many variables and requires significant judgment. Assumptions as to the occurrence of future events and the likelihood and amount of variable consideration, including the impact of change orders, claims, contract disputes and the achievement of contractual performance criteria, and award or other incentive fees are made during the contract performance period. The Company estimates variable consideration at the most likely amount it expects to receive. The Company includes estimated amounts in the transaction price to the extent it is probable that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is resolved. Estimates of variable consideration and determination of whether to include estimated amounts in the transaction price are based largely on an assessment of anticipated

F-10


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

performance and all information (historical, current and forecasted) that is reasonably available to management. Back charges to suppliers or subcontractors are recognized as a reduction of cost when it is determined that recovery of such cost is probable and the amounts can be reliably estimated. Disputed back charges are recognized when the same requirements described above for variable consideration have been satisfied.

F-10


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Changes in Estimates on Construction Contracts

The Company’s estimates of contract revenue and cost are highly detailed and many factors change during a contract performance period that result in a change to contract profitability. These factors include, but are not limited to, differing site conditions; availability of skilled contract labor; performance of major material suppliers and subcontractors; on-going subcontractor negotiations and buyout provisions; unusual weather conditions; changes in the timing of scheduled work; change orders; accuracy of the original bid estimate; changes in estimated labor productivity and costs based on experience to date; achievement of incentive-based income targets; and the expected, or actual, resolution terms for claims. The factors that cause changes in estimates vary depending on the maturation of the project within its lifecycle. For example, in the ramp-up phase, these factors typically consist of revisions in anticipated project costs and during the peak and closeout phases, these factors include the impact of change orders and claims, as well as additional revisions in remaining anticipated project costs. Generally, if the contract is at an early stage of completion, the current period impact is smaller than if the same change in estimate is made to the contract at a later stage of completion. Management evaluates changes in estimates on a contract by contractcontract-by-contract basis and discloses significant changes, if material, in the Notes to the Consolidated Financial Statements. The cumulative catch-up method is used to account for revisions in estimates.

(e) Depreciation of Property and Equipment and Amortization of Long-Lived Intangible Assets

Property and equipment and long-lived intangible assets are generally depreciated or amortized on a straight-line basis over their estimated useful lives ranging from three to forty years.

(f) Recoverability of Long-Lived Assets

Long-lived assets are reviewed for impairment whenever circumstances indicate that the future cash flows generated by the assets might be less than the assets’ net carrying value. In such circumstances, an impairment loss will be recognized by the amount the assets’ net carrying value exceeds their fair value.

(g) Recoverability of Goodwill

The Company tests goodwill for impairment annually as of October 1 for each reporting unit and between annual tests if events occur or circumstances change which suggest that goodwill should be reevaluated. Such events or circumstances include significant changes in legal factors and business climate, recent losses at a reporting unit, and industry trends, among other factors. The Civil, Building and Specialty Contractors segments each represent a reporting unit.unit, and the Civil reporting unit carried the remaining goodwill balance at December 31, 2019 as a result of the $379.9 million impairment loss recognized in the second quarter of 2019. The Company performs its annual quantitative impairment assessment during the fourth quarter of each year using a weighted-average of an income and a market approach. The income approach is based on estimated present value of future cash flows for each reporting unit.unit carrying a goodwill balance. The market approach is based on assumptions about how market data relates to each reporting unit.unit carrying a goodwill balance. The weighting of these two approaches is based on their individual correlation to the economics of each reporting unit.unit carrying a goodwill balance. The annual quantitative assessment performed in 2018the fourth quarter of 2019 resulted in an estimated fair value for eachthat exceeded the net book value of the Company’sCivil reporting units that exceeded their respective net book values;unit; therefore, no impairment charge was necessary for 2018.necessary.

(h) Recoverability of Non-Amortizable Trade Names

Certain trade names have an estimated indefinite life and are not amortized to earnings, but instead are reviewed for impairment annually, or more often if events occur or circumstances change which suggest that the non-amortizable trade names should be reevaluated. The Company performs its annual quantitative impairment assessment during the fourth quarter of each year using an income approach (relief from royalty method). The quantitative assessment performed in 2018 resulted in an estimated fair value for the and may assess its non-amortizable trade names for impairment initially using a qualitative approach to determine whether conditions exist to indicate that exceeded their respective net book values;it is more likely than not that the fair value of a trade name is less than its carrying value. If the Company concludes, based on assessment of relevant events, facts and circumstances, that it is more likely than not that the trade name’s fair value is greater than its carrying value, no further impairment testing through a quantitative assessment is required. The qualitative assessment performed for the Company’s annual impairment assessment in the fourth quarter of 2019 concluded that it was more likely than not that the trade name’s fair value was greater than its carrying value, and therefore no impairment chargea quantitative analysis was necessary for 2018.not required.

F-11


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

(i) Income Taxes

Deferred income tax assets and liabilities are recognized for the effects of temporary differences between the financial statement carrying amounts and the income tax basis of assets and liabilities using tax rates expected to be in effect when such differences reverse. Income tax positions must meet a more-likely-than-not threshold to be recognized. The Company recognizes interest and penalties related to uncertain tax positions as a component of the income tax provision.

(j) Earnings Per Common Share (EPS)

Basic EPS and diluted EPS are calculated by dividing net income attributable to Tutor Perini Corporation by the following: for basic EPS, the weighted-average number of common shares outstanding during the period; and for diluted EPS, the sum of the weighted-

F-11


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

averageweighted-average number of both outstanding common shares and potentially dilutive securities, which for the Company can include restricted stock units, unexercised stock options and the Convertible Notes, as defined in Note 7. For the year ended December 31, 2019, all potentially dilutive securities were excluded from the calculation of diluted EPS as a result of the net loss for the period.In accordance with ASC 260, Earnings Per Share, the settlement of the principal amount of the Convertible Notes has had no impact on diluted EPS because the Company has had the intent and ability to settle the principal amount in cash. The Company calculates the effect of the potentially dilutive restricted stock units and stock options using the treasury stock method.

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands, except per common share data)

2018

 

2017

 

2016

2019

2018

2017

Net income attributable to Tutor Perini Corporation

$

83,436 

 

$

148,382 

 

$

95,822 

Net income (loss) attributable to Tutor Perini Corporation

$

(387,690)

$

83,436

$

148,382

 

 

 

 

 

 

Weighted-average common shares outstanding, basic

 

49,952 

 

49,647 

 

49,150 

50,220

49,952

49,647

Effect of dilutive restricted stock units and stock options

 

349 

 

1,112 

 

714 

349

1,112

Weighted-average common shares outstanding, diluted

 

50,301 

 

50,759 

 

49,864 

50,220

50,301

50,759

 

 

 

 

 

 

Net income attributable to Tutor Perini Corporation per common share:

 

 

 

 

 

 

Net income (loss) attributable to Tutor Perini Corporation per common share:

Basic

$

1.67 

 

$

2.99 

 

$

1.95 

$

(7.72)

$

1.67

$

2.99

Diluted

$

1.66 

 

$

2.92 

 

$

1.92 

$

(7.72)

$

1.66

$

2.92

Anti-dilutive securities not included above

 

2,670 

 

798 

 

1,132 

3,640

2,670

798

(k) Cash, Cash Equivalents and Restricted Cash

The following table provides a reconciliation of cash, cash equivalents and restricted cash reported within the Consolidated Balance Sheets to the amounts shown in the Consolidated Statements of Cash Flows:

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Cash and cash equivalents available for general corporate purposes

$

51,749 

 

$

94,713 

$

43,760

$

51,749

Joint venture cash and cash equivalents

 

64,326 

 

 

98,155 

149,925

64,326

Cash and cash equivalents

 

116,075 

 

 

192,868 

193,685

116,075

Restricted cash

 

3,788 

 

 

4,780 

8,416

3,788

Total cash, cash equivalents and restricted cash

$

119,863 

 

$

197,648 

$

202,101

$

119,863

 

 

 

 

 

Cash equivalents include short-term, highly liquid investments with maturities of three months or less when acquired. Cash and cash equivalents, consist of amounts available for the Company’s general purposes, the Company’s proportionate share of cash held by the Company’s unconsolidated joint ventures and 100% of amounts held by the Company’s consolidated joint ventures. In both cases, cash held by joint ventures is available only for joint venture-related uses, including future distributions to joint venture partners.

Amounts included in restricted cash are primarily held as collateral to secure insurance-related contingent obligations, such as insurance claim deductibles, in lieu of letters of credit.

F-12


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

(l) Restricted Investments

The Company has restricted investments primarily held as collateral to secure insurance-related contingent obligations, such as insurance claim deductibles, in lieu of letters of credit. Restricted investments are primarily comprised of investments in corporate debt securities and U.S. government agency securities that are rated A3 or better.

(m) Share-Based Compensation

The Company’s long-term incentive plans allow the Company to grant share-based compensation awards in a variety of forms, including restricted and unrestricted stock units and stock options. Restricted stock units and stock options generally vest subject to service and/or performance requirements, with related compensation expense equal to the fair value of the award on the date of grant and recognized on a straight-line basis over the requisite period.

For share-based awards that have a service requirement, the Company accounts for forfeitures upon occurrence, rather than estimating the probability of forfeiture at the date of grant. Accordingly, the Company recognizes the full grant-date fair value of these awards on a straight-line basis throughout the requisite service period, reversing any expense if, and only if, there is a forfeiture.

F-12


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

For share-based awards that have a performance-based vesting requirement, the Company evaluates the probability of achieving the performance criteria throughout the performance period, and will adjust share-based compensation expense if it estimates that the achievement of the performance criteria is not probable. Certain performance-based awards contain market condition components and are valued on the date of grant using a Monte Carlo simulation model. The fair value of such awards is expensed ratably over the performance period and is not adjusted for actual achievement.

(n) Insurance Liabilities

The Company typically utilizes third-party insurance coverage subject to varying deductible levels with aggregate caps on losses retained. The Company assumes the risk for the amount of the deductible portion of the losses and liabilities primarily associated with workers’ compensation and general liability coverage. In addition, on certain projects, the Company assumes the risk for the amount of the deductible portion of losses that arise from any subcontractor defaults. Losses are accrued based upon the Company’s estimates of the aggregate liability for claims incurred using historical experience and certain actuarial assumptions followed in the insurance industry. The estimate of insurance liability within the deductible limits includes an estimate of incurred but not reported claims based on data compiled from historical experience.

(o) Other Comprehensive Income (Loss)

ASC 220, Comprehensive Income, establishes standards for reporting and displaying comprehensive income and its components in the consolidated financial statements. The Company reports the change in pension benefit plan assets/liabilities, cumulative foreign currency translation, and change in fair value of investments and change in fair value of an interest rate swap as components of accumulated other comprehensive lossincome (loss) (“AOCI”).

The tax effects of the components of other comprehensive income (loss) and the related tax effects for arethe years ended December 31, 2019, 2018 and 2017 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

2018

 

2017

 

2016

2019

2018

2017

(in thousands)

Before-Tax Amount

 

Tax (Expense) Benefit

 

Net-of-Tax Amount

 

Before-Tax Amount

 

Tax (Expense) Benefit

 

Net-of-Tax Amount

 

Before-Tax Amount

 

Tax Benefit

 

Net-of-Tax Amount

Before-Tax Amount

Tax (Expense) Benefit

Net-of-Tax Amount

Before-Tax Amount

Tax (Expense) Benefit

Net-of-Tax Amount

Before-Tax Amount

Tax (Expense) Benefit

Net-of-Tax Amount

Other comprehensive income (loss):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Defined benefit pension plan adjustments

$

1,079 

 

$

(308)

 

$

771 

 

$

2,416 

 

$

(992)

 

$

1,424 

 

$

(4,452)

 

$

1,829 

 

$

(2,623)

$

1,180 

$

(336)

$

844 

$

1,079 

$

(308)

$

771 

$

2,416 

$

(992)

$

1,424 

Foreign currency translation adjustment

 

(4,067)

 

 

1,122 

 

(2,945)

 

 

2,159 

 

 

(886)

 

1,273 

 

 

(439)

 

178 

 

(261)

1,867 

(530)

1,337 

(4,067)

1,122 

(2,945)

2,159 

(886)

1,273 

Unrealized gain (loss) in fair value of investments

 

(1,005)

 

 

227 

 

(778)

 

 

(4)

 

 

 

(2)

 

 

(576)

 

236 

 

(340)

1,982 

(421)

1,561 

(1,005)

227 

(778)

(4)

(2)

Unrealized gain (loss) in fair value of interest rate swap

 

 —

 

 

 —

 

 —

 

 

 —

 

 

 —

 

 —

 

 

(45)

 

21 

 

(24)

Total other comprehensive income (loss)

$

(3,993)

 

$

1,041 

 

$

(2,952)

 

$

4,571 

 

$

(1,876)

 

$

2,695 

 

$

(5,512)

 

$

2,264 

 

$

(3,248)

$

5,029 

$

(1,287)

$

3,742 

$

(3,993)

$

1,041 

$

(2,952)

$

4,571 

$

(1,876)

$

2,695 

Less: Other comprehensive income (loss) attributable to noncontrolling interests(a)

 

(221)

 

 

 —

 

(221)

 

 

 —

 

 

 —

 

 —

 

 

 —

 

 —

 

 —

393 

393 

(221)

(221)

Total other comprehensive income (loss) attributable to Tutor Perini Corporation

$

(3,772)

 

$

1,041 

 

$

(2,731)

 

$

4,571 

 

$

(1,876)

 

$

2,695 

 

$

(5,512)

 

$

2,264 

 

$

(3,248)

$

4,636 

$

(1,287)

$

3,349 

$

(3,772)

$

1,041 

$

(2,731)

$

4,571 

$

(1,876)

$

2,695 

_____________________________________________________________________________________________________________

(a)The only component of other comprehensive income (loss) attributable to noncontrolling interests is foreign currency translation.

(a)

The only component of other comprehensive loss attributable to noncontrolling interests is foreign currency translation.

F-13

F-13


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The changes in AOCI balances by component (after tax) attributable to Tutor Perini Corporation areduring the years ended December 31, 2019, 2018 and 2017 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(in thousands)

Defined Benefit Pension Plan

 

Foreign Currency Translation

 

Unrealized Gain (Loss) in Fair Value of Investments

 

Unrealized Gain (Loss) in Fair Value of Interest Rate Swap

 

Accumulated Other Comprehensive Income (Loss)

Defined Benefit Pension Plan

Foreign Currency Translation

Unrealized Gain (Loss) in Fair Value of Investments

Accumulated Other Comprehensive Income (Loss)

Attributable to Tutor Perini Corporation:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Balance as of December 31, 2015

$

(38,242)

 

$

(4,603)

 

$

656 

 

$

24 

 

$

(42,165)

Other comprehensive loss before reclassifications

 

(3,722)

 

 

(261)

 

 

(340)

 

 

(24)

 

 

(4,347)

Amounts reclassified from AOCI

 

1,099 

 

 

 —

 

 

 —

 

 

 —

 

 

1,099 

Balance as of December 31, 2016

$

(40,865)

 

$

(4,864)

 

$

316 

 

$

 —

 

$

(45,413)

$

(40,865)

$

(4,864)

$

316 

$

(45,413)

Other comprehensive income (loss) before reclassifications

 

306 

 

 

1,273 

 

 

(2)

 

 

 —

 

 

1,577 

306 

1,273 

(2)

1,577 

Amounts reclassified from AOCI

 

1,118 

 

 

 —

 

 

 —

 

 

 —

 

 

1,118 

1,118 

��

1,118 

Balance as of December 31, 2017

$

(39,441)

 

$

(3,591)

 

$

314 

 

$

 —

 

$

(42,718)

$

(39,441)

$

(3,591)

$

314 

$

(42,718)

Other comprehensive loss before reclassifications

 

(695)

 

 

(2,724)

 

 

(835)

 

 

 —

 

 

(4,254)

(695)

(2,724)

(835)

(4,254)

Amounts reclassified from AOCI

 

1,466 

 

 

 —

 

 

57 

 

 

 —

 

 

1,523 

1,466 

57 

1,523 

Balance as of December 31, 2018

$

(38,670)

 

$

(6,315)

 

$

(464)

 

$

 —

 

$

(45,449)

$

(38,670)

$

(6,315)

$

(464)

$

(45,449)

Other comprehensive income (loss) before reclassifications

(539)

944 

1,621 

2,026 

Amounts reclassified from AOCI

1,383 

(60)

1,323 

Balance as of December 31, 2019

$

(37,826)

$

(5,371)

$

1,097 

$

(42,100)

(p) Recent Accounting Pronouncements

In addition to the implementation of ASC 606 as discussed in 1(d), new accounting pronouncements implemented by the Company during the year ended December 31, 2018 are discussed below.

In November 2016, the FASB issued ASU 2016-18, Statement of Cash Flows (Topic 230): Restricted Cash, which requires restricted cash to be included with cash and cash equivalent balances in the statement of cash flows. The Company retrospectively adopted this ASU on January 1, 2018. The adoption of this ASU resulted in an increase of net cash used in investing activities of $45.7 million for the year ended December 31, 2017 and a decrease of net cash used in investing activities of $4.7 million for the year ended December 31, 2016.

In January 2017, the FASB issued ASU 2017-04, Intangibles—Goodwill and Other (Topic 350): Simplifying the Test for Goodwill Impairment (“ASU 2017-04”). This ASU simplifies the calculation of goodwill impairment by eliminating Step 2 of the impairment test prescribed by ASC 350, Intangibles—Goodwill and Other. Step 2 requires companies to calculate the implied fair value of their goodwill by estimating the fair value of their assets, other than goodwill, and liabilities, including unrecognized assets and liabilities, following the procedure that would be required in determining the fair value of assets acquired and liabilities assumed in a business combination. The calculated net fair value of the assets would then be compared to the fair value of the reporting unit to determine the implied fair value of goodwill, and to the extent that the carrying value of goodwill was less than the implied fair value, a loss would be recognized. Under ASU 2017-04, however, goodwill is impaired when the calculated fair value of a reporting unit is less than its carrying value, and the impairment charge will equal that difference (i.e., impairment will be calculated at the reporting unit level and there will be no need to estimate the fair value of individual assets and liabilities). This guidance will be effective for any goodwill impairment tests performed in fiscal years beginning after December 15, 2019; however, early adoption is permitted for tests performed on testing dates after January 1, 2017. The Company adopted this ASU on October 1, 2018. The adoption of this ASU did not have a material impact on the Company’s consolidated financial statements.

In May 2017, the FASB issued ASU 2017-09, Compensation—Stock Compensation (Topic 718): Scope of Modification Accounting. This ASU clarifies the scope of modification accounting under Topic 718 with respect to changes to the terms or conditions of a share-based payment award. Under this new guidance, modification accounting would not apply if a change to an award does not affect the total current fair value, vesting conditions or the classification of the award. The Company adopted this ASU effective January 1, 2018. The adoption of this ASU did not have a material impact on the Company’s consolidated financial statements.

In February 2018, the FASB issued ASU 2018-02, Income Statement—Reporting Comprehensive Income (Topic 220): Reclassification of Certain Tax Effects from the Accumulated Other Comprehensive Income. This ASU gives entities the option to reclassify to retained earnings tax effects related to items in accumulated other comprehensive income that the FASB refers to as having been stranded in accumulated other comprehensive income as a result of tax reform. Entities can apply the provisions of this ASU either in the period of adoption or retrospectively. The guidance is effective for interim and annual reporting periods beginning after December 15, 2018, with early adoption permitted. The Company adopted this ASU effective October 1, 2018 and elected to not reclassify the income tax effects of the tax reform from accumulated other comprehensive income to retained earnings.

F-14


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

In March 2018, the FASB issued ASU 2018-05, Income Taxes (Topic 740): Amendments to SEC Paragraphs Pursuant to SEC Staff Accounting Bulletin No. 118 (“ASU 2018-05”). This ASU provides guidance for companies that may not have completed their accounting for the income tax effects of the Tax Cut and Jobs Act of 2017 (the “Tax Act”) in the period of enactment. Staff Accounting Bulletin (“SAB”) No. 118 provides for a provisional one year measurement period to finalize the accounting for certain income tax effects related to the Tax Act and requires disclosure of the reasons for incomplete accounting. The Company applied the guidance provided in SAB No. 118 in 2017 and adopted this ASU effective January 1, 2018. The adoption of this ASU did not have a material impact on the Company’s consolidated financial statements.

The following new accounting pronouncement will be implemented in 2019.

In February 2016, the FASB issued ASU 2016-02, Leases (Topic 842), as amended and supplemented by subsequent ASUs (collectively, “ASU 2016-02”“ASC 842”). ASU 2016-02ASC 842 amends the existing guidance in ASC 840, Leases. This ASU requires, among other things, the recognition of lease right-of-use (“ROU”) assets and lease liabilities by lessees for those leases currently classified as operating leases. ASU 2016-02 allowsASC 842 allowed companies to adopt the new standard by applying either a modified retrospective method to the beginning of the earliest period presented in the financial statements or an optional transition method to initially apply the standard on January 1, 2019 and recognize a cumulative-effect adjustment to the opening balance of retained earnings in the period of adoption. The Company will adoptadopted the standard using the optional transition method. Under this method, financial results reported in periods prior to 2019 are unchanged. The Company has implemented changeselected the package of practical expedients which provides relief from having to certain business processes, systemsreassess (1) whether any expired or existing contracts contain leases, (2) lease classification (as operating or financing) for any expired or existing leases, and internal controls(3) initial direct costs for any existing leases. The Company also elected to support adoption of the new standard and the related disclosure requirements, including the implementation of a third-party leasing software solution.separate non-lease components from lease components. Based on the Company’s evaluation of ASU 2016-02, the Company expectsASC 842, the adoption to resulton January 1, 2019 resulted in an increase of approximately $40 million to $50$43.3 million to its assets and liabilities on the consolidated balance sheetsConsolidated Balance Sheets with an immaterialno impact to its consolidated statementsresults of incomeoperations or cash flows.

F-14


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The effects of the changes made to the Company’s January 1, 2019 consolidated balance sheet for the adoption of ASC 842 were as follows:

BALANCE SHEET

Balance as of

Adjustments due to

Balance as of

(in thousands)

December 31, 2018(a)

ASC 842

January 1, 2019

ASSETS

Other assets(b)

$

50,523

$

43,273

$

93,796

LIABILITIES

Accrued expenses and other current liabilities(b)

$

174,325

$

11,569

$

185,894

Other long-term liabilities(b)

151,639

31,704

183,343

_____________________________________________________________________________________________________________

(a)Balance as previously reported on the Company’s Annual Report on Form 10-K for the year ended December 31, 2018.

(b)Prior to the adoption of ASC 842, operating lease ROU assets and current and long-term operating lease liabilities were not recorded on the Consolidated Balance Sheets.

The following table presents the impacts of adoption of the new leases standard on the Consolidated Balance Sheet:

As of December 31, 2019

Balance Without

BALANCE SHEET

Adoption of

Effect of

(in thousands)

As Reported

ASC 842

Change

ASSETS

Other assets(a)

$

104,693

$

64,598

$

40,095

LIABILITIES

Accrued expenses and other current liabilities(a)

$

206,533

$

195,341

$

11,192

Other long-term liabilities(a)

199,288

170,373

28,915

_____________________________________________________________________________________________________________

(a)Prior to the adoption of ASC 842, operating lease ROU assets and current and long-term operating lease liabilities were not recorded on the Consolidated Balance Sheets.

In May 2014, the FASB issued ASU 2014-09, Revenue from Contracts with Customers (Topic 606), as amended by subsequent ASUs (collectively, “ASC 606”). The Company adopted this ASU effective January 1, 2018 using the modified retrospective transition method. As such, the 2017 comparative information has not been restated and continues to be reported under the accounting standards in effect for that period.

New accounting pronouncements requiring implementation in future periods are discussed below.

In June 2016, the FASB issued ASU 2016-13, Measurement of Credit Losses on Financial Instruments, and issued subsequent amendments to the initial guidance within ASU 2019-04 and ASU 2019-05 (collectively, “ASU 2016-13”). The amendments in ASU 2016-13 replace the incurred loss impairment methodology in current practice with a methodology that reflects expected credit losses and requires consideration of a broader range of reasonable and supportable information to estimate credit losses. ASU 2016-13 is effective for interim and annual reporting periods beginning after December 15, 2019. The Company does not expect the adoption of ASU 2016-13 to have a material impact on its financial position, results of operations or cash flows.

In December 2019, the FASB issued ASU 2019-12, Simplifying the Accounting for Income Taxes (“ASU 2019-12”), modifying ASC 740, Income Taxes (“ASC 740”). The amendments in ASU 2019-12, among other things, remove certain exceptions to the general principles in ASC 740 and seek more consistent application by clarifying and amending the existing guidance. ASU 2019-12 is effective for interim and annual reporting periods beginning after December 15, 2020. The Company is currently evaluating the new standard, which is not expected to have a material impact on the Company’s financial position, results of operations or cash flows. 

F-15


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

2.     Consolidated Statements of Cash Flows

Below are the changes in other components of working capital, net of balances related to incremental interest acquired in a Civil segment joint venture (see Note 13), as shown in the Consolidated Statements of Cash Flows, and the supplemental disclosure of cash paid for interest and income taxes:

Year Ended December 31,

(in thousands)

2019

2018

2017

(Increase) Decrease in:

Accounts receivable

$

(81,983)

$

3,899

$

(91,062)

Retainage receivable

(78,520)

56,754

33,453

Costs and estimated earnings in excess of billings

18,751

(209,537)

(100,932)

Other current assets

(76,146)

15,398

(19,718)

(Decrease) Increase in:

Accounts payable

53,999

(78,243)

(35,751)

Retainage payable

35,013

(49,864)

3,526

Billings in excess of costs and estimated earnings

245,292

76,703

125,757

Accrued expenses and other current liabilities

14,851

28,046

24,513

Changes in other components of working capital

$

131,257

$

(156,844)

$

(60,214)

Cash paid during the year for:

Interest

$

56,137

$

51,063

$

50,443

Income taxes

$

43,374

$

13,652

$

39,776



 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 



Year Ended December 31,

(in thousands)

2018

 

2017

 

2016

(Increase) Decrease in:

 

 

 

 

 

 

 

 

Accounts receivable

$

3,899 

 

$

(91,062)

 

$

(184,549)

Retainage receivable

 

56,754 

 

 

33,453 

 

 

(85,351)

Costs and estimated earnings in excess of billings

 

(209,537)

 

 

(100,932)

 

 

73,349 

Other current assets

 

15,398 

 

 

(19,718)

 

 

39,480 

(Decrease) Increase in:

 

 

 

 

 

 

 

 

Accounts payable

 

(78,243)

 

 

(35,751)

 

 

3,025 

Retainage payable

 

(49,864)

 

 

3,526 

 

 

53,527 

Billings in excess of costs and estimated earnings

 

76,703 

 

 

125,757 

 

 

42,926 

Accrued expenses and other current liabilities

 

28,046 

 

 

24,513 

 

 

(32,937)

Changes in other components of working capital

$

(156,844)

 

$

(60,214)

 

$

(90,530)



 

 

 

 

 

 

 

 

Cash paid during the year for:

 

 

 

 

 

 

 

 

Interest

$

51,063 

 

$

50,443 

 

$

47,403 

Income taxes

$

13,652 

 

$

39,776 

 

$

26,908 

F-15


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

3.     Revenue

Disaggregation of Revenue

The following tables disaggregate revenue by end market, customer type and contract type, which the Company believes best depictsdepict how the nature, amount, timing and uncertainty of its revenue and cash flows are affected by economic factors for the yearyears ended December 31, 2019 and 2018.

Year Ended December 31,

(in thousands)

2018

Civil segment revenue by end market:

Mass transit

$

702,614 

Bridges

431,202 

Highways

202,423 

Tunneling

103,980 

Other

145,874 

Total Civil segment revenue

$

1,586,093 

Year Ended December 31,

(in thousands)

2019

2018

Civil segment revenue by end market:

Mass transit

$

992,755

$

702,614

Bridges

334,117

431,202

Tunneling

128,229

103,980

Highways

86,747

202,423

Other

237,504

145,874

Total Civil segment revenue

$

1,779,352

$

1,586,093

Year Ended December 31,

(in thousands)

2018

Building segment revenue by end market:

Health care facilities

$

428,819 

Commercial and industrial facilities

374,312 

Hospitality and gaming

301,871 

Municipal and government

261,496 

Mixed use

150,549 

Education facilities

145,147 

Mass transit

67,588 

Other

131,917 

Total Building segment revenue

$

1,861,699 

Year Ended December 31,

(in thousands)

2019

2018

Building segment revenue by end market:

Commercial and industrial facilities

$

459,806

$

374,312

Hospitality and gaming

297,700

301,871

Municipal and government

254,736

261,496

Health care facilities

239,299

428,819

Mass transit

201,400

67,588

Education facilities

143,382

145,147

Mixed use

31,685

150,549

Other

114,032

131,917

Total Building segment revenue

$

1,742,040

$

1,861,699

F-16

Year Ended December 31,

(in thousands)

2018

Specialty Contractors segment revenue by end market:

Mass transit

$

296,092 

Commercial and industrial facilities

189,632 

Mixed use

163,308 

Education facilities

99,214 

Transportation

83,551 

Multi-unit residential

81,023 

Health care facilities

52,392 

Other

41,658 

Total Specialty Contractors segment revenue

$

1,006,870 



 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 



 

Year Ended December 31, 2018



 

 

 

 

 

 

 

Specialty

 

 

 

(in thousands)

 

Civil

 

Building

 

Contractors

 

Total

Revenue by customer type:

 

 

 

 

 

 

 

 

 

 

 

 

State and local agencies

 

$

1,294,630 

 

$

617,133 

 

$

406,782 

 

$

2,318,545 

Federal agencies

 

 

95,567 

 

 

201,745 

 

 

53,335 

 

 

350,647 

Private owners

 

 

195,896 

 

 

1,042,821 

 

 

546,753 

 

 

1,785,470 

Total revenue

 

$

1,586,093 

 

$

1,861,699 

 

$

1,006,870 

 

$

4,454,662 

F-16


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Year Ended December 31,

(in thousands)

2019

2018

Specialty Contractors segment revenue by end market:

Mass transit

$

419,402

$

296,092

Commercial and industrial facilities

186,819

189,632

Multi-unit residential

83,903

81,023

Education facilities

70,229

99,214

Mixed use

64,302

163,308

Health care facilities

29,519

52,392

Transportation

7,756

83,551

Other

67,510

41,658

Total Specialty Contractors segment revenue

$

929,440

$

1,006,870

Year Ended December 31, 2019

Year Ended December 31, 2018

Specialty

Specialty

(in thousands)

Civil

Building

Contractors

Total

Civil

Building

Contractors

Total

Revenue by customer type:

State and local agencies

$

1,401,001 

$

573,049 

$

496,195 

$

2,470,245 

$

1,294,630 

$

617,133 

$

406,782 

$

2,318,545 

Federal agencies

116,869 

153,467 

11,326 

281,662 

95,567 

201,745 

53,335 

350,647 

Private owners

261,482 

1,015,524 

421,919 

1,698,925 

195,896 

1,042,821 

546,753 

1,785,470 

Total revenue

$

1,779,352 

$

1,742,040 

$

929,440 

$

4,450,832 

$

1,586,093 

$

1,861,699 

$

1,006,870 

$

4,454,662 

State and local agencies. The Company’s state and local government customers include state transportation departments, metropolitan authorities, cities, municipal agencies, school districts and public universities. Services provided to state and local customers are primarily pursuant to contracts awarded through competitive bidding processes. Construction services for state and local government customers have included mass-transit systems, tunnels, bridges, highways, judicial and correctional facilities, schools and dormitories, health care facilities, convention centers, parking structures and other municipal buildings. The vast majority of the Company’s civil contracting and building construction services are provided in locations throughout the United States and its territories.

Federal agencies. The Company’s federal government customers include the U.S. State Department, the U.S. Navy, the U.S. Army Corps of Engineers, the U.S. Air Force and the National Park Service. Services provided to federal agencies are typically pursuant to competitively bid contracts for specific or multi-year assignments that involve new construction or infrastructure repairs or improvements. A portion of revenue from federal agencies is derived from projects in overseas locations.

Private owners. The Company’s private customersowners (i.e., customers) include real estate developers, health care companies, technology companies, hospitality and gaming resort owners, Native American sovereign nations, public corporations and private universities. Services are provided to private customers through negotiated contract arrangements, as well as through competitive bids.

Most federal, state and local government contracts contain provisions that permit the termination of contracts, in whole or in part, for the convenience of government customers, among other reasons.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 2018

Year Ended December 31, 2019

Year Ended December 31, 2018

 

 

 

 

 

 

 

Specialty

 

 

 

Specialty

Specialty

(in thousands)

 

Civil

 

Building

 

Contractors

 

Total

Civil

Building

Contractors

Total

Civil

Building

Contractors

Total

Revenue by contract type:

 

 

 

 

 

 

 

 

 

 

 

 

Fixed price

 

$

1,054,473 

 

$

377,538 

 

$

857,742 

 

$

2,289,753 

$

1,315,195 

$

561,831 

$

769,410 

$

2,646,436 

$

1,054,473 

$

377,538 

$

857,742 

$

2,289,753 

Guaranteed maximum price

 

 

15,709 

 

 

1,040,093 

 

 

62,132 

 

 

1,117,934 

6,951 

752,110 

21,291 

780,352 

15,709 

1,040,093 

62,132 

1,117,934 

Unit price

 

 

469,305 

 

 

32,468 

 

 

32,562 

 

 

534,335 

436,015 

12,063 

91,803 

539,881 

469,305 

32,468 

32,562 

534,335 

Cost plus fee and other

 

 

46,606 

 

 

411,600 

 

 

54,434 

 

 

512,640 

21,191 

416,036 

46,936 

484,163 

46,606 

411,600 

54,434 

512,640 

Total revenue

 

$

1,586,093 

 

$

1,861,699 

 

$

1,006,870 

 

$

4,454,662 

$

1,779,352 

$

1,742,040 

$

929,440 

$

4,450,832 

$

1,586,093 

$

1,861,699 

$

1,006,870 

$

4,454,662 

Fixed price. Fixed price or lump sum contracts are most commonly used for projects in the Civil and Specialty Contractors segments and generally commit the Company to provide all of the resources required to complete a project for a fixed sum. Usually, fixed price contracts transfer more risk to the Company, but offer the opportunity for greater profits. Billings on fixed price contracts are typically based on estimated progress against predetermined contractual milestones.

F-17


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Guaranteed maximum price (“GMP”). GMP contracts provide for a cost plus fee arrangement up to a maximum agreed upon price. These contracts place risks on the Company for amounts in excess of the GMP, but may permit an opportunity for greater profits than under cost plus fee contracts through sharing agreements with the owner on any cost savings that may be realized. Services provided by our Building segment to various private customers are often performed under GMP contracts. Billings on GMP contracts typically occur on a monthly basis and are based on actual costs incurred plus a negotiated margin.

Unit price. Unit price contracts are most prevalent for projects in the Civil and Specialty Contractors segments and generally commit the Company to provide an estimated or undetermined number of units or components that comprise a project at a fixed price per unit. This approach shifts the risk of estimating the quantity of units required to the project owner, but the risk of increased cost per unit is borne by the Company, unless otherwise allowed for in the contract. Billings on unit price contracts typically occur on a monthly basis and are based on actual quantity of work performed or completed during the billing period.

Cost plus fee. Cost plus fee contracts are used for many projects in the Building and Specialty Contractors segments. Cost plus fee contracts include cost plus fixed fee contracts and cost plus award fee contracts. Cost plus fixed fee contracts provide for reimbursement of approved project costs plus a fixed fee. Cost plus award fee contracts provide for reimbursement of the project costs plus a base fee, as well as an incentive fee based on cost and/or schedule performance. Cost plus fee contracts serve to minimize the Company’s financial risk, but may also limit profits. Billings on cost plus fee contracts typically occur on a monthly basis based on actual costs incurred plus a negotiated margin.

Changes in Contract Estimates that Impact Revenue

Changes to the total estimated contract revenue or cost for a given project, either due to unexpected events or revisions to management’s initial estimates, for a given project are recognized in the period in which they are determined. Net revenueRevenue was negatively impacted during the year ended December 31, 2019 related to performance obligations satisfied (or partially satisfied) in prior periods by $177.5 million for various projects, none of which was individually material, except for $123.9 million that resulted from the charge related to the Alaskan Way Viaduct matter discussed in Note 8. Revenue recognized during the year ended

F-17


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

December 31, 2018 related to performance obligations satisfied (or partially satisfied) in prior periods was $19.4 million for various projects, none of which was individually material.

Remaining Performance Obligations

Remaining performance obligations represent the transaction price of firm orders for which work has not been performed and exclude unexercised contract options. As of December 31, 2019, the aggregate amounts of the transaction prices allocated to the remaining performance obligations of the Company’s construction contracts were $5.2 billion, $2.2 billion and $2.2 billion for the Civil, Building and Specialty Contractors segments, respectively. As of December 31, 2018, the aggregate amounts of the transaction prices allocated to the remaining performance obligations of the Company’s construction contracts arewere $4.6 billion, $2.3 billion and $1.7 billion for the Civil, Building and Specialty Contractors segments, respectively. The Company typically recognizes revenue on Civil segment projects over a period of three to five years, whereas for projects in the Building and Specialty Contractors segments, the Company typically recognizes revenue over a period of one to three years.

F-18


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

4.     Contract Assets and Liabilities

The Company classifies contract assets and liabilities that may be settled beyond one year from the balance sheet date as current, consistent with the length of time of the Company’s project operating cycle.

Contract assets include amounts due under retainage provisions, costs and estimated earnings in excess of billings and capitalized contract costs. The amounts as included on the Consolidated Balance Sheets consistconsisted of the following:

 

 

 

 

 

 

 

 

 

As of December 31,

 

As of January 1,

As of December 31,

(in thousands)

 

2018

 

2018

2019

2018

Retainage receivable

 

$

478,744 

 

$

535,939 

$

562,375

$

478,744

Costs and estimated earnings in excess of billings:

 

 

 

 

 

 

Claims

 

 

698,274 

 

549,849 

705,993

698,274

Unapproved change orders

 

 

354,000 

 

296,591 

362,264

354,000

Other unbilled costs and profits

 

 

90,021 

 

86,318 

55,287

90,021

Total costs and estimated earnings in excess of billings

 

 

1,142,295 

 

932,758 

1,123,544

1,142,295

Capitalized contract costs

 

 

37,404 

 

 

32,773 

80,294

37,404

Total contract assets

 

$

1,658,443 

 

$

1,501,470 

$

1,766,213

$

1,658,443

Retainage receivable represents amounts invoiced to customers where payments have been partially withheld pending the completion of certain milestones, satisfaction of other contractual conditions or the completion of the project. Retainage agreements vary from project to project and balances could be outstanding for several months or years depending on a number of circumstances, such as contract-specific terms, project performance and other variables that may arise as the Company makes progress towards completion. As of December 31, 2018,2019, the amount of retainage receivablesreceivable estimated by management to be collected or remitted beyond one year is approximately 29%39% of the balance.

Costs and estimated earnings in excess of billings represent the excess of contract costs and profits (or contract revenue) over the amount of contract billings to date and are classified as a current asset. Costs and estimated earnings in excess of billings result when either: 1)(1) the appropriate contract revenue amount has been recognized over time in accordance with ASC 606, but a portion of the revenue recorded cannot be billed currently due to the billing terms defined in the contract, or 2)(2) costs are incurred related to certain claims and unapproved change orders. Claims occur when there is a dispute regarding both a change in the scope of work and the price associated with that change. Unapproved change orders occur when a change in the scope of work results in additional work being performed before the parties have agreed on the corresponding change in the contract price. The Company routinely estimates recovery related to claims and unapproved change orders as a form of variable consideration at the most likely amount it expects to receive and to the extent it is probable that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is resolved. Claims and unapproved change orders are billable upon the agreement and resolution between the contractual parties and after the execution of contractual amendments. Increases in claims and unapproved change orders typically result from costs being incurred against existing or new positions; decreases normally result from resolutions and subsequent billings. As discussed in Note 8, the resolution of these claims and unapproved change orders may require litigation or other forms of dispute resolution proceedings. Other unbilled costs and profits are billable in accordance with the billing terms of each of the existing contractual arrangements and, as such, the timing of contract billing cycles can cause fluctuations in the balance of unbilled costs and profits. Ultimate resolution of other unbilled costs and profits typically involves incremental progress toward contractual requirements or milestones. The amount of costs and estimated earnings in excess of billings as of December 31, 20182019 estimated by management to be collected beyond one year is approximately $529.3$572.1 million.

Capitalized contract costs primarily represent costs to fulfill a contract that (1) directly relate to an existing or anticipated contract, (2) generate or enhance resources that will be used in satisfying performance obligations in the future and (3) are expected to be recovered through the contract, and are included in other current assets. Capitalized contract costs are generally expensed to the associated

F-18


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

contract over the period of anticipated use on the project. During the year ended December 31, 2019 and 2018, $33.8 million and $16.3 million, respectively, of previously capitalized contract costs were amortized and recognized as expense on the related contracts.

F-19


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Contract liabilities include amounts owed under retainage provisions and billings in excess of costs and estimated earnings. The amount as reported on the Consolidated Balance Sheets consistsconsisted of the following:

 

 

 

 

 

 

 

 

 

As of December 31,

 

As of January 1,

As of December 31,

(in thousands)

 

 

2018

 

 

2018

2019

2018

Retainage payable

 

$

211,956 

 

$

261,820 

$

252,181

$

211,956

Billings in excess of costs and estimated earnings

 

573,190 

 

496,654 

844,389

573,190

Total contract liabilities

 

$

785,146 

 

$

758,474 

$

1,096,570

$

785,146

Retainage payable represents amounts invoiced to the Company by subcontractors where payments have been partially withheld pending the completion of certain milestones, other contractual conditions or upon the completion of the project. Generally, retainage payable is not remitted to subcontractors until the associated retainage receivable from customers is collected. As of December 31, 2018,2019, the amount of retainage payablespayable estimated by management to be collected or remitted beyond one year is approximately 24%28% of the balance.

Billings in excess of costs and estimated earnings represent the excess of contract billings to date over the amount of contract costs and profits (or contract revenue) recognized to date. The balance may fluctuate depending on the timing of contract billings and the recognition of contract revenue. Revenue recognized during the year ended December 31, 2019 and 2018 and included in the opening billings in excess of costs and estimated earnings balances totaled $479.6 million and $382.7 million.million, respectively.

5.     Income Taxes

Income (loss) before taxes is summarized as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

 

2018

 

2017

 

2016

2019

2018

2017

United States operations

 

$

106,222 

 

$

135,177 

 

$

128,072 

$

(456,403)

$

106,222

$

135,177

Foreign and U.S. territory operations

 

26,391 

 

18,798 

 

21,043 

30,569

26,391

18,798

Total

 

$

132,613 

 

$

153,975 

 

$

149,115 

$

(425,834)

$

132,613

$

153,975

The income tax (benefit) expense (benefit) is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

 

2018

 

2017

 

2016

2019

2018

2017

Current expense:

 

 

 

 

 

 

Federal

 

$

21,055 

 

$

12,329 

 

$

43,850 

$

(2,884)

$

21,055

$

12,329

State

 

 

8,676 

 

6,763 

 

13,039 

3,585

8,676

6,763

Foreign and U.S. territories

 

 

5,550 

 

3,435 

 

6,573 

5,299

5,550

3,435

Total current expense

 

 

35,281 

 

22,527 

 

63,462 

6,000

35,281

22,527

 

 

 

 

 

 

 

Deferred expense (benefit):

 

 

 

 

 

 

Deferred (benefit) expense:

Federal

 

 

(1,773)

 

(30,021)

 

(3,054)

(43,579)

(1,773)

(30,021)

State

 

 

1,278 

 

5,560 

 

(5,302)

(27,566)

1,278

5,560

Foreign and U.S. territories

 

 

46 

 

1,365 

 

(1,813)

(464)

46

1,365

Total deferred expense (benefit)

 

 

(449)

 

(23,096)

 

(10,169)

Total expense (benefit)

 

$

34,832 

 

$

(569)

 

$

53,293 

Total deferred (benefit) expense

(71,609)

(449)

(23,096)

Total (benefit) expense

$

(65,609)

$

34,832

$

(569)

F-20

F-19


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table is a reconciliation of the Company’s income tax provision at the statutory rates to the income tax (benefit) expense (benefit) at the Company’s effective rate:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

 

2018

 

2017

 

2016

2019

2018

2017

(dollars in thousands)

 

Amount

 

Rate

 

Amount

 

Rate

 

Amount

 

Rate

Amount

Rate

Amount

Rate

Amount

Rate

Federal income tax expense at statutory tax rate

 

$

27,849 

 

21.0 

%

 

$

53,892 

 

35.0 

%

 

$

52,190 

 

35.0 

%

Federal income tax (benefit) expense at statutory tax rate

$

(89,425)

21.0

%

$

27,849

21.0

%

$

53,892

35.0

%

State income taxes, net of federal tax benefit

 

9,011 

 

6.8 

 

 

7,753 

 

5.0 

 

 

4,614 

 

3.1 

 

(18,442)

4.3

9,011

6.8

7,753

5.0

Stock based compensation

1,706

(0.4)

Impact of federal tax law change

 

211 

 

0.2 

 

 

(53,348)

 

(34.6)

 

 

 —

 

 —

 

211

0.2

(53,348)

(34.6)

Officers' compensation

 

3,078 

 

2.3 

 

 

2,622 

 

1.7 

 

 

3,807 

 

2.6 

 

2,938

(0.7)

3,078

2.3

2,622

1.7

Goodwill impairment

43,990

(10.3)

Domestic production activities deduction

 

 —

 

 —

 

 

(2,668)

 

(1.7)

 

 

(4,018)

 

(2.7)

 

(2,668)

(1.7)

Noncontrolling interest

 

(3,232)

 

(2.4)

 

 

(2,137)

 

(1.4)

 

 

 —

 

 —

 

Noncontrolling interests

(6,064)

1.4

(3,232)

(2.4)

(2,137)

(1.4)

Federal R&D credits

 

(2,658)

 

(2.0)

 

 

(470)

 

(0.4)

 

 

(669)

 

(0.5)

 

(3,998)

0.9

(2,658)

(2.0)

(470)

(0.4)

Reversal of reserve for uncertain tax positions and taxes payable due to statute expirations

 

(1,958)

 

(1.5)

 

 

(4,337)

 

(2.8)

 

 

 —

 

 —

 

(773)

0.2

(1,958)

(1.5)

(4,337)

(2.8)

Foreign tax differences

4,940

(1.2)

(19)

(389)

(0.3)

Other

 

2,531 

 

1.9 

 

 

 

(1,876)

 

(1.2)

 

 

 

(2,631)

 

(1.8)

 

(481)

0.2

2,550

1.9

(1,487)

(0.9)

Income tax expense (benefit)

 

$

34,832 

 

26.3 

%

 

$

(569)

 

(0.4)

%

 

$

53,293 

 

35.7 

%

Income tax (benefit) expense

$

(65,609)

15.4

%

$

34,832

26.3

%

$

(569)

(0.4)

%

The Company’s provision for income taxes and effective tax rate for the year ended December 31, 2019 was significantly impacted by the goodwill impairment charge discussed in Note 6. Of the total goodwill impairment charge of $379.9 million, approximately $209.5 million pertained to goodwill that is not tax deductible and yielded permanent differences between book income and taxable income. For the year ended December 31, 2019, the Company recognized U.S. federal and state tax benefits totaling $49.4 million as a result of the impairment charge.

On December 22, 2017, the U.S. government enacted the TCJATax Cuts and Jobs Act of 2017 (“TCJA”) which made broad and complex changes to the U.S. tax code that impact the Company’s financial statements, including, but not limited to, a permanent decrease in the corporate federal statutory income tax rate from 35% to 21%, effective January 1, 2018, and a one-time transition tax from the inclusion of foreign earnings. Future distributions from foreign subsidiaries, however, are no longer subject to federal income tax.

As a result of the TCJA, the Company recognized an income tax benefit of $53.3 million in 2017, primarily due to the remeasurement of deferred tax assets and liabilities based on the reduced corporate federal statutory income tax rate of 21%.

F-21

In accordance with ASU 2018-05, the Company recorded a provisional amount for its one-time transition tax liability in 2017 which was not material. As


The following is a summary of the significant components of the deferred tax assets and liabilities:

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

 

2018

 

2017

2019

2018

Deferred tax assets:

 

 

 

 

Timing of expense recognition

 

$

20,832 

 

$

22,730 

$

44,761

$

20,832

Net operating losses

 

8,611 

 

8,590 

23,711

8,611

Goodwill

26,658

Other, net

 

18,828 

 

15,618 

17,098

18,828

Deferred tax assets

 

 

48,271 

 

46,938 

112,228

48,271

Valuation allowance

 

 

(1,150)

 

(381)

(2,212)

(1,150)

Net deferred tax assets

 

 

47,121 

 

46,557 

110,016

47,121

Deferred tax liabilities:

 

 

 

 

Intangible assets, due primarily to purchase accounting

 

(36,862)

 

(30,019)

(15,309)

(36,862)

Fixed assets, due primarily to purchase accounting

 

(75,998)

 

(73,833)

(75,461)

(75,998)

Construction contract accounting

 

(9,435)

 

(17,539)

(13,464)

(9,435)

Joint ventures

 

(9,853)

 

(11,343)

(24,331)

(9,853)

Other

 

(20,411)

 

(22,263)

(16,567)

(20,411)

Deferred tax liabilities

 

 

(152,559)

 

(154,997)

(145,132)

(152,559)

 

 

 

 

 

Net deferred tax liabilities

 

$

(105,438)

 

$

(108,440)

$

(35,116)

$

(105,438)

TheAs of December 31, 2019, the Company had federal and various state net operating loss carryforwards in variousfor income tax purposes of $29.3 million and $184.8 million, respectively. Federal net operating loss carryforwards do not have expiration dates, whereas the state tax jurisdictions totaling approximately $93.9 million as of December 31, 2018, withnet operating loss carryforwards have expiration dates ranging from 20202022 to 2035.2038. As of December 31, 2019, the Company has federal and state credit carryforwards for income tax purposes of approximately $6.0 million and $1.2 million, respectively.

F-20


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The net deferred The netdeferredtax liabilities liabilitiesare presented in the Consolidated BalanceintheConsolidatedBalance Sheets as follows:

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

 

2018

 

2017

2019

2018

Deferred tax assets

 

$

83 

 

$

64 

$

570

$

83

Deferred tax liabilities

 

(105,521)

 

(108,504)

(35,686)

(105,521)

Net deferred tax liabilities

 

$

(105,438)

 

$

(108,440)

$

(35,116)

$

(105,438)

Prior to 2017, the Company did not provide for deferred income taxes or foreign withholding tax on basis differences in its non-U.S. subsidiaries that result from undistributed earnings which the Company had the intent and the ability to reinvest in its foreign operations. Due toSince the enactment of the TCJA, the Company no longer intends to permanently reinvest in its foreign subsidiaries. Consequently, the Company now provides deferred income taxes and foreign withholding taxes related to its foreign subsidiaries.

The Company’s policy is to record interest and penalties on unrecognized tax benefits as an element of income tax expense. The cumulative amounts related to interest and penalties are added to the total unrecognized tax liabilities on the balance sheet. The total amount of gross unrecognized tax benefits as of December 31, 20182019 that, if recognized, would affect the effective tax rate is $5.0$5.7 million. During 2018, the Company recognized a net decrease of $1.5 million in liabilities. The amount of gross unrecognized tax benefits as of December 31, 2017 was $6.5 million. During 2017, the Company recognized a net decrease of $1.1 million in liabilities. The amount of gross unrecognized tax benefits as of December 31, 2016 was $7.6 million. During 2016, the Company recognized a net increase of $4.0 million in liabilities. The Company does not expect any significant release of unrecognized tax benefits within the next twelve months.

The Company accounts for its uncertain tax positions in accordance with GAAP. The following is a reconciliation of the beginning and ending amounts of these unrecognized tax benefits for the three years ended December 31, 20182019:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

 

2018

 

2017

 

2016

2019

2018

2017

Beginning balance

 

$

6,495 

 

$

7,574 

 

$

3,612 

$

4,998

$

6,495

$

7,574

Change in tax positions of prior years

 

 

(302)

 

(1,207)

 

 

3,543 

351

(302)

(1,207)

Change in tax positions of current year

 

 

763 

 

128 

 

 

419 

1,106

763

128

Reduction in tax positions for statute expirations

 

 

(1,958)

 

 —

 

 

 —

(773)

(1,958)

Ending Balance

 

$

4,998 

 

$

6,495 

 

$

7,574 

$

5,682

$

4,998

$

6,495

The Company conducts business internationally and, as a result, one or more of its subsidiaries files income tax returns in U.S. federal, U.S. state and certain foreign jurisdictions. Accordingly, in the normal course of business, the Company is subject to examination by taxing authorities principally throughout the United States, Guam and Canada. The Company is no longer subject to examination by the taxing authority regarding anya U.S. federal income tax returns

F-22


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

audit for fiscal years before 2014 while2016 and later, although there is currently no audit being conducted by the Internal Revenue Service. The Company has various years open for examination under certainto audit in a number of state and local jurisdictions vary.and is currently under audit by certain state taxing authorities.

6.     Goodwill and Other Intangible Assets

Goodwill

The following table presents the changes in the carrying amount of goodwill since its inception through December 31, 2019:

Specialty

(in thousands)

Civil

Building

Contractors

Total

Gross goodwill

$

492,074

$

424,724

$

156,193

$

1,072,991

Accumulated impairment

(76,716)

(411,269)

(487,985)

Balance as of December 31, 2018

415,358

13,455

156,193

585,006

Second quarter 2019 impairment

(210,215)

(13,455)

(156,193)

(379,863)

Balance as of December 31, 2019(a)

$

205,143

$

$

$

205,143

_____________________________________________________________________________________________________________

(a)As of December 31, 2018, 2017 and 2016,2019, accumulated impairment was $867.8 million.

The net change in the carrying amount of goodwill for the year ended December 31, 2019 was primarily due to a goodwill impairment charge of $379.9 million recorded in the second quarter of 2019. In connection with the preparation of its quarterly financial statements during the second quarter of 2019, the Company assessed the changes in circumstances that occurred during the quarter to determine whether it was more likely than not that the fair values of any of its reporting units were below their carrying amounts. While there was no single determinative event or factor, potential triggering events identified in the accounting guidance (ASC 350, Intangibles – Goodwill and Other) developed during the second quarter of 2019, which led the Company to conclude that, when considering the events and factors in totality, it was more likely than not that the fair values of each of its reporting units were below their carrying amounts. The triggering factors included:

The Company faced a declining stock price and observed a sustained decrease subsequent to the filing of the Company’s first quarter Form 10-Q on May 8, 2019, in both absolute terms and relative to its peers. Consistent with the average stock prices of companies in its peer group, the Company’s stock price had $585.0 millionbeen trending lower over several prior periods; however, during the second quarter of goodwill allocated2019, the Company’s stock price dropped to a 52-week low while the average stock price of companies in its peer group increased. The Company believes that delays experienced in resolving certain claims and unapproved change orders, which when combined with the increased working capital needs and significant negative operating cash flows in the first quarter of 2019, has contributed significantly to the sustained decrease in the Company’s stock price;

The Company experienced significant negative operating cash flows from each of its reporting units in the first quarter of 2019, and that trend continued at the beginning of the second quarter; and

The Company’s debt rating was downgraded by a major credit rating agency on May 17, 2019.

As the Company determined that it was more likely than not that the fair values of its reporting units were below their carrying amounts, the Company performed an interim impairment test as of June 1, 2019 (the “Interim Test”) and, as described below, recognized a non-cash impairment loss totaling $379.9 million.

The decrease in the Company’s stock price reduced its total market capitalization and increased the implied control premium to a level beyond observable market-comparable data. As a result, when performing the Interim Test, the Company increased the discount rates and the projected investments in working capital compared to the assumptions used in the previous October 1, 2018 test, which extended the timing of certain expected future cash flows in the calculation of fair value under the income-based approach. The Company believes these changes were consistent with market participant inputs as reflected in the decrease in the Company’s market valuation at that time.

Consistent with the previous October 1, 2018 test, the Company utilized a weighted-average of (1) an income approach and (2) a market approach to determine the fair value of the Company and each of its reporting units for the Interim Test. The income approach was based on estimated present value of future cash flows for each reporting unit. The market approach was based on assumptions about how market data relates to each reporting unit. The weighting of these two approaches was based on their individual correlation to the economics of each reporting unit as impacted by factors such as the availability of comparable market data for each reporting unit.

F-23


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Assessing impairment inherently involves management judgments as to the assumptions used to calculate fair value of the reporting units and the impact of market conditions on those assumptions. The key inputs that the Company uses in its assumptions to estimate the fair value of its reporting units under the income-based approach are as follows:

Weighted-average cost of capital (“WACC”), the risk-adjusted rate used to discount the projected cash flows;

Cash flows generated from existing work and new awards; and

Projected operating margins.

Expected future after-tax operating cash flows of each reporting unit are discounted to a present value using a risk-adjusted discount rate. Estimates of future cash flows require management to make significant assumptions concerning future operating performance including cash flows generated from existing work and new awards, projected operating margins, variations in the amount and timing of cash flows and the probability of achieving the estimated cash flows, as well as future economic conditions, which may differ from actual future cash flows. The discount rate, which is intended to reflect the risks inherent in future cash flow projections, used in estimating the present value of future cash flows, is based on estimates of the WACC of market participants relative to the reporting units. Financial and credit market volatility can directly impact certain inputs and assumptions used to develop the WACC.

To develop the cash flows generated from new awards and future operating margins, the Company tracks known prospects of significance for each of its reporting units and considers the estimated timing of when the work is expected to be bid, started and completed. The Company also gives consideration to its relationships with the prospective owners; the pool of competitors that are capable of performing large, complex work; business strategy; and the Company’s history of success in winning new work in each reporting unit. With regard to operating margins, the Company gives consideration to its historical reporting unit operating margins in the end markets that the prospective work opportunities are most significant, expected margins from existing work, current market trends in recent new work procurement, and business strategy.

The Company also estimated the fair value of its reporting units under a market-based approach by applying industry-comparable multiples of revenues and operating earnings to its reporting units’ revenues and operating earnings. The conditions and prospects of companies in the engineering and construction industry depend on common factors such as overall demand for services.

The Company believes that the discount rates, timing of cash flows and other inputs and assumptions used in the Interim Test were consistent with those that a market participant would use based on the events described above which occurred during the second quarter of 2019 and were reflective of the market assessment of the fair value of its reporting units at that time. In addition, the Company believes that its estimates and assumptions about future revenues and margin projections in the Interim Test were reasonable and consistent with the estimates and assumptions used in the annual goodwill impairment test as of October 1, 2018. As an additional step to corroborate the Interim Test results, the Company compared its implied control premium with those of recent comparable market transactions and concluded that the implied control premium was within the range of control premiums observed in prior industry-specific M&A transactions.

The assumption changes described above were relatively larger in the Specialty Contractors reporting unit than in the Civil or Building reporting units, as follows: Civil, $415.3 million; Building, $13.5 million; and Specialty Contractors $156.2 million. The balances presented include historical accumulatedhad not met recent market expectations at the time of the Interim Test.

Subsequent to the Interim Test, the Company performed its annual impairment test in the fourth quarter of $76.7 million for2019 using a weighted-average of an income and a market approach. These approaches utilize various valuation assumptions, and small changes to the assumptions could have a significant impact on the concluded fair value. Based on this assessment, the Company concluded goodwill was not impaired since the estimated fair value of the Civil reporting unit and $411.3 million for the Building reporting unit.

exceeded its carrying value; therefore, no further adjustment to goodwill was necessary. In addition, asno events or circumstances have occurred since the annual test that would indicate any additional impairment of goodwill.

Intangible Assets

As of December 31, 20182019 and 2017,2018, the Company had the following: (1) non-amortizable trade names with a carrying value of $50.4 million; (2) amortizable trade names with a gross carrying value of $51.1 million and accumulated amortization as of December 31, 2019 and 2018 of $21.3 million and 2017 of $18.8 million, and $16.3 million, respectively; and (3) amortizable customer relationships with a gross carrying value of $23.2 million and accumulated amortization as of December 31, 2019 and 2018 and 2017 of $20.0$21.0 million and $18.9$20.0 million, respectively; and (4) amortizable construction contract backlog with a gross carrying value as of December 31, 2019 and 2018 of $149.3 million and $73.7 million, respectively, and accumulated amortization as of December 31, 2019 and 2018 of $76.4 million and $73.7, respectively. The increase in amortizable construction contract backlog of $75.6 million is due to the acquisition of an additional interest in a joint venture, as discussed in Note 13.

F-24


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Amortization expense related to amortizable intangible assets was $6.2 million and $3.5 million for each of the years ended December 31, 2019 and 2018, 2017 and 2016. respectively. Future amortization expense related to amortizable intangible assets for the years 2020, 2021 and 2022 will be approximately $3.5$31.2 million, per year for the years 2019 through 2021, $2.6$31.1 million for the year 2022and $20.2 million, respectively, and $2.5 million for the year 2023.years 2023 and 2024.

The weighted-average amortization period for amortizable trade names, and customer relationships and construction contract backlog is approximately 20 years, and 12 years and 3 years, respectively.

In conjunction with its Interim Test for goodwill during the second quarter of 2019, the Company also evaluated its non-amortizable trade names for potential impairment due to the second quarter triggering factors related to goodwill mentioned above. The Company performed its interim impairment test by comparing the carrying value of its indefinite-lived intangible assets to their calculated fair value, which is determined by the income approach (relief from royalty method). This income-based valuation approach involves similar key assumptions to the goodwill impairment analysis discussed above. The interim impairment test performed in the second quarter of 2019 resulted in an estimated fair value for the non-amortizable trade names that substantially exceeded their respective net book values; therefore, no impairment charge was necessary for the second quarter. While the key assumptions used in the impairment test of the non-amortizable trade names are similar to those used in the evaluation of goodwill, historically, the headroom (the excess of calculated fair value over carrying value) has been relatively higher for non-amortizable trade names than for goodwill. Unlike goodwill, trade names possess inherent value based on market perception which is valued considering the cost savings available through ownership and the avoidance of paying royalties associated with revenue generation. The discounted value is not impacted by cash flow related assumptions such as working capital investment. Consequently, goodwill was impaired while the non-amortizable trade name intangible assets were not.

F-21


TableThe Company also performed an annual impairment assessment of Contentsits non-amortizable trade names in the fourth quarter of 2019 using a qualitative approach to determine whether conditions existed to indicate that it is more likely than not that the fair value of trade names is less than their carrying values. Based on this assessment, the Company concluded that it was more likely than not that the fair value of the non-amortizable trade names was greater than their carrying values, and therefore a quantitative analysis was not required.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

7.     Financial Commitments

Long-Term Debt

Long-term debt consisted of the following as of the dates ofreported on the Consolidated Balance Sheets presented:consisted of the following:

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

2017 Senior Notes

$

493,521 

 

$

492,734 

$

494,365

$

493,521

2017 Credit Facility

114,000

41,000

Convertible Notes

 

171,481 

 

161,635 

182,292

171,481

2017 Credit Facility

 

41,000 

 

 

 —

Equipment financing and mortgages

 

50,904 

 

76,820 

39,159

50,904

Other indebtedness

 

4,598 

 

5,087 

4,660

4,598

Total debt

 

761,504 

 

736,276 

834,476

761,504

Less: Current maturities

 

16,767 

 

30,748 

124,054

16,767

Long-term debt, net

$

744,737 

 

$

705,528 

$

710,422

$

744,737

The following table reconciles the outstanding debt balance to the reported debt balances as of December 31, 20182019 and 2017:2018:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31, 2018

 

As of December 31, 2017

As of December 31, 2019

As of December 31, 2018

(in thousands)

Outstanding Long-Term Debt

 

Unamortized Discount and Issuance Costs

 

Long-Term

Debt,

as reported

 

Outstanding Long-Term Debt

 

Unamortized Discounts and Issuance Costs

 

Long-Term Debt,
as reported

Outstanding Long-Term Debt

Unamortized Discount and Issuance Costs

Long-Term

Debt,

as reported

Outstanding Long-Term Debt

Unamortized Discount and Issuance Costs

Long-Term Debt,
as reported

2017 Senior Notes

$

500,000 

 

$

(6,479)

 

$

493,521 

 

$

500,000 

 

$

(7,266)

 

$

492,734 

$

500,000

$

(5,635)

$

494,365

$

500,000

$

(6,479)

$

493,521

Convertible Notes

 

200,000 

 

(28,519)

 

171,481 

 

200,000 

 

(38,365)

 

161,635 

200,000

(17,708)

182,292

200,000

(28,519)

171,481

The unamortized issuance costs related to the 2017 Credit Facility were $4.8$3.7 million and $6.2$4.8 million as of December 31, 20182019 and 2017,2018, respectively, and are included in other assets in the Consolidated Balance Sheets.

F-25


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

2017 Senior Notes

On April 20, 2017, the Company issued $500 million in aggregate principal amount of 6.875% Senior Notes due 2025 (the “2017 Senior Notes”) in a private placement offering. Interest on the 2017 Senior Notes is payable in arrears semi-annually in May and November of each year, beginning in November 2017.

Prior to May 1, 2020, the Company may redeem the 2017 Senior Notes at a redemption price equal to 100% of their principal amount plus a “make-whole” premium described in the indenture. In addition, prior to May 1, 2020, the Company may redeem up to 40% of the original aggregate principal amount of the notes at a redemption price of 106.875% of their principal amount with the proceeds received by the Company from any offering of the Company’s equity. After May 1, 2020, the Company may redeem the 2017 Senior Notes at specified redemption prices described in the indenture. Upon a change of control, holders of the 2017 Senior Notes may require the Company to repurchase all or part of the 2017 Senior Notes at 101% of the principal amount thereof, plus accrued and unpaid interest to the redemption date.

The 2017 Senior Notes are senior unsecured obligations of the Company and are guaranteed by substantially all of the Company’s existing and future subsidiaries that also guarantee obligations under the Company’s 2017 Credit Facility, as defined below. In addition, the indenture for the 2017 Senior Notes provides for customary covenants, including events of default and restrictions on the payment of dividends and share repurchases.

2017 Credit Facility

On April 20, 2017, the Company entered into a credit agreement (the “2017 Credit Facility”) with SunTrust Bank, now known as Truist Bank, as Administrative Agent, Swing Line Lender and L/C Issuer and a syndicate of other lenders. The 2017 Credit Facility provides for a $350 million revolving credit facility (the “2017 Revolver”) and a sublimit for the issuance of letters of credit and swingline loans up to the aggregate amount of $150 million and $10 million, respectively, both maturing on April 20, 2022 unless any of the Convertible Notes, as defined below, are outstanding on December 17, 2020, in which case all such borrowings will mature on December 17, 2020, (subject to certain further exceptions). In addition,provided that (i) if the Convertible Notes are refinanced in full with the proceeds of permitted refinancing indebtedness in accordance with the terms of the 2017 Credit Facility, the maturity date for the 2017 Credit Facility will remain April 20, 2022 and (ii) if the Company issues “New Convertible Notes” (as defined in the 2017 Credit Facility), the maturity date for the 2017 Credit Facility will be the earlier of (x) April 20, 2022 or December 17, 2020 if Convertible Notes are outstanding on December 17, 2020 and (y) 90 days prior to the maturity date for such New Convertible Notes. The 2017 Credit Facility also permits additional borrowings in an aggregate amount of $150 million, which can be in the form of increased capacity on the 2017 Revolver or the establishment of one or more term loans.

F-22


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Borrowings under the 2017 Revolver bear interest, at the Company’s option, at a rate equal to (a) the London Interbank Offered Rate (“LIBOR”) plus a margin of between 1.50% and 3.00% or (b) a base rate (determined by reference to the highest of (i) the administrative agent’s prime lending rate, (ii) the federal funds effective rate plus 50 basis points, (iii) the LIBOR rate for a one-month interest period plus 100 basis points and (iv) 0%), plus a margin of between 0.50% and 2.00%, in each case based on the Consolidated Leverage Ratio (as defined in the 2017 Credit Facility). In addition to paying interest on outstanding principal under the 2017 Credit Facility, the Company will pay a commitment fee to the lenders under the 2017 Revolver in respect of the unutilized commitments thereunder. The Companywill pay customary letter of credit fees. If an event of default occurs and is continuing, the otherwise applicable margin and letter of credit fees will be increased by 2% per annum. The weighted-average annual interest rate on borrowings under the 2017 Revolver was approximately 4.77%4.96% during the year ended December 31, 2018.2019.

The 2017 Credit Facility contains customary covenants for credit facilities of this type, including maximum consolidated leverage ratios ranging from 4.00:1.00 to 3.25:1.00 over the life of the facility and a minimum consolidated fixed charge coverage ratio of 1.25:1.00. On May 7, 2019, certain provisions of the 2017 Credit Facility were amended, including setting the maximum leverage ratio at 3.50:1.00 for the remainder of its term, thus eliminating the step down from 3.50:1:00 to 3.25:1.00. Substantially all of the Company’s subsidiaries unconditionally guarantee the obligations of the Company under the 2017 Credit Facility; additionally, the obligations are secured by a lien on all personal property of the Company and its subsidiaries guaranteeing these obligations.

As of December 31, 2018,2019, there was $309$236 million available under the 2017 Revolver, and the Company had not utilized the 2017 Credit Facility for letters of credit. The Company was in compliance with the financial covenants under the 2017 Credit Facility as of December 31, 2018.2019.

Repurchase and RedemptionAs a result of Notes and Termination ofthe aforementioned provision in the 2017 Credit Facility

On whereby the maturity date of the 2017 Credit Facility may be moved forward from April 20, 2017,2022, the facility will mature on December 17, 2020 if the Convertible Notes remain outstanding at that time (the “spring-forward” provision). While the Company used proceeds fromdoes not have call rights that allow it to unilaterally redeem the 2017 Senior

F-26


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Convertible Notes, and 2017 Revolverit intends to repurchase or redeemexchange the Convertible Notes and/or modify or replace the 2017 Credit Facility during 2020. Various alternatives are under consideration to determine the financing arrangement that is best suited to the Company’s needs and provides the most favorable terms. The Company is currently in discussions with lenders regarding its previously outstanding senior notes ($300 millionoptions. Due to the spring-forward provision in the 2017 Credit Facility, all borrowings under the facility are included in “Current maturities of 7.625% Senior Notes due November 1, 2018), to pay off and terminate its previous credit facility ($300 million revolving credit facility and a $250 million term loan, both maturinglong-term debt” on May 1, 2018), and to pay accrued but unpaid interest and fees.the Consolidated Balance Sheet as of December 31, 2019.

Convertible Notes

On June 15, 2016, the Company issued $200 million of 2.875% Convertible Senior Notes due June 15, 2021 (the “Convertible Notes”) in a private placement offering. The Convertible Notes are unsecured obligations of the Company and do not contain any financial covenants or restrictions on the payments of dividends, the incurrence of indebtedness or the issuance or repurchase of securities by the Company. The Convertible Notes bear interest at a rate of 2.875% per year, payable in cash semi-annually in June and December.

To account for the Convertible Notes, the Company applied the provisions of ASC 470-20, Debt with Conversion and Other Options (“ASC 470-20”). ASC 470-20 requires issuers of certain convertible debt instruments that may be settled in cash upon conversion to separately account for the liability (debt) and equity (conversion option) components of the instrument in a manner that reflects the issuer’s nonconvertible debt borrowing rate. This is done by allocating the proceeds from issuance to the liability component based on the fair value of the debt instrument excluding the conversion feature, with the residual allocated to the equity component and classified in additional paid in capital. The $46.8 million difference between the principal amount of the Convertible Notes ($200.0 million) and the proceeds initially allocated to the liability component ($153.2 million) is treated as a discount on the Convertible Notes. This difference is being amortized as non-cash interest expense using the interest method, as shown below under Interest Expense. The equity component, however, is not subject to amortization nor subsequent remeasurement.

In addition, ASC 470-20 requires that the debt issuance costs associated with a convertible debt instrument be allocated between the liability and equity components in proportion to the allocation of the debt proceeds between these two components. The debt issuance costs attributable to the liability component of the Convertible Notes ($5.1 million) are also treated as a discount on the Convertible Notes and amortized as non-cash interest expense. The debt issuance costs attributable to the equity component ($1.5 million) were netted with the equity component and are not amortized.

F-23


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table presents information related to the liability and equity components of the Convertible Notes:

 

 

 

 

(in thousands)

December 31,

2018

 

December 31,

2017

December 31,

2019

December 31,

2018

Liability component:

 

 

 

 

 

Principal

$

200,000 

 

$

200,000 

$

200,000

$

200,000

Conversion feature

 

(46,800)

 

(46,800)

(46,800)

(46,800)

Allocated debt issuance costs

 

(5,051)

 

(5,051)

(5,051)

(5,051)

Amortization of discount and debt issuance costs (non-cash interest expense)

 

23,332 

 

13,486 

34,143

23,332

Net carrying amount

$

171,481 

 

$

161,635 

$

182,292

$

171,481

 

 

 

 

Equity component:

 

 

 

 

Conversion feature

$

46,800 

 

$

46,800 

$

46,800

$

46,800

Allocated debt issuance costs

 

(1,543)

 

(1,543)

(1,543)

(1,543)

Deferred taxes

 

(18,815)

 

(18,815)

(18,815)

(18,815)

Net carrying amount

$

26,442 

 

$

26,442 

$

26,442

$

26,442

Prior to January 15, 2021, the Convertible Notes will be convertible only under the following circumstances: (1) during the five business day period after any ten10 consecutive trading day period in which the trading price per $1,000 principal amount of Convertible Notes for such trading day was less than 98% of the product of the last reported sale price of the Company’s common stock and the conversion rate on each such trading day; (2) if the last reported sale price of the common stock for at least 20 trading days (whether or not consecutive) during a period of 30 consecutive trading days ending on the last trading day of the immediately preceding calendar quarter is greater than or equal to 130% of the conversion rate of 33.0579 (or $39.32) on each applicable trading day; or (3) upon the occurrence of specified corporate events. On or after January 15, 2021 until the close of business on the second scheduled trading day immediately preceding the maturity date, holders may convert all or any portion of their notes, in multiples of $1,000 principal amount, at the option of the holder regardless of the foregoing circumstances.

The Convertible Notes will be convertible at an initial conversion rate of 33.0579 shares of the Company’s common stock per $1,000 principal amount of the Convertible Notes, which is equivalent to an initial conversion price of approximately $30.25. The conversion

F-27


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

rate will be subject to adjustment for some events but will not be adjusted for any accrued and unpaid interest. In addition, following certain corporate events that occur prior to the maturity date, the Company is required to increase, in certain circumstances, the conversion rate for a holder who elects to convert their Convertible Notes in connection with such a corporate event including customary conversion rate adjustments in connection with a “make-whole fundamental change” described in the indenture. Upon conversion, and at the Company’s election, the Company may satisfy its conversion obligation with cash, shares of its common stock or a combination thereof. As of December 31, 2018,2019, the conversion provisions of the Convertible Notes have not been triggered.

Equipment Financing and Mortgages

The Company has certain loans entered into for the purchase of specific property, plant and equipment and secured by the assets purchased. The aggregate balance of equipment financing loans was approximately $38.6$27.7 million and $61.1$38.6 million at December 31, 20182019 and 2017,2018, respectively, with interest rates ranging from 2.19%2.62% to 3.38%3.89% with equal monthly installment payments over periods up to ten years with additional balloon payments of $12.4 million in 2021 and $6.3 million in 2022 on the remaining loans outstanding at December 31, 2018.2019. The aggregate balance of mortgage loans was approximately $12.3$11.5 million and $15.7$12.3 million at December 31, 20182019 and 2017,2018, respectively, with interest rates ranging from a fixed 3.50% to LIBOR plus 3% and equal monthly installment payments over periods up to ten years with additional balloon payments of $2.9 million in 2021 and $7.0 million in 2023.

F-24


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table presents the future principal payments required under all of the Company’s debt obligations, discussed above:

 

 

 

 

 

 

Year (in thousands)

 

 

2019

 

$

16,817 

2020

 

 

46,275 

$

124,054

2021

 

 

218,875 

218,967

2022

 

 

7,457 

7,546

2023

 

 

7,078 

7,164

2024

88

Thereafter

 

 

500,000 

500,000

 

 

796,502 

857,819

Less: Unamortized discount and issuance costs

 

 

(34,998)

23,343

Total

 

$

761,504 

$

834,476

Interest Expense

Interest expense as reported in the Consolidated Statements of Income consistsOperations consisted of the following:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the year ended December 31,

For the year ended December 31,

(in thousands)

2018

 

2017

 

2016

2019

2018

2017

Cash interest expense:

 

 

 

 

 

 

 

 

Interest on 2017 Senior Notes

$

34,375 

 

$

23,967 

 

$

 —

$

34,375

$

34,375

$

23,967

Interest on 2017 Credit Facility

 

8,575 

 

 

5,517 

 

 

 —

11,990

8,575

5,517

Interest on Convertible Notes

 

5,750 

 

 

5,750 

 

 

3,115 

5,750

5,750

5,750

Interest on 2010 Senior Notes

 

 —

 

 

6,926 

 

 

22,875 

6,926

Interest on 2014 Credit Facility

 

 —

 

 

4,455 

 

 

19,201 

4,455

Other interest

 

2,747 

 

 

3,261 

 

 

3,623 

2,172

2,747

3,261

Cash portion of loss on extinguishment

 

 —

 

 

1,913 

 

 

 —

1,913

Total cash interest expense

 

51,447 

 

 

51,789 

 

 

48,814 

54,287

51,447

51,789

 

 

 

 

 

 

 

 

Non-cash interest expense(a):

 

 

 

 

 

 

 

 

Amortization of discount and debt issuance costs on Convertible Notes

 

9,846 

 

 

8,967 

 

 

4,519 

10,811

9,846

8,967

Amortization of debt issuance costs on 2017 Credit Facility

 

1,439 

 

 

962 

 

 

 —

1,552

1,439

962

Amortization of debt issuance costs on 2017 Senior Notes

 

787 

 

 

516 

 

 

 —

844

787

516

Amortization of debt issuance costs on 2014 Credit Facility

 

 —

 

 

1,703 

 

 

5,447 

1,703

Amortization of discount and debt issuance costs on 2010 Senior Notes

 

 —

 

 

308 

 

 

1,002 

308

Non-cash portion of loss on extinguishment

 

 —

 

 

5,139 

 

 

 —

5,139

Total non-cash interest expense

 

12,072 

 

 

17,595 

 

 

10,968 

13,207

12,072

17,595

 

 

 

 

 

 

 

 

Total interest expense

$

63,519 

 

$

69,384 

 

$

59,782 

$

67,494

$

63,519

$

69,384

_____________________________________________________________________________________________________________

F-28


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

(a)   The combination of cash and non-cash interest expense produces effective interest rates that are higher than contractual rates. Accordingly, the effective interest rates for the 2017 Senior Notes and the Convertible Notes were 7.13% and 9.39%, respectively, for the year ended December 31, 20182019.

F-25


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Leases

The Company leases certain construction equipment and office space under non-cancellable operating leases, with future minimum rent payments as of December 31, 2018 as follows:



 

 

 



 

 

 

Year (in thousands)

 

 

2019

 

$

14,039 

2020

 

 

10,706 

2021

 

 

7,464 

2022

 

 

6,567 

2023

 

 

5,587 

Thereafter

 

 

11,662 



 

 

56,025 

Less: Sublease rental agreements

 

 

(1,398)

Total

 

$

54,627 

Rental expense under operating leases of construction equipment, vehicles and office space was $24.3 million in 2018, $27.4 million in 2017 and $28.2 million in 2016.

8.     Commitments and Contingencies

The Company and certain of its subsidiaries are involved in litigation and variousother legal proceedings and forms of dispute resolution and are contingently liable for commitments and performance guarantees arising in the ordinary course of business. In addition, other activities inherentbusiness, including but not limited to the Company’s business may result in litigation disputes over contract payment and/or dispute resolution proceedings when there is a disagreementperformance-related issues (such as disagreements regarding delay or a change in the scope of work of a project and/or the price associated with that change.change) and other matters incidental to the Company’s business. In accordance with ASC 606, the Company makes assessments of these types of disputesmatters on a routine basis and, to the extent permitted by ASC 606, estimates and records recovery related to these disputesmatters as a form of variable consideration at the most likely amount itthe Company expects to receive, as discussed further in Note 1(d) and Note 4. In addition, the Company is contingently liable for litigation, performance guarantees and other commitments arising in the ordinary course of business, which are accounted for in accordance with ASC 450, Contingencies. Management reviews these matters regularly and updates or revises its estimates as warranted by subsequent information and developments. These assessments require judgments concerning matters that are inherently uncertain, such as litigation developments and outcomes, the anticipated outcome of negotiations and the estimated cost of resolving disputes. Consequently, these assessments are estimates, and actual amounts may vary from such disputes.estimates. In addition, because most contingenciessuch matters are typically resolved over long periods of time, the Company’s assets and liabilities may change inover time should the future due to various factors.circumstances dictate. The description of the legal proceedings listed below include management’s assessment of those proceedings. Management believes that, based on current information and discussions with the Company’s legal counsel, the ultimate resolution of theseother matters is not expected to have a material adverse effect on the Company’s consolidated financial position, results of operations or cash flows.

Several matters are inA description of the litigation and dispute resolution processes that include characteristics which management consider to bematerial pending legal proceedings, other than ordinary routine contract performance related issues. The following discussion provides a background and current status of such material matters.

Long Island Expressway/Cross Island Parkway Matter

The Company reconstructed the Long Island Expressway/Cross Island Parkway Interchange (“LIE” Project) for the New York State Department of Transportation (“NYSDOT”). The $130 million project was substantially complete in January 2004 and was accepted by NYSDOT as complete in February 2006. The Company incurred significant added costs in completing its work and suffered extended schedule costs due to numerous design errors, undisclosed utility conflicts, lack of coordination with local agencies and other interferences for which the Company believes NYSDOT is responsible.

In March 2011, the Company opened a case with the New York State Court of Claims against NYSDOT relatedlitigation incidental to the LIE Project. In May 2011, NYSDOT filed a motion to dismiss the Company’s claim on the grounds that the Company had not provided required documentation for project closeout and filing of a claim. In September 2011, the Company reached agreement on final payment with the Comptroller’s Office on behalf of NYSDOT, which resulted in an amount of $0.5 million payable to the Company and formally closed out the project allowing the Company to re-file its claim. In March 2012, the Company filed its formal Verified Claim seeking $50.7 million in damages. In May 2012, NYSDOT served its answer and asserted counterclaims in the amount of $151 million alleging fraud in the inducement and punitive damages related to alleged violations of the disadvantaged business enterprise (“DBE”) requirements for the project. The Court subsequently ruled that NYSDOT’s counterclaims may only be assertedis as a defense and offset to the Company’s claims and not as affirmative claims. In November 2014, the Appellate Division First Department affirmed the dismissal of NYSDOT’s affirmative counterclaims. In June 2018, following additional summary judgment motions, the Court granted the Company’s motion to dismiss NYSDOT’s affirmative defenses, which eliminated the use of NYSDOT’s counterclaim of $151 million as a defense to the claims of the Company. In October 2018, NYSDOT filed a notice of appeal. A trial date for the appeal has not been set.follows:

F-26


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Management has made an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the consolidated financial statements at that time.

Fontainebleau Matter

Desert Mechanical, Inc. (“DMI”) and Fisk Electric Company (“Fisk”), wholly owned subsidiaries of the Company, were subcontractors on the Fontainebleau project located in Las Vegas, Nevada, a hotel/casino complex with approximately 3,800 rooms (the “Project”). In June 2009, the owners of the Project filed for bankruptcy protection, under Chapter 11 of the U.S. Bankruptcy Code, in the Southern District of Florida.

DMI and Fisk recorded mechanic’s liens against the Project totaling approximately $44 million, for unpaid labor, materials and equipment it furnished to the Project. Other unaffiliated contractors, subcontractors and suppliers also recorded mechanic’s liens against the Project, subjecting the property to approximately $550 million in total lien claims by the various lien claimants who furnished labor, materials and equipment to the Project (the “Statutory Lienholders”). In June 2009, DMI filed suit against Turnberry West Construction, Inc., the general contractor, in the Eighth Judicial District Court, Clark County, Nevada, and in May 2010, the court entered an order in favor of DMI for approximately $45 million.

In January 2010, the Bankruptcy Court approved the sale of the Property to Icahn Nevada Gaming Acquisition, LLC for approximately $150 million. Certain Project lenders (the “Lenders”) who had recorded deeds of trust as security interests in the property which far exceeded the sale proceeds, filed suit against the Statutory Lienholders, including DMI and Fisk, alleging that all mechanic’s liens were subordinate to the Lenders’ deeds of trust against the property. The Nevada Supreme Court ruled in October 2012 that under Nevada Law, the mechanic’s lien claims had priority over a portion of the deeds of trust, but not all of them.

In October 2013, a comprehensive settlement agreement was reached by and among the Statutory Lienholders and the Lenders to divide the Sale Proceeds such that the Statutory Lienholders would receive approximately $85 million of the sale proceeds (the “Net Statutory Lienholder Proceeds”) and the Lenders would receive the balance. The Bankruptcy Court appointed a mediator to facilitate a settlement between the Statutory Lienholders as to how the Net Statutory Lienholder Proceeds would be distributed, but after engaging in numerous mediation sessions spanning several years, the parties were unable to reach a resolution. DMI filed a motion seeking permission from the Bankruptcy Court to file an action in Nevada to enforce its lien rights against the Net Statutory Lienholder Proceeds, and the motion was granted. Pursuant to that order, litigation involving all Statutory Lienholders was commenced at the end of November 2017 (the “Nevada Action”).

A determination of each Statutory Lienholder’s rights against the Net Statutory Lienholder Proceeds in the Nevada Action is expected by May 2019, with a pro rata distribution of those monies to follow shortly thereafter.

Management has made an estimate of the total anticipated recovery on this Project, and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the consolidated financial statements at that time.

Westgate Planet Hollywood Matter

Tutor-Saliba Corporation (“TSC”), a wholly owned subsidiary of the Company, was contracted to construct a timeshare development project in Las Vegas, which was substantially completed in December 2009. The Company’s claims against the owner, Westgate Planet Hollywood Las Vegas, LLC (“WPH”), relate to unresolved owner change orders and other claims. The Company filed a lien on the project in the amount of $23.2 million and filed its complaint with the District Court, Clark County, Nevada. Several subcontractors have also recorded liens, some of which have been released by bonds and some of which have been released as a result of subsequent payment. WPH has posted a mechanic’s lien release bond for $22.3 million.

WPH filed a cross-complaint alleging non-conforming and defective work for approximately $51 million, primarily related to alleged defects, misallocated costs and liquidated damages. WPH revised the amount of their counterclaims to approximately $45 million.

Following multiple post-trial motions, final judgment was entered in this matter on March 20, 2014. TSC was awarded total judgment in the amount of $19.7 million on its breach of contract claim, which includes an award of interest up through the date of judgment, plus attorney’s fees and costs. WPH was awarded total judgment in the amount of $3.1 million on its construction defect claims, which includes interest up through the date of judgment. WPH and its Sureties filed a notice of appeal. TSC filed a notice of appeal on the defect award. In July 2014, the District Court ordered WPH to post an additional supersedeas bond on appeal, in the amount of

F-27


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

$1.7 million, in addition to the lien release bond of $22.3 million, which increases the security up to $24.0 million. In May 2017, the Nevada Supreme Court issued its ruling on the appeal by WPH and its Sureties. With only minor adjustments, the Nevada Supreme Court affirmed the District Court’s judgment, and following further proceedings in the District Court, the anticipated final recovery to the Company is estimated to exceed $20 million, including interest and recovery of certain attorneys’ fees and costs of which the Company collected more than $16 million in 2017. In December 2017 and in January 2018, the District Court issued several post-appeal orders confirming its previous rulings. Some of those matters have been appealed and are expected to be resolved in the first half of 2019. Once resolved, TSC will seek an order from the District Court seeking the remaining $4 million in interest and fees associated with the matter.

The Company does not expect the ultimate resolution of this matter to have a material effect on its consolidated financial statements. Management has made an estimate of the total anticipated recovery on this project and such estimate is included in revenue recorded to date. To the extent new facts become known or the final recovery included in the claim settlement varies from the estimate, the impact of the change will be reflected in the consolidated financial statements at that time.

Five Star Electric Matter

In the third quarter of 2015, Five Star Electric Corp. (“Five Star”), a wholly owned subsidiary of the Company that was acquired in 2011, entered into a tolling agreement (which has since expired) related to an ongoing investigation being conducted by the United States Attorney’s Office for the Eastern District of New York (“USAO EDNY”). Five Star has been cooperating with the USAO EDNY since late June 2014, when it was first made aware of the investigation, and has provided information requested by the government related to its use of certain minority-owned, women-owned, small and disadvantaged business enterprises and certain of Five Star’s employee compensation, benefit and tax practices.

As of December 31, 2018,2019, the Company cannot predict the ultimate outcome of the investigation and cannot reasonably estimate the potential loss or range of loss that Five Star or the Company may incur or the impact of the results of the investigation on Five Star or the Company.

Alaskan Way Viaduct Matter

In January 2011, Seattle Tunnel Partners (“STP”), a joint venture between Dragados USA, Inc. and the Company, entered into a design-build contract with the Washington State Department of Transportation (“WSDOT”) for the construction of a large diameter bored tunnel in downtown Seattle, King County, Washington to replace the Alaskan Way Viaduct, also known as State Route 99. The Company has a 45% interest in STP.

The construction of the large diameter bored tunnel required the use of a tunnel boring machine (“TBM”). In December 2013, the TBM struck a steel pipe, installed by WSDOT as a well casing for an exploratory well. The TBM was significantly damaged and was required to be shut down for repair.repaired. STP has asserted that the steel pipe casing was a differing site condition that WSDOT failed to properly disclose. The Disputes Review Board mandated by the contract to hear disputes issued a decision finding the steel casing was a Type I (material) differing site condition. WSDOT has not accepted that finding.

The TBM was insured under a Builder’s Risk Insurance Policy (the “Policy”) with Great Lakes Reinsurance (UK) PLC and a consortium of other insurers (the “Insurers”). STP submitted the claims to the Insurers and requested interim payments under the Policy. The Insurers refused to pay and denied coverage. In June 2015, STP filed a lawsuit in the King County Superior Court, State of Washington (“Washington Superior Court”) seeking declaratory relief concerning contract interpretation, as well as damages as a result of the Insurers’ breach of their obligations under the terms of the Policy. STP is also asserting extra-contractual and statutory claims against the Insurers. WSDOT is deemed a plaintiff since WSDOT is an insured under the Policy and had filed its own claim for damages. Hitachi Zosen (“Hitachi”), the manufacturer of the TBM, has also joined the case as a plaintiff for costs incurred to repair the damages to the TBM.

F-29


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

In September 2018, rulings received on pre-trial motions effectively limited potential recovery under the Policy for STP, WSDOT and Hitachi. However, on December 19, 2018, the Court of Appeal granted the Company’s request for a discretionary appeal of those rulings. The appeal is expected to be heard in mid to late 2020. STP submitted damages to the second halfInsurers in the King County lawsuit in the amount of 2019. To$532 million. STP is also seeking these damages from WSDOT related to the extent we are unable to recover damages underpipe-strike by the Policy, we can still seek recovery against WSDOT and Hitachi.TBM in a related lawsuit in Thurston County (see following paragraph).

In March 2016, WSDOT filed a complaint against STP in Thurston County Superior Court for breach of contract alleging STP’s delays and failure to perform, seeking $57.2 million in damages and seeking declaratory relief concerning contract interpretation. STP filed its answer to WSDOT’s complaint and filed a counterclaim against WSDOT and Hitachi. TrialHitachi, as the TBM designer, seeking damages of $667 million. On October 3, 2019, STP and Hitachi entered into a settlement agreement which caused the release and dismissal of claims that STP and Hitachi had against each other. The jury trial between STP and WSDOT commenced on October 7, 2019 and concluded on December 13, 2019, with a jury verdict in favor of WSDOT awarding them $57.2 million in damages. Judgment was entered on January 10, 2020, and a notice of appeal was filed by STP on January 17, 2020.

The Company recorded the impact of the jury verdict during the fourth quarter of 2019, resulting in a pre-tax charge of $166.8 million. The charge includes a pre-tax accrual of $25.7 million (which is scheduledthe Company’s 45% proportionate share of the $57.2 million in damages awarded by the jury to WSDOT). Payment of damages will only be made if the adverse verdict is upheld on appeal, as the payment is secured by a bond for the course of the appeal. Other than the possible future payment in cash of $25.7 million in damages, the charge is for non-cash write-downs primarily related to the costs and estimated earnings in excess of billings and receivables that the Company previously recorded to reflect its expected recovery in this case.

With respect to STP’s direct and indirect claims against the Insurers, management has included in receivables an estimate of the total anticipated recovery concluded to be probable.

George Washington Bridge Bus Station Matter

In August 2013, Tutor Perini Building Corporation (“TPBC”) entered into a contract with the George Washington Bridge Bus Station Development Venture, LLC (the “Developer”) to renovate the George Washington Bridge Bus Station, a mixed-use facility owned by the Port Authority of New York and New Jersey that serves as a transit facility and retail space. The $100 million project experienced significant design errors and associated delays, resulting in damages to TPBC and its subcontractors, including WDF and Five Star, wholly owned subsidiaries of the Company. The project reached substantial completion on May 16, 2017.

On February 26, 2015, the Developer filed a demand for arbitration, subsequently amended, seeking $30 million in alleged damages and declaratory relief that TPBC’s requests for additional compensation are invalid due to lack of notice. TPBC denied the Developer’s claims and filed a counterclaim in March 2018. TPBC seeks in excess of $113 million in the arbitration, which includes unpaid contract balance claims, the return of $29 million retained by the Developer in alleged damages, as well as extra work claims, pass-through claims and delay claims.

Hearings on the merits commenced on September 24, 2018 before the arbitration panel, and were expected to continue over various weeks through March 2020. On April 15, 2019, the counsel for the Developer withdrew from the case, which resulted in further delays to the proceedings. On June 4, 2019, the arbitration panel, as confirmed by the U.S. District Court in the Southern District of New York, issued a writ of attachment for $23 million of the $29 million discussed above. On October 7, 2019, the Developer filed for bankruptcy protection in the Southern District of New York under Chapter 11 of the Bankruptcy Code. The filing for bankruptcy stayed the pending arbitration proceedings. TPBC appeared in the bankruptcy proceedings on October 8, 2019 and filed a Proof of Claim in the amount of $113 million on December 13, 2019.

Separately, on July 2, 2018, TPBC filed a lawsuit against the Port Authority of New York and New Jersey, as owner of the project, and STV Incorporated, as designer, seeking the same $113 million in damages. On January 13, 2020, the Court dismissed STV Incorporated from the case. That lawsuit is proceeding against the Port Authority of New York and New Jersey.

On January 27, 2020, the Company filed separate litigation in the United States District Court for the Southern District of New York in which the Company asserted claims against individual owners of the Developer for their wrongful conversion of project funds and against certain lenders that received interest payments from project funds and other amounts earmarked to pay the contractors.

As of December 31, 2018,2019, the Company has concluded that the potential for a material adverse financial impact due to the Insurers’ denial of coverage and WSDOT’s legal actionsDeveloper’s claims is neither probable nor remote, and the potential loss or range of loss is not reasonably estimable.remote. With respect to STP’sTPBC’s claims against the Insurers, WSDOTDeveloper and Hitachi,the Port Authority of New York and New Jersey, management has includedmade an estimate of the total anticipated recovery on this project, and such estimate is included in revenue recorded to date.

F-30

F-28


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

anticipated recovery, concluded

9.     Leases

The Company leases certain office space, construction and office equipment, vehicles and temporary housing generally under non-cancelable operating leases. Leases with an initial term of one year or less are not recorded on the balance sheet, and the Company generally recognizes lease expense for these leases on a straight-line basis over the lease term. As of December 31, 2019, the Company’s operating leases have remaining lease terms ranging from less than one year to be both probable10 years, some of which include options to renew the leases. The exercise of lease renewal options is generally at the Company’s sole discretion. The Company’s leases do not contain any material residual value guarantees or material restrictive covenants.

The Company determines if an arrangement is a lease at inception. Operating lease ROU assets are included in other assets, while current and reliably estimable,long-term operating lease liabilities are included in receivables or costsaccrued expenses and estimated earningsother current liabilities, and other long-term liabilities, respectively, on the Consolidated Balance Sheet as of December 31, 2019. ROU assets represent the Company’s right to use an underlying asset for the lease term and lease liabilities represent the Company’s obligation to make lease payments arising from the lease. ROU assets and lease liabilities are recognized at the commencement date based on the present value of lease payments over the lease term. The present value of future lease payments are discounted using either the implicit rate in excess of billings recorded to date. To the extent new facts becomelease, if known, or the final recoveries varyCompany’s incremental borrowing rate for the specific lease as of the lease commencement date. The ROU asset is also adjusted for any prepayments made or incentives received. The lease terms include options to extend or terminate the lease only to the extent it is reasonably certain any of those options will be exercised. Lease expense is recognized on a straight-line basis over the lease term. The Company accounts for lease components (e.g., fixed payments) separate from the estimate,non-lease components (e.g., common-area maintenance costs).The Company does not have any material financing leases.

The following table presents components of lease expense for the impactyear ended December 31, 2019:

Year Ended

(in thousands)

December 31, 2019

Operating lease expense

$

15,854

Short-term lease expense(a)

72,562

88,416

Less: Sublease income

1,077

Total lease expense

$

87,339

(a)Short-term lease expense includes all leases with lease terms ranging from less than one month to one year. Short-term leases include, among other things, construction equipment rented on an as-needed basis as well as temporary housing.

The following table presents supplemental balance sheet information related to operating leases as of December 31, 2019:

As of December 31,

(dollars in thousands)

Balance Sheet Line Item

2019

Assets

ROU assets

Other assets

$

40,156

Total lease assets

$

40,156

Liabilities

Current lease liabilities

Accrued expenses and other current liabilities

$

11,392

Long-term lease liabilities

Other long-term liabilities

31,900

Total lease liabilities

$

43,292

Weighted-average remaining lease term (in years)

5.0

Weighted-average discount rate

5.96%

F-31


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table presents supplemental cash flow information and non-cash activity related to operating leases for the change will be reflected in the financial statements at that time.year ended December 31, 2019:

9.

Year Ended

(in thousands)

December 31, 2019

Operating cash flow information:

Cash paid for amounts included in the measurement of lease liabilities

$

(15,658)

Non-cash activity:

ROU assets obtained in exchange for lease liabilities

$

9,784

The following table presents maturities of operating lease liabilities on an undiscounted basis as of December 31, 2019:

Year (in thousands)

Operating Leases

2020

$

13,572

2021

9,372

2022

7,971

2023

6,761

2024

5,093

Thereafter

7,618

Total lease payments

50,387

Less: Imputed interest

7,095

Total

$

43,292

As of December 31, 2018, future minimum lease payments under long-term non-cancelable operating leases as classified under ASC 840 were as follows:

Year (in thousands)

Operating Leases

2019

$

14,039

2020

10,706

2021

7,464

2022

6,567

2023

5,587

Thereafter

11,662

56,025

Less: Sublease rental agreements

1,398

Total

$

54,627

10.     Other Income, Net

On May 31, 2017, the Company entered into a settlement agreement with Merrill Lynch, Pierce, Fenner & Smith Incorporated (“Merrill Lynch”), as successor in interest to Banc of America Securities LLC and Bank of America, N.A. (collectively “BofA”), to resolve the pending litigation between the Company and Merrill Lynch. The litigation, which was filed by the Company in 2011, related to the Company’s purchase of certain auction-rate securities from BofA.

On June 6, 2017, the Company received the $37.0 million cash settlement payment agreed to in the settlement agreement, and the pending litigation was dismissed with prejudice. Neither party made any admission of liability or wrongdoing, and the settlement agreement includes mutual releases of all claims and liabilities related to the subject matter of the pending litigation.

The Company recognized the settlement as a gain and reported it as a component of other income, net in its Consolidated Statement of IncomeOperations for the year ended December 31, 2017.

F-32

10.


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

11.     Share-Based Compensation

On April 10, 2018, the Company adopted the Tutor Perini Corporation Omnibus Incentive Plan (the “Current Plan”), which was approved by the Company’s shareholders on May 23, 2018. The Current Plan effected the merger of the Company’s Amended and Restated Tutor Perini Corporation Long-Term Incentive Plan, as amended and restated on October 2, 2014 (the “2014 Plan”) and the Tutor Perini Corporation Incentive Compensation Plan adopted on April 3, 2017 (the “2017 Plan,” together with the 2014 Plan and the Current Plan, the “Plans”). The Current Plan provides for various types of share-based grants, including restricted and unrestricted stock units and stock options. Restricted and unrestricted stock units give the holder the right to exchange their stock units for shares of the Company’s common stock on a one-for-one basis. Stock options give the holder the right to purchase shares of the Company’s common stock subsequent to the vesting date at a defined exercise price. A stock option exercise price must be equal to or greater than the fair value of the Company’s common stock on the date of the award. Restricted stock units and stock options are usually subject to certain service and performance conditions as well as other restrictions. The term for stock options is limited to 10 years from the date of grant.award date. As of December 31, 2018,2019, there were 800,6671,241,879 shares of common stock available for grant under the Company’s Current Plan. As of December 31, 2018,2019, the Plans had an aggregate of 4,732,0444,144,015 of restricted stock units and stock options from outstanding, historical awards that either have not vested or have vested but have not been exercised. Any awards that were granted under the 2014 Plan or the 2017 Plan that are forfeited, cancelled or held back for net settlement will become available to be issued under the Current Plan.

The terms of the Plans give the Company the right to settle the vesting of share-based grants in cash or shares. During the yearyears ended December 31, 2019 and 2018, the Company did not0t settle any awards in cash. During the year ended December 31, 2017, the Company paid approximately $0.6 million to settle share-based awards.

Many of the awards issued under the Plans contain separate tranches, each for a separate performance period and each with a performance target to be established subsequent to the award date; accordingly, the tranches are accounted for under ASC 718, Stock Compensation (“ASC 718”) as separate grants, with the grant date being the date the performance targets for a given tranche are established and communicated to the grantee. Similarly, for these awards, compliance with the requirements of the Plans is also based on the number of units granted in a given year, as determined by ASC 718, rather than the number of units awarded in a given year. As a result, as of December 31, 2018,2019, the Company had outstanding awards with 160,00075,000 restricted stock units and 160,00075,000 stock options that had not been granted yet. These units will be granted in 2019 and 2020 when the performance targets for those respective years are established.

F-29


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table summarizes restricted stock unit and stock option activity:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Restricted Stock Units

 

Stock Options

Restricted Stock Units

Stock Options

 

 

Weighted-

 

 

 

Weighted-

Weighted-

Weighted-

 

 

Average

 

 

 

Average

Average

Average

 

 

Grant Date

 

 

 

Exercise/

Grant Date

Exercise/

 

 

Fair Value

 

 

 

(Strike) Price

Fair Value

(Strike) Price

Number

 

Per Share

 

Number

 

Per Share

Number

Per Share

Number

Per Share

Outstanding as of December 31, 2015

725,597 

 

$

25.28 

 

1,998,000 

 

$

19.62 

Granted

483,387 

 

 

19.14 

 

274,000 

 

 

16.20 

Vested/exercised

(52,500)

 

 

18.74 

 

(97,500)

 

 

12.72 

Outstanding as of December 31, 2016

1,156,484 

 

$

22.64 

 

2,174,500 

 

$

19.50 

1,156,484

$

22.64

2,174,500

$

19.50

Granted

1,064,000 

 

 

30.02 

 

539,000 

 

 

24.54 

1,064,000

30.02

539,000

24.54

Expired or cancelled

(20,985)

 

 

23.91 

 

(19,466)

 

 

26.56 

(20,985)

23.91

(19,466)

26.56

Vested/exercised

(801,515)

 

 

19.38 

 

(140,000)

 

 

21.41 

(801,515)

19.38

(140,000)

21.41

Outstanding as of December 31, 2017

1,397,984 

 

$

30.11 

 

2,554,034 

 

$

20.45 

1,397,984

$

30.11

2,554,034

$

20.45

Granted

699,000 

 

 

24.21 

 

664,000 

 

 

23.20 

699,000

24.21

664,000

23.20

Expired or cancelled

(240,289)

 

 

32.76 

 

(274,990)

 

 

22.82 

(240,289)

32.76

(274,990)

22.82

Vested/exercised

(387,695)

 

 

28.67 

 

 —

 

 

 —

(387,695)

28.67

Outstanding as of December 31, 2018

1,469,000 

 

$

27.27 

 

2,943,044 

 

$

20.89 

1,469,000

$

27.27

2,943,044

$

20.89

Granted

530,000

20.23

220,000

19.66

Expired or cancelled

(104,029)

28.98

(884,029)

21.03

Vested/exercised

(179,971)

25.39

Outstanding as of December 31, 2019

1,715,000

$

25.19

2,279,015

$

20.62

F-33


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table summarizes unrestricted stock units, which are generally issued to the non-employee members of the Company’s Board of Directors as part of their annual retainer fees:



 

 

 

 

 



 

 

 

 

 



 

Unrestricted Stock Units



 

 

 

Weighted-Average



 

 

 

Grant Date

Year

 

Number

 

Fair Value Per Share

2016

 

64,603 

 

$

21.67 

2017

 

99,155 

 

 

26.26 

2018

 

115,420 

 

 

21.26 

Unrestricted Stock Units

Weighted-Average

Grant Date

Year

Number

Fair Value Per Share

2017

99,155

$

26.26

2018

115,420

21.26

2019

98,591

15.72

Unrestricted stock units vest immediately upon grant and are converted to shares of the Company’s stock on a one-for-one basis. The fair value of unrestricted stock units issued during 2019, 2018 2017 and 20162017 was approximately $1.5 million, $2.5 million and $2.6 million, and $1.4 million, respectively.

The fair value of restricted stock units that vested during 2019, 2018 2017 and 20162017 was approximately $3.1 million, $7.9 million $25.3 million and $1.0$25.3 million, respectively. There were no0 stock options exercised during 2019 or 2018. The aggregate intrinsic value, representing the difference between the market value on the date of exercise and the option price of the stock options exercised during 2017 and 2016 was $1.3 million, and $1.1 million, respectively, with a corresponding tax benefit of $0.6 million and $0.5 million, respectively.million. As of December 31, 2018,2019, the balance of unamortized restricted stock and stock option expense was $21.4$17.3 million and $6.0$3.6 million, respectively, which willis expected to be recognized over weighted-average periods of 2.0 years for both restricted stock units and 1.8 years for stock options.

The 2,943,0442,279,015 outstanding stock options as of December 31, 20182019 had an intrinsic value of $2.5$0.9 million and a weighted-average remaining contractual life of 4.85.5 years. Of those outstanding options: (1) 2,034,0441,509,015 were exercisable with an intrinsic value of $2.5$0.9 million, a weighted-average exercise price of $19.42$19.69 per share and a weighted-average remaining contractual life of 3.14.1 years; (2) 909,000770,000 have been granted but have not vested with no intrinsic value, a weighted-average exercise price of $23.92$22.44 per share and a weighted-average remaining contractual life of 8.58.4 years. Of the granted but unvested options, 876,750,770,000, are expected to vest.

The fair value of restricted and unrestricted stock units is based on the closing price of the Company’s common stock on the New York Stock Exchange on the date of the grant and the fair value of stock options is based on the Black-Scholes model. For certainCertain performance-based awards containingcontain market condition components tied to the Company’s total shareholder return in relation to its peer companies, as calculated over a multi-year performance period (“TSR awards”). The fair value onof the grant dateTSR awards is determined using a Monte Carlo simulation model. Significant assumptions used in this simulation model include the Company’s expected volatility, a risk-free rate based on U.S. Treasury yield curve rates with maturities consistent with the performance period, and the volatilities for each of the Company’s peers. The ultimate payout on TSR awards is determined at the end of the performance period and will vary based on actual total shareholder return performance results. Compensation expense related to the TSR awards is recognized regardless of whether the market condition is satisfied, provided that the requisite service period has been completed.

F-30


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The fair value on the grant date and the significant assumptions used in the Black-Scholes option-pricing model are as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

2018

 

2017

 

2016

2019

2018

2017

Total stock options granted

 

664,000 

 

 

539,000 

 

 

274,000 

 

220,000

664,000

539,000

Weighted-average grant date fair value

$

11.09 

 

 

$

13.11 

 

 

$

5.31 

 

$

7.59

$

11.09

$

13.11

Weighted-average assumptions:

 

 

 

 

 

 

 

 

 

Risk-free rate

 

2.6 

%

 

 

1.8 

%

 

 

1.2 

%

2.1

%

2.6

%

1.8

%

Expected life of options(a)

 

5.8 

 

 

 

4.8 

 

 

 

4.2 

 

6.1

5.8

4.8

Expected volatility(b)

 

42.2 

%

 

 

43.1 

%

 

 

40.6 

%

39.4

%

42.2

%

43.1

%

Expected quarterly dividends

$

 —

 

 

$

 —

 

 

$

 —

 

$

$

$

(a)

Calculated using the simplified method due to the terms of the stock options and the limited pool of grantees.

(b)

Calculated using historical volatility of the Company’s common stock over periods commensurate with the expected life of the option.

_____________________________________________________________________________________________________________

(a)Calculated using the simplified method due to the terms of the stock options and the limited pool of grantees.

(b)Calculated using historical volatility of the Company’s common stock over periods commensurate with the expected life of the option.

For the respective years ended December 31, 2019, 2018 2017 and 2016,2017, the Company recognized, as part of general and administrative expenses, costs for share-based payment arrangements for employees of $17.5 million, $21.1 million $19.6 million and $13.4$19.6 million. Additionally for the same periods, the Company also recognized as part of general and administrative expenses costs for share-based awards to non-employee directors of $1.6 million, $1.7 million $1.6 million and $1.4$1.6 million, respectively. The aggregate tax benefits for these awards were approximately $2.9 million, $3.8 million $8.7 million and $6.1$8.7 million, for the respective periods.

F-34


Table of Contents

11.

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

12.     Employee Benefit Plans

Defined Benefit Pension Plan

The Company has a defined benefit pension plan that covers certain of its executive, professional, administrative and clerical employees, subject to certain specified service requirements. The pension plan is noncontributory and benefits are based on an employee’s years of service and “final average earnings,” as defined by the pension plan. The pension plan provides reduced benefits for early retirement and takes into account offsets for social security benefits. The Company also has an unfunded supplemental retirement plan (“Benefit Equalization Plan”) for certain employees whose benefits under the defined benefit pension plan were reduced because of compensation limitations under federal tax laws. Effective June 1, 2004, all benefit accruals under the Company’s pension plan and Benefit Equalization Plan were frozen; however, the current vested benefit was preserved. Pension disclosure as presented below includes aggregated amounts for both of the Company’s plans, except where otherwise indicated.

The Company historically has used the date of its year-end as its measurement date to determine the funded status of the pension plan.

The long-term investment goals of the Company’s pension plan are to manage the assets in accordance with the legal requirements of all applicable laws; produce investment returns which maximize return within reasonable and prudent levels of risks; and achieve a fully funded status with regard to current pension liabilities. Some risk must be assumed in order to achieve the investment goals. Investments with the ability to withstand short and intermediate term variability are considered and some interim fluctuations in market value and rates of return are tolerated in order to achieve the pension plan’s longer-term objectives.

The pension plan’s assets are managed by a third-party investment manager. The Company monitors investment performance and risk on an ongoing basis.

F-31


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

AThe following table sets forth a summary of net periodic benefit cost is as follows:for the years ended December 31, 2019, 2018 and 2017:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

2018

 

 

2017

 

 

2016

 

2019

2018

2017

Interest cost

$

3,496 

 

 

$

3,919 

 

 

$

4,153 

 

$

3,801

$

3,496

$

3,919

Service cost

 

875 

 

 

 

850 

 

 

 

600 

 

900

875

850

Expected return on plan assets

 

(4,302)

 

 

 

(4,358)

 

 

 

(4,803)

 

(4,170)

(4,302)

(4,358)

Recognized net actuarial losses

 

2,067 

 

 

 

1,897 

 

 

 

1,745 

 

1,933

2,067

1,897

Net periodic benefit cost

$

2,136 

 

 

$

2,308 

 

 

$

1,695 

 

$

2,464

$

2,136

$

2,308

Actuarial assumptions used to determine net cost:

 

 

 

 

 

 

 

 

 

 

 

Discount rate

 

3.45 

%

 

 

3.90 

%

 

 

4.10 

%

4.12

%

3.45

%

3.90

%

Expected return on assets

 

6.00 

%

 

 

6.00 

%

 

 

6.00 

%

5.75

%

6.00

%

6.00

%

Rate of increase in compensation

 

N/A

 

 

 

N/A

 

 

 

N/A

 

N/A

N/A

N/A

The target asset allocation for the Company’s pension plan by asset category for 20192020 and the actual asset allocation as of December 31, 20182019 and 20172018 by asset category are as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Percentage of Plan Assets as of December 31,

Percentage of Plan Assets as of December 31,

 

Target

 

 

 

Target

 

Allocation

 

 

Actual Allocation

Allocation

Actual Allocation

Asset Category

 

2019

 

 

2018

 

 

2017

2020

2019

2018

Cash

 

%

 

 

%

 

 

%

5

%

4

%

3

%

Equity funds:

 

 

 

 

 

 

 

 

 

 

 

Domestic

 

45 

 

 

 

50 

 

 

 

41 

 

45

47

50

International

 

20 

 

 

 

27 

 

 

 

31 

 

18

18

27

Fixed income funds

 

30 

 

 

 

20 

 

 

 

25 

 

32

31

20

Total

 

100 

%

 

 

100 

%

 

 

100 

%

100

%

100

%

100

%

F-35

As


Table of December 31, 2018 and 2017, pension plan assets included approximately $16.5 million and $30.7 million, respectively, of investments in hedge funds and equity partnerships which do not have readily determinable fair values. The underlying holdings of the funds were comprised of a combination of assets for which the estimate of fair value is determined using information provided by fund managers.Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The Company expects to contribute approximately $4.6$4.1 million to its defined benefit pension plan in 2019.2020.

Future benefit payments under the plans are estimated as follows:

 

 

 

 

(in thousands)

 

 

Year ended December 31,

 

2019

$

6,810 

2020

 

6,779 

$

6,822

2021

 

6,729 

6,789

2022

 

6,669 

6,724

2023

 

6,590 

6,637

2024-2028

 

31,752 

2024

6,611

2025-2029

31,183

Total

$

65,329 

$

64,766

F-32


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following tables provide a reconciliation of the changes in the fair value of plan assets and plan benefit obligations during 20182019 and 2017,2018, and a summary of the funded status as of December 31, 20182019 and 2017:2018:

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

2018

 

2017

2019

2018

Change in Fair Value of Plan Assets

 

 

 

 

 

Balance at beginning of year

$

71,541 

 

$

66,057 

$

63,109

$

71,541

Actual return on plan assets

 

(4,758)

 

 

9,224 

12,123

(4,758)

Company contribution

 

2,975 

 

 

2,838 

4,793

2,975

Benefit payments

 

(6,649)

 

 

(6,578)

(6,668)

(6,649)

Balance at end of year

$

63,109 

 

$

71,541 

$

73,357

$

63,109

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

2018

 

2017

2019

2018

Change in Benefit Obligations

 

 

 

 

 

Balance at beginning of year

$

106,218 

 

$

103,681 

$

95,869

$

106,218

Interest cost

 

3,496 

 

 

3,919 

3,801

3,496

Service cost

 

875 

 

 

850 

900

875

Assumption change (gain) loss

 

(7,056)

 

 

3,854 

Actuarial (gain) loss

 

(1,014)

 

 

492 

Assumption change loss (gain)

8,373

(7,056)

Actuarial loss (gain)

332

(1,014)

Benefit payments

 

(6,650)

 

 

(6,578)

(6,668)

(6,650)

Balance at end of year

$

95,869 

 

$

106,218 

$

102,607

$

95,869

 

 

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Funded status

$

(32,760)

 

$

(34,677)

$

(29,250)

$

(32,760)

Net unfunded amounts recognized in Consolidated Balance Sheets consist of:

 

 

 

 

 

Current liabilities

$

(262)

 

$

(279)

$

(279)

$

(262)

Long-term liabilities

 

(32,498)

 

 

(34,398)

(28,971)

(32,498)

Total net unfunded amount recognized in Consolidated Balance Sheets

$

(32,760)

 

$

(34,677)

$

(29,250)

$

(32,760)

Amounts not yet recognized in net periodic benefit cost and included in accumulated other comprehensive loss consist of net actuarial losses before income taxes of $57.6$56.5 million and $58.7$57.6 million as of December 31, 2019 and 2018, respectively.

In 2019, net other comprehensive income of $1.2 million consisted of reclassification adjustments for the amortization of previously existing actuarial losses and 2017, respectively.

net actuarial losses arising during the period. In 2018, net other comprehensive income of $1.1 million consisted of reclassification adjustments for the amortization of previously existing actuarial losses and net actuarial gains arising during the period. In 2017, net other comprehensive income of $2.4 million consisted of reclassification adjustments for the amortization of previously existing actuarial losses and net actuarial gains arising during the period. In 2016, net actuarial losses arising during the year were partially offset by reclassification adjustments for the amortization of previously existing actuarial losses and resulted in net other comprehensive loss of $4.3 million.

The estimated amount of the net accumulated loss (consisting of net actuarial losses) that will be amortized from accumulated other comprehensive loss into net periodic benefit cost in 20192020 is $1.9$2.4 million.

F-36


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The discount rate used in determining the accumulated post-retirement benefit obligation was 3.1% as of December 31, 2019 and 4.1% as of December 31, 2018 and 3.5% as of December 31, 2017.2018. The discount rate used for the accumulated post-retirement obligation was derived using a blend of U.S. Treasury and high-quality corporate bond discount rates.

The expected long-term rate of return on assets assumption was 5.8% for 2019 and 6.0% for both 2018 and 2017.2018. The expected long-term rate of return on assets assumption was developed considering forward looking capital market assumptions and historical return expectations for each asset class assuming the plans’ target asset allocation and full availability of invested assets.

Closely held fund strategies seek to capitalize on inefficiencies identified across different asset classes or markets and include long-short equity and long equity, event-driven, multi-strategy and distressed credit.

Plan assets were measured at fair value. Registered investment companies are public investment vehicles valued using the Net Asset Value (“NAV”) of shares held by the pension plan at year-end. Equity and fixed income funds are valued based on quoted market

F-33


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

prices in active markets. Closely held funds held by the pension plan, which are only available through private offerings, do not have readily determinable fair values. Estimates of fair value of these funds were determined using the information provided by the fund managers and are generally based on the NAV per share or its equivalent.

The following table sets forth the pension plan assets at fair value in accordance with the fair value hierarchy described in Note 12:13:



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 



As of December 31, 2018

 

As of December 31, 2017



Fair Value Hierarchy

 

 

 

 

Fair Value Hierarchy

 

 

 

(in thousands)

Level 1

 

Level 2

 

Level 3

 

Total

 

Level 1

 

Level 2

 

Level 3

 

 

Total

Cash and cash equivalents

$

7,587 

 

$

 —

 

$

 —

 

$

7,587 

 

$

2,390 

 

$

 —

 

$

 —

 

$

2,390 

Fixed income funds

 

 —

 

 

2,585 

 

 

 —

 

 

2,585 

 

 

18,031 

 

 

 —

 

 

 —

 

 

18,031 

Equity funds

 

36,436 

 

 

 —

 

 

 —

 

 

36,436 

 

 

20,372 

 

 

 —

 

 

 —

 

 

20,372 



$

44,023 

 

$

2,585 

 

$

 —

 

$

46,608 

 

$

40,793 

 

$

 —

 

$

 —

 

$

40,793 

Closely held funds(a)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Equity partnerships

 

 

 

 

 

 

 

 

 

 

5,580 

 

 

 

 

 

 

 

 

 

 

 

8,711 

Hedge fund investments

 

 

 

 

 

 

 

 

 

 

10,921 

 

 

 

 

 

 

 

 

 

 

 

22,037 

Total closely held funds(a)

 

 

 

 

 

 

 

 

 

 

16,501 

 

 

 

 

 

 

 

 

 

 

 

30,748 

Total

$

44,023 

 

$

2,585 

 

$

 —

 

$

63,109 

 

$

40,793 

 

$

 —

 

$

 —

 

$

71,541 

(a)

Closely held funds in private investment were comprised of a combination of Level 1, 2 and 3 investments, but were not categorized in the fair value hierarchy because they were measured at NAV using the practical expedient under ASC 820, Fair Value Measurement (“ASC 820”).

As of December 31, 2019

As of December 31, 2018

Fair Value Hierarchy

Fair Value Hierarchy

(in thousands)

Level 1

Level 2

Level 3

Total

Level 1

Level 2

Level 3

Total

Cash and cash equivalents

$

2,867

$

$

$

2,867

$

7,587

$

$

$

7,587

Fixed income funds

2,861

2,861

2,585

2,585

Mutual funds

54,085

54,085

36,436

36,436

$

56,952

$

2,861

$

$

59,813

$

44,023

$

2,585

$

$

46,608

Closely held funds(a)

Equity partnerships

3,660

5,580

Hedge fund investments

9,884

10,921

Total closely held funds(a)

13,544

16,501

Total

$

56,952

$

2,861

$

$

73,357

$

44,023

$

2,585

$

$

63,109

_____________________________________________________________________________________________________________

(a)Closely held funds in private investment were comprised of a combination of Level 1, 2 and 3 investments, but were not categorized in the fair value hierarchy because they were measured at NAV using the practical expedient under ASC 820, Fair Value Measurement (“ASC 820”).

As of December 31, 2019 and 2018, pension plan assets included approximately $13.5 million and $16.5 million, respectively, of investments in hedge funds and equity partnerships which do not have readily determinable fair values. The underlying holdings of the funds were comprised of a combination of assets for which the estimate of fair value is determined using information provided by fund managers.

The plans have benefit obligations in excess of the fair value of each plan’s assets as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31, 2018

 

As of December 31, 2017

As of December 31, 2019

As of December 31, 2018

 

 

 

Benefit

 

 

 

 

 

 

 

Benefit

 

 

 

Benefit

Benefit

Pension

 

Equalization

 

 

 

 

Pension

 

Equalization

 

 

 

Pension

Equalization

Pension

Equalization

(in thousands)

Plan

 

Plan

 

Total

 

Plan

 

Plan

 

Total

Plan

Plan

Total

Plan

Plan

Total

Projected benefit obligation

$

92,816 

 

$

3,053 

 

$

95,869 

 

$

102,806 

 

$

3,412 

 

$

106,218 

$

99,515

$

3,092

$

102,607

$

92,816

$

3,053

$

95,869

Accumulated benefit obligation

$

92,816 

 

$

3,053 

 

$

95,869 

 

$

102,806 

 

$

3,412 

 

$

106,218 

$

99,515

$

3,092

$

102,607

$

92,816

$

3,053

$

95,869

Fair value of plans' assets

 

63,109 

 

 

 —

 

 

63,109 

 

 

71,541 

 

 

 —

 

 

71,541 

73,357

73,357

63,109

63,109

Projected benefit obligation greater than fair value of plans' assets

$

29,707 

 

$

3,053 

 

$

32,760 

 

$

31,265 

 

$

3,412 

 

$

34,677 

$

26,158

$

3,092

$

29,250

$

29,707

$

3,053

$

32,760

Accumulated benefit obligation greater than fair value of plans' assets

$

29,707 

 

$

3,053 

 

$

32,760 

 

$

31,265 

 

$

3,412 

 

$

34,677 

$

26,158

$

3,092

$

29,250

$

29,707

$

3,053

$

32,760

Section 401(k) Plan

The Company has a contributory Section 401(k) plan which covers its executive, professional, administrative and clerical employees, subject to certain specified service requirements. The cost recognized by the Company for its 401(k) plan was $4.1 million in 2019

F-37


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

and $4.2 million in both 2018 $4.2 million in 2017 and $4.0 million in 2016.2017. The Company’s contribution is based on a non-discretionary match of employees’ contributions, as defined by the plan.

Multiemployer Plans

In addition to the Company’s defined benefit pension and contribution plans discussed above, the Company participates in multiemployer pension plans for its union construction employees. Contributions are based on the hours worked by employees covered under various collective bargaining agreements. Under the Employee Retirement Income Security Act, a contributor to a multiemployer plan is only liable for its proportionate share of a plan’s unfunded vested liability upon termination, or withdrawal from a plan. The Company currently has no intention of withdrawing from any of the multiemployer pension plans in which it participates and, therefore, has not recognized a liability for its proportionate share of any unfunded vested liabilities associated with these plans.

F-34


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following table summarizes key information for the plans that the Company made significant contributions to during the three years ended December 31, 2018:2019:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Expiration

Expiration

 

 

 

 

 

 

 

FIP/RP 

 

 

 

 

 

 

 

 

 

 

 

 

Date of

FIP/RP

Date of

 

 

 

Pension Protections Act

 

Status

 

Company Contributions

 

 

 

Collective

Pension Protections Act

Status

Company Contributions

Collective

 

EIN/Pension

 

Zone Status

 

Pending Or

 

(amounts in millions)(b)

 

Surcharge

 

Bargaining

EIN/Pension

Zone Status

Pending Or

(amounts in millions)

Surcharge

Bargaining

Pension Fund

 

Plan Number

 

2018

 

2017

 

Implemented

 

2018

 

2017

 

2016

 

Imposed

 

Agreement

Plan Number

2019

2018

Implemented

2019(b)

2018(b)

2017

Imposed

Agreement

The Pension, Hospitalization and Benefit Plan of the Electrical Industry - Pension Trust Fund

 

13-6123601/001

 

Green

 

Green

 

N/A

 

$

12.2 

 

$

16.0 

 

$

15.8 

(a)

 

No

 

4/30/2019

13-6123601/001

Green

Green

N/A

$

9.3

$

12.2

$

16.0

(a)

No

4/13/2022

Carpenters Pension Trust Fund for Northern California

 

94-6050970

 

Red

 

Red

 

Implemented

 

4.9 

 

 

8.2 

 

 

4.4 

 

 

No

 

6/30/2019

94-6050970

Red

Red

Implemented

4.0

4.9

8.2

No

6/30/2023

Excavators Union Local 731 Pension Fund

 

13-1809825/002

 

Green

 

Green

 

N/A

 

4.1 

 

 

4.3 

 

 

4.2 

 

 

No

 

4/30/2022

13-1809825/002

Green

Green

N/A

5.1

4.1

4.3

No

4/30/2022

Northern California Electrical Workers Pension Plan

 

94-6062674

 

Green

 

Green

 

N/A

 

4.1 

 

 

5.2 

 

 

1.5 

 

 

No

 

5/31/2022

94-6062674

Green

Green

N/A

3.0

4.1

5.2

No

5/31/2022

Laborers Pension Trust Fund for Northern California

 

94-6277608

 

Green

 

Yellow

 

N/A

 

3.8 

 

 

6.6 

 

 

5.6 

 

 

No

 

6/30/2019

94-6277608

Green

Green

N/A

3.4

3.8

6.6

No

6/30/2023

Steamfitters Industry Pension Fund

 

13-6149680/001

 

Green

 

Green

 

N/A

 

3.5 

 

 

3.9 

(a)

 

3.9 

(a)

 

No

 

6/30/2020

13-6149680/001

Green

Green

N/A

1.7

3.5

3.9

(a)

No

6/30/2020

_____________________________________________________________________________________________________________

(a)

These amounts exceeded 5% of the respective total plan contributions.

(b)

The Company's contributions as a percentage of total plan contributions were not available for the 2018 plan year for any of the above pension funds nor the 2017 plan year for The Pension, Hospitalization and Benefit Plan of the Electrical Industry - Pension Trust Fund.

(a)These amounts exceeded 5% of the respective total plan contributions.

(b)The Company's contributions as a percentage of total plan contributions were not available for the 2019 and 2018 plan years for any of the above pension funds, excluding Excavators Union Local 731 Pension Fund, Northern California Electrical Workers Pension Plan and Steamfitters Industry Pension Fund for the 2018 plan year.

In addition to the individually significant plans described above, the Company also contributed approximately $31.4 million in 2019, $29.3 million in 2018 and $27.8 million in 2017 and $48.3 million in 2016 to other multiemployer pension plans. Funding for these payments is principally provided for in the contracts with our customers.

12.13.     Fair Value Measurements

The fair value hierarchy established by ASC 820 prioritizes the use of inputs used in valuation techniques into the following three levels:

     Level 1 inputs are observable quoted prices in active markets for identical assets or liabilities

     Level 2 inputs are observable, either directly or indirectly, but are not Level 1 inputs

     Level 3 inputs are unobservable

F-38


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following fair value hierarchy table presents the Company’s assets that are measured at fair value on a recurring basis as of December 31, 20182019 and 2017:2018:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31, 2018

 

As of December 31, 2017

As of December 31, 2019

As of December 31, 2018

Fair Value Hierarchy

 

 

 

 

Fair Value Hierarchy

 

 

 

Fair Value Hierarchy

Fair Value Hierarchy

(in thousands)

 

Level 1

 

Level 2

 

Level 3

 

Total

 

Level 1

 

Level 2

 

Level 3

 

Total

Level 1

Level 2

Level 3

Total

Level 1

Level 2

Level 3

Total

Cash and cash equivalents(a)

 

$

116,075 

 

$

 —

 

$

 —

 

$

116,075 

 

$

192,868 

 

$

 —

 

$

 —

 

$

192,868 

$

193,685

$

$

$

193,685

$

116,075

$

$

$

116,075

Restricted cash(a)

 

 

3,788 

 

 

 —

 

 

 —

 

 

3,788 

 

 

4,780 

 

 

 —

 

 

 —

 

 

4,780 

8,416

8,416

3,788

3,788

Restricted investments(b)

 

 

 —

 

 

58,142 

 

 

 —

 

 

58,142 

 

 

 —

 

 

 —

 

 

 —

 

 

 —

70,974

70,974

58,142

58,142

Investments in lieu of retainage(c)

 

 

62,858 

 

 

1,190 

 

 

 —

 

 

64,048 

 

 

69,891 

 

 

2,405 

 

 

 —

 

 

72,296 

89,572

1,219

90,791

62,858

1,190

64,048

Total

 

$

182,721 

 

$

59,332 

 

$

 —

 

$

242,053 

 

$

267,539 

 

$

2,405 

 

$

 —

 

$

269,944 

$

291,673

$

72,193

$

$

363,866

$

182,721

$

59,332

$

$

242,053

_____________________________________________________________________________________________________________

(a)Includes money market funds and short-term investments with original maturity dates of three months or less.less when acquired.

(b)During 2018, the Company reclassified its restricted investments from the held-to-maturity category to the available-for-sale category as a result of a change in management’s investment strategy. At the time of the transfer, the securities had an aggregate amortized cost of $60.1 million and an immaterial aggregate unrealized loss. Restricted investments, as of December 31, 2018,2019, consist of investments in corporate debt securities of $30.4$35.8 million, and U.S. government agency securities of $27.7$33.8 million and corporate certificates of deposits of $1.4 million with maturities of up to five years, and are valued based on pricing models, which are determined from a compilation of primarily observable market information, broker quotes in non-active markets or similar assets and are therefore classified as Level 2 Assets.assets. As of December 31, 2017,2018, restricted investments consisted of investments in U.S. agency securities of $26.1 million and corporate debt securities of $33.0 million.$30.4 million and U.S. government agency securities of $27.7 million with maturities of up to five years. The amortized cost of these available-for-sale securities at December 31, 20182019 and 20172018 was not materially different from the fair value.

F-35(c)Investments in lieu of retainage are included in retainage receivable and as of December 31, 2019 are comprised of money market funds of $89.6 million and municipal bonds of $1.2 million. The fair values of the money market funds are measured using quoted market prices; therefore, they are classified as Level 1 assets. The fair values of municipal bonds are measured using readily available pricing sources for comparable instruments; therefore, they are classified as Level 2 assets. As of December 31, 2018, investments in lieu of retainage consisted of money market funds of $62.9 million and municipal bonds of $1.2 million. The amortized cost of these available-for-sale securities at December 31, 2019 and 2018 was not materially different from the fair value.


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

(c)

Investments in lieu of retainage are included in retainage receivable and as of December 31, 2018 are comprised of money market funds of $62.9 million and municipal bonds of $1.2 million. The fair values of the money market funds are measured using quoted market prices; therefore, they are classified as Level 1 assets. The fair values of municipal bonds are measured using readily available pricing sources for comparable instruments; therefore, they are classified as Level 2 assets. As of December 31, 2017, investments in lieu of retainage consisted of money market funds of $69.9 million and municipal bonds of $2.4 million. The amortized cost of these available-for-sale securities at December 31, 2018 and 2017 was not materially different from the fair value.

The Company did not have material transfers between Levels 1 and 2 during the years ended December 31, 20182019 and 2017.2018.

The carrying values of receivables, payables and other amounts arising out of normal contract activities, including retainage, which may be settled beyond one year, are estimated to approximate fair value. Of the Company’s long-term debt, the fair value of the 2017 Senior Notes was $466.8$485.0 million and $537.5$466.8 million as of December 31, 20182019 and 2017,2018, respectively. The fair value of the Convertible Notes was $184.4$193.4 million and $222.2$184.4 million as of December 31, 20182019 and 2017,2018, respectively. The fair values of the 2017 Senior Notes and Convertible Notes were determined using Level 1 inputs, specifically current observable market prices. The reported value of the Company’s remaining borrowings approximates fair value as of December 31, 20182019 and 2017.2018.

13.During the year ended December 31, 2019, the Company acquired an additional 25% interest in a Civil segment joint venture. The Company’s 50% ownership interest prior to the acquisition was accounted for under the proportionate consolidation method and had a carrying value of $3.2 million. Through this acquisition, the Company’s interest increased from 50% to 75%, and it obtained a controlling financial interest in the joint venture, thereby requiring consolidation by the Company. The transaction was accounted for as a business combination achieved in stages, and under ASC 805, Business Combinations, the previously held equity interest in the joint venture was remeasured at the acquisition date fair value with the resulting gain of $37.8 million recognized in earnings, which was included in general and administrative expenses in the Company’s Consolidated Statement of Operations. The fair value of the joint venture and the Company’s existing investment therein was determined based on the fair value of the underlying assets and liabilities acquired by applying an income approach that used discounted future estimated cash flows based on projected revenues, expenses and weighted-average cost of capital. The fair value of the assets and liabilities of the joint venture was recognized in the Company’s consolidated financial statements as of the acquisition date with the 25% interest not owned by the Company recorded as a noncontrolling interest. The acquisition resulted in the recording of an intangible asset for construction contract backlog of $75.6 million. The fair values of the other assets acquired and liabilities assumed were not material. Pro forma results of operations for this acquisition of additional interest in the joint venture have not been presented because they are not material to the Company’s results of operations.

14.     Variable Interest Entities (VIEs)

The Company may form joint ventures or partnerships with third parties for the execution of single contracts or projects. In accordance with ASC 810, the Company assesses its partnerships and joint ventures at inception to determine if any meet the qualifications of a VIE. The Company considers a joint venture a VIE if either (a) the total equity investment is not sufficient to permit the entity to finance its

F-39


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

activities without additional subordinated financial support, (b) characteristics of a controlling financial interest are missing (either the ability to make decisions through voting or other rights, the obligation to absorb the expected losses of the entity or the right to receive the expected residual returns of the entity), or (c) the voting rights of the equity holders are not proportional to their obligations to absorb the expected losses of the entity and/or their rights to receive the expected residual returns of the entity, and substantially all of the entity’s activities either involve or are conducted on behalf of an investor that has disproportionately few voting rights. Upon the occurrence of certain events outlined in ASC 810, the companyCompany reassesses its initial determination of whether the joint venture is a VIE.

ASC 810 also requires the Company to determine whether it is the primary beneficiary of the VIE. The Company concludes that it is the primary beneficiary and consolidates the VIE if the Company has both (a) the power to direct the economically significant activities of the VIE and (b) the obligation to absorb losses of, or the right to receive benefits from, the VIE that could potentially be significant to the VIE. The Company considers the contractual agreements that define the ownership structure, distribution of profits and losses, risks, responsibilities, indebtedness, voting rights and board representation of the respective parties in determining if the Company is the primary beneficiary. The Company also considers all parties that have direct or implicit variable interests when determining whether it is the primary beneficiary. In accordance with ASC 810, management’s assessment of whether the Company is the primary beneficiary of a VIE is performed continuously.

As of December 31, 2019, the Company had unconsolidated VIE-related current assets and liabilities of $1.5 million and $1.4 million, respectively, included in the Company’s Consolidated Balance Sheet. As of December 31, 2018, the Company had unconsolidated VIE-related current assets and liabilities of $4.0 million and $3.8 million, respectively, included in the Company’s Consolidated Balance Sheet. As of December 31, 2017, the Company had unconsolidated VIE-related current assets and liabilities each of $0.8 million, included in the Company’s Consolidated Balance Sheet. The Company’s maximum exposure to loss as a result of its investments in unconsolidated VIEs is typically limited to the aggregate of the carrying value of the investment and future funding commitments. There were no future funding requirements for the unconsolidated VIEs as of December 31, 2018.2019.

As of December 31, 2019, the Company’s Consolidated Balance Sheet included current and noncurrent assets of $365.0 million and $52.0 million, respectively, as well as current liabilities of $556.1 million related to the operations of its consolidated VIEs. As of December 31, 2018, the Company’s Consolidated Balance Sheet included current and noncurrent assets of $173.9 million and $51.5 million, respectively, as well as current liabilities of $319.9 million related to the operations of its consolidated VIEs. As of December 31, 2017, the Company’s Consolidated Balance Sheet included current and noncurrent assets of $95.5 million and $11.6 million, respectively, as well as current liabilities of $140.7 million related to the operations of its consolidated VIEs.

Below is a discussion of some of the Company’s more significant or unique VIEs.

The Company established a joint venture to construct the Purple Line Extension Section 2 Extension project, a $1.4 billion(Tunnels and Stations) and Section 3 (Stations) mass-transit projectprojects in Los Angeles, California.California with a combined value of approximately $2.8 billion. The Company has a 75% interest in the joint venture with the remaining 25% held by O&G Industries, Inc. (“O&G”). The joint venture was initially financed with contributions from the partners and, per the terms of the joint venture agreement, the partners may be required to provide additional capital contributions in the future. The Company has determined that this joint venture is a VIE for which the Company is the primary beneficiary.

F-36


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The Company also established a joint venture with Parsons Corporation (“Parsons”) to construct the Newark Liberty International Airport Terminal One project, a $1.4 billion transportation infrastructure project in Newark, New Jersey. The Company has an 80% interest in the joint venture with the remaining 20% held by Parsons. The joint venture was initially financed with contributions from the partners and, per the terms of the joint venture agreement, the partners may be required to provide additional capital contributions in the future. The Company has determined that this joint venture is a VIE for which the Company is the primary beneficiary.

14.15.     Business Segments

The Company offers general contracting, pre-construction planning and comprehensive project management services, including planning and scheduling of manpower, equipment, materials and subcontractors required for the timely completion of a project in accordance with the terms and specifications contained in a construction contract. The Company also offers self-performed construction services: site work, concrete forming and placement, steel erection, electrical, mechanical, plumbing, and HVAC (heating, ventilation and air conditioning). As described below, the Company’s business is conducted through three3 segments: Civil, Building and Specialty Contractors. These segments are determined based on how the Company’s Chairman and Chief Executive Officer (chief operating decision maker) aggregates business units when evaluating performance and allocating resources.

The Civil segment specializes in public works construction and the replacement and reconstruction of infrastructure. The contracting services provided by the Civil segment include construction and rehabilitation of highways, bridges, tunnels, mass-transit systems, and water management and wastewater treatment facilities.

F-40


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The Building segment has significant experience providing services for private and public works customers in a number of specialized building markets, including: high-rise residential, hospitality and gaming, transportation, health care, commercial and government offices, sports and entertainment, education, correctional facilities, biotech, pharmaceutical, industrial and high-tech.technology.

The Specialty Contractors segment specializes in electrical, mechanical, plumbing, HVAC, fire protection systems and pneumatically placed concrete for a full range of civil and building construction projects in the industrial, commercial, hospitality and gaming, and mass-transit end markets. This segment provides the Company with unique strengths and capabilities that allow the Company to position itself as a full-service contractor with greater control over scheduled work, project delivery, and cost and risk management.

To the extent that a contract is co-managed and co-executed among segments, the Company allocates the share of revenues and costs of the contract to each segment to reflect the shared responsibilities in the management and execution of the project.

F-37


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

The following tables set forth certain reportable segment information relating to the Company’s operations for the years ended December 31, 2019, 2018 2017 and 2016:2017:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segments

 

 

 

 

 

Reportable Segments

 

 

 

 

Specialty

 

Segment

 

 

 

Consolidated

Specialty

Segment

Consolidated

(in thousands)

Civil

 

Building

 

Contractors

 

Total

 

Corporate

 

Total

Civil

Building

Contractors

Total

Corporate

Total

Year ended December 31, 2019

Total revenue

$

2,054,097

$

1,764,753

$

929,738

$

4,748,588

$

$

4,748,588

Elimination of intersegment revenue

(274,745)

(22,713)

(298)

(297,756)

(297,756)

Revenue from external customers

$

1,779,352

$

1,742,040

$

929,440

$

4,450,832

$

$

4,450,832

Income (loss) from construction operations(a)

$

(150,837)

$

23,655

$

(172,637)

$

(299,819)

$

(65,188)

(b)

$

(365,007)

Capital expenditures

$

82,156

$

518

$

688

$

83,362

$

834

$

84,196

Depreciation and amortization(c)

$

47,905

$

1,934

$

4,136

$

53,975

$

11,069

$

65,044

Year ended December 31, 2018

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenue

$

1,810,232 

 

$

1,866,902 

 

$

1,006,870 

 

$

4,684,004 

 

$

 —

 

$

4,684,004 

$

1,810,232

$

1,866,902

$

1,006,870

$

4,684,004

$

$

4,684,004

Elimination of intersegment revenue

 

(224,139)

 

 

(5,203)

 

 

 —

 

 

(229,342)

 

 

 —

 

(229,342)

(224,139)

(5,203)

(229,342)

(229,342)

Revenue from external customers

$

1,586,093 

 

$

1,861,699 

 

$

1,006,870 

 

$

4,454,662 

 

$

 —

 

$

4,454,662 

$

1,586,093

$

1,861,699

$

1,006,870

$

4,454,662

$

$

4,454,662

Income (loss) from construction operations(a)

$

168,256 

 

$

43,939 

 

$

43,430 

 

$

255,625 

 

$

(63,749)

(b)

$

191,876 

Income (loss) from construction operations(d)

$

168,256

$

43,939

$

43,430

$

255,625

$

(63,749)

(b)

$

191,876

Capital expenditures

$

73,866 

 

$

1,655 

 

$

777 

 

$

76,298 

 

$

771 

 

$

77,069 

$

73,866

$

1,655

$

777

$

76,298

771

77,069

Depreciation and amortization(c)

$

29,685 

 

$

1,956 

 

$

4,358 

 

$

35,999 

 

$

11,268 

 

$

47,267 

$

29,685

$

1,956

$

4,358

$

35,999

$

11,268

$

47,267

Year ended December 31, 2017

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenue

$

1,856,164 

 

$

1,982,857 

 

$

1,213,708 

 

$

5,052,729 

 

$

 —

 

$

5,052,729 

$

1,856,164

$

1,982,857

$

1,213,708

$

5,052,729

$

$

5,052,729

Elimination of intersegment revenue

 

(253,989)

 

 

(41,532)

 

 

 —

 

 

(295,521)

 

 

 —

 

(295,521)

(253,989)

(41,532)

(295,521)

(295,521)

Revenue from external customers

$

1,602,175 

 

$

1,941,325 

 

$

1,213,708 

 

$

4,757,208 

 

$

 —

 

$

4,757,208 

$

1,602,175

$

1,941,325

$

1,213,708

$

4,757,208

$

$

4,757,208

Income (loss) from construction operations(d)

$

192,207 

 

$

34,199 

 

$

18,938 

 

$

245,344 

 

$

(65,867)

(b)

$

179,477 

$

192,207

$

34,199

$

18,938

$

245,344

$

(65,867)

(b)

$

179,477

Capital expenditures

$

27,694 

 

$

267 

 

$

721 

 

$

28,682 

 

$

1,598 

 

$

30,280 

$

27,694

$

267

$

721

$

28,682

$

1,598

$

30,280

Depreciation and amortization(c)

$

33,767 

 

$

2,021 

 

$

4,699 

 

$

40,487 

 

$

11,443 

 

$

51,930 

$

33,767

$

2,021

$

4,699

$

40,487

$

11,443

$

51,930

Year ended December 31, 2016

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Total revenue

$

1,830,857 

 

$

2,146,747 

 

$

1,234,272 

 

$

5,211,876 

 

$

 —

 

$

5,211,876 

Elimination of intersegment revenue

 

(161,894)

 

 

(76,906)

 

 

 —

 

 

(238,800)

 

 

 —

 

(238,800)

Revenue from external customers

$

1,668,963 

 

$

2,069,841 

 

$

1,234,272 

 

$

4,973,076 

 

$

 —

 

$

4,973,076 

Income (loss) from construction operations(d)

$

172,668 

 

$

51,564 

 

$

37,908 

 

$

262,140 

 

$

(60,220)

(b)

$

201,920 

Capital expenditures

$

13,541 

 

$

516 

 

$

1,005 

 

$

15,062 

 

$

681 

 

$

15,743 

Depreciation and amortization(c)

$

48,561 

 

$

2,186 

 

$

5,035 

 

$

55,782 

 

$

11,520 

 

$

67,302 

_____________________________________________________________________________________________________________

(a)During the year ended December 31, 2019, the Company recorded a non-cash goodwill impairment charge of $379.9 million in income (loss) from construction operations (an after-tax impact of $330.5 million, or $6.58 per diluted share) resulting from an interim impairment test the Company performed as of June 1, 2019. For further information and breakdown of the goodwill impairment charge by segment, see Note 6. In addition, during the year ended December 31, 2019 the Company recorded a charge of $166.8 million in income (loss) from construction operations (an after-tax impact of $119.4 million, or $2.38 per diluted share), which principally impacted the Civil segment, as a result of the adverse jury verdict on the Alaskan Way Viaduct Matter, as discussed in Note 8. Lastly, the Company recognized a one-time gain of $37.8 million (an after-tax impact of $27.1 million, or $0.54 per diluted share) in Civil segment general and administrative expenses related to a remeasurement of its investment in a joint venture (see Note 13).

(b)Consists primarily of corporate general and administrative expenses.

(c)Depreciation and amortization is included in income (loss) from construction operations.

(d)During the year ended December 31, 2018, the Company recorded a charge of $17.8 million in income (loss) from construction operations (an after-tax impact of $12.8 million, or $0.25 per diluted share), which was primarily non-cash, as a result of the unexpected adverse outcome of an arbitration decision related to a subcontract back charge dispute on a Civil segment project in New York that was completed in 2013.

(a)

During the year ended December 31,  2018, the Company recorded a charge of $17.8 million in income from construction operations (an after-tax impact of $12.8 million, or $0.25 per diluted share), which was primarily non-cash, as a result of the unexpected outcome of an arbitration decision related to a subcontract back charge dispute on a Civil segment project in New York that was completed in 2013.

(b)

Consists primarily of corporate general and administrative expenses.

F-41


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

(c)

Depreciation and amortization is included in income from construction operations.

(d)

During the year ended December 31, 2016 the Company recorded net favorable adjustments totaling $3.0 million in income from construction operations (an after-tax impact of $1.8 million, or $0.04 per diluted share) for various Five Star Electric projects in New York in the Specialty Contractors segment. The net impact included material adjustments related to two electrical subcontract projects: a favorable adjustment of $14.0 million for a completed project (an after-tax impact of $8.2 million, or $0.17 per diluted share) and an unfavorable adjustment of $13.8 million for a project that was nearly complete (an after-tax impact of $8.1 million, or $0.16 per diluted share).

The above were the only changes in estimates considered material to the Company’s results of operations during the periods presented herein.

Total assets by segment arewere as follows:



 

 

 

 

 



 

 

 

 

 



As of December 31,

(in thousands)

2018

 

2017

Civil

$

2,574,326 

 

$

2,452,108 

Building

 

913,746 

 

 

909,207 

Specialty Contractors

 

745,313 

 

 

767,807 

Corporate and other(a)

 

154,367 

 

 

135,001 

Total assets

$

4,387,752 

 

$

4,264,123 

(a)

Consists principally of cash, equipment, tax-related assets and insurance-related assets, offset by the elimination of assets related to intersegment revenue.

As of December 31,

(in thousands)

2019

2018

Civil

$

2,791,402

$

2,574,326

Building

995,298

913,746

Specialty Contractors

635,180

745,313

Corporate and other(a)

63,897

154,367

Total assets

$

4,485,777

$

4,387,752

_____________________________________________________________________________________________________________

(a)Consists principally of cash, equipment, tax-related assets and insurance-related assets, offset by the elimination of assets related to intersegment revenue.

F-38


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

Geographic Information

Information concerning principal geographic areas is as follows:

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

2018

 

2017

 

2016

2019

2018

2017

Revenue:

 

 

 

 

 

 

United States

$

4,180,206 

 

$

4,613,644 

 

$

4,802,393 

$

4,073,691

$

4,180,206

$

4,613,644

Foreign and U.S. territories

 

274,456 

 

143,564 

 

170,683 

377,141

274,456

143,564

Total revenue

$

4,454,662 

 

$

4,757,208 

 

$

4,973,076 

$

4,450,832

$

4,454,662

$

4,757,208

 

 

 

 

 

 

 

 

As of December 31,

As of December 31,

(in thousands)

2018

 

2017

2019

2018

Assets:

 

 

 

 

United States

$

4,225,143 

 

$

4,093,673 

$

4,271,722

$

4,225,143

Foreign and U.S. territories

 

162,609 

 

170,450 

214,055

162,609

Total assets

$

4,387,752 

 

$

4,264,123 

$

4,485,777

$

4,387,752

Reconciliation of Segment Information to Consolidated Amounts

A reconciliation of segment results to the consolidated income (loss) before income taxes is as follows:

 

 

 

 

 

 

 

Year Ended December 31,

Year Ended December 31,

(in thousands)

2018

 

2017

 

2016

2019

2018

2017

Income from construction operations

$

191,876 

 

$

179,477 

 

$

201,920 

Income (loss) from construction operations

$

(365,007)

$

191,876

$

179,477

Other income, net

 

4,256 

 

43,882 

 

6,977 

6,667

4,256

43,882

Interest expense

 

(63,519)

 

(69,384)

 

(59,782)

(67,494)

(63,519)

(69,384)

Income before income taxes

$

132,613 

 

$

153,975 

 

$

149,115 

Income (loss) before income taxes

$

(425,834)

$

132,613

$

153,975

15.

16.     Related Party Transactions

The Company leases, at market rates, certain facilities from an entity owned by Ronald N. Tutor, the Company’s Chairman and Chief Executive Officer. Under these leases, the Company paid $3.1 million in 2019, $3.0 million in 2018 and $2.8 million in both 2017, and 2016, and recognized expense of $3.2 million in each of the three years.

Raymond R. Oneglia, Vice Chairman of O&G, is a director of the Company. The Company occasionally forms construction project joint ventures with O&G. During the three years ended December 31, 2018,2019, the Company had active joint ventures with O&G including two infrastructure projects in the northeastern United States that were completed in 2017 and one2 mass-transit projects in Los Angeles, California to construct the Purple Line Extension Section 2 Extension project in Los Angeles, California(Tunnels and Stations) and Section 3 (Stations), in which the Company’s and O&G’s joint venture interests are 75% and 25%, respectively. O&G may provide equipment and services to these

F-42


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

joint ventures on customary trade terms; there were no material payments made by these joint ventures to O&G for services and equipment during the years ended December 31, 2019, 2018 2017 and 2016.2017.

Peter Arkley, Senior Managing Director, Construction Services Group, of Alliant Insurance Services, Inc. (“Alliant”), is a director of the Company. The Company uses Alliant for various insurance-related services. The associated expenses for services provided for the years ended December 31, 2019, 2018 and 2017 and 2016 were $18.4 million, $14.7 million $17.6 million and $8.9$17.6 million, respectively. The Company owed Alliant $4.1$2.7 million and $0.5$4.1 million as of December 31, 20182019 and 2017,2018, respectively, for services rendered.

F-39


Table of Contents

TUTOR PERINI CORPORATION AND SUBSIDIARIES

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS (Continued)

16.17.     Unaudited Quarterly Financial Data

The following table presents selected unaudited quarterly financial data for each full quarterly period of 20182019 and 2017:2018:

(in thousands, except per common share amounts)

First

Second

Third

Fourth

Year Ended December 31, 2019

Quarter

Quarter

Quarter

Quarter

Revenue

$

958,487

$

1,125,275

$

1,189,345

$

1,177,725

Gross profit (loss)

88,470

100,943

115,063

(62,704)

Income (loss) from construction operations

22,913

(341,717)

47,943

(94,146)

Income (loss) before income taxes

6,910

(358,339)

32,312

(106,717)

Net income (loss)

4,722

(315,439)

26,721

(76,229)

Net income (loss) attributable to Tutor Perini Corporation

(356)

(320,530)

19,313

(86,117)

Earnings (loss) per common share:

Basic

$

(0.01)

$

(6.38)

$

0.38

$

(1.71)

Diluted

$

(0.01)

$

(6.38)

$

0.38

$

(1.71)

(in thousands, except per common share amounts)

First

Second

Third

Fourth

Year Ended December 31, 2018

Quarter

Quarter

Quarter

Quarter

Revenue

$

1,028,156

$

1,120,085

$

1,123,137

$

1,183,284

Gross profit

67,068

118,640

111,124

157,621

Income (loss) from construction operations

(925)

54,815

47,306

90,680

Income (loss) before income taxes

(15,210)

39,867

32,804

75,152

Net income (loss)

(10,942)

27,896

25,436

55,391

Net income (loss) attributable to Tutor Perini Corporation

(12,124)

24,883

21,272

49,405

Earnings (loss) per common share:

Basic

$

(0.24)

$

0.50

$

0.43

$

0.99

Diluted

$

(0.24)

$

0.49

$

0.42

$

0.98



 

 

 

 

 

 

 

 

 

 

 

 



 

 

 

 

 

 

 

 

 

 

 

 

(in thousands, except per common share amounts)

 

First

 

Second

 

Third

 

Fourth

Year Ended December 31, 2017

 

Quarter

 

Quarter

 

Quarter

 

Quarter

Revenue

 

$

1,117,361 

 

$

1,247,274 

 

$

1,199,505 

 

$

1,193,068 

Gross profit

 

 

102,720 

 

 

102,838 

 

 

118,251 

 

 

130,596 

Income from construction operations

 

 

37,017 

 

 

34,045 

 

 

49,072 

 

 

59,343 

Income before income taxes

 

 

21,870 

 

 

52,516 

 

 

34,396 

 

 

45,193 

Net income

 

 

13,764 

 

 

32,633 

 

 

25,300 

 

 

82,847 

Net income attributable to Tutor Perini Corporation

 

 

13,764 

 

 

30,096 

 

 

23,584 

 

 

80,938 

Earnings per common share:

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

0.28 

 

$

0.61 

 

$

0.47 

 

$

1.63 

Diluted

 

$

0.27 

 

$

0.59 

 

$

0.47 

 

$

1.60 

F-43

F-40