Table of Contents

 

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

 


 

FORM 10-K

 

(Mark One)

 

x      ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the fiscal year ended December 31, 20142017

 

OR

 

o         TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

 

For the transition period from                  to           

 

Commission file number: 0001-34145001-34145

 

Primoris Services Corporation

(Exact name of registrant as specified in its charter)

 

Delaware

Delaware

20-4743916

(State or other jurisdiction of

 

(I.R.S. Employer

incorporation or organization)

 

Identification No.)

 

2100 McKinney Avenue, Suite 1500

Dallas, Texas

75201

(Address of principal executive offices)

 

(Zip Code)

 

(214) 740-5600

(Registrant’s telephone number, including area code)

 

Securities registered pursuant to Section 12(b) of the Act:

 

Title of each class

Name of exchange on which registered

Common Stock, $0.0001 par value

 

The NASDAQ Stock Market LLC

 

Securities registered pursuant to Section 12(g) of the Act: None

 

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act.  Yes x  No o

 

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Act.  Yes o  No x

 

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.  Yes x  No o

 

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§ 229.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).  Yes x  No o

 

Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of registrant’s knowledge, in definitive proxy or information statements incorporated by reference in Part III in this Form 10-K or any amendment to this Form 10-K. o

 

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company, (as definedor an emerging growth company. See the definitions of “large accelerated filer,” “accelerated filer,” “smaller reporting company,” and “emerging growth company” in Rule 12b-2 of the Exchange Act).Act.

 

Large accelerated filer x

Accelerated filer o

 

 

 

Large accelerated filer ☒

Accelerated filer ☐

Non-accelerated filer o

Smaller reporting company ☐

 

Smaller Reporting Company o(Do not check if a
smaller reporting company)

Emerging growth company ☐

 

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).  Yes o  No x

 

The aggregate market value of the voting common equity held by non-affiliates of the registrant was approximately $1,157.7 million$1.02 billion based upon the closing price of such common equity as of June 30, 20142017 (the last business day of the Registrant’s most recently completed second fiscal quarter). On March 16, 2015,February 26, 2018, there were 51,569,56451,531,339 shares of common stock, par value $0.0001, outstanding. For purposes of this Annual Report on Form 10-K, in addition to those stockholders which fall within the definition of “affiliates” under Rule 405 of the Securities Act of 1933, holders of ten percent or more of the Registrant’s common stock are deemed to be affiliates.

 


 



Table of Contents

TABLE OF CONTENTS

 

Page

Part I

Page

Item 1.Part I

Business

2

Item 1.

Business

4

Item 1A.

Risk Factors

10

11

Item 1B.

Unresolved Staff Comments

21

24

Item 2.

Properties

21

24

Item 3.

Legal Proceedings

22

25

Item 4.

Mine Safety Disclosures

23

25

 

 

 

Part II

 

 

Item 5.

Market for Registrant’s Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities

23

26

Item 6.

Selected Financial Data

27

29

Item 7.

Management’s Discussion and Analysis of Financial Condition and Results of Operations

28

30

Item 7A.

Quantitative and Qualitative Disclosures About Market Risk

48

56

Item 8.

Financial Statements and Supplementary Data

49

56

Item 9.

Changes In and Disagreements With Accountants on Accounting and Financial Disclosure

49

56

Item 9A.

Controls and Procedures

49

56

Item 9B.

Other Information

50

58

 

 

 

Part III

 

 

Item 10.

Directors, Executive Officers and Corporate Governance

51

59

Item 11.

Executive Compensation

51

60

Item 12.

Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters

51

60

Item 13.

Certain Relationships and Related Transactions, and Director Independence

51

60

Item 14.

Principal Accounting Fees and Services

51

60

 

 

 

Part IV

 

 

Item 15.

Exhibits and Financial Statement Schedules

52

Signatures

58

61

 

 

Signatures

65

Index to Consolidated Financial Statements

F-1

 

1


2



FORWARD-LOOKING STATEMENTS

 

This Annual Report on Form 10-K contains forward-looking statements within the meaning of Section 27A of the Securities Act of 1933, as amended (the “Securities Act”), and Section 21E of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), which are subject to the “safe harbor” created by those sections. Forward-looking statements include information concerning our possible or assumed future results of operations, business strategies, financing plans, competitive position, industry environment, potential growth opportunities, the effects of regulation and the economy, generally. Forward-looking statements include all statements that are not historical facts and usually can be identified by terms such as “anticipates,” “believes,” “could,” “estimates,” “expects,” “intends,” “may,” “plans,” “potential,” “predicts,” “projects,” “should,” “will,” “would” or similar expressions.

 

Forward-looking statements involve known and unknown risks, uncertainties and other factors which may cause our actual results, performance or achievements to be materially different from any future results, performance or achievements expressed or implied by the forward-looking statements. We discuss many of these risks in detail in “Item 1A. Risk Factors”.  You should read this Annual Report on Form 10-K completely and with the understanding that our actual future results may be materially different from what we expect.

 

Given these uncertainties, you should not place undue reliance on forward-looking statements.  Forward-looking statements represent our management’s beliefs and assumptions only as of the date of this Annual Report on Form 10-K.  We assume no obligation to update forward-looking statements publicly, or to update the reasons actual results could differ materially from those anticipated in any forward-looking statements, even if new information becomes available.

3


PART I

 

PART I

ITEM 1.  BUSINESS

 

Business Overview

 

Primoris Services Corporation (“Primoris”, the “Company”, “we”, “us”, or “our”) is a holding company of various subsidiaries which form one of the larger publicly traded specialty constructioncontractors and infrastructure companies in the United States. Serving diverse end-markets, we provide a wide range of construction, fabrication, maintenance, replacement, water and wastewater, and engineering services to major public utilities, petrochemical companies, energy companies, municipalities, state departments of transportation and other customers. Growing both organically and through acquisitions, Primoris has more than doubled its revenues since 2010.  The Company’s national footprint now extends nearly nationwide and into Canada.

We install, replace, repair and rehabilitate natural gas, refined product, water and wastewater pipeline systems; large diameter gas and liquid pipeline facilities; and heavy civil projects, earthwork and site development. We also construct mechanical facilities and other structures, including power plants, petrochemical facilities, refineries, water and wastewater treatment facilities and parking structures. Finally, we provide specialized process and product engineering services.

 

The Company’sHistorically, we have longstanding relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the United States, as well as significant projects for our engineering customers. We enter into a large number of contracts each year and the projects can vary in length from several weeks to as long as 60 months, or longer for completion of larger projects. Although we have not been dependent upon any one customer, in any year a small number of customers tend to constitute a substantial portion of our total revenues.

Our common stock trades on the NASDAQ Select Global Market under the symbol “PRIM”.  Founded as ARB, Inc. (“ARB”) in 1960, we became organized as Primoris in Nevada in 2003, and we became a Delaware public company in July 2008 when we merged with a special purpose acquisition company (a non-operating shell)shell company).

 

Our service capabilities and geographic footprint have expanded primarily through the following four acquisitions.significant acquisitions over the last nine years.

 

In 2009, we acquired James Construction Group, LLC, a privately-held Florida limited liability company (“JCG”).  Headquartered in Baton Rouge, Louisiana, JCG is one of the largest general contractors based in the Gulf Coast states and is engaged in highway, industrial and environmental construction, primarily in Louisiana, Texas, Arkansas, Mississippi and Florida.  JCG is the successorand its predecessor company to T. L. James and Company, Inc., a Louisiana company that hashave been in business for over 80 years.

 

In 2010, we acquired privately-held Rockford Corporation (“Rockford”).  While it is based in Hillsboro (Portland), Oregon,  Rockford specializes in construction of large diameter natural gas and liquid pipeline projects and related facilities throughout the United States.

 

2



Table of Contents

In March 2012, we purchased Sprint Pipeline Services, L.P. (“Sprint”), a Texas based company headquartered in Pearland (outside Houston)near Houston, which we renamed as Primoris Energy Services (“PES”).  SprintPES provides a comprehensive range of pipeline construction, maintenance, upgrade, fabrication and specialty services primarily in the southeastern United States. In accordance with the terms of the purchase agreement, we changed the name of the Sprint operations to “Primoris Pipeline Services” in March 2015.

 

In November 2012, we purchased Q3 Contracting, Inc., a privately-held Minnesota corporation (“Q3C”).  Based in Little Canada, Minnesota (north of St. Paul), Q3C specializes in small diameter pipeline and gas distribution construction, restoration and other services, primarily in the upper Midwest region of the United States.

 

In addition to these primary acquisitions, we have entered into several smaller agreements to purchase smaller businesses or business assets to start a business as we continue to seek opportunities to expand our skill sets or operating locations.  In 2012, we acquiredThese include The Saxon Group (“Saxon”) and The Silva Group (“Silva”) (merged with JCG), and in 2013,which we acquired Force Specialty Services, Inc. (“FSSI”).in 2012.  During 2014 we acquired Vadnais Trenchless Services, Inc. (“Vadnais”) and made three small acquisitions duringconsisting of the third quarter 2014 which consistedpurchase of the net assets of Surber Roustabout, LLC (“Surber”), Ram-Fab, LLC (“Ram-Fab”) and Williams Testing, LLC (“Williams”).  In February 2015, we acquired the net assets of Aevenia, Inc.  In 2016, we further enhanced our market reach with the purchase of the net assets of Mueller Concrete Construction Company (“Mueller”) and Northern Energy & Power (“Northern”).  During 2017, we acquired Florida Gas Contractors (“FGC”), Coastal Field

4


Services (“Coastal”), and a small acquisition of certain engineering assets. We continue to evaluate potential acquisition candidates, especially those with strong management teams with good reputations.

 

Reportable Segments

 

For a number of years and throughThrough the end of the second quarter 2014, the Companyyear 2016, we segregated itsour business into three operatingreportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment and the Engineering segment. In the thirdfirst quarter 2014, the Company reorganized its business2017, we changed our reportable segments to match the change in the Company’sconnection with a realignment of our internal organization and management structure. The segment changes during the quarter reflect the focus of our new chief operating officerdecision maker (“CODM”) on the range of services we provide to our energy related customers, primarily in the Gulf Coast area (the “Energy segment”) and a continuing geographic view for the West and East segments. The chief operating officerend user markets. Our CODM regularly reviews theour operating and financial performance based on these revised segments.

The operatingcurrent reportable segments include:  The West Construction Services segmentinclude the Power, Industrial, and Engineering (“West segment”Power”), which is unchanged from the previous segment, the East Construction ServicesPipeline and Underground (“Pipeline”) segment, (“East segment”), which is realigned from the previous East Construction ServicesUtilities and Distribution (“Utilities”) segment, and the Energy segment (which includes the previous Engineering segment).  AllCivil segment. Segment information for prior period amounts related to the segment change haveperiods has been retrospectively reclassified throughout these consolidated financial statementsrestated to conform to the new segment presentation.

Each of our reportable segments is comprised of similar business units that specialize in services unique to the segment. Driving the new end-user focused segments are differences in the economic characteristics of each segment, the nature of the services provided by each segment; the production processes of each segment; the type or class of customer using the segment’s services; the methods used by the segment to provide the services; and the regulatory environment of each segment’s customers.

The classification of revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our segments may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses, were made.

The following is a brief description of each of the Company’s reportable segments and business activities.segments:

 

The WestPower segment includes the underground and industrial operations and construction services performed by ARB, ARB Structures, Inc., Rockford, Alaska Continental Pipeline, Inc., Q3C, Primoris Renewables, LLC, Juniper Rock Corporation, Stellaris, LLC and Vadnais, acquired in June 2014.  Most of the entities perform work primarily in California; however, Rockford operates throughout the United States and Q3C operates in Colorado and the upper Midwest United States.  The Blythe joint venture is also included as a part of the segment.  The West segment consists of businesses headquartered primarily in the western United States.

The East segment includes the JCG Heavy Civil division, the JCG Infrastructure and Maintenance division, BW Primoris and Cardinal Contractors, Inc. construction business, located primarily in the southeastern United States and in the Gulf Coast region of the United States and includes the heavy civil construction and infrastructure and maintenance operations.

The Energy segment businesses are located primarily in the southeastern United States and in the Gulf Coast region of the United States.  The segment includes the operations of the PES pipeline and gas facility construction and maintenance operations, the JCG Industrial division and the newly acquired Surber and Ram-Fab operations.  Additionally, the segment includes the OnQuest, Inc. and OnQuest Canada, ULC operations for the design and installation of high-performance furnaces and heaters for the oil refining, petrochemical and power generation industries.

Each of the three segments specializes in a range of services that include designing, building/installing, replacing, repairing/rehabilitatingfull Engineering, Procurment, and providing management services forConstruction (“EPC”) project delivery, turnkey construction, related projects. Our services include:

·Providing installation of underground pipeline, cableretrofits, upgrades, repairs, outages, and conduitsmaintenance for entities in the petroleum, petrochemical, water, and water industries;other industries.

 

·ProvidingThe Pipeline segment operates throughout the United States and specializes in a range of services, including pipeline construction, pipeline maintenance, services to utilities for installationpipeline facility work, compressor stations, pump stations, metering facilities, and repair of gas distribution lines;

·Providing installation and maintenance of industrial facilitiesother pipeline related services for entities in the petroleum and petrochemical and water industries;industries.

 

3The Utilities segment operates primarily in California and the Midwest and Southeast regions of the United States and specializes in a range of services, including utility line installation and maintenance, gas and electric distribution, streetlight construction, substation work, and fiber optic cable installation.

The Civil segment operates primarily in the Southeastern and Gulf Coast regions of the United States and specializes in highway and bridge construction, airport runway and taxiway construction, demolition, heavy earthwork, soil stabilization, mass excavation, and drainage projects.

Strategy

Our strategy has remained consistent from year to year and continues to emphasize the following key elements:


·

Diversification Through Controlled Expansion.  We continue to emphasize the expansion of our scope of services beyond our current focus by increasing the scope of services offered to current customers and by adding new customers.  We will evaluate acquisitions that offer growth opportunities and the ability to leverage our resources as a leading service provider to the oil and gas, power, refining and water industries. Our strategy also considers selective expansion to new geographic regions.

5



·

Emphasis on Retention of Existing Customers and Recurring Revenue.  In order to fully leverage our relationships with our existing customer base, we believe it is important to maintain strong customer relationships and to expand our base of recurring revenue sources and recurring customers.

·

Ownership of Equipment.  Many of our services are equipment intensive. The cost of construction equipment, and in some cases the availability of construction equipment, provides a significant barrier to entry into several of our businesses. We believe that our ownership of a large and varied construction fleet and our maintenance facilities enhances our access to reliable equipment at a favorable cost.

·

Stable Work Force.  Our business model emphasizes self-performance of a significant portion of our work.  In each of our separate segments, we maintain a stable work force of skilled, experienced laborers, many of whom are cross-trained in projects such as pipeline and facility construction, refinery maintenance, and piping systems.

·

Selective Bidding.  We selectively bid on projects that we believe offer an opportunity to meet our profitability objectives or that offer the opportunity to enter promising new markets. In addition, we review our bidding opportunities to attempt to minimize concentration of work with any one customer, in any one industry, or in stressed labor markets.  We believe that by carefully positioning ourselves in market segments that have meaningful barriers of entry, we can position ourselves so that we compete with other strong, experienced bidders.

·

Maintain a conservative capital structure and strong balance sheet. We have maintained a capital structure that provides access to debt financing as needed while relying on tangible net worth to provide the primary support for our operations.  We believe this structure provides our customers, our lenders, and our bonding companies assurance of our financial capabilities.  We maintain a revolving credit facility to provide letter of credit capability; however, we have not had any outstanding bank borrowing against this facility while we have been a public company.

Backlog

 

·Providing installation of complex commercial and industrial cast-in-place structures;

·Providing construction of highways and bridges; and

·Providing industrial and environmental construction.

A discussion regarding the revenues and operating results for each segmentBacklog is found indiscussed in Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations” of this Annual Report on Form 10-K.

 

TrendsCustomers

 

We continue to operate in an uncertain business environment with increasing regulatory requirements and only gradual recovery in the economy from the recessionary levels of the past few years.  Economic and regulatory issues have adversely affected our customers and have affected demand for our services.  For some of our customers, the additional uncertainty associated with state and federal budgets adds to the difficulty in predicting the timing or magnitude that industry trends may have on our business, particularly in the near-term.

For our underground services, we are in a period of uncertainty caused by the significant decline in oil prices since the middle of 2014.  We expect that the decline will impact underground pipeline opportunities in oil and gas gathering lines, compressor systems and related infrastructure especially in the shale formations.  In the near term we do not expect a significant decline in mid-stream pipelines as the existing pipeline infrastructure appears to be insufficient to meet the continuing natural gas demand which could lead to opportunities for new pipeline construction.  In many cases, customers have invested significant time and money in obtaining regulatory approval, purchasing raw materials and obtaining end-user agreements for mid-stream lines; therefore, we anticipate that the customers will complete their pipeline projects.  We believe that these integrity testing requirements will increase the demand for our underground services.  We have the ability to offer construction and maintenance of large diameter pipeline and mid-stream pipeline in both our West and Energy segments.

The U.S. Energy Information Administration has stated that the number of natural gas-fired power plants built will increase significantly over the next two decades. While renewable energy generation continues to increase and become a larger percentage of the overall power generation mix, natural gas facilities, especially the conversion of current facilities to more efficient sources of power, will provide a significant contribution to the revenue and profitability of the West segment and over the next few years also the Energy segment.  Regulations limiting the discharge of cooling water into the ocean will require construction of alternative cooling systems and may lead to repowering at current sites over the next four to six years in California.

As many states institute renewable power standards mandating renewable energy generation as a part of the total power usage, large, utility-scale projects will provide construction opportunities over the next few years.  In many locations, the development and construction of solar and wind facilities may result in a need for “peaker” plants to meet demand when the renewable resources are not available.  In addition, alternative energy sources such as “waste-to-power” facilities provide long-term construction opportunities.  The low long-term natural gas prices and the increased emission regulations of the Environmental Protection Agency may result in the construction of gas-fired power plants as an alternative to coal-fired plants.  We believe that our gas-fired plant experience and industry knowledge will provide opportunities for us.

The continuing long-term low cost of natural gas is leading to industrial opportunities as chemical plants that use natural gas as a feedstock initiate new projects or expand current facilities.  Construction for many of these projects is expected in the Louisiana and Texas Gulf coast region which requires significant site preparation work as part of the project.  Both our East and Energy segments provide services to many of the companies planning facility additions.

The low price and abundance of natural gas may also lead to the development and construction of liquid natural gas (LNG) export facilities since natural gas prices in many international markets are greater than those in the United States.  Future export LNG facilities could also provide opportunity for construction of additional pipelines.  In addition, the development of small LNG facilities could provide opportunity for both our East and Energy segments.

Our highway construction services continue to operate in a challenging market in the near-term.  Declining tax revenues, budget deficits, financing constraints and competing priorities have resulted in cutbacks in new infrastructure projects in the public sector.  Some funding sources that have been specifically earmarked for infrastructure spending, such as diesel and gasoline taxes, have generated less revenue for government agencies as actual consumption is reduced.  Offsetting these financial challenges is the need for continuing improvements and additions in highway infrastructure and the perception of federal and state funding of transportation projects as an investment in infrastructure.  Our highway construction operation is focused on the states of Louisiana, Texas and Mississippi.  Of these states, Texas continues to increase its highway construction budget while the other two states have cut back in the current environment.

4



Table of Contents

Over the past few years, several areas of the United States have suffered significant drought-like conditions.  In these areas, state and municipal officials are considering using alternative sources for potable water, including using water pipelines to transport water from distant aquifers or building complex water treatment facilities to treat non-potable water.  In some areas such as West Texas, state agencies are contemplating significant investment to improve the quantity of water.  These investments may provide an opportunity for our East segment services.

Strategy

Our strategy continues to emphasize the following key elements:

·Diversification Through Controlled Expansion.  We continue to emphasize the expansion of our scope of services beyond our traditional focus by increasing the scope of services offered to current customers and by adding new customers.  We intend to continue to evaluate acquisitions that offer growth opportunities and the ability to leverage our resources as a leading service provider to the oil and gas, power, refining and water industries. Our strategy also considers potential selective expansion to new geographic regions.

·Emphasis on Retention of Existing Customers and Recurring Revenue.  In order to fully leverage our relationships with our existing customer base, we believe it is important to maintain strong customer relationships and to expand our base of recurring revenue sources and recurring customers.

·Ownership of Equipment.  Many of our services are equipment intensive. The cost of construction equipment, and in some cases the availability of construction equipment, provides a significant barrier to entry into several of our businesses. We believe that our ownership of a large and varied construction fleet and our maintenance facilities enhances our access to reliable equipment at a favorable cost.

·Stable Work Force.  In each of our separate segments, we maintain a stable work force of skilled, experienced laborers, many of whom are cross-trained in projects such as pipeline and facility construction, refinery maintenance, and piping systems.

·Selective Bidding.  We selectively bid on projects that we believe offer an opportunity to meet our profitability objectives, or that offer the opportunity to enter promising new markets. In addition, we review our bidding opportunities to attempt to minimize concentration of work with any one customer, in any one industry, or in stressed labor markets.  We believe that by carefully positioning ourselves in market segments that have meaningful barriers of entry, we can position ourselves so that we compete with other strong, experienced bidders.

·Maintain a conservative capital structure and strong balance sheet. We have maintained a capital structure that provides access to debt financing as needed while relying on tangible net worth to provide the primary support for our operations.  We believe this structure provides both our customers and banks and bonding companies assurance of our financial capabilities.  We maintain a revolving credit facility to provide letter of credit capability; however, we have not had any outstanding bank borrowing against this facility while we have been a public company.

Backlog

Backlog is discussed in Item 7. “Management’s Discussion and Analysis of Financial Condition and Results of Operations” of this Annual Report on Form 10-K.

Customers

Historically, we have longstanding customer relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the western United States, as well as significant projects for our engineering customers.  Through JCG, we expanded our customer base to include a significant presence in the Gulf Coast region of the United States,States; with Q3C, we expanded into the upper Midwest United StatesStates; and with Rockford, we are expandingoperate throughout the United States.  TheOver time, the various acquisitions

5



Table of Contents

have also changed the composition of our customer base with significant increases in public state agency projects. We enter into a large number of contracts each year and the projects can vary in length from several weeks to as long as 4860 months, or longer for completion on larger projects. Although we have not been dependent upon any one customer in any year, a small number of customers tend to constitute a substantial portion of our total revenues.

 

Our customers have included the Texas Department of Transportation and Louisiana Department of Transportation and Development in the Southern United States as well as many of the leading energy and utility companies in the United States, including, among others, Enterprise Liquids Pipeline, Xcel Energy, Pacific Gas & Electric, Southern California Gas, Sempra Energy, Williams, NRG, Chevron, Calpine, Kinder Morgan, Dominion, and Kinder Morgan.Sasol.

 

6


The following customers accounted for more than 5% of our revenues in the periods indicated:

 

Description of customer’s business

 

2014

 

2013

 

2012

 

Texas DOT

 

8.8

%

7.2

%

5.8

%

Petrochemical producer

 

7.9

%

*

 

*

 

Private Gas and electric utility

 

7.0

%

5.4

%

*

 

Public gas and electric utility

 

6.9

%

7.9

%

14.6

%

Pipeline operator

 

5.8

%

*

 

*

 

Gas utility

 

*

 

7.4

%

5.6

%

Private gas and electric utility

 

*

 

*

 

6.9

%

Gas utility

 

*

 

7.7

%

*

 

Louisiana DOT

 

*

 

*

 

11.1

%

Totals

 

36.4

%

35.6

%

44.0

%

 

 

 

 

 

 

 

Description of customer’s business

    

2017

 

2016

 

2015

State DOT

 

9.3%

 

9.7%

 

9.5%

Public gas and electric utility

 

8.9%

 

9.2%

 

6.2%

Private gas and electric utility

 

8.0%

 

10.1%

 

9.0%

Chemical/Energy producer

 

6.8%

 

10.4%

 

9.0%

Pipeline operator

 

5.4%

 

*

 

*

Pipeline operator

 

*

 

6.2%

 

*

Pipeline operator

 

*

 

*

 

8.6%

Gas utility

 

*

 

*

 

6.6%

Totals

 

38.4%

 

45.6%

 

48.9%

(*)Indicates a customer with less than 5% of revenues during such period.

 

As shown incan be seen from the table, the customers accounting for revenues in excess of 5% each year varies from year to year due to the nature of our business.  A large construction project for a customer may result in significant revenues in that particularone year, with significantly less revenues in subsequent years after project completion.

 

For the years ended December 31, 2014, 20132017, 2016 and 2012, approximately 53.6%2015, 56.4%, 50.0%60.4% and 55.9%59.4%, respectively, of total revenues were generated from theour top ten customers of the Company in each year.  In each of the years, a different group of customers comprised the top ten customers by revenue.

 

Management at each of our operatingbusiness units is responsible for developing and maintaining successful long-term relationships with customers. Our operatingbusiness unit management teams build existing customer relationships to secure additional projects and increase revenue from our current customer base.  OperatingBusiness unit managers are also responsible for pursuing growth opportunities with prospective new customers.

 

We believe that our strategic relationships with customers will result in future opportunities. Some of our strategic relationships are in the form of strategic alliance or long-term maintenance agreements.  However, we realize that future opportunities also require cost effective bids, as pricing is a key element for most construction projects.

 

Ongoing Projects

 

The following is a summary of significant ongoing construction projects demonstrating our capabilities in different markets at December 31, 2014:2017:

Segment

 

Project

 

Location

 

Approximate
Contract
Amount

 

Estimated
Completion
Date

 

Remaining
Backlog at
December 31,
2014

 

 

 

 

 

 

 

(Millions)

 

 

 

(Millions)

 

West

 

89 mile 36” crude oil pipeline

 

Rosenburg, TX

 

$

133

 

09/2015

 

$

132

 

West

 

71 MW Power plant project

 

Pasadena, CA

 

$

55

 

05/2016

 

$

48

 

East

 

IH 35 from S.363 to N.363

 

Temple, TX

 

$

250

 

06/2017

 

$

217

 

East

 

IH 35 Salado to Belton

 

Salado, TX

 

$

127

 

10/2015

 

$

88

 

Energy

 

Industrial facility

 

Lake Charles, LA

 

$

165

 

12/2016

 

$

165

 

Energy

 

100,000 GPD LNG plant

 

Miami, FL

 

$

27

 

9/2015

 

$

25

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

 

    

 

    

 

 

    

 

    

Remaining

 

 

 

 

 

 

 

Approximate

 

Estimated

 

Backlog at

 

 

 

 

 

 

 

Contract

 

Completion

 

December 31, 

 

Segment

 

Project

 

Location

 

Amount

 

Date

 

2017

 

 

 

 

 

 

 

(Millions)

 

 

 

(Millions)

 

Pipeline

 

177 Mile Natural Gas Pipeline

 

Atlantic Coast

 

$

678

 

12/2019

 

$

677

 

Civil

 

I-10 Highway

 

Breaux Bridge, LA

 

$

126

 

11/2019

 

$

108

 

Power

 

500 MW Natural Gas Simple Cycle Power Plant

 

Carlsbad, CA

 

$

299

 

10/2018

 

$

101

 

Civil

 

IH 35 Highway

 

Temple, TX

 

$

281

 

03/2019

 

$

88

 

Pipeline

 

Dual force main & generator replacement

 

Marina Del Rey, CA

 

$

87

 

07/2018

 

$

62

 

Utilities

 

230KV Transmission Line

 

San Diego, CA

 

$

74

 

06/2018

 

$

15

 

 

6



Table of Contents

Competition

 

We face substantial competition on large construction projects from both regional and national contractors. Competitors on small construction projects range from a few large construction companies to a variety of smaller contractors. We compete with many local and regional firms for construction services and with a number of large firms on select projects. Each business segmentunit faces varied competition depending on the typetypes of projectprojects and services offered.

 

7


We compete with different companies in different end markets.  LargeFor example, large competitors in our underground markets include Quanta Services, Inc., and MasTec, Inc. and Willbros Group;; competitors in our industrial end markets include Kiewit Corporation; and competitors in our highway services markets include Sterling Construction Company, and privately-held Boh Brothers and Zachary Construction Company. In each market we may also compete with local, private companies.

 

We believe that the primary factors influencing competition in our industry are price, reputation for quality, delivery and safety, relevant experience, availability of skilled labor, machinery and equipment, financial strength, knowledge of local markets and conditions, and estimating abilities. We believe that we have the ability to compete favorably in all of the foregoingthese factors.

 

Geographic Areas — Financial Information

 

The majority of the Company’sour revenues are derived from customers and projects geographically located in the United States andwith approximately 1% is generated from sources outside the United States.  Assets located outside the United States also represent approximately 1% of our total assets of the Company.  Our revenue from operations in the United States is related to projects primarily in the geographic United States.assets.  Our revenue from operations in Canada is primarily derived from our EnergyPower segment’s office in Calgary, Canada, but relates to specific projects in other countries, especiallyincluding in the Far East and Australia.

 

Risks Attendant to Foreign Operations

 

In 20142017, approximately 1.0%1% of our revenue was attributable to external customers in foreign countries. The current expectation is that a similar portion of revenue will continue to come from international projects for the foreseeable future.  Though a small portion of our revenues, international operations are subject to foreign economic and political uncertainties and risks as disclosed more fully in Item 1A “Risk Factors” of this Annual Report.  Unexpected and adverse changes in the foreign countries in which we operate could result in project disruptions, increased costs and potential losses. Our business is subject to fluctuations in demand and to changing domestic and international economic and political conditions which are beyond our control.

 

Contract Provisions and Subcontracting

 

We typically structure contracts as unit-price, time and material, fixed-price or cost reimbursable plus fixed fee.  A substantial portion of our revenue is derived from contracts that are fixed pricefixed-price or fixed unit priceunit-price contracts. Under a fixed pricefixed-price contract, we undertake to provide labor, equipment and services required by a project for a competitively bid or negotiated fixed price. The materials required under a fixed price contract, such as pipe, turbines, boilers and vessels are often supplied by the party retaining us. Under a fixed unit priceunit-price contract, we are committed to providing materials or services required by a project at fixed unit prices.  While the fixed unit priceunit-price contract shifts the risk of estimating the quantity of units required for a particular project to the party retaining us,customer, any increase in our unit cost over the unit price bid, whether due to inflation, inefficiency, faulty estimates or other factors, is borne by us. Significant materials required under a fixed-price or unit-price contract, such as pipe, turbines, boilers and vessels, are usually supplied by the customer.

Our gas distribution services are typically provided pursuant to renewable contracts on a “unit-cost” basis. Fees on unit-cost contracts are negotiated and are earned based on units completed. Historically, substantially all of the gas distribution customers have renewed their maintenance contracts. Facilities maintenance services, such as regularly scheduled and emergency repair work, are provided on an ongoing basis at predetermined rates.

 

Construction contracts are primarily obtained through competitive bidding or through negotiations with long-standing customers. We are typically invited to bid on projects undertaken by recurring customers who maintain pre-qualified contractor lists. Contractors are selected for the pre-approved contractor lists by virtue of their prior performance for such customers, as well as their experience, reputation for quality, safety record, financial strength and bonding capacity.

 

In evaluating bid opportunities, we consider such factors as the customer, the geographic location of the work, the availability of labor, our competitive advantage or disadvantage relative to other likely contractors, our current and projected workload, the likelihood of additional work, and the project’s cost and profitability estimates. We use

8


computer-based estimating systems and our estimating staff has significant experience in the construction industry. The project estimates form the basis of a project budget against which performance is tracked through a project cost system, thereby enabling management to monitor a project. Project costs are accumulated and monitored weeklyregularly against billings and payments to assure proper controlunderstanding of cash flow on the project.

7



Table of Contents

 

Most contracts provide for termination of the contract for the convenience of the owner. In addition, many contracts are subject to certain completion schedule requirements with damages or liquidated damages in the event schedules are not met. To date, these provisions have not materially adversely affected us.

 

We act as prime contractor on a majority of the construction projects we undertake. In the construction industry, the prime contractor is normally responsible for the performance of the entire contract, including subcontract work. Thus, we are potentially subject to increased costs and reputational risk associated with the failure of one or more subcontractors to perform as anticipated. While we subcontract specialized activities such as blasting, hazardous waste removal and selected electrical work, we perform most of the work on our projects with our own resources, including labor and equipment.

 

Our gas distribution services are typically provided pursuant to renewable contracts on a “unit-cost” basis. Fees on unit-cost contracts are negotiated and are earned based on units completed. Historically, substantially all of the gas distribution customers have renewed their maintenance contracts. Facilities maintenance services, such as regularly scheduled and emergency repair work, are provided on an ongoing basis at predetermined rates.

Risk Management, Insurance and Bonding

 

We maintain general liability and excess liability insurance covering our construction equipment, and workers’ compensation insurance in amounts consistent with industry practices. In the States of California, Texas and Louisiana,certain states, we self-insure our workers’ compensation claims in an amount of up to $250,000 per occurrence, and we maintain insurance covering larger claims. In addition, we maintain umbrella coverage.coverage policies.  We believe that our insurance programs are adequate.

 

We maintain a diligent safety and risk management program that has resulted in a favorable loss experience factor. Through our safety director and the employment of a large staff of regional and site specific safety managers, we have been able to effectively assess and control potential losses and liabilities in both the pre-construction and performance phases of our projects. Though we strongly focus on safety in the workplace, we cannot give assurances that we can prevent or reduce all injuries or claims in our workplace.

 

In connection with our business, we generally are required to provide various types of surety bonds guaranteeing our performance under certain public and private sector contracts. Our ability to obtain surety bonds depends upon our capitalization, working capital, backlog, past performance, management expertise and other factors and the surety company’s current underwriting standards.  To date, we have obtained the level of surety bonds necessary for the needs ofto support our business.

 

Regulation

 

Our operations are subject to various federal, state, local and international laws and regulations including:

 

·Licensing, permitting and inspection requirements;

·Regulations relating to worker safety, including those established by the Occupational Safety and Health Administration;

·Permitting and inspection requirements applicable to construction projects; and

·Contractor licensing requirements.

·

Licensing, permitting and inspection requirements;

·

Regulations relating to worker safety, including those established by the Occupational Safety and Health Administration;

·

Permitting and inspection requirements applicable to construction projects; and

·

Contractor licensing requirements.

 

We believe that we have all the licenses required to conduct our operations and that we are in substantial compliance with applicable regulatory requirements.

 

Environmental Matters and Climate Change Impacts

 

We are subject to numerous federal, state, local and international environmental laws and regulations governing our operations, including the handling, transportation and disposal of non-hazardous and hazardous substances and wastes, as well as emissions and discharges into the environment, including discharges to air, surface water, groundwater and soil. We have a substantial investment in construction equipment that utilizes diesel fuel. Any changes in laws

9


requiring us to use equipment that runs on alternative fuels could require a significant investment, which could adversely impact our financial performance.

We also are subject to laws and regulations that impose liability and cleanup responsibility for releases of hazardous substances into the environment. Under some of these laws and regulations, liability can be imposed for cleanup of previously owned or operated properties, or properties to which hazardous substances or wastes were sent by current or former operations at our facilities, regardless of whether we directly caused the contamination or violated any law at the time of discharge or disposal. The presence of contamination from such substances or wastes could interfere with ongoing operations or adversely affect our ability to sell, lease or use our properties as collateral for financing.

8



Table of Contents

 

In addition, we could be held liable for significant penalties and damages under certain environmental laws and regulations and also could be subject to a revocation of our licenses or permits, which could materially and adversely affect our business and results of operations. Our contracts with our customers may also impose liabilities on us regarding environmental issues that arise through the performance of our services.  From time to time, we may incur costs and obligations for correcting environmental noncompliance matters and for remediation at or relating to certain of our properties. We believe that we are in substantial compliance with our environmental obligations to date and that any such obligations will not have a material adverse effect on our business or financial performance.

 

The potential physical impact of climate change on our operations areis highly uncertain. Climate change may result in, among other things, changes in rainfall patterns, storm patterns and intensities and temperature levels. As discussed elsewhere in this Annual Report on Form 10-K, including in Item 1A. Risk Factors”, our operating results are significantly influenced by weather. Therefore, major changes in historical weather patterns could significantly impact our future operating results. For example, if climate change results in significantly more adverse weather conditions in a given period, we could experience reduced productivity, which could negatively impact our revenues and gross margins.

 

Climate change could also affect our customers and the types of projects that they award.  Demand for power projects, underground pipelines or highway projects could be affected by significant changes in weather.  Reductions in project awards could adversely affect our operations and financial performance.

 

Employees

 

We believe that our employees are ourthe most valuable resource in successfully completing construction work. Our ability to maintain sufficient continuous work for approximately 5,0005,800 hourly employees helps us to instill in our employees loyalty to and understanding of our policies and contributes to our strong production, safety and quality record.

 

As of December 31, 2014,2017, we employed approximately 1,2671,345 salaried employees and approximately 5,4905,757 hourly employees.  The total number of hourly personnel employed is subject to the volume of construction work in progress. During the calendar year 2014, the aggregate number of employees ranged from approximately 6,500 to 8,700.

The following is a summary of employees by function and geography as of December 31, 2014:

 

 

CA

 

LA

 

TX

 

CO

 

FL

 

MN

 

Other
US

 

Canada

 

Total

 

Salaried

 

309

 

208

 

435

 

83

 

39

 

68

 

95

 

30

 

1,267

 

Hourly

 

1183

 

1,320

 

1,381

 

415

 

163

 

247

 

781

 

0

 

5,490

 

Total

 

1,492

 

1,528

 

1,816

 

498

 

202

 

315

 

876

 

30

 

6,757

 

 

Several of our subsidiaries have operations that are unionized through the negotiation and execution of collective bargaining agreements. These collective bargaining agreements have varying terms and are subject to renegotiation upon expiration. We have not experienced recent work stoppages and believe our employee and union relations are good.

 

Website Access and Other Information

 

Our website address is www.prim.com. You may obtain free electronic copies of our Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q, Current Reports on Form 8-K, and any amendments to these reports through our website under the “Investor Relations”“Investors” tab or through the website of the Securities and Exchange Commission (the “SEC”) at www.sec.gov. These reports are available on our website as soon as reasonably practicable after we electronically file them with, or furnish them to, the SEC. In addition, our Corporate Governance Guidelines, Code“Code of Ethics and Business ConductEthics” (including a separate codesupplement which applies to our CEO, CFO and senior financial executives) and the charters of our Audit Committee, Compensation Committee and Governance and Nominating Committee are posted on our website under the “Investor Relations/Corporate “Investors/Governance” tab.  We intend to disclose on our website any amendments or waivers to our Code of Ethics and Business Conduct

10


that are required to be disclosed pursuant to Item 5.05 of Form 8-K. You may obtain copies of these items from our website.

 

We will make available to any stockholder, without charge, copies of our Annual Report on Form 10-K as filed with the SEC. For copies of this or any other information, stockholders should submit a request in writing to Primoris Services Corporation, Inc., Attn: Corporate Secretary, 2100 McKinney Avenue, Suite 1500, Dallas, TX 75201.

9



Table of Contents

 

This Annual Report on Form 10-K and our website may contain information provided by other sources that we believe are reliable. However, we cannot assure you that the information obtained from other sources is accurate or complete. No information on our website is incorporated by reference herein and should not be considered part of this Annual Report.

 

ITEM 1A.  RISK FACTORS

 

Our business is subject to a variety of risks and uncertainties, many of which are described below.below (not necessarily in probability of occurrence or order of importance).  The following list is not all-inclusive, and there can be no assurance that we have correctly identified and appropriately assessed all factors affecting our business or that the publicly available andor other information with respect to these matters is complete and correct. Additional risks and uncertainties not presently known to us or that we currently believe to be immaterial also may have a material adverse effectseffect on our business financial conditionin the future.  This Form 10-K includes projections, assumptions and beliefs that are intended to be “forward looking statements” and should be read in conjunction with the discussion of “Forward Looking Statements” at the beginning of this Annual Report on Form 10-K.

The following risk factors could have a material adverse effect our business, the results of our operations, inour cash flow and the future.price of our shares.  These risk factors could prevent us from meeting our goals or expectations.

 

Risks Related Primarily to Operating our Business

 

Our financial and operating results may vary significantly from quarter-to-quarter and year-to-year.

 

Our business is subject to seasonal and annual fluctuations.  Some of the quarterly variation is the result of weather, particularly rain, ice and snow, which create difficult operating conditions.  Similarly, demand for routine repair and maintenance services for gas utilities is lower during their peak customer needs in the winter.  Some of the annual variation is the result of large construction projects which fluctuate based on general economic conditions and customer needs.  Annual and quarterly results may also be adversely affected by:

 

·Changes in our mix of customers, projects, contracts and business;

·Regional and/or general economic conditions;

·Variations and changes in the margins of projects performed during any particular quarter;

·Increases in the costs to perform services caused by changing weather conditions;

·The termination of existing agreements or contracts;

·The budgetary spending patterns of customers;

·Increases in construction costs that we may be unable to pass through to our customers;

·Cost or schedule overruns on fixed-price contracts;

·Availability of qualified labor for specific projects;

·Changes in bonding requirements and bonding availability for existing and new agreements;

·Costs we incur to support growth whether organic or through acquisitions;

·The timing and volume of work under contract; and

·Losses experienced in our operations.

·

Changes in our mix of customers, projects, contracts and business;

·

Regional or national and/or general economic conditions and demand for our services;

·

Variations and changes in the margins of projects performed during any particular quarter;

·

Increases in the costs to perform services caused by changing weather conditions;

·

The termination or expiration of existing agreements or contracts;

·

The budgetary spending patterns of customers;

·

Increases in construction costs that we may be unable to pass through to our customers;

·

Cost or schedule overruns on fixed-price contracts;

·

Availability of qualified labor for specific projects;

·

Changes in bonding requirements and bonding availability for existing and new agreements;

·

The need and availability of letters of credit;

·

Costs we incur to support growth, whether organic or through acquisitions;

·

The timing and volume of work under contract; and

·

Losses experienced in our operations.

 

As a result, our operating results in any particular quarter may not be indicative of the operating results expected for any other quarter or for an entire year.

11


Table of Contents

Demand for our services may decrease during economic recessions or volatile economic cycles, and thea reduction in demand in end markets may adversely affect our business.

 

A substantial portion of our revenues and profits is generated from construction projects, the awarding of which we do not directly control.  The engineering and construction industry historically has experienced cyclical fluctuations in financial results due to economic recessions, downturns in business cycles of our customers, material shortages, price increases by subcontractors, interest rate fluctuations and other economic factors beyond our control. When the general level of economic activity deteriorates, our customers may delay or cancel upgrades, expansions, and/or maintenance and repairs to their systems. Many factors, including the financial condition of the industry, could adversely affect our customers and their willingness to fund capital expenditures in the future.

 

Traditionally, the construction industry has lagged recoveries in the general economy. While economic conditions have improved in general, economic,Economic, regulatory and market conditions affecting some of our specific end markets may adversely impact the demand for our services, resulting in the delay, reduction or cancellation of certain projects and these conditions may continue to adversely affect us in the future.

Much For example, much of the work that we perform in the highway markets involves funding by federal, state and local governments.  InThis funding is subject to fluctuation based on the current budgetarybudgets and political environment, funding for these projects could be reduced significantly, which could have a material adverse effect on our operations and financial results.

10



Tableoperating priorities of Contentsthe various government agencies.

 

We are also dependent on the amount of work our customers outsource. In a slower economy, our customers may decide to outsource less infrastructure services reducing demand for our services. In addition, consolidation, competition or capital constraints in the industries we serve may result in reduced spending by our customers.

 

Industry trends and government regulations could reduce demand for our pipeline construction services.

 

The demand for our pipeline construction services is dependent on the level of capital project spending by companies in the oil and gas industry.  This level of spending is subject to large fluctuations depending primarily on the current and expectations of future prices of oil and natural gas.  The price is a function of many factors, including levels of supply and demand, government policies and regulations, oil industry refining capacity and the potential development of alternative fuels.  Since the middle of 2014, there has been a significant decrease in oil prices caused partially by a significant increase in the supply of natural gas due to the development of North American shale formations.  If the lower price results in a decrease in activity in the discovery or development of oil and gas reserves, customers could reduce their capital spending on underground projects which could result in a reduction of demand for our services which could adversely affect our overall financial position, results of operations and cash flow.

 

Specific government decisions could affect demand for our construction services.  For example, a limitation on the use of “fracking” technology, or creation of significant regulatory issues for the construction of underground pipelines, could significantly affect the revenues and profitability ofreduce our operations.underground work.

 

Conversely, government regulations may increase the demand for our pipeline services.  The anticipation by utilities that coal-fueled power plants may become uneconomical to operate because of potential environmental regulations or low natural gas prices has increased demand for gas pipeline construction for utility customers.

Many of our customers are regulated by federal and state government agencies and the addition of new regulations or changes to existing regulations may adversely impact demand for our services and the profitability of those services.

 

Many of our energy customers are regulated by the Federal Energy Regulatory Commission, or FERC, and our utility customers are regulated by state public utility commissions. These agencies could change the way in which they interpret current regulations and may impose additional regulations. These changes could have an adverse effect on our customers and the profitability of the services they provide which could reduce demand for our services, adversely affect our results of operations, cash flows and liquidity.services.

 

Our business may be materially adversely impacted by regional, national and/or global requirements to significantly limit or reduce greenhouse gas emissions in the future.

 

Greenhouse gases that result from human activities, including burning of fossil fuels, are the focus of increased scientific and political scrutiny and may be subjected to various legal requirements. International agreements, federal laws, state laws and various regulatory schemes limit or otherwise regulate emissions of greenhouse gases, and additional restrictions are under consideration by different governmental entities. We derive a significant amount of revenues and contract profits from engineering and construction services to clients that own and/or operate a wide range of process plants and own and/or operate electric power generating plants that generate electricity from burning natural

12


Table of Contents

gas or various types of solid fuels. These plants may emit greenhouse gases as part of the process to generate electricity or other products. Compliance with the existing greenhouse gas regulation may prove costly or difficult. It is possible that owners and operators of existing or future process plants and electric generating plants could be subject to new or changed environmental regulations that result in significantly limiting or reducing the amounts of greenhouse gas emissions, increasing the cost of emitting such gases or requiring emissions allowances. The costs of controlling such emissions or obtaining required emissions allowances could be significant. It also is possible that necessary controls or allowances may not be available. Such regulations could negatively impact client investments in capital projects in our markets, which could negatively impact the market for our products and/or services. This could materially adversely affect our business, financial condition, results of operations and cash flows.business.

 

In addition, the establishment of rules limiting greenhouse gas emissions could impact our ability to perform construction services or to perform these services with current levels of profitability.  New regulations may require us to acquire different equipment or change processes.  The new equipment may not be available, or it may not be purchased or rented in a cost effective manner.  Project deferrals, delays or cancellations resulting from the potential regulations could adversely impact our business.

 

Changes to renewable portfolio standards and decreased demand for renewable energy projects could negatively impact our future results of operations, cash flows and liquidity.

 

A significant portion of our future business may be focused on providing construction and/or installation services to owners and operators of solar power and other renewable energy facilities. Currently, the development of solar and other renewable energy facilities is highly dependent on tax credits, the existence of renewable portfolio standards and other state incentives. Renewable portfolio standards are state-specific statutory provisions requiring that electric utilities generate a certain amount of electricity from renewable energy sources.  These standards have initiated significant growth in the renewable energy industry and a potential demand for renewable energy infrastructure construction services. Since renewable energy is generally more expensive to produce, elimination of, or changes to, existing renewable portfolio standards, tax credits or similar environmental policies may negatively affect future demand for our services.

 

11



Table of Contents

We may lose business to competitors through the competitive bidding processes, which could have an adverse effect on our financial condition, results of operations and cash flows.processes.

 

We are engaged in highly competitive businesses in which most customer contracts are awarded through bidding processes based on price and the acceptance of certain risks. We compete with other general and specialty contractors, both foreignregional and domestic, including large international contractorsnational, and small local contractors. The strong competition in our markets requires maintaining skilled personnel and investing in technology, and it also puts pressure on profit margins.  We do not obtain contracts from all of our bids and our inability to win bids at acceptable profit margins would adversely affect our financial condition and results of operations.business.

 

We may be unsuccessful at generating internal growth which may affect our ability to expand our operations or grow our business, which may cause an adverse effect on our financial condition, results of operations and cash flows.business.

 

Our ability to generate internal growth may be affected by, among other factors, our ability to:

 

·Attract new customers;

·Increase the number of projects performed for existing customers;

·Hire and retain qualified personnel;

·Successfully bid for new projects; and

·Adapt the range of services we offer to address our customers’ evolving construction needs.

·

Attract new customers;

·

Increase the number of projects performed for existing customers;

·

Hire and retain qualified personnel;

·

Successfully bid for new projects; and

·

Adapt the range of services we offer to address our customers’ evolving construction needs.

 

In addition, our customers may reduce the number or size of projects available to us due to their inability to obtain capital.  Our customers may also reduce projects in response to economic conditions.

 

Many of the factors affecting our ability to generate internal growth may be beyond our control, and we cannot be certain that our strategies will be successful or that we will be able to generate cash flow sufficient to fund our

13


Table of Contents

operations and to support internal growth. If we are unsuccessful, we may not be able to achieve internal growth, expand our operations or grow our business and the failure to do so could have an adverse effect on our financial condition, results of operation and cash flows.business.

 

The timing of new contracts may result in unpredictable fluctuations in our cash flow and profitability, which could adversely affect our business.

 

Substantial portions of our revenues are derived from project-based work that is awarded through a competitive bid process. The portion of revenue generated from the competitive bid process for 2014, 20132017, 2016 and 20122015 was approximately 64%52%, 66%45%, and 69%47%, respectively. It is generally very difficult to predict the timing and geographic distribution of the projects that we will be awarded. The selection of, timing of or failure to obtain projects, delays in award of projects, the re-bidding or termination of projects due to budget overruns, cancellations of projects or delays in completion of contracts could result in the under-utilization of our assets and reduce our cash flows. Even if we are awarded contracts, we face additional risks that could affect whether, or when, work will begin. For example, some of our contracts are subject to financing, permitting and other contingencies that may delay or result in termination of projects. We may have difficulty in matching workforce size and equipment location with contract needs. In some cases, we may be required to bear the cost of a ready workforce and equipment that is larger than necessary, resulting in unpredictability in our cash flow, expenses and profitability. If any expected contract award or the related work release is delayed or not received, we could incur substantial costs without receipt of any corresponding revenues. Moreover, construction projects for which our services are contracted may require significant expenditures by us prior to receipt of relevant payments by a customer and may expose us to potential credit risk if the customer encounters financial difficulties. Finally, the winding down or completion of work on significant projects that were active in previous periods will reduce our revenue and earningearnings if the significantthese projects have not been replaced in the current period.replaced.

 

We derive a significant portion of our revenues from a few customers, and the loss of one or more of these customers could have significant effects on our revenues, resulting in adverse effects on our financial condition, results of operations and cash flows.

 

Our customer base is highly concentrated, with our top ten customers accounting for approximately 53% of our revenue in 2014, 50% of our revenue in 2013 and 56% of our revenue in 2012.2017, 60% of our revenue in 2016 and 59% of our revenue in 2015. However, the customers included in our top ten customer list generally variesvary from year to year.  Our revenue is dependent both on performance of larger construction projects and relatively smaller MSAMaster Services Agreements (“MSA”) contracts.  For the large construction projects, the completion of the project does not necessarily represent the permanent loss of a customer.

12



Table of Contentscustomer; however, the future revenues generated from work for that customer may fluctuate significantly.

 

We also generate ongoing revenues from our MSA customers, which are generally comprised of regulated gas utilities.  If we were to lose one of these customers, our revenue could significantly decline.  Reduced demand for our services by larger construction customers or a loss of a significant MSA customer could have an adverse effect on our financial condition, results of operations and cash flows.business.

 

Our international operations expose us to legal, political and economic risks in different countries as well as currency exchange rate fluctuations that could harm our business and financial results.  We could be adversely affected by our failure to comply with laws applicable to our foreign activities, such as the U.S. Foreign Corrupt Practices Act.

 

During 2014, 20132017, 2016 and 2012,2015, revenue attributable to our services outside of the United States was 1.0%0.3%, 0.8%0.6% and 0.7%0.9% of our total revenue, respectively.  While much of this revenue is derived from the operations of our Canadian subsidiary, OnQuest Canada, ULC, actual construction operationsactivities have occurred in the several far eastern countries and in Australia. There are risks inherent in doing business internationally, including:

 

·

Imposition of governmental controls and changes in laws, regulations, policies, practices, tariffs and taxes;

·

Political and economic instability;

·

Changes in United States and other national government trade policies affecting the market for our services;

·

Potential non-compliance with a wide variety of laws and regulations, including the United States Foreign Corrupt Practices Act (“FCPA”) and similar non-United States laws and regulations;

·

Currency exchange rate fluctuations, devaluations and other conversion restrictions;

·Imposition

14


Table of governmental controls and changes in laws, regulations, policies, practices, tariffs and taxes;Contents

·Political and economic instability;

·Changes in United States and other national government trade policies affecting the market for our services;

·Potential non-compliance with a wide variety of laws and regulations, including the United States Foreign Corrupt Practices Act (“FCPA”) and similar non-United States laws and regulations;

·Currency exchange rate fluctuations, devaluations and other conversion restrictions;

·Restrictions on repatriating foreign profits back to the United States; and

·Difficulties in staffing and managing international operations.

·

Restrictions on repatriating foreign profits back to the United States; and

·

Difficulties in staffing and managing international operations.

 

The FCPA and similar anti-bribery laws in other jurisdictions prohibit U.S.-based companies and their intermediaries from making improper payments to non-U.S. officials for the purpose of obtaining or retaining business. We pursue opportunities in certain parts of the world that experience government corruption, and in certain circumstances, compliance with anti-bribery laws may conflict with local customs and practices. Our internal policies mandate compliance with all applicable anti-bribery laws. We require our partners, subcontractors, agents and others who work for us or on our behalf to comply with the FCPA and other anti-bribery laws. There is no assurance that our policies or procedures will protect us against liability under the FCPA or other laws for actions taken by our agents, employees and intermediaries. If we are found to be liable for FCPA violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others), we could suffer from severe criminal or civil penalties or other sanctions, which could have a material adverse effect on our reputation business, results of operations or cash flows.and business.  In addition, detecting, investigating and resolving actual or alleged FCPA violations is expensive and could consume significant time and attention of our senior management.

 

In spite of the minimal revenue amounts, any of these factors could have a material adverse effect on our business, financial condition, results of operations and cash flows.

Backlog may not be realized or may not result in revenues or profits.

 

Backlog is measured and defined differently by companies within our industry. We refer to “backlog” as our estimated revenue on uncompleted contracts, includingless the revenue we have recognized under such contracts, plus the amount of revenue on contracts on which work has not begun, less the revenue we have recognized under such contracts plus an estimated level of MSA revenues for the next four quarters.  Backlog is not a comprehensive indicator of future revenues.  Most contracts may be terminated by our customers on short notice. Reductions in backlog due to cancellation by a customer, or for other reasons, could significantly reduce the revenue and profitthat we actually receive from contracts in backlog. In the event of a project cancellation, we may be reimbursed for certain costs, but we typically have no contractual right to the total revenues reflected in our backlog. Projects may remain in backlog for extended periods of time.  While backlog includes estimated MSA revenues, customers are not contractually obligated to purchase an amount of services under the MSA.

 

Given these factors, our backlog at any point in time may not accurately represent the revenue that we expect to realize during any period, and our backlog as of the end of a fiscal year may not be indicative of the revenue we expect to earn in the following fiscal year. Inability to realize revenue from our backlog could have an adverse effect on our financial condition, results of operations and cash flows.business.

 

Backlog is an indicator of future revenues; however, recognition of revenues from backlog does not necessarily insureensure that the projects will be profitable.  Poor project or contract performance could reduceimpact profits from contracts included in backlog.  For projects for which a loss is expected, future revenues will be recorded with no margin, which may reduce the overall margin percentage for work performed.

 

13



Table of Contents

Our actual cost may be greater than expected in performing our fixed-price and unit-price contracts, causing us to realize significantly lower profits or losses on our projects, which would have an adverse effect on our financial condition, results of operations and cash flows.projects.

 

We currently generate, and expect to continue to generate, a portion of our revenue and profits under fixed-price and unit-price contracts. The approximate portion of revenue generated from fixed-price contracts for the years 2014, 20132017, 2016 and 20122015 was 23%40%, 48%35% and 51%39%, respectively.  The approximate portion of revenue generated from unit-price contracts for the years 2014, 20132017, 2016 and 20122015 was 32%46%, 39%45%, and 30%43%, respectively.  In general, we must estimate the costs of completing a specific project to bid these types of contracts. The actual cost of labor and materials may vary from the costs we originally estimated, and we may not be successful in recouping additional costs from our customers. These variations may cause gross profits for a project to differ from those we originally estimated.  Reduced profitability or losses on projects could occur due to changes in a variety of factors such as:

��

·

·Failure to properly estimate costs of engineering, materials, equipment or labor;

·

Unanticipated technical problems with the structures, materials or services being supplied by us, which may require that we spend our own money to remedy the problem;

·

Project modifications not reimbursed by the client creating unanticipated costs;

15


Table of engineering, materials, equipment or labor;Contents

·Unanticipated technical problems with the structures, materials or services being supplied by us, which may require that we spend our own money to remedy the problem;

·Project modifications not reimbursed by the client creating unanticipated costs;

·Changes in the costs of equipment, materials, labor or subcontractors;

·Our suppliers or subcontractors failure to perform;

·Changes in local laws and regulations, and;

·Delays caused by local weather conditions.

·

Changes in the costs of equipment, materials, labor or subcontractors;

·

Our suppliers or subcontractors failure to perform;

·

Changes in local laws and regulations, and;

·

Delays caused by local weather conditions.

 

As projects grow in size and complexity, these factors may combine, and depending on the size of the particular project, variations from the estimated contract costs could have a material adverse effect on our financial condition, results of operations and cash flows.business.

 

Weather can significantly affect our revenues and profitability.

Our ability to perform work and meet customer schedules can be affected by weather conditions such as snow, ice and rain.  Weather may affect our ability to work efficiently and can cause project delays and additional costs.  Our ability to negotiate change orders for the impact of weather on a project could impact our profitability.  In addition, the impact of weather can cause significant variability in our quarterly revenue and profitability.

We require subcontractors and suppliers to assist us in providing certain services, and we may be unable to retain the necessary subcontractors or obtain supplies to complete certain projects adversely affecting our business.

 

We use subcontractors to perform portions of our contracts and to manage workflow, particularly for design, engineering, procurement and some foundation work. WeWhile we are not dependent on any single subcontractor. However,subcontractor, general market conditions may limit the availability of subcontractors to perform portions of our contracts causing delays and increases in our costs, which could have an adverse effect on our financial condition, results of operations and cash flows.costs.

 

We also use suppliers to provide the materials and some equipment used for projects.  However, significant materials and equipment are usually supplied by the customer.  If a supplier fails to provide supplies and equipment at a price we estimated, or fails to provide supplies and equipment that isare not of acceptable quantity or fails to provide supplies when scheduled, we may be required to source the supplies or equipment at a higher price or may be required to delay performance of the project.  The additional cost or project delays could negatively impact project profitability.

 

Failure of a subcontractor or supplier to comply with laws, rules or regulations could negatively affect our reputation and our business.

 

We may enter into joint ventures which require satisfactory performance by our venture partners of their obligations.  The failure of our joint venture partners to perform their joint venture obligations could impose additional financial and performance obligations on us that could result in reduced profits or losses for us with respect to the joint venture.

 

As is typical in our industry, we may enter into various joint ventures and teaming arrangements where control may be shared with unaffiliated third parties.  At times, we also participate in joint ventures where we are not a controlling party. In such instances, we may have limited control over joint venture decisions and actions, including internal controls and financial reporting which may have an impact on our business.  If our joint venture partners fail to satisfactorily perform their joint venture obligations, the joint venture may be unable to adequately perform or deliver its contracted services. Under these circumstances, we may be required to make additional investments or provide additional services to ensure the adequate performance and delivery of the contracted services.  These additional obligations could result in reduced profits for us with respect toand may impact our reputation in the joint venture.industry.

 

We may experience delays and defaults in client payments and we may pay our suppliers and subcontractors before receiving payment from our customers for the related services; we could experience an adverse effect on our financial condition, results of operations and cash flows.

 

We use subcontractors and material suppliers for portions of certain work, and our customers pay us for those related services. If we pay our suppliers and subcontractors for materials purchased and work performed for customers who fail to pay us, or such customers delay in paying us for the related work or materials, we could experience a material

16


Table of Contents

adverse effect on our financial condition, results of operations and cash flows.business. In addition, if customers fail to pay us for work we perform, we could experience a material adverse effect on our business.

 

14



Table of Contents

Our inability to recover on claims against project owners or subcontractors for payment or performance could negatively affect our financial results and liquidity.business.

 

We occasionally present claims or change orders to our clients and subcontractors for additional costs exceeding a contract price or for costs not included in the original contract price.  IfChange orders are modifications of an original contract that effectively change certain provisions of the contract.  They generally include changes in specifications or design, facilities, equipment, materials, sites and periods for completion of work.  Claims are amounts in excess of the agreed contract price (or amounts not included in the original contract price) that we doseek to collect from customers or others for customer-caused changes in contract specifications or design, other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers, or non-customer-caused changes, such as weather delays.  These costs may or may not properlybe recovered until the claim is resolved. In some instances, these claims can be the subject of lengthy legal proceedings, and it is difficult to accurately predict when they will be fully resolved. A failure to promptly document the nature of our claims and negotiate a recovery for change orders or are otherwise not successful in negotiatingand claims could have a reasonable settlement, we could incur reduced profitability or a lossnegative impact on a project.  Claims often occur from owner-caused delays or changes in scope from the original project.  Claims may be subject to lengthyour cash flows, and costly arbitration or litigation and may require a lengthy process.  The timing of a settlement and thean overall ability to reach an acceptable settlement may adverselyrecover change orders and claims could have a negative impact on our financial condition, results of operations and cash flow.flows.

 

For some projects we may guarantee a timely completion or provide a performance guarantee which could result in additional costs, such as liquidated damages, to cover our obligations.

 

In many of our fixed-price and unit-price contracts we may provide a project completion date, and in some of our projects we commit that the project will achieve specific performance standards.  If we do not complete the project as scheduled, or if the project does not meet the contracted performance standards, we may be held responsible for the impact to the client resulting from the delay or the inability to meet the standards.  Generally, the impact to the client is in the form of liquidated damages specified in the contract.  To the extent that we incur these additional costs, the project profitability and our financial performance could be adversely affected.

 

A significant portion of our business depends on our ability to provide surety bonds, and we may be unable to compete for or work on certain projects if we are not able to obtain the necessary surety bonds adversely affecting on financial condition, results of operations and cash flows.bonds.

 

Our contracts frequently require that we provide payment and performance bonds to our customers. Under standard terms in the surety market, sureties issue or continue bonds on a project-by-project basis and can decline to issue bonds at any time or require the posting of additional collateral as a condition to issuing or renewing bonds.

 

Current or future market conditions, as well as changes in our surety providers’ assessments of our operating and financial risk, could cause our surety providers to decline to issue or renew, or to substantially reduce, the availability of bonds for our work and could increase our bonding costs. These actions could be taken on short notice. If our surety providers were to limit or eliminate our access to bonding, our alternatives would include seeking bonding capacity from other sureties, finding more business that does not require bonds and posting other forms of collateral for project performance, such as letters of credit or cash. We may be unable to secure these alternatives in a timely manner, on acceptable terms, or at all. Accordingly, if we were to experience an interruption or reduction in the availability of bonding capacity, we may be unable to compete for or work on certain projects and such interruption or reduction could have an adverse effect on our financial condition, results of operations and cash flows.projects.

 

Our bonding requirements may limit our ability to incur indebtedness, which would limit our ability to refinance our existing credit facilities or to execute our business plan, and potentially result in an adverse effect on our business.plan.

 

Our ability to obtain surety bonds depends upon various factors including our capitalization, working capital, tangible net worth and amount of our indebtedness. In order to help ensure that we can obtain required bonds, we may be limited in our ability to incur additional indebtedness that may be needed to refinance our existing credit facilities upon maturity and to execute our business plan. Our inability to incur additional indebtedness could have an adverse effect on our business, operating results and financial condition.

 

17


Table of Contents

We may be unable to win some new contracts if we cannot provide clients with letters of credit.

 

For many of our clients surety bonds provide an adequate form of security, but for some clients additional security in the form of a letter of credit may be required.  While we have capacity for letters of credit under our credit facility, the amount required by a client may be in excess of our credit limit.  Any such amount would be issued at the sole discretion of our lenders.  Failure to provide a letter of credit when required by a client may result in our inability to compete for or win a project.

 

15



Table of Contents

During the ordinary course of our business, we may become subject to material lawsuits or indemnity claims, which could materially and adversely affect our business and results of operations.claims.

 

We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings during the ordinary course of our business. These actions may seek, among other things, compensation for alleged personal injury, workers’ compensation, employment discrimination, breach of contract, property damage, punitive damages, and civil penalties or other losses or injunctive or declaratory relief. In addition, we generally indemnify our customers for claims related to the services we provide and actions we take under our contracts with them, and, in some instances, we may be allocated risk through our contract terms for actions by our customers or other third parties. Because our services in certain instances may be integral to the operation and performance of our customers’ infrastructure, we may become subject to lawsuits or claims for any failure of the systems thaton which we work, on, even if our services are not the cause of such failures, and we could be subject to civil and criminal liabilities to the extent that our services contributed to any property damage, personal injury or system failure. The outcome of any of these lawsuits, claims or legal proceedings could result in significant costs and diversion of management’s attention to the business. Payments of significant amounts, even if reserved, could adversely affect our reputation liquidity and results of operations.our business.

 

We are self-insured against potential liabilities.

 

Although we maintain insurance policies with respect to employer’s liability, general liability, auto and workers compensation claims, those policies are subject to deductibles or self-insured retention amounts of up to $250,000 per occurrence. We are primarily self-insured for all claims that do not exceed the amount of the applicable deductible/self-insured retention. In addition, for our employees not part of a collective bargaining agreement, we provide employee health care benefit plans.  Our primary health insurance plan is subject to a deductible of $250,000 per individual claim per year.

 

Our insurance policies include various coverage requirements, including the requirement to give appropriate notice. If we fail to comply with these requirements, our coverage could be denied.

 

Losses under our insurance programs are accrued based upon our estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported.  Insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes the accruals are adequate. If we were to experience insurance claims or costs significantly above our estimates, our results of operations could be adversely affected in a given period.trends.

 

Our business is labor intensive.  If we are unable to attract and retain qualified managers and skilled employees, our operating costs may increase which could reduce our profitability and liquidity.increase.

 

Our business is labor intensive and our ability to maintain our productivity and profitability may be limited by our ability to employ, train and retain skilled personnel necessary to meet our requirements. We may not be able to maintain an adequately skilled labor force necessary to operate efficiently and to support our growth strategy. We have from time-to-time experienced, and may in the future experience, shortages of certain types of qualified personnel. For example, periodically there are shortages of engineers, project managers, field supervisors, and other skilled workers capable of working on and supervising the construction of underground, heavy civil and industrial facilities, as well as providing engineering services. The supply of experienced engineers, project managers, field supervisors and other skilled workers may not be sufficient to meet current or expected demand. The beginning of new, large-scale infrastructure projects or increased competition for workers currently available to us, could affect our business, even if we are not awarded such projects. Labor shortages or increased labor costs could impair our ability to maintain our

18


Table of Contents

business or grow our revenues. If we are unable to hire employees with the requisite skills, we may also be forced to incur significant training expenses. The occurrence of any of the foregoing could have an adverse effect on our business, operating results, financial condition and value of our common stock.

 

Our unionized workforce may commence work stoppages, which could adversely affect our operations.

 

As of December 31, 2014,2017, approximately 34%52% of our hourly employees, primarily consisting of field laborers, were covered by collective bargaining agreements. Of the 8297 collective bargaining agreements to which we are a party, forty five75 expire during 20152018 and require renegotiation.  Although the majority of these agreements prohibit strikes and work stoppages, we cannot be certain that strikes or work stoppages will not occur in the future. Strikes or work stoppages would adversely impact our relationships with our customers and could have an adverse effect on our financial condition, results of operations and cash flows.business.

 

Our ability to complete future acquisitions could be adversely affected because of our union status for a variety of reasons. For instance, in certain geographic areas, our union agreements may be incompatible with the union agreements of a business we want to acquire and some businesses may not want to become affiliated with a union company.  In addition, if we acquire a union affiliated company, we may increase our future exposure to withdrawal liabilities for any underfunded pension plans.

 

16



Table of Contents

The current Federal administration has expressed strong support for legislation and regulation that would create more flexibility and opportunity for labor unions to organize non-union workers. This legislation or regulation could result in a greater percentage of our workforce being subject to collective bargaining agreements.

Withdrawal from multiemployer pension plans associated with our unionized workforce could adversely affect our financial condition and results of operations.

 

Our collective bargaining agreements generally require that we participate with other companies in multiemployer pension plans. To the extent those plans are underfunded, the Employee Retirement Income Security Act of 1974 (“ERISA”), as amended by the Multiemployer Pension Plan Amendments Act of 1980 (“MEPA”), may subject us to substantial liabilities under those plans if we withdraw from them or they are terminated. In addition, the Pension Protection Act of 2006 added new funding rules generally applicable to plan years beginning after 2007 for multiemployer plans that are classified as endangered, seriously endangered or critical status.  For a plan in critical status, additional required contributions and benefit reductions may apply if a plan is determined to be underfunded, which could adversely affect our financial condition or results of operations.  For plans in critical status, we may be required to make additional contributions, generally in the form of surcharges on contributions otherwise required.  Participation in those plans with high funding levels could adversely affect our results of operations, financial condition or cash flows if we are not able to adequately mitigate these costs.

 

The amount of the withdrawal liability legislated by ERISA and MEPA varies for every pension plan to which we contribute.  For each plan, our liability is the total unfunded vested benefits of the plan multiplied by a fraction:  the numerator of the fraction is the sum of our contributions to the plan for the past ten years and the denominator is the sum of all contributions made by all employers for the past ten years.  For some pension plans to which we contribute, the total unfunded vested benefits are in the billions of dollars.  If we cannot reduce the liability through exemptions or negotiations, the withdrawal from a plan could have a material adverse impact on our financial condition, results of operations and cash flows.business.

 

We depend on key personnel and we may not be able to operate and grow our business effectively if we lose the services of any of our key personnelpersons or are unable to attract qualified and skilled personnel in the future. This could lead to a decrease in our overall competitiveness, resulting in an adverse effect on our business, operating results, financial condition and value of your common stock.

 

We are dependent upon the efforts of our key personnel, and our ability to retain them and hire other qualified employees. The loss of our executive officers or other key personnel could affect our ability to run our business effectively. Competition for senior management personnel is intense, and we may not be able to retain our personnel. The loss of any key person requires the remaining key personnel to divert immediate and substantial attention to seeking a replacement. In addition, as some of our key persons approach retirement age, we need to provide for smooth transitions.  An inability to find a suitable replacement for any departing executive or senior officer on a timely basis could adversely affect our ability to operate and grow our business.

 

19


Table of Contents

If we fail to integrate acquisitions successfully, we may experience operational challenges and risks which may have an adverse effect on our business and results of operations.business.

 

As part of our growth strategy, we intend to acquire companies that expand, complement or diversify our business.  Acquisitions may expose us to operational challenges and risks, including, among others:

 

·The diversion of management’s attention from the day-to-day operations of the combined company;

·Managing a significantly larger company than before completion of an acquisition;

·The assimilation of new employees and the integration of business cultures;

·Retaining key personnel;

·The integration of information, accounting, finance, sales, billing, payroll and regulatory compliance systems;

·Challenges in keeping existing customers and obtaining new customers;

·Challenges in combining service offerings and sales and marketing activities;

·The assumption of unknown liabilities of the acquired business for which there are inadequate reserves;

·The potential impairment of acquired goodwill and intangible assets; and

·The inability to enforce covenants not to compete.

17


·

The diversion of management’s attention from the day-to-day operations of the combined company;

·

Managing a significantly larger company than before completion of an acquisition;


Table of Contents

·

The assimilation of new employees and the integration of business cultures;

·

Training and facilitating our internal control processes within the acquired organization;

·

Retaining key personnel;

·

The integration of information, accounting, finance, sales, billing, payroll and regulatory compliance systems;

·

Challenges in keeping existing customers and obtaining new customers;

·

Challenges in combining service offerings and sales and marketing activities;

·

The assumption of unknown liabilities of the acquired business for which there are inadequate reserves;

·

The potential impairment of acquired goodwill and intangible assets; and

·

The inability to enforce covenants not to compete.

 

If we cannot effectively manage the integration process or if any significant business activities are interrupted as a result of the integration process of any acquisition, our business could suffer and our results of operations and financial condition may be negatively affected.suffer.

 

Our business growth could outpace the capabilityWe may incur higher costs to lease, acquire and maintain equipment necessary for our operations.

A significant portion of our internal infrastructure and may prohibit us from expandingcontracts is built with our operationsown construction equipment rather than leased or execute our business plan, which failures may adversely affect the value of our common stock.

Our internal infrastructure may not be adequate to support our operations as they expand.rented equipment. To the extent that we are unable to buy or build equipment necessary for a project, either due to a lack of available funding or equipment shortages in the marketplace, we may be forced to rent equipment on a short-term basis or to find alternative ways to perform the work without the benefit of equipment ideally suited for the job, which could increase the costs of completing the project. We often bid for work knowing that we will have to rent equipment on a short-term basis, and we include our assumptions of market equipment rental rates in our bid. If market rates for rental equipment increase between the time of bid submission and project execution, our margins for the project may be reduced. In addition, our equipment requires continuous maintenance, which we generally provide through our own repair facilities. If we are unable to continue to maintain the equipment in our fleet, we may be forced to obtain additional third-party repair services at a higher cost or be unable to bid on contracts.

 

Our business may be affected by difficult work sites and environments which may adversely affect our ability to procure materials and labor, which may adversely affect our overall business.labor.

 

We perform our work under a variety of conditions, including, but not limited to, difficult and hard to reach terrain, difficult site conditions and busy urban centers where delivery of materials and availability of labor may be impacted. Performing work under these conditions can slow our progress, potentially causing us to incur contractual liability to our customers. These difficult conditions may also cause us to incur additional, unanticipated costs that we might not be able to pass on to our customers.

 

We may incur liabilities or suffer negative financial or reputational impacts relating to health and safety matters.

 

Our operations are subject to extensive laws and regulations relating to the maintenance of safe conditions in the workplace. While we have invested, and will continue to invest, substantial resources in our occupationalenvironmental, health and safety programs, our industry involves a high degree of operational risk and there can be no assurance that we will avoid significant liability exposure. Although we have taken what we believe are appropriate precautions, we have suffered fatalities in the past and may suffer additional fatalities in the future. Serious accidents, including fatalities, may subject us to substantial penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in substantial costs and liabilities, which could materially and adversely affect our financial condition, results of operations or cash flows. In addition, if our safety record were to

20


Table of Contents

substantially deteriorate over time or we were to suffer substantial penalties or criminal prosecution for violation of health and safety regulations, our customers could cancel our contracts and not award us future business.

 

We may incur additional healthcare costs arising from federal healthcare reform legislation.

In March 2010, the Patient Protection and Affordable Care Act and the Health Care and Education Reconciliation Act of 2010 were signed into law in the U.S. This legislation expands health care coverage to many uninsured individuals and expands coverage to those already insured. The changes required by this legislation could cause us to incur additional healthcare and other costs for which we may not be reimbursed by our customers.  The employee insurance requirements are expected to impact our expenses beginning in 2015 as our insurance costs could increase by $2 million to $6 million annually.  While we anticipate increases in our customer billing rates to reflect the increased expense, there can be no guarantee that we will be able to pass these costs to our customers or that our competition will increase their bids to reflect the increased healthcare costs.  For our multi-year highway projects, we may not be able to anticipate further increases in healthcare costs associated with the healthcare reform legislation.

Interruptions in information technology or breaches in data security could adversely impact our operations, our ability to report financial results and our business and results of operations.business.

 

We rely on computer, information and communication technology and related systems to operate our business.  As we continue to grow our business, we need to add software and hardware and effectively upgrade our systems and network infrastructure in order to improve the efficiency and protection of our systems and information.  OurWhile we do not maintain customer information in our computer systems, our computer and communications systems, and consequently our operations, could be damaged or interrupted by natural disasters, loss of power, telecommunications failures, acts of war, acts of terrorism, computer viruses, physical or electronic break-ins and actions by hackers and cyber-terrorists.  Any of these, or similar, events could cause system disruptions, delays and loss of critical information, delays in processing transactions and delays in the reporting of financial information.  While we have implemented network security and internal control measures, there can be no assurance that a system or network failure or data security breach would not adversely affect our financial condition and results of operations.business.

 

18



Table of Contents

As a holding company, we are dependent on our subsidiaries for cash distributions to fund debt payments, dividend payments and other liabilities.

 

We are a holding company with no operations or significant assets other than the stock that we own of our subsidiaries.  
We depend on dividends, loans and distributions from these subsidiaries to service our indebtedness, pay dividends, fund share repurchases and satisfy other financial obligations.  If contractual limitations or legal regulations were to restrict the ability of our subsidiaries to make cash distributions to us, we may not have sufficient funds to cover our financial obligations.

 

We may need additional capital in the future for working capital, capital expenditures or acquisitions, and we may not be able to do so on favorable terms, or at all, which would impair our ability to operate our business or achieve our growth objectives.

 

Our ability to generate cash is essential for the funding of our operations and the servicing of our debt.  If existing cash balances together with the borrowing capacity under our credit facilities arewere not sufficient to make future investments, make acquisitions or provide needed working capital, we may require financing from other sources.  Our ability to obtain such additional financing in the future will depend on a number of factors including prevailing capital market conditions; conditions in our industry; and our operating results.  These factors may affect our ability to arrange additional financing on terms that are acceptable to us.  If additional funds were not available on acceptable terms, we may not be able to make future investments, take advantage of acquisitions or other opportunities or respond to competitive challenges.

 

Risks Related Primarily to the Financial Accounting of our Business

 

Our financial results are based upon estimates and assumptions that may differ from actual results and such differences between the estimates and actual results may have an adverse effect on our financial condition, results of operations and cash flows.results.

 

In preparing our consolidated annual and quarterly financial statements in conformity with generally accepted accounting principles, many estimates and assumptions are used by management in determining the reported revenues, costs and expenses recognized during the periods presented, and disclosures of contingent assets and liabilities known to exist as of the date of the financial statements. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events, or is not capable of being readily calculated based on generally accepted methodologies. Often times, these estimates are particularly difficult to determine, and we must exercise significant judgment. Estimates may be used in our assessments of the allowance for doubtful accounts, useful lives of property and equipment, fair value assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities, revenue recognition under percentage-of-completion accounting and provisions for income taxes. Actual results for estimates could differ materially from the estimates and assumptions that we use, which could have an adverse effect on our financial condition, resultsused.

21


Table of operations and cash flows.Contents

 

Our use of percentage-of-completion accounting could result in a reduction or elimination of previously reported profits, which may result in an adverse effect on our financial conditionrevenue and results of operations.profits.

 

WeFor fixed-price and unit-price contracts, we recognize revenue using the percentage-of-completion method of accounting, using the cost-to-cost method, where revenues are estimated based on the percentage of costs incurred to date to total estimated costs. This method is used because management considers expended costs to be the best available measure of progress on these contracts. The earnings or losses recognized on individual contracts are based on estimates of total contract revenues, total expected costs and profitability.costs incurred to date. Contract losses are recognized in full when determined, and contract profit estimates are adjusted based upon ongoing reviews of contract profitability.

 

Penalties or potential charges are recorded when known or finalized, which generally is during the latter stages of the contract.finalized. In addition, we record adjustments to estimated costs of contracts when we believe the change in the estimate is probable and the amounts can be reasonably estimated. These adjustments could result in both increases and decreases in profit margins. Actual results could differ from estimated amounts and could result in a reduction or elimination of previously recognized earnings. In certain circumstances, it is possible that such adjustments could be significant and could have an adverse effect on our financial condition, results of operations and cash flows, especially when comparing the results of several periods.business.

 

19



Table of Contents

Our reported results of operations and financial condition could be adversely affected as a result of changes in accounting standards.

 

In May 2014, theThe Financial Accounting Standards Board finalized revised standards(“FASB”) periodically issues Accounting Standards Updates (“ASU”) that revise the treatment for revenue recognition which become effectivevarious accounting topics. See Note 2 — “Summary of Significant Accounting Policies - Recently Issued Accounting Pronouncements” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for the Company beginning in 2017.  The FASB has also announced they expect to finalize standards regarding the accounting for leases.a discussion of ASUs not yet adopted.  These changes and other future changes could result in changes in the way we report our financial results.  For example, if the lease accounting standard changes the accounting for operating leases, we may need to negotiate changes to our credit agreements to meet certain financial covenants.  If we were unable to successfully negotiate these changes, we could negatively impact our ability to maintain or obtain future credit for growth opportunities.

 

Our reported results of operations could be adversely affected as a result of impairments of goodwill, other intangible assets or investments.

 

When we acquire a business, we record an asset called “goodwill” for the excess amount we pay for the business over the net fair value of the tangible and intangible assets of the business we acquire. At December 31, 2014,2017, our balance sheet included a goodwill amount of $119$153.4 million and intangible assets of $40$44.8 million resulting from acquisitions made since 2008.previous acquisitions.   Fair value is determined using a combination of the discounted cash flow, market multiple and market capitalization valuation approaches.  Under current accounting rules, goodwill and other intangible assets that have indefinite useful lives cannot be amortized, but instead must be tested at least annually for impairment, while intangible assets that have finite useful lives are amortized over their useful lives.  Any impairment of the goodwill or intangible assets recorded in connection with the various acquisitions, or for any future acquisitions, would negatively impact our results of operations.

 

In addition, we may enter into various types of investment arrangements, such as an equity interest we hold in a business entity.  Our equity method investments are carried at original cost and are included in other assets net in our consolidated balance sheetConsolidated Balance Sheet and are adjusted for our proportionate share of the investees’ income, losses and distributions.  Equity investments are reviewed for impairment by assessing whether any decline in the fair value of the investment below its carrying value is other than temporary. In making this determination, factors such as the ability to recover the carrying amount of the investment and the inability of the investee to sustain future earnings capacity are evaluated in determining whether an impairment should be recognized. Any future impairments,

Compliance with and changes in tax laws could adversely affect our performance.

We are subject to extensive tax liabilities imposed by multiple jurisdictions. The Tax Cuts and Jobs Act (the “Tax Act”) was signed into law on December 22, 2017. This legislation makes significant changes to the U.S. Internal Revenue Code and requires complex computations not previously provided in U.S. tax law.  Given the significance of the legislation, the SEC staff issued Staff Accounting Bulletin (“SAB”) 118 which provides guidance on accounting for uncertainties of the effects of the Tax Act.  Specifically, SAB 118 allows companies to record provisional estimates of

22


Table of Contents

the impact of the Tax Act during a one year “measurement period” similar to that used when accounting for business combinations.

New tax laws and regulations and changes in existing tax laws and regulations are continuously being enacted or proposed, and could result in a different tax rate on our earnings, which could have a material impact on our earnings and cash flow from operations. In addition, significant judgment is required in determining our provision for income taxes. In the ordinary course of our business, there are many transactions and calculations where the ultimate tax determination is uncertain. We are regularly under audit by tax authorities, and our tax estimates and tax positions could be materially affected by many factors including impairmentsthe final outcome of goodwill, intangibletax audits and related litigation, the introduction of new tax accounting standards, legislation, regulations and related interpretations, our mix of earnings, the realizability of deferred tax assets or investments,and changes in uncertain tax positions. A significant increase in our tax rate could have a material adverse effect on our results of operations.profitability and liquidity.

 

We may not be successful in continuing to meet the internal control requirements of the Sarbanes-Oxley Act of 2002.

 

The Sarbanes-Oxley Act of 2002 has many requirements applicable to us regarding corporate governance and financial reporting, including the requirements for management to report on internal controls over financial reporting and for our independent registered public accounting firm to express an opinion over the operating effectiveness of our internal control over financial reporting. At December 31, 2014,2017, our internal control over financial reporting was effective using the internal control standardsframework issued by the Committee of Sponsoring Organizations (“COSO”) of the Treadway Commission:  Internal control—Integrated Framework (1992)(2013)In 2013,

We have successfully completed the implementation of an updated setintegrated financial system in the majority of internalour operations.  With the completion of the conversion from the previous system, virtually all of our operations use the same information platform, allowing us to establish more consistent financial and operational controls.  While we plan to convert the remaining operations to the same platform in 2018, there can be no assurance that the conversion will be completed on schedule, which would mean continued use of manual processes and controls, which tend to increase the risk of control standards, COSO 2013, was published.  We intend to adopt the COSO 2013 framework in assessing our internal control over financial reporting in 2015; however,deficiencies.

Please note that there can be no assurance that our internal control over financial reporting will be effective in future years. Failure to maintain effective internal controls or the identification of significantmaterial internal control deficiencies in acquisitions already made or made in the future could result in a decrease in the market value of our common stock, the reduced ability to obtain financing, the loss of customers, penalties and additional expenditures to meet the requirements in the future.

 

Starting in the fourth quarter of 2014, and continuing through the date of this Annual Report on Form 10-K, the Company’sour management, outside counsel and the Audit Committee of the Board of Directors spent considerable time and resourceshave been reviewing and analyzing various issues relating to the methods used by the Company’sour subsidiaries to recognize revenue and estimate contingencies for ongoing projects.  The internal review is not yet completedconstruction projects in progress.  We have implemented a number of changes in the documentation of contingencies and we cannot estimate when such reviewthe control processes surrounding the recognition of revenue.  We will be completed.  However, as outlined in Item 9A of this Annual Reportcontinue to focus on Form 10-K, our CEO and CFO concludedmaking additional improvements that our internal control over financial reporting is effective as of December 31, 2014.  During the fourth quarter of 2014, we made process and procedural changes that we believewill enhance our controls overand documentation.

We have been cooperating with an inquiry by the staff of the Securities and Exchange Commission, which appears to be focused on certain percentage-of-completion contract revenue recognition practices of the Company during 2013 and these enhanced controls were in place at December 31, 2014.  We anticipateare continuing enhancement of our controls, especially asto respond to the staff’s inquiries in connection with this matter.  At this stage, we beginare unable to integrate our financial and operations information systems onto a common platform.

As our internal review is ongoing, we cannot predict when the finalstaff’s inquiry will conclude or the outcome.  Depending on the outcome of the review. Until our review efforts are completed, the Company’s management, outside counsel and the Audit Committee of the Board of Directors will continue to devote considerable time and resources.  Ainquiry, a government entity or other third party could bring an action and seek interest, injunctions, fines, civil and criminal penalties, or other remedies, or assert other claims or litigation against the Companyus with respect to any issues that might arise in connection with the review. We also may not be able to effectively improve and expand our financial infrastructure, and internal operating and administrative systems and controls, or do so on a timely basis.inquiry.  Findings from the our reviewinquiry could result in a loss of investor confidence and decrease in the market value of our common stock, the reduced ability to obtain financing and the loss of customers.

 

20


23



Table of Contents

Risks Related to our Common Stock

 

Our common stock is subject to potential dilution to our stockholders.

 

As part of our acquisition strategy, we have issued shares of common stock and used shares of common stock as a part of contingent earn-out consideration, which have resulted in dilution to our stockholders.  Our Articles of Incorporation permit us to issue up to 9090.0 million shares of common stock of which 51.56approximately 51.4 million were outstanding at December 31, 2014.2017.  While NASDAQ rules require that we obtain stockholder approval to issue more than 20% additional shares, stockholder approval is not required below that level. In addition, we can issue shares of preferred stock which could cause further dilution to the stockholder, resulting in reduced net income and cash flow available to common stockholders.

 

In 2013, our stockholders adopted our 2013 Equity Incentive Plan (“Equity Plan”).  The Equity Plan replaced a previous plan.  The Equity Plan authorized the Board of Directors to issue equity awards totaling 2,526,275 shares of our common stock.  Our current director compensation plan, our management long-term incentive plan and any additional equity awards made will have the effect of diluting our earnings per share and stockholders’ percentage of ownership.

 

Our Chairman Chief Executive Officer and President is a significant stockholder, which may make it possible for him to have significant influence over the outcome of matters submitted to our stockholders for approval and his interests may differ from the interests of other stockholders.

 

As of December 31, 20142017 our Chairman Chief Executive Officer and Presidentof the Board beneficially owned approximately 23%17% of the outstanding shares of our common stock. He may have significant influence over the outcome of all matters submitted to our stockholders for approval, including the election of our directors and other corporate actions. Such influence could have the effect of discouraging others from attempting to purchase us or take us over and could reduce the market price offered for our common stock.

 

Delaware law and our charter documents may impede or discourage a takeover or change in control.

 

As a Delaware corporation, anti-takeover provisions may impose an impediment to the ability of others to acquire control of us, even if a change of control would be of benefit to our stockholders.  In addition, certain provisions of our Articles of Incorporation and Bylaws also may impose an impediment or discourage others from a takeover.  These provisions include:

 

·Our Board of Directors is classified;

·Stockholders may not act by written consent;

·There are restrictions on the ability of a stockholder to call a special meeting or nominate a director for election; and

·Our Board of Directors can authorize the issuance of preferred shares.

·

Our Board of Directors is classified;

·

Stockholders may not act by written consent;

·

There are restrictions on the ability of a stockholder to call a special meeting or nominate a director for election; and

·

Our Board of Directors can authorize the issuance of preferred shares.

 

These types of provisions may limit the ability of stockholders to obtain a premium for their shares.

 

ITEM 1B.UNRESOLVED STAFF COMMENTS

 

None.

 

ITEM 2.PROPERTIES

 

Facilities

 

Our executive offices are located at 2100 McKinney Avenue, Suite 1500, Dallas, Texas 75201. The telephone number of our executive office is (214) 740-5600. The East and Energy segments of our businessWe have regional offices located in Baton Rouge, Louisiana, inLouisiana; Lake Forest, Pittsburg, Hayward, Bakersfield, San Dimas and San Diego, California; Houston, Conroe,Belton, Deer Park, and

24


Table of Contents

Beaumont, Texas; Sarasota, Fort Worth and Pasadena, Texas, Suwanee, Georgia and in SarasotaMyers and Fort Lauderdale, Florida.  The Energy segment also has business offices located in San Dimas, CaliforniaFlorida; Little Canada, Minnesota; Hillsboro, Oregon; Denver, Colorado; and in Calgary, Canada. The West segment has regional offices located in Lake Forest, Pittsburg, San Francisco, Bakersfield and San Diego, California and offices located in Hillsboro, Oregon, Toledo, Washington, Montrose, Pennsylvania and Little Canada, Minnesota.

 

We lease most of the facilities and production yards used in our operations. The leases are generally for 10 to 12-year terms, expiring through 2023.2024.  The aggregate lease payments made for our facilities in 20142017 were approximately $6.0$6.1 million. We believe that our facilities are adequate to meet our current and foreseeable requirements for the next several years.

 

21



Table of Contents

We lease some of our facilities, employees and certain construction and transportation equipmentPrior to March 2017, we leased three properties in California from Stockdale Investment Group, Inc. (“SIGI”).  We believe that these leases were entered into on similar terms as negotiated with an independent third party. Brian Pratt, our largest stockholder and our Chief Executive Officer, President andOur Chairman of the Board of Directors, holdswho is our largest stockholder, and his family hold a majority interest in SIGI and is the chairman and chief executive officer and a director of SIGI.  John M. Perisich,In March 2017, we exercised a right of first refusal and purchased the SIGI properties.  The purchase was approved by our Executive Vice President and General Counsel, is secretaryBoard of SIGI.Directors for $12.8 million.  We assumed three mortgage notes totaling $4.2 million with the remainder paid in cash.

 

Property, Plant and Equipment

 

We ownThe construction industry is capital intensive, and maintain both construction and transportation equipment.we expect to continue making capital expenditures to meet anticipated needs for our services. In 2014, 2013 and 2012, we spent2017, capital expenditures were approximately $88.0$79.8 million.  In addition, the companies acquired during the period added $12.4 million $85.8 million and $40.3 million, respectively, in cash forto property, plant and equipment. Additionally, we acquired property andTotal construction equipment through the use of capital leases of approximately $0.0purchases in 2017 were $43.7 million in 2014, $2.6 million in 2013 and $2.9 million in 2012. We estimate that as of December 31, 2017, our capital equipment includes the following:

 

·Heavy construction and specialized equipment—1,415 units; and

·Transportation equipment—2,870 units.

·

Heavy construction and specialized equipment—5,160 units; and

·

Transportation equipment—4,386 units.

 

We believe the ownership of equipment is generally preferable to leasing to ensure the equipment is available as needed. In addition, ownership has historically resulted in lower overall equipment costs. We attempt to obtain projects that will keep our equipment fully utilized in order to increase profit. All equipment is subject to scheduled maintenance to insureensure reliability. Maintenance facilities exist at most of our regional offices as well as on-site on major jobs to properly service and repair equipment. Major equipment not currently utilized is rented to third parties whenever possible to supplement equipment income.possible.

 

The following summarizes total property, plant and equipment, net of accumulated depreciation, as of December 31, 2014 and 2013:

 

 

2014

 

2013

 

Useful Life

 

 

 

(In Thousands)

 

(In Thousands)

 

 

 

Land and buildings

 

$

40,604

 

$

36,883

 

30 years

 

Leasehold improvements

 

11,267

 

7,958

 

Lease life

 

Office equipment

 

3,651

 

3,171

 

3 - 5 years

 

Construction equipment

 

308,915

 

247,997

 

3 - 7 years

 

Transportation equipment

 

83,845

 

67,550

 

3 - 18 years

 

 

 

448,282

 

363,559

 

 

 

Less: accumulated depreciation and amortization

 

(176,851

)

(137,047

)

 

 

Net property, plant and equipment

 

$

271,431

 

$

226,512

 

 

 

ITEM 3.LEGAL PROCEEDINGS

Legal Proceedings

On February 7, 2012, the Company was sued in an action entitled North Texas Tollway Authority, Plaintiff v. James Construction Group, LLC, and KBR, Inc., Defendants, v. Reinforced Earth Company, Third-Party Defendant (the “Lawsuit”). In the Lawsuit, the North Texas Tollway Authority (“NTTA”) alleged damages to a road and retaining wall that were constructed in 1999 on the George Bush Turnpike near Dallas, Texas, due to negligent construction by JCG.  The Lawsuit claimed that the cost to repair the retaining wall was approximately $5,400.  The NTTA also alleged that six other walls constructed on the project by JCG had the same potential exposure to failure.  For the past 18 months, the Company participated in Court-ordered mediation, and on February 25, 2015 the Lawsuit was settled for an expected cost to the Company of $9 million.  During the years ended December 31, 2014, 2013, and 2012, the Company recorded liability amounts of $3,000, $4,500 and $1,500, respectively.  The amounts recorded were the approximate amounts that the Company allocated for negotiation purposes in the mediation process.

At December 31, 2014, the Company is engaged in dispute resolution to enforce collection for two construction projects completed by the Company in 2014.  For one project, a cost reimbursable contract, the Company has recorded a receivable of $33.8 million, and for the other project, the Company has recorded a receivable of $29.3 million.  At December 31, 2014, the Company has not recorded revenues in excess of cost for these two projects.  At this time, the Company cannot predict the amount that it will collect nor the timing of any collection.

 

22ITEM 3.LEGAL PROCEEDINGS



Table of Contents

 

The Company is subject to other claims andLegal Proceedings

For information regarding legal proceedings, arising out of its business. The Company provides for costs related to contingencies when a loss from such claims is probablesee Note 13 — “Commitments and the amount is reasonably determinable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, the Company reviews and evaluates its litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defense to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on the consolidated results of operations, financial condition or cash flowsContingencies of the Company.Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K, which is incorporated herein by reference.

 

Government Regulations

 

Our operations are subject to compliance with regulatory requirements of federal, state, and municipal agencies and authorities, including regulations concerning labor relations, affirmative action and the protection of the environment. While compliance with applicable regulatory requirements has not adversely affected operations in the past, there can be no assurance that these requirements will not change and that compliance with such requirements will not adversely affect operations.

 

ITEM 4.MINE SAFETY DISCLOSURES

 

Not applicable.

 

25


Table of Contents

PART II

 

ITEM 5.MARKET FOR REGISTRANT’S COMMON EQUITY, RELATED STOCKHOLDER MATTERS AND ISSUER PURCHASES OF EQUITY SECURITIES

 

Market Information

 

On July 31,August 6, 2008, our common stock began trading on the NASDAQ Global Market under the symbol “PRIM”. Previously, our common stock traded on the OTC Bulletin Board under the ticker symbol “RPSD”. Prior to their expiration on October 2, 2010, the Company had certain warrants and unit purchase options outstanding that were traded under the NASDAQ Global Market under the symbols “PRIMW” and “PRIMU”, respectively.

We had outstanding 51,561,39651,448,753 shares of common stock and 364365 stockholders of record as of December 31, 2014.2017. These holdersstockholders of record include depositories that hold shares of stock for brokerage firms, which in turn, hold shares of stock for numerous beneficial owners.

 

The following table shows the range of market prices of our common stock during 20142017 and 2013.2016.

 

 

Market price per
Share

 

 

 

 

 

 

 

 

 

High

 

Low

 

 

Market price per

 

Year ended December 31, 2014

 

 

 

 

 

 

Share

 

    

High

    

Low

 

Year Ended December 31, 2017

 

 

 

 

 

 

 

First quarter

 

$

33.35

 

$

29.26

 

 

$

29.19

 

$

21.98

 

Second quarter

 

$

30.88

 

$

26.39

 

 

$

25.74

 

$

21.83

 

Third quarter

 

$

29.80

 

$

23.88

 

 

$

30.00

 

$

23.73

 

Fourth quarter

 

$

28.72

 

$

19.99

 

 

$

29.82

 

$

25.45

 

 

 

 

 

 

 

 

 

 

 

 

 

Year ended December 31, 2013

 

 

 

 

 

Year Ended December 31, 2016

 

 

 

 

 

 

 

First quarter

 

$

22.25

 

$

15.64

 

 

$

25.25

 

$

18.10

 

Second quarter

 

$

23.12

 

$

19.12

 

 

$

24.86

 

$

17.60

 

Third quarter

 

$

25.71

 

$

19.79

 

 

$

21.07

 

$

16.13

 

Fourth quarter

 

$

31.13

 

$

23.50

 

 

$

24.53

 

$

18.71

 

 

23



Table of Contents

Dividends

 

The following table shows cash dividends to our common stockholders declared by the Companyus during the threetwo years ended December 31, 2014:2017:

 

Declaration Date

Payable Date

Record Date

Type

February 24, 2012

April 16, 2012

March 30, 2012

$

0.030 per share

May 4, 2012

July 16, 2012

June 29, 2012

$

0.030 per share

August 3, 2012

October 15, 2012

October 1, 2012

$

0.030 per share

November 1, 2012

December 26, 2012

December 18, 2012

$

0.030 per share

 

 

 

 

 

 

 

 

Declaration Date

Record Date

Payable Date

Amount Per Share

February 22, 2016

March 5, 201331, 2016

 

April 15, 2013

March 29, 20132016

 

$

0.055

0.030 per shareMay 2, 2016

 

May 3, 2013June 30, 2016

 

July 15, 2013

June 28, 20132016

 

$

0.035 per share

0.055

August 2, 2013

October 15, 20133, 2016

 

September 30, 20132016

October 14, 2016

 

$

0.055

0.035 per shareNovember 2, 2016

 

December 31, 2016

January 16, 2017

$

0.055

February 21, 2017

March 31, 2017

April 15, 2017

$

0.055

May 5, 2017

June 30, 2017

July 14, 2017

$

0.055

August 2, 2017

September 29, 2017

October 30, 201314, 2017

$

0.055

November 2, 2017

December 29, 2017

 

January 15, 2014

December 31, 20132018

 

$

0.035 per share

February 26, 2014

April 15, 2014

March 31, 2014

$

0.035 per share

May 2, 2014

July 15, 2014

June 30, 2014

$

0.035 per share

August 5, 2014

October 15, 2014

September 30, 2014

$

0.040 per share

November 4, 2014

January 15, 2015

December 31, 2014

$

0.040 per share

0.060

 

In addition, onOn February 24, 2015,21, 2018, the Board of Directors declared a $0.04$0.06 per common share dividend with a payable date of April 15, 2015 and a record date of March 31, 2015.30, 2018 and a payable date of on or about April 13, 2018. The payment of future dividends is contingent upon our revenues and earnings, capital requirements and general financial condition, of the Company, as well as contractual restrictions and other considerations deemed relevant by the Board of Directors.

 

Equity Compensation Plan Information

 

In July 2008, theMay 2013, our shareholders approved and the Companywe adopted the Primoris Services Corporation 2008 Long-term Incentive Equity Plan, which was replaced by the Primoris Services Corporation 2013 Long-term Incentive Equity Plan (“2013 Equity Plan”), as approved by. As part of the shareholderscompensation of the non-employee members of the Board of Directors, we issued 11,784 shares of common stock in February 2017 and adopted by the Company on May 3, 2013.11,448 shares in August 2017.  In

26


 

In March 2014,Table of Contents

February 2017 our management employees purchased 77,45565,429 shares of stock as part of a management incentive compensation program.  As part of the quarterly compensation of the non-employee members of the Board of Directors, the Company issued 6,375 shares of common stock in March 2014 and 6,172 shares in August 2014.  The issuance of the employee shares and the director shares werewas under the terms of the 2013 Equity Plan.

 

The following table gives information about our common stock that may be issued upon the exercise of options, warrants and rights under all of our existing equity compensation plans as of December 31, 2014.2017.

 

 

 

 

 

 

 

 

    

 

 

 

    

Number of securities

 

 

 

 

 

 

remaining available

 

 

Number of securities

 

 

 

for future issuance

 

 

to be issued upon

 

Weighted-average

 

under equity

 

 

exercise of

 

exercise price of

 

compensation plans

 

 

outstanding options,

 

outstanding options,

 

(excluding securities

 

 

warrants and rights

 

warrants and rights

 

reflected in column (a))

 

Plan category

 

Number of securities
to be issued upon
exercise of
outstanding options,
warrants and rights
(a)

 

Weighted-average
exercise price of
outstanding options,
warrants and rights
(b)

 

Number of securities
remaining available
for future issuance
under equity
compensation plans
(excluding securities
reflected in column (a))
(c)

 

 

(a)

 

(b)

 

(c)

 

Equity compensation plans approved by security holders

 

148,512

 

0

 

2,278,651

 

 

262,162

 

 —

 

1,853,494

 

Equity compensation plans not approved by security holders

 

0

 

0

 

0

 

 

 —

 

 —

 

 —

 

Total

 

148,512

 

0

 

2,278,651

 

 

262,162

 

 —

 

1,853,494

 

 

These securities represent shares of common stock available for issuance under our 2013 Equity Plan.  The 2013 Equity Plan is discussed in Note 218 of the Notes to our consolidated financial statements for the year ended December 31, 2014Consolidated Financial Statements included in Part II, Item 8 Financial Statements and Supplementary Data”.of this Form 10-K.

 

Repurchases of Securities

 

In February 2014, the Company’s2017, our Board of Directors authorized a $5.0 million share repurchase program under which the Company, from time to time and depending on market conditions, share price and other factors, may acquire shares of its common stock on the open market or in privately negotiated transactions up to an aggregate purchase price of $23 million.  During the period from February 2014 through September 2014, the Company purchased and cancelled 100,000 shares of stock for $2.8 million at an average cost of $28.44 per share.  This share repurchase program expired on December 31, 2014.

24



Table of Contents

In May 2012, the Company’s Board of Directors authorized a share repurchase program under which the Companywe could, from time to time and depending on market conditions, share price and other factors, acquire shares of itsour common stock on the open market or in privately negotiated transactions up to an aggregate purchase price of $20 million.transactions. During the period from May 2012March 23, 2017 through June 2012, the CompanyMarch 28, 2017, we purchased and cancelled 89,600216,350 shares of stock for $1.0$5.0 million at an average cost of $11.17$23.10 per share. Thisshare

In August 2016, our Board of Directors authorized a $5.0 million share repurchase program expiredunder which we could, depending on market conditions, share price and other factors, acquire shares of our common stock on the open market or in privately negotiated transactions.  During the month of December 31, 2012.2016, we purchased and cancelled 207,800 shares of stock for $5.0 million at an average cost of $24.02 per share.

 

There were no share repurchases authorized during 2015.

Sales of Unregistered Securities during 2012 through 2013

 

The Company issued 62,052We did not issue any unregistered shares of our common stock as part of the consideration for the March 2012 acquisition of Sprint and 29,273 unregistered shares were issued in February 2013 as part of the consideration for the acquisition of Q3C.during 2017, 2016 or 2015.

 

As part of the attainment of contingent consideration targets for the November 2010 acquisition of Rockford, the Company issued 494,095 shares of unregistered common stock to the sellers in the first quarter 2011 and 232,637 unregistered shares in April 2012.

27


 

All securities listed on the following table are issued unregistered shares of our common stock. At December 31, 2014, there was no remaining obligation to issue shares of common stock under contingent consideration arrangements. We relied on Section 4(a)(2) of the Securities Act, as the basis for exemption from registration. For all issuances, we believe the shares were issued to “accredited investors” as defined in Rule 501 of the Securities Act.  All issuances were as a result of privately negotiated transactions, and not pursuant to public solicitations.

Period

Number of
Shares

Purchaser

Consideration

January 1, 2012 through December 31, 2012

232,637 common shares

Stockholders of acquired companies

Achievement of financial target as contingent consideration in sale of acquired company

January 1, 2012 through December 31, 2012

62,052 common shares

Stockholders of acquired companies

Part of consideration in sale of acquired company

January 1, 2013 through February 28, 2013

29,273 common shares

Employees and Stockholders of acquired companies

Part of consideration in sale of acquired company

25



Table of Contents

Performance Graph

 

Performance Graph

The following Performance Graph and related information shall not be deemed to be filed with the Securities and Exchange Commission,SEC, nor shall such information be incorporated by reference into any future filing under the Securities Act of 1933 or Securities Exchange Act of 1934, each as amended, except to the extent that we specifically incorporate it by reference into such filing.

 

The following graph compares the cumulative total return to holders of the Company’sour common stock during the five-year period from December 31, 2009,2012, and in each quarter up tothrough December 31, 2014.2017. The return is compared to the cumulative total return during the same period achieved on the Standard & Poor’s 500 Stock Index (the “S&P 500”) and a peer group index selected by our management that includes five public companies within our industry (the “Peer Group”). The Peer Group is composed of MasTec, Inc., Matrix Service Company, Quanta Services, Inc., Sterling Construction Company, Inc. and Willbros Group, Inc.  The companies in the Peer Group were selected because they comprise a broad group of publicly held corporations, each of which has some operations similar to ours. When taken as a whole, management believes the Peer Group more closely resembles our total business than any individual company in the group.

 

The returns are calculated assuming that an investment with a value of $100 was made in the Company’sour common stock and in each stock as of December 31, 2009.2012.  All dividends were reinvested in additional shares of common stock, although none of the comparable companies did not paypaid dividends during the periods shown. The Peer Group investment is calculated based on a weighted average of the five company share prices. The graph lines merely connect the measuring dates and do not reflect fluctuations between those dates. The stock performance shown on the graph is not intended to be indicative of future stock performance.

 

COMPARISON OF DECEMBER 31, 20092012 THROUGH DECEMBER 31, 20142017

CUMULATIVE TOTAL RETURN

Among Primoris Services Corporation (“PRIM”), the S&P 500 and the Peer Group

 

 

26


28



Table of Contents

ITEM 6.SELECTED FINANCIAL DATA

 

The following selected financial data should be read in conjunction with Item 7, “Management’s Discussion and Analysis of Financial Condition and Results of Operations” and our audited financial statements and the accompanying notes included elsewhere in this Annual Report on Form 10-K.

 

 

 

Year Ended December 31,

 

 

 

2014

 

2013

 

2012

 

2011

 

2010

 

 

 

(In millions except share and per share data)

 

Statement of Operations Data:

 

 

 

 

 

 

 

 

 

 

 

Revenues

 

$

2,086

 

$

1,944

 

$

1,542

 

$

1,460

 

$

942

 

Cost of revenues

 

1,850

 

1,688

 

1,349

 

1,275

 

819

 

Gross profit

 

236

 

256

 

193

 

185

 

123

 

Selling, general and administrative expense

 

132

 

131

 

96

 

86

 

65

 

Operating income

 

104

 

125

 

97

 

99

 

58

 

Other income (expense)

 

(2

)

(5

)

(4

)

(2

)

(2

)

Income before provision for income taxes

 

102

 

120

 

93

 

97

 

56

 

Income tax provision

 

(38

)

(45

)

(34

)

(38

)

(22

)

Net Income

 

$

64

 

$

75

 

$

59

 

$

59

 

$

34

 

 

 

 

 

 

 

 

 

 

 

 

 

Less net income attributable to noncontrolling interests

 

(1

)

(5

)

(2

)

 

 

Net income attributable to Primoris

 

$

63

 

$

70

 

$

57

 

$

59

 

$

34

 

 

 

 

 

 

 

 

 

 

 

 

 

Dividends per common share

 

$

0.15

 

$

0.135

 

$

0.12

 

$

0.11

 

$

0.10

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

1.22

 

$

1.35

 

$

1.10

 

$

1.15

 

$

0.79

 

Diluted

 

$

1.22

 

$

1.35

 

$

1.10

 

$

1.14

 

$

0.72

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average common shares outstanding (in thousands):

 

 

 

 

 

 

 

 

 

 

 

Basic

 

51,607

 

51,540

 

51,391

 

50,707

 

42,694

 

Diluted

 

51,747

 

51,610

 

51,406

 

51,153

 

46,878

 

 

 

As of December 31,

 

 

 

2014

 

2013

 

2012

 

2011

 

2010

 

Balance Sheet Data:

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

139

 

$

196

 

$

158

 

$

120

 

$

115

 

Short term investments

 

$

31

 

$

19

 

$

3

 

$

23

 

$

26

 

Accounts receivable, net

 

$

337

 

$

305

 

$

268

 

$

187

 

$

208

 

Total assets

 

$

1,111

 

$

1,051

 

$

931

 

$

728

 

$

704

 

Total current liabilities

 

$

419

 

$

430

 

$

421

 

$

345

 

$

382

 

Long-term debt/capital leases, net of current portion

 

$

205

 

$

193

 

$

132

 

$

67

 

$

73

 

Stockholders’ equity

 

$

454

 

$

398

 

$

333

 

$

275

 

$

208

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 

 

 

    

2017

    

2016

    

2015

    

2014

    

2013

 

 

 

(In millions except per share data)

 

Statement of Operations Data:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues

 

$

2,380

 

$

1,997

 

$

1,929

 

$

2,086

 

$

1,944

 

Cost of revenues

 

 

2,102

 

 

1,796

 

 

1,709

 

 

1,850

 

 

1,688

 

Gross profit

 

 

278

 

 

201

 

 

220

 

 

236

 

 

256

 

Selling, general and administrative expense

 

 

172

 

 

140

 

 

152

 

 

132

 

 

131

 

Impairment of goodwill

 

 

 —

 

 

 3

 

 

 —

 

 

 —

 

 

 —

 

Operating income

 

 

106

 

 

58

 

 

68

 

 

104

 

 

125

 

Other income (expense)

 

 

(1)

 

 

(9)

 

 

(7)

 

 

(2)

 

 

(5)

 

Income before provision for income taxes

 

 

105

 

 

49

 

 

61

 

 

102

 

 

120

 

Income tax provision

 

 

(28)

 

 

(21)

 

 

(24)

 

 

(38)

 

 

(45)

 

Net income

 

$

77

 

$

28

 

$

37

 

$

64

 

$

75

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Less net income attributable to noncontrolling interests

 

 

(5)

 

 

(1)

 

 

 —

 

 

(1)

 

 

(5)

 

Net income attributable to Primoris

 

$

72

 

$

27

 

$

37

 

$

63

 

$

70

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Dividends per common share

 

$

0.225

 

$

0.220

 

$

0.205

 

$

0.150

 

$

0.135

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

1.41

 

$

0.52

 

$

0.71

 

$

1.22

 

$

1.35

 

Diluted

 

$

1.40

 

$

0.51

 

$

0.71

 

$

1.22

 

$

1.35

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average common shares outstanding:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

 

51

 

 

52

 

 

52

 

 

52

 

 

52

 

Diluted

 

 

52

 

 

52

 

 

52

 

 

52

 

 

52

 

 

27


 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

As of December 31, 

 

 

    

2017

    

2016

    

2015

    

2014

    

2013

 

Balance Sheet Data:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

170

 

$

136

 

$

161

 

$

139

 

$

196

 

Short term investments

 

 

 —

 

 

 —

 

 

 —

 

 

31

 

 

19

 

Accounts receivable, net

 

 

358

 

 

388

 

 

321

 

 

337

 

 

305

 

Total assets

 

 

1,256

 

 

1,171

 

 

1,132

 

 

1,111

 

 

1,051

 

Total current liabilities

 

 

481

 

 

450

 

 

416

 

 

419

 

 

430

 

Long-term debt/capital leases, net of current portion

 

 

194

 

 

203

 

 

220

 

 

205

 

 

193

 

Stockholders’ equity

 

 

562

 

 

499

 

 

483

 

 

454

 

 

398

 

29



Table of Contents

ITEM 7.MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

 

You should read the following discussion of our financial condition and results of operations in conjunction with the financial statements and the notes to those statements included as item 8 in this Annual Report on Form 10-K. This discussion includes forward-looking statements that are based on current expectations and are subject to uncertainties and unknown or changed circumstances. For a further discussion, please see “Forward Looking Statements” at the beginning of this Annual Report on Form 10-K. Our actual results may differ materially from those anticipated in these forward-looking statements as a result of many factors, including those risks inherent with our business as discussed in “Item 1A Risk Factors”.

 

The following discussion starts with an overview of our business and a discussion of trends, including seasonality, that affect our industry.  That is followed by an overview of the critical accounting policies and estimates that we use to prepare our financial statements.  Next we discuss our results of operations and liquidity and capital resources, including our off-balance sheet transactions and contractual obligations.  We conclude with a discussion of our outlook and backlog.

 

Introduction

 

Primoris is a holding company of various subsidiaries, which form one of the larger publicly traded specialty contractors and infrastructure companies in the United States. Serving diverse end-markets, we provide a wide range of construction, fabrication, maintenance, replacement, water and wastewater, and engineering services to major public utilities, petrochemical companies, energy companies, municipalities, state departments of transportation and other customers. We install, replace, repair and rehabilitate natural gas, refined product, water and wastewater pipeline systems; large diameter gas and liquid pipeline facilities; and heavy civil projects, earthwork and site development. We also construct mechanical facilities and other structures, including power plants, petrochemical facilities, refineries, water and wastewater treatment facilities and parking structures. Finally, we provide specialized process and product engineering services.

 

Historically, weWe have longstanding customer relationships with major utility, refining, petrochemical, power and engineering companies. We have completed major underground and industrial projects for a number of large natural gas transmission and petrochemical companies in the western United States, as well as significant projects for our engineering customers. We enter into a large number of contracts each year, and the projects can vary in length from several weeks to as long as 4860 months, or longer for completion on larger projects. Although we have not been dependent upon any one customer in any year, a small number of customers tend to constitute a substantial portion of our total revenues.

 

Generally, we recognize revenues and profitability on our contracts depending on the type of contract.  For our fixed price, or lump sum, contracts, we record revenue as the work progresses on a percentage-of-completion basis which means that we recognize revenue based on the percentage of costs incurred to date in proportion to the total estimated costs expected to complete the contract.  Fixed price contracts may include retainage provisions under which customers withhold a percentage of the contract price until the project is complete.  For our unit price and cost-plus contracts, we recognize revenue as units are completed or services are performed.  The “Critical Accounting Policies and Estimates” section below provides additional information on our contracts and revenue recognition practices.

For a number of years and throughThrough the end of the second quarter 2014,year 2016, we segregated our business into three operatingreportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment and the Engineering segment. In the thirdfirst quarter 2014,2017, we reorganizedchanged our businessreportable segments to match the change in the Company’sconnection with a realignment of our internal organization and management structure. The segment changes during the quarter reflect the focus of our new chief operating officerdecision maker (“CODM”) on the range of services we provide to our energy related customers, primarily in the Gulf Coast area (the “Energy segment”) and a continuing geographic view for the West and East segments. The chief operating officerend user markets. Our CODM regularly reviews our operating and financial performance based on these revised segments.

The operatingcurrent reportable segments include:  The West Construction Services segment (“West segment”), which is unchanged frominclude the previousPower, Industrial, and Engineering segment, the East Construction ServicesPipeline and Underground segment, (“East segment”), which is realigned from the previous East Construction ServicesUtilities and Distribution segment, and the Energy segment (which includesCivil segment.  See Note 14 – “Reportable Segments” of the previous Engineering segment).  All prior period amounts relatedNotes to the segment change have been retrospectively reclassified throughoutConsolidated Financial Statements included in Item 8 of this Annual Report on Form 10-K to conform to the new presentation.  The following isfor a brief description of each of ourthe reportable segments and business activities.

The West segment includes the underground and industrial operations and construction services performed by ARB, ARB Structures, Inc., Rockford, Alaska Continental Pipeline, Inc., Q3C, Primoris Renewables, LLC, Juniper Rock Corporation, Stellaris, LLC and Vadnais, acquired in June 2014.  Most of the entities perform work primarily in California; however, Rockford operates throughout the United States and Q3C operates in Colorado and the upper Midwest United States.  The Blythe joint venture is also included as a part of the segment.  The West segment consists of businesses headquartered primarily in the western United States.

28



Table of Contentstheir operations.

 

The Eastclassification of revenues and gross profit for segment includesreporting purposes can at times require judgment on the JCG Heavy Civil division, the JCG Infrastructurepart of management. Our segments may perform services across industries or perform joint services for customers in

30


multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and Maintenance division, BW Primorisindirect costs, such as facility costs, equipment costs and Cardinal Contractors, Inc. construction business, located primarily in the southeastern United States and in the Gulf Coast region of the United States and includes the heavy civil construction and infrastructure and maintenance operations.

The Energy segment businesses are located primarily in the southeastern United States and in the Gulf Coast region of the United States.  The segment includes the operations of the PES pipeline and gas facility construction and maintenance operations, the JCG Industrial division and the newly acquired Surber and Ram-Fab operations.  Additionally, the segment includes the OnQuest, Inc. and OnQuest Canada, ULC operations for the design and installation of high-performance furnaces and heaters for the oil refining, petrochemical and power generation industries.indirect operating expenses were made.

 

The following table lists the Company’sour primary operating subsidiariesbusiness units and their current and prior operatingreportable segment:

 

Subsidiary

Operating Segment

Prior Operating Segment

ARB, Inc., including Stellaris, LLC (“ARB”)

 

West

West

ARB Structures, Inc.

West

West

Q3 Contracting, Inc. (“Q3C”)

West

West

Rockford Corporation (“Rockford”)

West

West

Vadnais Trenchless Services, Inc. (“Vadnais”); acquired in 2014

West

West

Silva Group (“Silva”)

East

East

Cardinal Contractors, Inc.

East

East

BW Primoris, LLC (“BWP”)

East

East

James Construction Group, LLC (“JCG”):

 

 

 

 

Business Unit

Reportable Segment

Prior Reportable Segment

ARB Industrial (a division of ARB, Inc.)

Power

West

ARB Structures

Power

West

Primoris Power (formerly PES Saxon division)

Power

Energy

Primoris Renewable Energy (a division of Primoris AV)

Power

Energy

Primoris Industrial Constructors (formerly PES Industrial Division)

Power

Energy

Primoris Fabrication (a division of PES)

Power

Energy

Primoris Mechanical Contractors (a combination of a division of PES and Cardinal Contractors)

Power

Energy

OnQuest

Power

Energy

OnQuest Canada

Power

Energy

Primoris Design and Construction (“PD&C”); created 2017

Power

NA

Rockford Corporation (“Rockford”)

Pipeline

West

Vadnais Trenchless Services (“Vadnais Trenchless”)

Pipeline

West

Primoris Field Services (a division of PES Primoris Pipeline)

Pipeline

Energy

Primoris Pipeline (a division of PES Primoris Pipeline)

Pipeline

Energy

Primoris Coastal Field Services; created 2017

Pipeline

NA

ARB Underground (a division of ARB, Inc.)

Utilities

West

Q3 Contracting (“Q3C”)

Utilities

West

Primoris AV

Utilities

Energy

Primoris Distribution Services ("PDS"); created 2017

Utilities

NA

Primoris Heavy Civil (formerly JCG Heavy Civil DivisionDivision)

Civil

 

East

 

East

Primoris I&M (formerly JCG Infrastructure and& Maintenance DivisionDivision)

Civil

 

East

 

East

JCG Industrial DivisionPrimoris Build Own Operate

 

EnergyCivil

 

East

Primoris Energy Services Corporation (“PES”)

 

Energy

East

OnQuest, Inc.

Energy

Engineering

OnQuest, Canada, ULC (Born Heaters Canada, ULC prior to 2013)

Energy

Engineering

 

In 2012, PES purchased Sprint Pipeline Services, L.P. which has operated usingWe own a 50% interest in two separate joint ventures, both formed in 2015. The Carlsbad Power Constructors joint venture (“Carlsbad”) is engineering and constructing a gas-fired power generation facility, and the Sprint name“ARB Inc. & B&M Engineering Co.” joint venture (“Wilmington”) is also engineering and constructing a gas-fired power generation facility.  Both projects are located in Southern California.  The joint venture operations are included as a DBA from the acquisition through February 2015.  In accordance with the purchase agreement, the namepart of the former Sprint operating entity was changedPower segment.  As a result of determining that we are the primary beneficiary of the two variable interest entities (“VIEs”), the results of the Carlsbad and Wilmington joint ventures are consolidated in our financial statements.  Both projects are expected to “Primoris Pipeline Services” (“PPS”)be completed in March 2015.  In this Annual Report on Form 10-K references to PPS are references to the Sprint operating entity.  PES acquired two subsidiaries, The Saxon Group (“Saxon”) in 2012 and Force Specialty Services, Inc. (“FSSI”) in 2013. Effective January 1, 2014, Saxon and FSSI were merged into PES along with the Industrial division of JCG.   Throughout this Annual Report on Form 10-K, references to PPS, FSSI, Saxon and James Industrial are to the divisions of PES for 2014, while the references for the years prior to 2014 are to the entities or divisions.2018.

 

The Company ownsWe owned 50% of the Blythe Power Constructors joint venture (“Blythe”) created for the installation of a parabolic trough solar field and steam generation system in California, and its operations arehave been included as part of the West Construction ServicesPower segment.  The CompanyWe determined that in accordance with FASB Topic 810, the Company waswe were the primary beneficiary of a variable interest entity and hashave consolidated the results of Blythe in itsour financial statements. The project has been completed, and the project warranty will expireexpired in May 2015, at which timeand dissolution of the Company anticipates terminating Blythe.

In January 2014,joint venture was completed in the Company created a wholly owned subsidiary, BW Primoris, LLC, a Texas limited liability company (“BWP”). BWP’s goal is to develop water projects, primarily in Texas, that will need the Company’s construction services.  On January 22, 2014, BWP entered into an agreement to purchase the assets and business of Blaus Wasser, LLC, a Wyoming limited liability company, for approximately $5 million.  During the firstthird quarter of 2014, BWP entered into an intercompany construction contract with Cardinal Contractors, Inc. to build a small water treatment facility which will be owned by BWP.  When the treatment facility is completed, the facility will generate revenues through a take-or-pay contract with a west Texas municipal entity.  For 2014, all intercompany revenue and profit of the project have been eliminated, and at December 31, 2014, a total of $12.9 million has been capitalized as property, plant and equipment.

In May 2014, the Company created a wholly owned subsidiary, Vadnais Trenchless Services, Inc., a California company (“Vadnais”), which on June 5, 2014,  purchased the assets of Vadnais Corporation for $6.4 million. Vadnais Corporation was a general contractor specializing in micro-tunneling. The assets purchased were primarily equipment, buildings and land.   The purchase included a contingent earnout on meeting certain operating targets.2015. 

 

29Financial information for the joint ventures is presented in Note 12— “



TableNoncontrolling Interests of Contentsthe Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K.

 

DuringWe continue to be acquisitive, and the third quarter 2014,following outlines the Companyvarious acquisitions made over the past three small purchases totaling $8.2 millionyears. See Note 4— “Business Combinations” of the Notes to acquireConsolidated Financial Statements included in Item 8 of this Form 10-K

On February 28, 2015, we acquired the net assets of Surber Roustabout, LLC (“Surber”), Ram-Fab, LLC (“Ram-Fab”) and Williams Testing, LLC (“Williams”). Surber and Ram-Fab operate as divisions of PES, and Williams is a division of Cardinal Contractors,Aevenia, Inc. Surber provides general oil and gas related construction activities in Texas; Ram-Fab is a fabricator of custom piping systems located in Arkansas; and Williams provides construction services related to sewer pipeline maintenance, rehabilitation and integrity testingfor $22.3 million. Aevenia operations are included in the Florida market.  The Surber and Ram-Fab purchases provided for a contingent earnout amounts as discussed in “Note 4—Business CombinationsUtilities segment.

31


Table of Contents

 

For some end marketsOn January 29, 2016, we performacquired the same servicesnet assets of Mueller Concrete Construction Company ("Mueller") for $4.1 million, and on November 18, 2016, we acquired the net assets of Northern Energy & Power (“Northern”) for $6.9 million. On June 24, 2016, we purchased property, plant and equipment from Pipe Jacking Unlimited, Inc. (“Pipe Jacking”), consisting of specialty directional drilling and tunneling equipment for $13.4 million. We determined this purchase did not meet the definition of a business as defined under ASC 805.  Mueller operations are included in each of the West, EastUtilities segment, Northern operations are included in the Power segment, and Energy segments, while for other end markets, such as poured-in-place parking structures or turn-around services, only one of our segments currently servesPipe Jacking operations are included in the market.  The following table shows the approximate percentage of revenues over three years derived from our major end-markets, with prior periods conformed to the current year market breakdown:Pipeline segment.

 

 

 

Twelve Months Ended
December 2014

 

Twelve Months Ended
December 2013

 

Twelve Months Ended
December 2012

 

 

 

 

 

 

 

 

 

Underground capital projects

 

17

%

23

%

14

%

Utility services

 

28

%

29

%

27

%

Industrial

 

27

%

22

%

22

%

Heavy Civil

 

22

%

20

%

29

%

Engineering

 

3

%

2

%

2

%

Other

 

3

%

4

%

6

%

Total

 

100

%

100

%

100

%

On May 26, 2017, we acquired the net assets of Florida Gas Contractors (“FGC”) for $37.7 million; on May 30, 2017, we acquired certain engineering assets for approximately $2.3 million; and on June 16, 2017, we acquired the net assets of Coastal Field Services (“Coastal”) for $27.5 million. FGC operations are included in the Utilities segment, the engineering assets are included in the Power segment, and Coastal operations are included in the Pipeline segment.

 

In August 2017, we announced we are investing approximately $22.0 million to build, own, and operate a portfolio of solar projects in a California School District acquired from the developers, Spear Point Energy, LLC, and PFMG Solar, LLC.  This investment amount includes the estimated cost of Engineering, Procurement, and Construction (“EPC”) work on the projects, which is projected to be completed in 2018. The solar projects are expected to generate a 25-year recurring revenue stream from the District's signed power purchase agreement. As an investment in a renewable energy project, the solar assets should provide us with investment tax credits valued at over $5.0 million. As of December 31, 2017, our investment for the solar projects was approximately $9.9 million. The $9.9 million investment is our construction in progress on the solar projects and is included in Property and equipment, net on the Consolidated Balance Sheets.

Material trends and uncertainties

 

We generate our revenue from both large and small construction and engineering projects. The award of these contracts is dependent on many factors, most of which are not within our control. We depend in part on spending by companies in the energy and oil and gas industries, the gas utility industry, as well as municipal water and wastewater customers. Over the past several years, each segment has benefited from demand for more efficient and more environmentally friendly energy and power facilities, local highway and bridge needs and from the strength ofactivity level in the oil and gas industry; however,industry. However, periodically, each of these industries and the government agencies periodically areis adversely affected by macroeconomic conditions. Economic factors outside of our control may affect the amount and size of contracts we are awarded in any particular period.

 

We closely monitor our customers to assess the effect that changes in economic, market and regulatory conditions may have on them. We have experienced reduced spending by some of our customers over the last several years, which we attribute to negative economic and market conditions, and we anticipate that these negative conditions may continue to affect demand for our services in the near-term.  Fluctuations in market prices of oil, gas and other fuel sources can affecthave affected demand for our services.  The recent significant reductionWhile we have seen signs of a recovery in the price of oil, the significant volatility in the price of oil, gas and liquid natural gas that occurred in the past few years has created uncertainty with respect to demand for our oil and gas pipeline and roustabout services both in the near term, with additional uncertainty resulting over the length of time that prices will remain depressed.  When the current oversupply easesnear-term and with the continuing global demand increases for oil, oil prices would expect to recover from the current levels.future projects.  We believe that whileour upstream operations, such as the construction of gathering lines within the oil shale formations, maywill remain at lower levels for an extended period,period. While there was some stability in the price of oil in 2017, that stability has not resulted in a significant change in the contracting activities of our customers. We believe that over time, the need for pipeline infrastructure for mid-stream and gas utility companies will result in a continuing need for our services, over time.but the impact of the low oil prices may delay midstream pipeline opportunities. The continuing changes in the regulatory environment also can affect the demand for our services, either by increasing our work or delaying projects.  For example, the regulatory environment in California may well result in delays for the construction of gas-fired power plants while the regulators continue to search for significant renewable resources.  Weresources, but renewable resources may also create a demand for our construction services such as the need for storage of renewable generated electricity.  Finally, we believe that regulated utility customers will continue to invest in our maintenance and replacement services.

 

32


Table of Contents

Seasonality, cyclicality and variability

 

Our results of operations are subject to quarterly variations. Some of the variation is the result of weather, particularly rain, ice and snow, which can impact our ability to perform construction services. While the majority of the Company’sour work is in the southern half of the United States, these seasonal impacts can affect revenues and profitability in all of our businesses since gas and other utilities defer routine replacement and repair during their period of peak demand. Any quarter can be affected either negatively or positively by atypical weather patterns in any part of the country.  In addition, demand for new projects tends to be lower during the early part of the year due to clients’ internal budget cycles.  As a result, the Companywe usually experiencesexperience higher revenues and earnings in the third and fourth quarters of the year as compared to the first two quarters.

 

30



Table of Contents

The Company isWe are also dependent on large construction projects which tend not to be seasonal, but can fluctuate from year to year based on general economic conditions.  Our business may be affected by declines or delays in new projects or by client project schedules.  Because of the cyclical nature of our business, the financial results for any period may fluctuate from prior periods, and the Company’sour financial condition and operating results may vary from quarter-to-quarter.quarter to quarter.  Results from one quarter may not be indicative of its financial condition or operating results for any other quarter or for an entire year.

 

The variability resulting from the combination of seasonality and awards of large projects were demonstrated in the fourth quarter of 2014 when revenues were less than that of the second and third quarters, primarily reflecting the completion of a large power plant project in 2013.

Critical Accounting Policies and Estimates

 

General—The preparation of financial statements in conformity with accounting principles generally accepted in the United States requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent assets and liabilities as of the date of the financial statements and also affect the amounts of revenues and expenses reported for each period. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements cannot be calculated with a high degree of precision from data available, is dependent on future events, or is not capable of being readily calculated based on generally accepted methodologies. Often, estimates are particularly difficult to determine, and we must exercise significant judgment. Estimates may be used in our assessments of revenue recognition under percentage-of-completion accounting, the allowance for doubtful accounts, useful lives of property and equipment, fair value assumptions in analyzing goodwill and long-lived asset impairments, self-insured claims liabilities and deferred income taxes. Actual results could differ from those that result from using the estimates under different assumptions or conditions.

 

An accounting policy is deemed to be critical if it requires an accounting estimate to be based on assumptions about matters that are highly uncertain at the time the estimate is made, and different estimates that reasonably could have been used, or changes in the accounting estimates that are reasonably likely to occur periodically, could materially impact our consolidated financial statements.

 

The following accounting policies are based on, among other things, judgments and assumptions made by management that include inherent risks and uncertainties. Management’s estimates are based on the relevant information available at the end of each period.

We periodically review these accounting policies with the Audit Committee of the Board of Directors.

 

Revenue recognition

Fixed-price contracts Historically,We generate revenue under a range of contracting options, including fixed-price, unit-price, time and material, and cost reimbursable plus fee contracts. A substantial portion of our revenue has been generated underis derived from contracts that are fixed-price contracts. For fixed-price contracts, we recognize revenues primarilyor unit-price, using the percentage-of-completion method, which may result in unevenmethod. For time and irregular results. material and cost reimbursable plus fee contracts, revenue is recognized primarily based on contractual terms. Generally, time and material and cost reimbursable contract revenues are recognized on an input basis, based on labor hours incurred and on purchases made.

In the percentage-of-completion method, estimated revenues,contract values, estimated contract valuescost at completion and total costs incurred to date are used to calculate revenues earned. Unforeseen events and circumstances can alter the estimate of the costs and potential profit associated with a particular contract.  Total estimated costs, and thus contract revenues and income, can be impacted by changes in productivity, scheduling, the unit cost of labor, subcontracts, materials and equipment. Additionally, external factors such as weather, client needs, client delays in providing permits and approvals,

33


Table of Contents

labor availability, governmental regulation and politics may affect the progress of a project’s completion and thus the timing of revenue recognition.

To the extent that original cost estimates are modified, estimated costs to complete increase, delivery schedules are delayed, or progress under a contract is otherwise impeded, cash flow, revenue recognition and profitability from a particular contract may be adversely affected. As a significant change in one or more of these estimates could affect the profitability of our contracts, we review and update our contract-related estimates regularly. We recognize adjustments in estimated profit on contracts as changes in accounting estimates in the period in which the revisions are identified. Revenue and profit in future periods of contract performance are recognized using the adjusted estimate. 

If at any time the estimate of contract profitability indicates an anticipated loss on a contract, the projected loss is recognized in full in the period it is identified and recognized as an “accrued loss provision” which is included in the accrued expenses and other current liabilities amount on the balance sheet. For contract revenue recognized under the percentage-of-completion method, the accrued loss provision is adjusted so that the gross profit for the contract remains zero in future periods. The provision for estimated losses on uncompleted contracts was $10.1 million and $12.8 million at December 31, 2017 and 2016, respectively.

 

We consider unapproved change orders to be contract variations for which wecustomers have customer approval for a change innot agreed to both scope but for which we do not have an agreed upon price change.and price.  Costs associated with unapproved change orders are included in the estimated cost to complete the contracts and are treated as project costs as incurred. We will recognize revenue equal to costs incurred on unapproveda change orders when realization of change order approvalin contract value if we believe it is probable.probable that the contract price will be adjusted and can be reliably estimated.  Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers.

 

We consider claims to be amounts that we seek, or will seek, to collect from customers or others for customer-caused changes in contract specifications or design, or other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers on both scopecustomers. Claims can also be caused by non-customer-caused changes, such as rain or other weather delays.  Costs associated with claims are included in the estimated costs to complete the contracts and price changes.are treated as project costs when incurred.  Claims are included in revenue to the calculation of revenue whenextent we have a reasonable legal basis, the related costs have been incurred, realization is probable, and amounts can be reliably determined. Revenue in excess of contract costs incurred on claims are recognized when the amounts have been agreed upon with the customer.estimated.  Revenue in excess of contract costs from claims is recognized whenafter an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract. Costs associated with

At December 31, 2017, we had unapproved change orders and claims are included in the estimated costs to completeexpected contract value that totaled approximately $67.8 million. These claims were in the contractsprocess of being negotiated in the normal course of business. Approximately $56.7 million of unapproved change orders and are treatedclaims had been recognized as project costs when incurred.

31



Table of Contents

Other contract forms — We also use unit-price, time and material, and cost reimbursable plus fee contracts.  For these jobs, revenue is recognized primarily based on contractual terms.  For example, time and material contract revenues are generally recognized on an input basis, based on labor hours incurred and on purchases made.  Similarly, unit price contracts generally recognize revenue on an output based measurement such as the completion of specific units at a specified unit price.

At any time during a fixed-price contract if an estimate of total contract cost indicates a loss on a contract, the projected loss is recognized in full at that time. The loss amount is recognized as an “accrued loss provision” and is included in the accrued expenses and other liabilities amount on the balance sheet. As thecumulative percentage-of-completion method is used to calculate revenues, the accrued loss provision is changed so that the gross profit for the contract remains zero in future periods. If we anticipate that there will be a loss for unit price or cost reimbursable contracts, the projected loss is recognized in full at that time.  The provision for estimated losses on uncompleted contracts was $2.4 million and $1.4 million atbasis through December 31, 2014 and 2013, respectively.

Changes in job performance, job conditions and estimated profitability, including those arising from final contract settlements, may result in revisions to costs and income. These revisions are recognized in the period in which the revisions are identified.2017.

 

In all forms of contracts, we estimate the collectability of contract amounts at the same time that we estimate project costs.  If we anticipate that there may be issues associated with the collectability of the full amount calculated as revenue,revenues, we may reduce the amount recognized as revenue to reflect the uncertainty associated with realization of the eventual cash collection. For example, when a cost reimbursable project exceeds the client’s expected budget amount, the client frequently requests an adjustment to the final amount. Similarly, some utility clients reserve the right to audit costs for significant periods after performance of the work. In these situations, we may choose to defer recognition of a portion of the revenue up to the time thatuntil the client pays for the services.  In some instances we may be sufficiently concerned about the collectability of contract amounts that we may choose to recognize revenue only to the extent of cost that is with no margin, until we believe that we have resolved the collectability matter.

 

The caption “Costs and estimated earnings in excess of billings” in the Consolidated Balance SheetSheets represents unbilled receivables which arise when revenues have been recorded but the amount will not be billed until a later date.  Balances represent:  (a) unbilled amounts arising from the use of the percentage-of-completion method of accounting which may not be billed under the terms of the contract until a later date or project milestone; (b) incurred costs to be billed under cost reimbursementreimbursable type contracts, (c)including amounts arising from routine lags in billing,billing; or (d)(c) the revenue associated with unapproved change orders or claims when realization is probable and amounts can be reliably determined.estimated.  For those contracts in which billings exceed contract revenues recognized to date, the excess amounts are included in the caption “Billings in excess of costs and estimated earnings”.

34


Table of Contents

 

In accordance with applicable terms of certain construction contracts, retainage amounts may be withheld by customers until completion and acceptance of the project.  Some payments of the retainage may not be received for a significant period after completion of our portion of a project.  In some jurisdictions, retainage amounts are deposited into an escrow account.

 

Valuation of acquired businesses—We use the fair value of the consideration paid and the fair value of the assets acquired and liabilities assumed to account for the purchase price of businesses.  The determination of fair value requires estimates and judgments of future cash flow expectations for the assignment of the fair values to the identifiable tangible and intangible assets.

 

Identifiable Tangible Assets.  Significant identifiable tangible assets acquired would include accounts receivable, costs and earnings in excess of billings for projects, inventory and fixed assets generally(generally consisting of construction equipment,equipment) for each acquisition. We determine the fair value of these assets onas of the acquisition date.  For current assets and current liabilities of an acquisition, the Companywe will evaluate whether the book value is equivalent to fair value due to their short term nature.  We estimate the fair value of fixed assets using a market approach, based on comparable market values for similar equipment of similar condition and age.

 

Identifiable Intangible Assets.  When necessary, we use the assistance of an independent third party valuation specialist to determine the fair value of the intangible assets acquired forin the acquisitions.

32



Table of Contents

 

A liability for contingent consideration based on future earnings is estimated at its fair value at the date of acquisition, with subsequent changes in fair value recorded in earnings as a gain or loss.  Fair value is estimated as of the acquisition date using estimated earnout payments based on management’s best estimate.

 

Accounting principles generally accepted in the United States provide a “measurement period” of up to one year in which to finalize all fair value estimates associated with the acquisition of a business.  Most estimates are preliminary until the end of the measurement period.  During the measurement period, adjustments to initial valuations and estimates that reflect newly discovered information that existed at the acquisition date are recorded.  After the measurement date, any adjustments would be recorded as a current period gain or loss.

 

Goodwill and Indefinite-Lived intangible Assets—Goodwill and certain intangible assets acquired in a business combination and determined to have indefinite useful lives are not amortized but are assessed for impairment annually and more frequently if triggering events occur. In performing these assessments, management relies on various factors, including operating results, business plans, economic projections, anticipated future cash flows, comparable transactions and other market data. There are inherent uncertainties related to these factors and judgment in applying them to the analysis of goodwill for impairment. Since judgment is involved in performing fair value measurements used in goodwill impairment analyses, there is risk that the carrying values of our goodwill may not be properly stated.

 

We account for goodwill, including evaluation of any goodwill impairment under ASC Topic 350 “Intangibles — Goodwill and Other”, performed at the reporting unit level for those units with recorded goodwill onas of October 1 of each year, unless there are indications requiring a more frequent impairment test.

 

To date, goodwillGoodwill has arisen from acquisitions and is recorded at our reporting unitssegments as follows at December 31 (in millions)thousands):

 

Reporting Unit

 

Segment

 

December 31,
2014

 

Rockford

 

West

 

$

32.1

 

Q3C

 

West

 

13.2

 

JCG (includes Heavy Civil and Infrastructure and Maintenance divisions)

 

East

 

42.9

 

Cardinal Contractors, Inc.

 

East

 

0.4

 

PES (includes JCG Industrial, PPS, FSSI, Saxon & Surber divisions)

 

Energy

 

28.4

 

OnQuest Canada, ULC

 

Energy

 

2.4

 

Total Goodwill

 

 

 

$

119.4

 

 

 

 

 

 

 

 

 

Reporting Segment

 

2017

 

2016

 

Power

 

$

24,391

 

$

24,512

 

Pipeline

 

 

51,521

 

 

42,252

 

Utilities

 

 

37,312

 

 

20,312

 

Civil

 

 

40,150

 

 

40,150

 

Total Goodwill

 

$

153,374

 

$

127,226

 

 

35


Table of Contents

Under ASU 2012-02 - ASC 350, “Intangibles — Goodwill and Other (Topic 350):  Testing Indefinite-Lived Intangible Assets for ImpairmentOther”, the Companywe can assess qualitative factors to determine if a quantitative impairment test of intangible assets is necessary.  Typically, however, the Company useswe use the two-step impairment test outlined in ASC Topic 350.  The Company tests for goodwill impairment on October 1 each year.  First, we compare the fair value of a reporting unit with its carrying amount. Fair value for the goodwill impairment test is determined utilizing a discounted cash flow analysis based on our budgetsfinancial plan discounted using our weighted average cost of capital and market indicators of terminal year cash flows. Other valuation methods may be used to corroborate the discounted cash flow method. If the carrying amount of a reporting unit is in excess of its fair value, goodwill is considered potentially impaired and further tests are performed to measure the amount of impairment loss. In the second step of the goodwill impairment test, we compare the implied fair value of reporting unit goodwill with the carrying amount of the reporting unit’s goodwill. If the carrying amount of the reporting unit’s goodwill exceeds the implied fair value of that goodwill, an impairment loss is recognized in an amount equal to the carrying amount of goodwill over its implied fair value. The implied fair value of goodwill is determined in the same manner that the amount of goodwill recognized in a business combination iswas determined. We allocate the fair value of a reporting unit to all of the assets and liabilities of that unit, including intangible assets, as if the reporting unit had been acquired in a business combination. Any excess of the fair value of a reporting unit over the amounts assigned to its assets and liabilities represents the implied fair value of goodwill.

During the third quarter of 2016, we made a decision to divest the Texas heavy civil business unit, a division of Primoris Heavy Civil within the Civil segment.  We engaged a financial advisor to assist in the marketing and sale of the business unit, and planned to continue operating the business unit until completion of a sale.  In April 2017, the Board of Directors determined that based on the information available, we would attain the best long-term value by withdrawing from the sales process and continuing to operate the business unit.   

Under the provisions of ASC 350, the planned divestiture triggered an analysis of the goodwill amount of Primoris Heavy Civil.  The analysis resulted in a pretax, non-cash goodwill impairment charge of approximately $2.7 million in the third quarter of 2016. 

In the fourth quarter of 2015, an impairment expense of $0.4 million was recorded relating to the goodwill attributed to Cardinal Contractors, Inc., which is a part of the Power segment.  There were no other impairments of goodwill for the years ended December 31, 2017, 2016 and 2015.

 

Disruptions to our business, such as end market conditions, protracted economic weakness, unexpected significant declines in operating results of reporting units and the divestiture of a significant component of a reporting unit, may result in our having to perform a goodwill impairment first step valuation analysis for some or all of our reporting units prior to the required annual assessment. These types of events and the resulting analysis could result in goodwill impairment charges in any periods in the future.

 

Reserve for uninsured risks—Estimates are inherent in the assessment of our exposure to uninsured risks. Significant judgments by us and, where possible, third-party experts are needed in determining probable and/or reasonably estimable amounts that should be recorded or disclosed in the financial statements.  Semiannually, we obtain a third-party actuarial valuation for some of our uninsured risks. The results of any changes in accounting estimates are reflected in the financial statements of the period in which we determine we need to record a change.

 

33



Table of Contents

We self-insure worker’s compensation claims up to $0.25 million per claim.  We maintained a self-insurance reserve totaling approximately $22.3$18.5 million at December 31, 20142017 and approximately $20.6$18.8 million at December 31, 2013.2016. Claims administration expenses were charged to current operations as incurred.  Our accruals are based on judgment, the probability of losses, and where applicable, the consideration of opinions of internal and/or external legal counsel.counsel and third party consultants. The amount is included in “accruedAccrued expenses and other current liabilities” on our balance sheets.Consolidated Balance Sheets. Actual payments that may be made in the future could materially differ from such reserves.

 

Income taxes—We account for income taxes under the asset and liability method as set forth in ASC Topic 740, “Income Taxes”Income Taxes, which requires the recognition of deferred tax assets and liabilities for the expected future tax consequences of events that have been included in the financial statements. Under this method, deferred tax assets and liabilities are determined based on the temporary differences between the financial statementsreporting bases and tax basisbases of

36


Table of Contents

assets and liabilities using enacted tax rates in effect for the yearyears in which the differences are expected to reverse. The effect of a changechanges in tax rates on net deferred tax assets andor liabilities is recognized as an increase or decrease in net income in the period that includes the enactment date.tax change is enacted.

 

Deferred income tax assets may be reduced by a valuation allowance if, in the judgment of our management, it is more likely than not that all or a portion of a deferred tax asset will not be realized. In making such determination, we consider all available evidence, including recent financial operations, projected future taxable income, scheduled reversals of deferred tax liabilities, tax planning strategies, and the length of tax asset carryforward periods. The realization of deferred tax assets is primarily dependent upon our ability to generate sufficient future taxable earnings in certain jurisdictions. If we subsequently determine that some or all deferred tax assets that were previously offset by a valuation allowance are realizable, the value of the deferred tax assets would be increased andby reducing the valuation allowance, would be reduced, thereby increasing net income in the period when that determination is made. During 2017, we determined it is more likely than not that a portion of our deferred tax asset for foreign tax credits will not be realized. Accordingly, a valuation allowance of $0.6 million was made.recorded.

 

A tax position is recognized as a benefit only if it is more likely than not that the tax position would be sustained based on its technical merits in a tax examination, using the presumption that the tax authority has full knowledge of all relevant facts regarding the position. The amount recognized is the largest amount of tax benefit that is greater than 50% likely of being realized on ultimate settlement with the tax authority. For tax positions not meeting the more likely than not test, no tax benefit is recorded.

 

Tax Cuts and Jobs Act—On December 22, 2017, the U.S. Government enacted comprehensive tax legislation commonly referred to as the Tax Cuts and Jobs Act (the “Tax Act”).  The Tax Act makes broad and complex changes to the U.S. tax code that affect our 2017 results, including the allowance of bonus depreciation that provides for immediate deduction of qualified property placed in service after September 27, 2017.   The Tax Act also establishes new tax laws that may affect our 2018 and future results, including but not limited to:

·

Reduction of the U.S. federal corporate income tax rate from 35% to 21%;

·

The repeal of the domestic production activities deduction;

·

Further limitations on the deductibility of certain executive compensation;

·

Disallowance of certain entertainment expense deductions;

·

Limitations on the use of foreign tax credits to reduce the U.S. income tax liability;

·

Limitations on interest expense deductibility;

·

Elimination of the corporate alternative minimum tax.

While the Tax Act also contains complex changes to the tax code for companies operating internationally, we are not materially impacted by the international provisions of the Tax Act.

Given the significant impact of the legislation, the SEC staff issued Staff Accounting Bulletin (“SAB”) 118 which provides guidance on accounting for uncertainties of the effects of the Tax Act.  Specifically, SAB 118 allows companies to record provisional estimates of the impact of the Tax Act during a one year “measurement period” similar to that used when accounting for business combinations. 

As a result of the Tax Act, we remeasured our deferred tax assets and liabilities using the newly enacted tax rates and recorded a one-time net tax benefit of $9.4 million in the period ended December 31, 2017. This tax benefit is a provisional estimate that could be revised once we finalize our deductions for tax depreciation and executive compensation accruals. We may also revise our estimate based on any additional guidance issued by the U.S. Treasury Department, the U.S. Internal Revenue Service, and other standard-setting bodies.

Long-Lived Assets—Assets held and used by the Company,us, primarily property, plant and equipment, are reviewed for impairment whenever events or changes in business circumstances indicate that the carrying amount of the asset may not be fully recoverable. We perform an undiscounted operation cash flow analysis to determine if an impairment exists. For purposes of recognition and measurement of an impairment for assets held for use, we group assets and liabilities at the lowest level for which cash flows are separately identified. If an impairment is determined to exist, any related

37


Table of Contents

impairment loss is calculated based on fair value. The calculation of the fair value of long-lived assets is based on assumptions concerning the amount and timing of estimated future cash flows and assumed discount rates, reflecting varying degrees of perceived risk. Since judgment is involved in determining the fair value and useful lives of long-lived assets, there is a risk that the future carrying value of our long-lived assets may be overstated or understated.have differing future fair values.

 

Multiemployer plans —  Various subsidiaries in the West segment are signatories to collective bargaining agreements. These agreements require that the Companywe participate in and contribute to a number of multiemployer benefit plans for itsour union employees at rates determined by the agreements. The trustees for each multiemployer plan determine the eligibility and allocations of contributions and benefit amounts, determine the types of benefits, and administer the plan. To the extent that any plans are underfunded, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, requires that if the Companywe were to withdraw from an agreement or if a plan is terminated, we may incur a withdrawal obligation. Since the withdrawal liability is based on estimates of our proportional share of the plan’s unfunded vested liability, as calculated by the plan’s actuaries, the potential withdrawal obligation may be significant.

In November 2011, members of the CompanyPipe Line Contractors Association ���PLCA” including ARB, Rockford and Q3C (prior to our acquisition in 2012), withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan for which we have(“Plan”).  These withdrawals were made in order to mitigate additional liability in connection with the significantly underfunded Plan.  We recorded a withdrawal liability of $7.5 million, which represents our best estimatewas increased to $7.6 million after the acquisition of Q3C.  During the first quarter of 2016, we received a final payment schedule.  As a result of payments made and based on this schedule, the liability recorded at December 31, 2017 was $4.7 million.  We expect to pay the time it was recorded.  Any changes in the estimated withdrawalremaining liability could materially affect our results of operations, cash flowbalance during 2018 and financial position in the period such a change occurs.  See Note 14 — “Commitments and Contingencies” in the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for further information.  The Company hashave no plans to withdraw from any other labor agreements.

 

Litigation and contingenciesLitigation and contingencies are included in our consolidated financial statements based on our assessment of the expected outcome of litigation proceedings or the expected resolution of the contingency.  We provide for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable.estimable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, we review and evaluate litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss. Management is unable to ascertain the ultimate outcome of

34



Table of Contents

other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defense to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on theour consolidated results of operations, financial condition or cash flowsflows.  See Note 13 — “Commitments and Contingencies of the Company.Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for further information.

 

Recently Issued Accounting Pronouncements

 

See Note 2 — “Summary of Significant Accounting Policies - Recently Issued Accounting Pronouncements” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K for a descriptiondiscussion of recently issued accounting pronouncements, including the expected datespronouncements.

Results of adoption and estimated effectsOperations

Consolidated Results

Two events had a material impact on our results of operations financial positionin 2016.  In the third quarter we received a $38.0 million settlement for one of the construction projects that we had identified as part of our “Receivable Collection Actions”, discussed below.  Because we had recorded the project with zero gross profit, the settlement added $27.5 million to revenues and cash flows.$26.7 million to gross profit.  Also in the third quarter, we recorded a charge of $37.3 million primarily related to certain Belton, Texas area projects for the Texas Department of Transportation (“TXDOT”), as a result of project delays and productivity issues.       

38


Table of Contents

 

Results of OperationsRevenues

 

Revenue, gross profit, operating income2017 and net income2016

Revenues for the yearsyear ended December 31, 2014, 2013 and 2012 were as follows:

 

 

2014

 

2013

 

2012

 

 

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenues

 

$

2,086.2

 

100.0

%

$

1,944.2

 

100.0

%

$

1,541.7

 

100.0

%

Gross profit

 

236.0

 

11.3

%

256.0

 

13.2

%

192.7

 

12.5

%

Selling, general and administrative expense

 

132.2

 

6.3

%

130.8

 

6.8

%

96.4

 

6.3

%

Operating income

 

103.8

 

5.0

%

125.2

 

6.4

%

96.3

 

6.2

%

Other income (expense)

 

(1.5

)

(0.1

)%

(5.6

)

(0.2

)%

(4.2

)

(0.3

)%

Income before income taxes

 

102.3

 

4.9

%

119.6

 

6.2

%

92.1

 

6.0

%

Provision for income taxes

 

(38.6

)

(1.9

)%

(44.9

)

(2.3

)%

(33.8

)

(2.2

)%

Net income

 

63.7

 

3.0

%

74.7

 

3.9

%

58.3

 

3.8

%

Net income attributable to noncontrolling interests

 

(0.5

)

(0.0

)%

(5.0

)

(0.3

)%

(1.5

)

(0.1

)

Net income to Primoris

 

$

63.2

 

3.0

%

$

69.7

 

3.6

%

$

56.8

 

3.7

%

Consolidated Results

Revenues

2014 and 2013

Revenue in 2014 grew to $2.1 billion, an increase of $142.02017 increased by $383.0 million, or 7.3% from19.2%, compared to 2016.  All segments reported year over year growth.  Progress on three major pipeline jobs ($83.6 million), higher activity with major utility clients in California and the prior year.Midwest ($135.6 million) and progress on our joint venture power plant projects in Southern California and a Mid-Atlantic power plant project ($158.2 million combined) drove higher 2017 revenue.  Also contributing to 2017 growth was higher volume on our Belton area (Civil) projects and a Louisiana methanol plant project. The overall increase in revenue at the energy segment of $269.8 million, and at the East segment of $59.5 million, was partially offset by a declinedecreases associated with projects substantially completed in 2017 and revenue recognized from the West segmentone-time benefit of $187.3 million. In 2014, the West segment represented 46.2%settlement of total revenue,one of the Energy segment represented 30.3%, and the East segment was 23.5% of total revenue.“Receivable Collection Actions” in 2016. Revenue from 2017 acquisitions made in 2014 and 2013 added $18.9 million to revenue.incremental revenue from 2016 acquisitions (where we only owned a business for a portion of the year) totaled $53.6 million.

 

20132016 and 20122015

 

RevenueRevenues for year ended December 31, 2016 increased by $402.5$67.5 million, or 26.1%, in 20133.5% compared to 2012 as a result of both acquisitive and organic growth.  Revenues from acquisitions made in 2012 were $344.8 million,2015.  The increase was primarily due to an increase of $152.4$64.1 million or 79.2%,from Rockford’s pipeline work, $34.5 million for work at a large petrochemical project in Louisiana and $35.4 million from a new collaboration MSA arrangement at ARB Underground.  These increases were partially offset by a revenue reduction of $50.1 million at OnQuest, a reduction of $16.4 million at Saxon, and a reduction of $24.5 million in Heavy Civil projects.  Revenues for 2016 also included the one-time benefit of $27.5 million from the $192.4 million in 2012.  Organically, revenues atsettlement of one of the West segment increased by $163.2 million, or 19.6%, revenues at the East segment decreased by $39.5 million, or 8.4%, and revenues increased at the Energy segment by $46.6 million, or 33.6%, all compared to 2012.  In 2013, the West segment represented 59.2% of total revenues, the East segment represented 22.1% of total revenues and the Energy segment represented 18.7% of total revenues.  In 2012, the West segment represented 54.0% of total revenues, the East segment represented 30.5% of total revenues and the Energy segment represented 15.5% of total revenues.“Receivable Collection Actions”.

 

35As discussed in Note 2 — “



TableSummary of ContentsSignificant Accounting Policies

Gross Profit

2014”, we had unapproved change orders and 2013claims included in contract value that totaled approximately $67.8 million at December 31, 2017. Of this amount, approximately $49.7 million was claims related to the Belton area projects.

 

Gross Profit

2017 and 2016

For the year ended December 31, 2017, gross profit for 2014 decreasedincreased by $20.0$77.1 million, or 7.8%38.3%, compared to 2016. All segments reported year over year improvement.  Strong revenue growth and the favorable performance on the two large pipeline projects in Florida drove significant improvement.  Also benefiting 2017 were higher volumes for the Power segment and better performance from 2013.  As discussed in the segment results below, the decrease inCivil.  The year over year increase was partially offset by $26.7 million of gross profit was $47.3 millionrecognized in 2016 from the West segment.settlement of one of the “Receivable Collection Actions”. Gross profit for the Energy segment increased by $25.9 millionProfit from 2017 acquisitions and increased by $1.4 million for the East segment.  Grossincremental gross profit from 2016 acquisitions made in 2014 and 2013 added $3.0 million to 2014 gross profit.  The large decrease in both revenue and gross profit in(where we only owned a business for a portion of the West segment resulted in a decrease of grossyear) totaled $8.6 million. Gross profit as a percentage of revenuerevenues increased to 11.7% in 2017 from 13.2%  to 11.3%.10.1% in 2016 for the reasons noted above.

 

2016 and 2015

For the year ended December 31, 2016, gross profit decreased by $18.6 million, or 8.4% compared to 2015.  The decrease was primarily from the decrease in Heavy Civil projects of $38.2 million, of which $33.4 million was from a decrease at the Belton area projects.  Gross profit decreased by $6.1 million at the Louisiana petrochemical project, in spite of an increase in revenue, as the scope of our work has changed to less equipment intensive, lower margin work.  Gross profit also decreased at ARB Underground by $6.3 million and $8.6 million at ARB Industrial with these decreases offset by a gross profit increase of $15.4 million at Rockford. Our gross profit benefitted by $26.7 million from the settlement of one of the “Receivable Collection Actions”. Gross profit as a percentage of revenues decreased from 13.2%11.4% in 20132015 to 11.3%10.1% in 2014.2016 for the reasons noted above.

 

2013

39


Table of Contents

Selling, general and 2012administrative expenses

 

Gross profit increased by $63.3 million, or 32.9%, in 2013 compared with 2012.  Of this increase, gross profit from 2012 acquisitions contributed $30.1 million or 15.6%, and organic growth accounted for $33.2 million or 17.3%.  Gross profit at the West segment increased by $71.4 million or 60.0% with Q3C contributing $29.4 million of this increase. The balance of $42.0 million was due to organic growth, including the impact of the close-out of a major power plant project. Gross profit at the East segment decreased by $14.7 million, or 36.6%, whereas profit at the Energy segment increased by $6.6 million, or 19.9%, all compared to 2012.  In 2013, the West segment gross profit represented 74.5% of total gross profit, the Energy segment gross profit represented 15.5% of the gross profit, and the East segment represented 10.0% of gross profit.  In 2012, the West segment gross profit represented 61.9% of total gross profit, the East segment gross profit represented 20.9% of the gross profit, and the Energy segment represented 17.2% of gross profit.

Gross profit as a percentage of revenues increased from 12.5% in 2012 to 13.2% in 2013.

Selling, general and administrative expenses

2014 and 2013

Selling, general and administrative (“SG&A”) expenses consist primarily of compensation and benefits to executive, management level and administrative salaries and benefits,employees, marketing and communications, professional fees, office rent and utilities and acquisition costs. 

2017 and 2016

For 2017, SG&A expenses were $132.2$172.1 million, in 2014 compared to $130.8$140.8 million in 2013.  The prior year included one-time expenses of $8.2 million, as described in the following paragraph.  Excluding the one-time expenses, SG&A in 2014 increased $9.6 million, or 7.8%, which includedfor 2016, an increase of $1.4$31.3 million.  Approximately $12.4 million as a result of the 2014 acquisitionsincrease in SG&A is related to businesses acquired in 2017 and a full year of Vadnais, Surber and Ram-Fab.  Remaining increases wereexpense in 2017 for the Northern acquisition compared to less than two months of expense in 2016. The remaining increase was primarily due to increases in compensation and benefits, marketing and communications expenses and professional fees.

2013 and 2012

SG&A expenses consist primarily of compensation and benefits marketing and communications, professional fees, office rent and utilities and acquisition costs.  SG&A expenses increased $34.4 million, or 35.6%, for 2013 compared to 2012.  The primary reasons for the change are as follows:

·$15.9 million as a result of the March 11, 2013 acquisition of FSSI and the full year impact of acquisitions made in 2012.

·$8.2$12.6 million increase in 2013 from the following one-time items:

·$1.7compensation related expenses, including incentive compensation accruals; and a $1.3 million for the impairment of an intangible asset and expensing of a prepaid asset at FSSI;

·$4.0 million from an other than temporary impairment of WesPac and Alvah’s basis differences; and

·$2.5 million impact of a favorable settlement of litigation in 2012.

·$10.3 million from an increase in compensation and compensation related expenses.legal costs.

 

SG&A as a percentage of revenue

for the year ended December 31, 2017 increased slightly to 7.2% compared to 7.1% for the year ended December 31, 2016. Excluding the impact of acquisitions, SG&A expenses as a percentage of revenue for the year ended December 31, 2017, decreased slightly to 6.3%6.9% compared to 7.1% for 2014, from 6.8%the year ended December 31, 2016.

2016 and 2015

For 2016, SG&A expenses were $140.8 million, compared to $151.7 million for 20132015, a decrease of $10.9 million.  The decrease was primarily as a result of decreases in professional fees of $7.4 million due to reduced legal fees and 6.3% for 2012.  Excludingdue to completion of the implementation of the integrated financial system.  The reduction in SG&A was also the result of a $2.6 million prior year 2013 one-time chargesvaluation adjustment for the value of $8.2 million, the 2013 percentage would have been 6.3% of revenues.  With this adjustment,a long-term asset.  Additionally, SG&A expenseswas reduced as a result of a decrease of $1.8 million in compensation and staffing levels.

SG&A as a percentage of revenue for the year ended December 31, 2016 decreased to 7.1% compared to 7.9% for the year ended December 31, 2015 as a result of the decreased expenses while revenues over the last three years would be unchanged at 6.3%.increased.

 

36



Table of Contents

Other income and expense

 

Non-operating income and expense items for the years ended December 31, 2014, 20132017, 2016 and 20122015 were as follows:

 

2014

 

2013

 

2012

 

 

 

 

 

 

 

 

 

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

 

2017

    

2016

    

2015

 

Other income (expense)

 

 

 

 

 

 

 

Income (loss) from non-consolidated investments

 

$

5.3

 

$

(4.8

)

$

0.2

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Investment income

 

$

5.8

 

$

 —

 

$

 —

 

Foreign exchange gain (loss)

 

0.3

 

0.2

 

(0.1

)

 

 

0.2

 

 

0.2

 

 

(0.8)

 

Other income (expense)

 

(0.8

)

4.8

 

(0.9

)

 

 

0.5

 

 

(0.3)

 

 

1.7

 

Interest income

 

0.1

 

0.1

 

0.2

 

 

 

0.6

 

 

0.1

 

 

0.1

 

Interest expense

 

(6.4

)

(5.9

)

(3.6

)

 

 

(8.1)

 

 

(8.9)

 

 

(7.7)

 

Total other income (expense)

 

$

(1.5

)

$

(5.6

)

$

(4.2

)

 

$

(1.0)

 

$

(8.9)

 

$

(6.7)

 

 

For 2014,Investment income for the year ended December 31, 2017 is related to a gain from non-consolidated joint ventures was due primarily toa short-term investment in marketable equity securities.We purchased the salesecurities in the third quarter of our interest2017 and sold the securities in the fourth quarter of the WesPac-energy non-consolidated joint venture.2017.

 

The loss from non-consolidated joint ventures for 2013 included an impairment expense of $4.9 million for the WesPac-energy joint ventureForeign exchange gains and a loss of $0.6 million from WesPac operations, partially offset by a $0.7 million profit from the Alvah investment.

Income from non-consolidated joint ventures for 2012 included $1.1 million from the St.-Bernard Levee Partners joint venture, reduced by $0.9 million expense for the WesPac-Energy joint venture.

The foreign exchange gain for 2014 and 2013 and the loss for 2012losses reflect currency exchange fluctuations of the United States dollar compared to the Canadian dollar.  OurMany of our contracts in Calgary, Canada are sold based on United States dollars, but a portion of the work is paid for with Canadian dollars creating a currency exchange difference.

 

The 2014 netOther income for 2017 was $0.5 million compared to other expense of $0.3 million for 2016. The $0.8 million change was primarily due to adjustmentsremeasurement of the contingent consideration related to the FGC performance target contemplated in their purchase agreement. Under ASC 805, we are required to estimate the fair value of contingent consideration based on facts and circumstances that existed as of the acquisition date and remeasure to fair value at each

40


Table of Contents

reporting date until the contingency is resolved. As a result of that remeasurement, we reduced the contingent consideration liabilities related to the acquisitions of Q3C, Surber and Vadnais.

Net other income for 2013 was $4.8 million.  The major components include $6.5 million as reductions in the liability for contingent consideration since the PPS, Saxon and FSSI acquisitions did not meet the performance targets outlined in their purchase agreements.  The income was partially offset by increases of $2.5$0.5 million in the fair valuefourth quarter of 2017. Other expense for 2016 was $0.3 million compared to other income of $1.7 million for 2015. The $2.0 million change was primarily due to the liabilities fornet reversal of $1.9 million of contingent consideration recorded throughout 2013 for acquisitions, including Q3C.

In 2012, net other expense was $0.9 million which consisted of (a) the increase in the estimated fair value of the contingent earn-out liabilities for the Rockford, PPS, Saxon2015 as Ram-Fab, Vadnais and Q3C acquisitions, and (b) income of $0.6 million for final settlementSurber missed financial targets contemplated in December 2012 of a previously discontinued operation in Ecuador.their respective purchase agreements.   

 

Interest income is derived from interest earned on excess cash invested primarily in certificate of deposits (“CD’s”) and CDs purchased through the CDARS (Certificate of Deposit Account Registry Service) and in short term U.S. Treasury bills, with various financial institutions that are backed by the federal government. These relatively risk-free investments provide minimal income.

The main reasons for the increase in interest expenses for 2014 of $0.5 million, compared to 2013, is an increase in our equipment debt financing, and a full year of interest on the $25 million long-term note drawn-down in July 2013.

 

Interest expense decreased in 2013 increased by $2.3 million,2017 compared to 2016 primarily due to a lower average debt balance. Interest expense increased in 2016 compared to 2015 primarily due to a higher borrowing levels, including the $50 million long-term note executed at the end of 2012, and the $25 million long-term note drawn-down in July 2013, coupled with an increase in our equipmentaverage debt financing.

balance. The weighted average interest rate on total debt outstanding at December 31, 2014, 20132017, 2016 and 20122015 was 3.0%, 3.3%2.9% and 2.7%2.9%, respectively.

 

37



Table of Contents

Provision for income taxes

Our provision for income tax increased $7.3 million to $28.4 million for 2017 compared to 2016.  Increased pretax profits in 2017 of $53.0 million drove an increase in income tax of $23.4 million using the 2016 effective tax rate. This increase in income tax was offset by a $9.4 million decrease in income tax from the remeasurement of our U.S. deferred tax liability and a $6.7 million decrease due to a decrease in 2017 effective tax rates.   The remeasurement benefit is a provisional estimate under SAB 118 that could be revised once we finalize our deductions for tax depreciation and executive compensation accruals. We may also revise our estimate based on any additional guidance issued by the U.S. Treasury Department, the U.S. Internal Revenue Service, and other standard-setting bodies.

 The 2017 effective tax rate on income including noncontrolling interests was 27.0%. The 2017 effective tax rate on income attributable to Primoris (excluding noncontrolling interests) was 28.2%. Three factors contributed to the decrease in the 2017 effective tax rate compared to 2016. First, state effective tax rates decreased due to changes in the mix of profit by state and the implementation of state tax planning. Second, partially nondeductible per diem expenses stayed relatively constant year over year despite the increase in pretax profits. Lastly, the benefit of the domestic production activities deduction increased compared to 2016.

 

Our provision for income tax decreased $6.3$2.8 million to $38.6$21.1 million for 20142016 compared to 20132015 primarily as a result of decreased pretax profits between the years and a decrease in our effective tax rate.  The effective tax rate on income before provision for income taxes and noncontrolling interests was 37.77% and 37.54% for the years 2014 and 2013, respectively.  The effective tax rate excluding income attributable to noncontrolling interests was 37.96% for the year 2014 and 39.19% for 2013.  The two primary reasons for the decrease were a reduction in the state effective tax rate and the benefit recognized at the conclusion of the IRS examination.pretax profits.  

 

Our provision for income tax increased $11.1 million to $44.9 million for 2013 compared to 2012 as a result

41


Table of increased pretax profits between the years and an increase in our effective tax rate.  The effective tax rate on income before provision for income taxes and noncontrolling interests for the year 2013 was 37.54%.  The effective tax rate excluding income attributable to noncontrolling interests was 39.19%.Contents

Segment Results

 

Power Segment Results

As discussed in the Introduction of this Item 7, we realigned our segment reporting in the third quarter of 2014, and we have adjusted all historical numbers below to reflect this realignment.  The following discussion describes the significant factors contributing to the results of our three operating segments.  All intersegment revenues and gross profit, which were immaterial, have been eliminated in the following tables.

West Segment

 

Revenue and gross profit for the WestPower segment for the years ending December 31, 2014, 20132017, 2016 and 20122015 were as follows:

 

2014

 

2013

 

2012

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

 

Year Ended December 31, 

 

West Construction Services

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

2015

 

 

 

 

    

% of

    

 

 

    

% of

    

 

 

    

% of

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

 

Segment

 

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

Power Segment

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

964.1

 

 

 

$

1,151.4

 

 

 

$

832.8

 

 

 

 

$

606.1

 

 

 

$

478.6

 

 

 

$

466.3

 

 

 

Gross profit

 

$

143.5

 

14.9

%

$

190.7

 

16.6

%

$

119.3

 

14.3

%

 

$

65.7

 

10.8%

 

$

49.8

 

10.4%

 

$

53.6

 

11.5%

 

 

20142017 and 20132016

 

West segment revenue in 2014 decreasedRevenue increased by $187.3$127.5 million, or 16.3%26.6%, during 2017 compared to 2013.  Revenue declined at Rockford2016. The growth is primarily due to progress on our joint venture power plant projects in Southern California ($115.3 million), a power plant construction project in the Mid-Atlantic region that began late in the third quarter of 2016 ($42.9 million) and a methane plant project in Texas that started in 2017.  In addition, we benefited from acquisitions completed in November 2016 and May 2017 ($20.3 million). The overall increase was partially offset by $175.6the substantial completion of a large petrochemical plant in Louisiana in the second quarter of 2017 ($42.0 million) and the completion of two large parking structures in 2016.

Gross profit increased by $15.9 million, or 31.9%, during 2017 compared to 2016.  The increase is primarily attributable to the revenue growth and the impact of acquired operations ($1.6 million).  Gross profit as a percentage of revenues increased to 10.8% in 2017 compared to 10.4% in 2016 primarily as a result of an improved revenue mix.

2016 and 2015

Revenue increased by $12.3 million, or 2.6%, during 2016 compared to 2015. The increase is primarily due to a $60.6 million increase at Primoris Industrial Constructors from a large petrochemical project in Louisiana, partially offset by a $50.1 million decrease at OnQuest and OnQuest Canada from the completion of several large projects in 2013 and a $102 million decrease for a customer2015 that were not fully replaced in the Marcellus shale region.   Revenue2016.

Gross profit decreased by $41.8$3.8 million, at the ARB Underground divisionor 7.1%, during 2016 compared to 2015. The decrease is primarily due to reduced revenuea $8.6 million reduction at ARB Industrial from a reduction in revenues and a decrease of $23.2$6.7 million from traditional MSA customers,at OnQuest and OnQuest Canada as a declineresult of $40.1 million for one-time projects completed in 2013reducted volumes. These decreases are partially offset by an $11.6 million increase in pipeline integrity work for aat Primoris Industiral Constructors from increased volume at the large gas utility customer.  ARB Industrial division revenues declined by $21.8 million as a result of an $84.3 million decrease from the substantial completion of a major power plantpetrochemical project in 2013.  The decrease was partially offset by an increase of $53.2 million for construction of a solar plant project in the Mojave Desert in 2014.  Finally, revenue at Q3C increased $62.2 million compared to 2013 due primarily to increase in work for a large utility located in the north central United States.

Gross profit for the West segment decreased by $47.3 million or 24.8%.  The primary reason for the decrease was a reduction of gross profit at ARB of $54.3 million.  The declines were due to a combination of the close out of a major power plant project, the substantial completion of the Blythe joint venture project, the mix of MSA jobs at ARB Underground and the decline in revenue including $4.4 million less equipment cost absorption by the jobs as a result of the lower activity levels in 2014 compared to 2013.  Gross profit at Rockford decreased by $5.1 million while gross profit at Q3C increased by $13.5 million, with the revenue at the operating units serving as the primary driver of gross profit changes.Louisiana.

 

Gross profit as a percentage of revenues decreased to 14.9%10.4% in 20142016 compared to 16.6%11.5% in 2013.2015. The decline in margin is largely attributable to the low margin percentage realized by two joint venture projects in 2013 was higher than our historical percentages,process, which have ranged from 13% to 16% of revenue as a resultaccounted for 5.6% of the substantial completionPower segment’s revenues in 2013 of a power plant project by the ARB Industrial division.  In addition, ARB Industrial recorded revenue of $29.5 million2016 versus 0.9% in 2013 and revenue of $82.6 million in 2014 for construction services at a large solar project in the Mojave Desert.  Because of uncertainty as to collectability at the end of the cost-reimbursable project, we recorded revenues equal to cost for this project.  Excluding the revenue and cost of this project, gross profit as a percentage of revenues would have been 16.3% for 2014 compared to 17.0% for 2013.2015.

 

2013 and 2012

42


 

West segment revenue increased by $318.6 million, or 38.3%, for 2013 compared to 2012 primarily from increases of $207.4 million at Rockford and $155.4 million at Q3C, which was acquired in November 2012.  Revenue at the ARB Underground division decreased by $44.9 million primarily from decreases at its two largest California utility customers of $57.3 million and $23.5 million, respectively.  For the year, revenues in the West from West’s largest customer decreased from $224.8 million to $156.3 million.  The decline was partially due to completion of one large program without the start of a new program.

38



Table of Contents

Gross profit for the West segment increased by $71.4 million, or 59.9%, compared to 2012.  The primary driver of the gross profit increase was the successful substantial completion of a major power plant project in Southern California on time which allowed us to recognize profitability related to potential liquidated damages.  The contribution of this projectPipeline and of the Blythe joint venture project increased our West Industrial gross profit by $41.4 million.  Q3C full year operations increased gross profit by $29.4 million, and in spite of the impact of very unusual and negative weather conditions, Rockford added $1.1 million.  The revenue reduction at the ARB Underground division reduced gross profit by $0.6 million.

Gross profit as a percent of revenues increased to 16.6% in 2013 compared to 14.3% in 2012 primarily from the substantial completion of the power plant project by the ARB Industrial division.  The 2013 percentage was higher than historical percentages.

East Segment

 

Revenue and gross profit for the EastPipeline segment for the years ended December 31, 2014, 20132017, 2016 and 20122015 were as follows:

 

2014

 

2013

 

2012

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

 

Year Ended December 31, 

 

East Construction Services

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

2015

 

 

 

 

    

% of

 

 

    

% of

 

 

    

% of

 

 

 

 

 

Segment

 

 

 

Segment

 

 

 

Segment

 

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

Pipeline Segment

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

489.9

 

 

 

$

430.4

 

 

 

$

470.0

 

 

 

 

$

465.6

 

 

 

$

401.9

 

 

 

$

299.4

 

 

 

Gross profit

 

$

25.7

 

5.3

%

$

24.3

 

5.6

%

$

40.2

 

8.6

%

 

$

92.1

 

19.8%

 

$

68.1

 

16.9%

 

$

24.7

 

8.2%

 

 

As discussed in the section “Receivable Collection Actions”, during the third quarter of 2016, we collected a disputed receivable related to a major pipeline project completed in 2014, which resulted in recognizing revenue of approximately $27.5 million and 2013gross profit of approximately $26.7 million. The following discussion excludes the impact of this collection, which was a one-time item.

2017 and 2016

 

Revenue for the East segment increased by $59.5$91.2 million, or 13.8% from 2013.  Of24.4%, during 2017 compared to 2016. The increase is primarily due to two large pipeline jobs in Florida, which began in the third quarter of 2016 ($31.6 million) and activity on a pipeline project in Pennsylvania that began in 2017 ($52.0 million).  In addition, impact of the acquired Coastal operations ($17.9 million) also benefited 2017.  The overall increase $66.1 million was at JCG’s heavy civil and infrastructure and maintenance divisions due primarily to increases of $42.8 million in Texas DOT revenue and an increase of $40.2 million in Mississippi DOT revenue.  The increases were partially offset by a reduction of $19.1 million in Louisiana DOT revenue.  Additionally, Cardinal Construction revenue decreased by $8.9 million, reflecting decreasedmaintenance work in the wastewater facility market in Florida.($31.1 million).

 

Gross profit for the East segment increased by $1.4$50.7 million, or 5.9%122.5%, during 2017 compared to 2013.2016. The increased percentage was lower thanincrease is attributable to the combination of revenue growth and our strong performance on the two pipeline jobs in Florida, where we experienced good weather conditions resulting in no weather delays and high productivity. In addition, the acquisition of Coastal in 2017 contributed gross profit of $3.2 million. Gross profit as a percentage of revenue increased to 19.8% in 2017 compared to 11.1% in 2016. The increase is due to the good weather conditions noted above, which is not common and not to be expected in the future.

2016 and 2015

Revenue increased by $75.0 million, or 25.1%, during 2016 compared to 2015. The increase is primarily due to a $64.1 million increase at Rockford from two large pipeline projects in Florida which started in the third quarter of 2016 and a $6.1 million increase at Primoris Pipeline from several smaller diameter pipeline projects in Texas.

Gross profit increased by $16.7 million, or 67.6%, during 2016 compared to 2015 primarily due to a $15.4 million increase from the Rockford Florida projects described above. Gross profit as a percentage of revenues increased to 11.1% in 2016 compared to 8.2% in 2015 primarily as a result of reducedthe increase in revenues.

43


Table of Contents

Utilities Segment

Revenue and gross profit of $1.9for the Utilities segment for the years ended December 31, 2017, 2016 and 2015 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 

 

 

 

2017

 

2016

 

2015

 

 

 

 

 

    

% of

 

 

 

    

% of

 

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

Utilities Segment

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

806.5

 

 

 

$

637.2

 

 

 

$

587.0

 

 

 

Gross profit

 

$

113.0

 

14.0%

 

$

100.1

 

15.7%

 

$

96.5

 

16.4%

 

2017 and 2016

Revenue increased by $169.3 million, or 26.6%, during 2017 compared to 2016. The increase is primarily attributable to higher activity with two major utility customers in California ($67.7 million) and two major utility customers in the Midwest ($32.3 million). In addition, higher revenue from a collaboration MSA arrangement for JCG heavy civil projects offset by increases of $1.8 million at JCG’s infrastructurea major utility customer in California ($35.6 million) and maintenance divisions and $0.6 million for Cardinal Construction projects.  Heavy civil experienced a $7.9 million decrease in gross profit due to both the impact of the acquired FGC operations ($15.5 million) also benefited 2017.

Gross profit increased $12.9 million, or 12.9%, during 2017 compared to 2016. The increase is primarily due the growth in revenue and the impact of acquired operations. Gross profit as a percentage of revenues decreased to 14.0% in 2017 compared to 15.7% in 2016 primarily as a result of lower Louisiana DOTgross margins on the collaboration MSA work.

2016 and 2015

Revenue increased by $50.2 million, or 8.6%, during 2016 compared to 2015. The increase is primarily due to a $35.4 million increase at ARB Underground from a new collaboration MSA arrangement as well as a $12.1 million increase at Q3C from increased volume.

Gross profit increased by $3.6 million, or 3.7%, during 2016 compared to 2015 primarily due to increased profitability at Q3C. Gross profit as a percentage of revenues decreased to 15.7% in 2016 compared to 16.4% in 2015.  The decrease was primarily the result of lower margins on the collaboration MSA work.

44


Table of Contents

Civil Segment

Revenue and reduced gross profit for the Civil segment for the years ended December 31, 2017, 2016 and 2015 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 

 

 

 

2017

 

2016

 

2015

 

 

 

 

 

    

% of

 

 

 

    

% of

 

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

(Millions)

 

Revenue

 

Civil Segment

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

501.8

 

 

 

$

479.2

 

 

 

$

576.7

 

 

 

Gross profit

 

$

7.6

 

1.5%

 

$

(16.7)

 

(3.5%)

 

$

45.1

 

7.8%

 

In the third quarter of 2016, we recorded a $37.3 million write-down related to the Belton area projects. The following discussion excludes the impact of the write-down.

2017 and 2016

Revenue increased by $22.6 million, or 4.7%, during 2017 compared to 2016.  The increase is primarily due to progress on Texas DOT work.  This decreasea methanol plant project in Louisiana that began in 2017 ($31.9 million) and higher volume on the Belton area projects ($23.3 million). The overall increase was partially offset by grosssubstantial completion of a large petrochemical plant project in Lousiana in the first half of 2017.

Gross profit increases of $5.6decreased by $13.0 million, in other heavy civil work,or 63.1%, during 2017 compared to 2016. The decrease was primarily due to higher costs on Mississippitwo Arkansas DOT projects.projects and one Louisiana DOT project, despite the revenue increase.

 

Gross profit as a percentage of revenues decreased to 5.3 %1.5% in 20142017 compared to 5.6%4.3% in 20132016.  The decrease was primarily the result of the project cost impacts noted above.

Revenue at the Belton area projects was $144.5 million for the year ended December 31, 2017, representing 28.9% of total Civil revenue. Revenue for which no margin was recognized was $134.7 million for the year ended December 31, 2017, of which $78.6 million was from the Belton area projects. During 2017, the four Belton area jobs in a loss position contributed $2.4 million gross profit as a result of lower anticipated costs. Two of the lowerBelton area jobs in a loss position were completed during 2017, and the remaining two loss jobs are schedule to be completed in 2018. At December 31, 2017, the accrued loss provision for the four Belton area projects was $5.0 million and estimated remaining revenue for the two open jobs in a loss position was $49.0 million. The remaining Belton area job contributed $0.3 million gross profit Texas and Louisiana heavy civil projects.during the year ended December 31, 2017. At December 31, 2017, estimated revenue for the job was $88.0 million, with completion scheduled for early 2019.

 

20132016 and 20122015

 

Revenue for the East segment decreased by $39.5$97.5 million, or 8.4% from 2012.  Of16.9%, during 2016 compared to 2015. Revenue at Primoris I&M (“I&M”) decreased by $76.4 million due primarily to the decrease, $54.8 million was at JCG’s heavy civillarge petrochemical project in Louisiana and infrastructure and maintenance divisions.  The primary reason for the decrease was a reduction of $106.2 milliondecreases in Texas I&M work. Primoris Heavy Civil division revenue decreased by $24.5 million.  Decreases in Louisiana DOT revenue only partially replacedprojects of $19.4 million and Mississippi DOT projects of $58.9 million were offset by an increaseincreases in Arkansas DOT projects of $51.7$6.7 million, in Texas DOT revenue.  While JCG had received the final notices to proceed for the I-35 projects near Belton, Texas, the Louisiana work continued to decrease into 2014.  Cardinal Construction revenues increased by $14.6of $8.4 million reflecting improved opportunities in the wastewater facility market in the Texas area.and airport projects of $31.7 million.

 

Gross profit for the East segment decreased by $15.9$24.5 million, or 39.5%54.3%, during 2016 compared to 2012.  The gross profit2015 primarily due to decreased revenue at the JCG heavy civil division decreased by $17.1 million primarily reflecting the impact of the revenue decrease and increased weather related costs for LADOT projects.  This decrease was offset by an increase of $2.1 million at Cardinal Contractors as a result of their increased revenue.Primoris I&M.

 

Gross profit as a percentage of revenues decreased to 5.6%4.3% in 20132016 compared to 8.6%7.8% in 20122015 primarily as a result of the decreased profitability at the JCG heavy civil division.decrease in revenues.

 

39


45



Table of Contents

Energy Segment

Revenue and gross profit for the Energy segment for the years ended December 31, 2014, 2013 and 2012 were as follows:

 

 

2014

 

2013

 

2012

 

 

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

(Millions)

 

% of
Revenue

 

Energy Segment

 

 

 

 

 

 

 

 

 

 

 

 

 

Revenue

 

$

632.2

 

 

 

$

362.4

 

 

 

$

238.9

 

 

 

Gross profit

 

$

66.8

 

10.6

%

$

40.9

 

11.3

%

$

33.2

 

13.9

%

2014 and 2013

Revenue for the Energy segment increased by $269.8 million, or 74.5% from 2013.    The JIC Industrial division revenue increased by $129.0 million primarily from work activity at petrochemical facilities in south Louisiana.  PES’s PPS division revenue increased by $85.5 million as a resultPlanned Divestiture of increased revenues from capital projects.  PES’s Saxon division revenue increased by $17.1 million and OnQuest and OnQuest Canada revenue in 2014 increased by $21.5 million as a result of additional revenue from construction of a micro LNG facility in 2014.

Gross profit for the Energy segment increased by $25.9 million, or 63.1%, compared to 2013.    The JIC Industrial division gross profit increased $14.6 million primarily due to the division’s increased revenues.  PES’s PPS division gross profit increased $4.1 million due to increased revenues and the Saxon division gross profit increased $3.7 million as a result of increased revenues and improved profit margins compared to 2013.   OnQuest and OnQuest Canada profit margins in 2014 increased by $1.5 million due to increased revenues.

Gross profit as a percentage of revenues decreased to 10.6% in 2014 compared to 11.3% in 2013 primarily as a result of the reduced margins at PES’s PPS division.  Similar to ARB Industrial, PPS recorded revenues equal to cost for a large pipeline project for which we have concerns about collectability of the full contractual amount.  In 2013, PPS recorded revenue of $9.2 million and in 2014, PPS recorded revenue of $121.2 million for the project.  Excluding the revenue of this project, gross profit as a percentage of revenues would have been 13.0% for 2014 compared to 11.6% for 2013.

2013 and 2012Texas Heavy Civil Business Unit

 

In 2012,October 2016, we acquired Sprintannounced that we planned to divest our Texas heavy civil business unit, which operates as a division of Primoris Heavy Civil.  We engaged a financial advisor to assist in the marketing and Saxon, and in 2013, we acquired FSSI, all of which are a partsale of the Energy segment.  Combined, these companies are referredbusiness unit, and planned to continue to operate the business unit until completion of a sale.  In April 2017, the Board of Directors determined that based on the information available, we would attain the best long-term value by withdrawing from the sales process and continuing operating the business unit.  We will aggressively pursue claims for five Texas Department of Transportation projects that resulted in significant losses recorded in 2016.  However, there can be no assurance as “Acquired Companies”to the final amounts collected. As of December 31, 2017, we had approximately $49.7 million of claims related to the Belton area projects included in the following discussion.contract value. 

 

Revenue for the Energy segment increased by $123.4 million, or 51.7% from 2012.  Of the increase, the Acquired Companies added $76.8 million:  $40.5 million from Saxon and FSSI and $36.3 million from Sprint.  JCG’s Industrial Division revenue increased by $48.3 million primarily from work activity at petrochemical facilities in south Louisiana.  OnQuest and OnQuest Canada revenue in 2013 decreased by $1.6 million due primarily to the impact of completing a $16 million project in 2012.

Gross profit for the Energy segment increased by $7.8 million, or 23.4%, compared to 2012, primarily due to the gross profit increase of $6.5 million at JCG’s Industrial Division.  The gross profit contribution from the Acquired Companies was $0.5 million with project delays affecting Sprint’s ability to improve its margin from the prior year and project execution issues impacting Saxon.

Gross profit as a percentage of revenues decreased to 11.3% in 2013 compared to 13.9% in 2012 primarily as a result of the reduced margins at the Acquired Companies.

Liquidity and Capital Resources

 

Cash Needs

 

Liquidity represents our ability to pay our liabilities when they become due, fund business operations and meet our contractual obligations and execute our business plan.  Our primary sources of liquidity are our cash balances at the beginning of each period and our net cash flow.  If needed, we have availability under our lines of credit to augment liquidity needs.  In order to maintain sufficient liquidity, we evaluate our working capital requirements on a regular basis.  We may elect to raise additional capital by issuing common stock, convertible notes, term debt or increasing our credit facility as necessary to fund our operations or to fund the acquisition of new businesses.

 

Our cash and cash equivalents totaled $170.5$170.4 million at December 31, 20142017 compared to $214.8$135.8 million at December 31, 2013.2016.  We anticipate that our cash and investments on hand, existing borrowing capacity under our credit facility and our future cash flows from operations will provide sufficient funds to enable us to meet our operating needs, our planned capital expenditures, and settle our ability to growcommitments and contingencies for at least the next twelve months.

40



Table In evaluating our liquidity needs, we do not consider cash and cash equivalents held by our consolidated VIEs. These amounts, which totaled $60.3 million and $7.0 million as of ContentsDecember 31, 2017 and December 31, 2016, respectively, are not available for general corporate purposes.

 

The construction industry is capital intensive, and we expect to continue to make capital expenditures to meet anticipated needs for our services.  Historically, we have invested an amount that approximated the sum of depreciation and amortization expenses plus proceeds from equipment sales.  In 2014,2017, we spent approximately $79.8 million for capital expenditures, were approximately $88 million.which included $9.9 million spent for our investment in the solar projects.  In addition, the companies acquired during the period added $12.4 million to property, plant and equipment. For 2014,2017, the amount of depreciation, amortization and equipment sales was approximately $64$75.0 million.  Included in the total investment amount was approximately $22 million for the building of the BWP treatment facility and a new facilities for JCG and PES.  Capital expenses are expected to total $75-$85$70.0 to $75.0 million for 2015 with one key item being the amount of investment needed for the $290+ million Sasol project in Lake Charles, LA.2018.

 

Cash Flows

 

Cash flows during the years ended December 31, 2014, 20132017, 2016 and 20122015 are summarized as follows:

 

 

 

2014

 

2013

 

2012

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Change in cash

 

 

 

 

 

 

 

Net cash provided by operating activities

 

$

36.1

 

$

77.7

 

$

98.4

 

Net cash used in investing activities

 

(102.6

)

(97.1

)

(95.0

)

Net cash provided (used) in financing activities

 

9.9

 

57.9

 

33.9

 

Net change in cash

 

$

(56.6

)

$

38.5

 

$

37.3

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 

 

 

 

2017

 

2016

 

2015

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Change in cash:

 

 

 

 

 

 

 

 

 

 

Net cash provided by operating activities

 

$

188.9

 

$

62.6

 

$

48.4

 

Net cash used in investing activities

 

 

(131.4)

 

 

(59.4)

 

 

(48.5)

 

Net cash (used in) provided by financing activities

 

 

(22.9)

 

 

(28.5)

 

 

21.8

 

Net change in cash and cash equivalents

 

$

34.6

 

$

(25.3)

 

$

21.7

 

 

46


Table of Contents

Operating Activities

 

The sourcesources and uses of our cash flow fromassociated with operating activities and the use of a portion of that cash in our operations for the years ended December 31, 2014, 20132017, 2016 and 20122015 were as follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

    

2016

    

2015

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Operating Activities:

 

 

 

 

 

 

 

 

 

 

Net income

 

$

76.9

 

$

27.7

 

$

37.2

 

Depreciation and amortization

 

 

66.3

 

 

68.0

 

 

65.2

 

Net deferred taxes

 

 

3.7

 

 

10.9

 

 

(7.0)

 

Changes in assets and liabilities

 

 

50.4

 

 

(43.9)

 

 

(46.5)

 

Other

 

 

(8.4)

 

 

(0.1)

 

 

(0.5)

 

Net cash provided by operating activities

 

$

188.9

 

$

62.6

 

$

48.4

 

 

 

 

2014

 

2013

 

2012

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Operating Activities

 

 

 

 

 

 

 

Operating income

 

$

103.8

 

$

125.2

 

$

96.3

 

Depreciation and amortization

 

58.4

 

49.9

 

35.6

 

Loss (gain) on sale of property and equipment

 

(1.9

)

(1.4

)

(2.8

)

Stock-based compensation expense

 

0.9

 

0.3

 

 

Distributions received from non-consolidated entities

 

 

2.8

 

1.4

 

Other than temporary impairment expense for non-consolidated entities

 

 

4.0

 

 

Intangible asset impairment

 

 

0.8

 

 

Net deferred taxes

 

9.0

 

(12.6

)

(0.9

)

Changes in assets and liabilities

 

(88.7

)

(45.6

)

7.0

 

Foreign exchange gain (loss)

 

0.3

 

0.2

 

(0.1

)

Interest income

 

0.1

 

0.1

 

0.2

 

Interest expense

 

(6.4

)

(5.9

)

(3.6

)

Other income (expense)

 

(0.8

)

4.8

 

(0.9

)

Provision for income taxes

 

(38.6

)

(44.9

)

(33.8

)

Net cash provided by operating activities

 

$

36.1

 

$

77.7

 

$

98.4

 

2017 and 2016

 

Net cash provided by operating activities for 20142017 was $188.9 million , an increase of $36.1 million decreased by $41.7$126.3 million compared to 2013.  This2016.  The improvement year over year was caused by the decrease in operating income of $21.4 million andprimarily due to the $88.7 million net changesa favorable change in assets and liabilities.  This accounted for the $41.6 million reductionliabilities and significant growth in cash from operations compared to 2013.   net income.

The significant components of the $50.4 million change in assets and liabilities for the twelve monthsyear ended December 31, 20142017 are summarized as follows:

 

·

Accounts receivable decreased by $40.5 million from December 31, 2016, reflecting successful collection efforts during 2017. For non-disputed receivables (excluding retainage), our days sales outstanding declined slightly from 47 days at December 31, 2016 to 46 days at December 31, 2017;

·a decrease of $4.8 million in customer retention deposits;

·

Billings in excess of costs and estimated earnings increased by $46.0 million compared to December 31, 2016, primarily due to favorable milestone billings on certain lump sum projects;

·

Accounts payable decreased by $30.5 million due primarily to the timing of payments; and

·

Costs and estimated earnings in excess of billings (“CIE”) increased by $20.9 million compared to December 31, 2016. CIE results primarily from either time lags between revenue recognition and contractual billing terms or the billing lag at the end of each month.

2016 and 2015

 

·an increaseNet cash provided by operating activities for 2016 of $29.7$62.6 million increased by $14.2 million compared to 2015.  The improvement year over year was primarily due to a reduction in accounts receivable primarily as a resultincome taxes paid. 

The significant components of the withholding of $34.1$43.7 million of receivable payment due from a PPS customer with whom we have a dispute (compared to a $7.5 million balance atchange in assets and liabilities for the end of 2013) as discussed further in the section “Receivable Collection Actions” below.   Atyear ended December 31, 2014, accounts receivable represented 30.4% of our total assets compared to 29.0% at the end of 2013.  We continue to maintain an excellent collection history, and we have certain lien rights that can provide additional security for collections;2016 are summarized as follows:

 

·

an increase of $65.8 million in accounts receivable as revenues for the fourth quarter 2016 were stronger than in the same period in 2015, primarily as a result of significant work being performed during the fourth quarter 2016 on two Florida pipeline projects. However, as outlined in the section “Receivable Collection Actions”, we are in dispute resolution with one customer with a total receivable amount $32.9 million, or 8.5% of our total accounts receivable balance at December 31, 2016;

41


·

an increase of $22.2 million in costs and estimated earnings in excess of billings. Increases associated with the time lag from when revenues were earned until the customer can be billed were approximately $13.6


47


Table of Contents

million related to two large utility customers, and $4.9 million related to public agency heavy civil projects which require inspector approval prior to billing;

·

a decrease in inventory and other current assets of $17.7 million primarily as a result of reduced inventory levels for projects nearing completion;

·

accounts payable increased by $42.9 million, primarily impacted by the timing of vendor payments and the increased activity for the two Florida pipeline projects in the fourth quarter of 2016; and

·

a decrease of $27.5 million in billings in excess of costs and estimated earnings reflecting the timing of work progression and billings.

 

·an increase of $11.5 million in costs and estimated earnings in excess of billings. Increases associated with the time lag from when revenues were earned until the customer can be billed were approximately $1.2 million for ARB and $9.4 million for Rockford;

·an increase in inventory and other current assets of $25.7 million primarily as a result of an increase in current tax receivable and an increase in customer held inventory and prepaid expenses of $20.2 million;

·accounts payable increased nominally by $0.9 million, primarily impacted by the timing of vendor payments;

·a net decrease of $14.8 million in billings in excess of costs and estimated earnings reflecting the timing of work progression and billings;

·a decrease of $4.1 million in contingent earn-out liabilities, primarily as a result of a payment of $5.0 million made in March 2014 offset by increases from acquisitions in 2014; and

·a net decrease of $7.4 million in accrued expenses, mainly due to a decrease in the corporate taxes payable.

During the twelve months of 2014, we paid $57.6 million for income taxes compared to $48.1 million in the same period of the previous year.  The Company expects that its tax overpayments will result in refunds of $4.5 million and the prepayment of $17.3 million for the 2015 tax year.

Investing activities

 

 

2014

 

2013

 

2012

 

 

 

(Millions)

 

(Millions)

 

(Millions)

 

Capital expenditures — cash

 

$

88.0

 

$

87.1

 

$

37.4

 

Capital expenditures — financed

 

 

2.6

 

2.9

 

Total capital expenditures

 

$

88.0

 

$

89.7

 

$

40.3

 

 

We purchased property and equipment for $88.0$79.8 million, $89.7$58.0 million and $40.3$67.1 million in the years ended December 31, 2014, 20132017, 2016 and 2012,2015, respectively, principally for our construction activities.  We believe the ownership of equipment is generally preferable to renting equipment on a project-by-project basis, as ownership helps to ensure the equipment is available for our workloadsprojects when needed. In addition, ownership has historically resulted in lower overall equipment costs.

 

We periodically sell and acquire equipment, typically to update our fleet. We received proceeds from the sale of used equipment of $5.8$8.7 million, $7.9$9.6 million and $9.0$9.9 million for 2014, 20132017, 2016 and 2012,2015, respectively. For the past few years, we have been able to rent major equipment not used for our own projects to third parties, but with the current economic environment, equipment rentals have decreased.

 

As part of our cash management program,During 2017, we invested $33.8$13.6 million $23.1in short-term investments. During 2016 and 2015, we did not purchase any short-term investments.  We sold short-term investments amounting to $19.4 million, $0.0 million and $6.9$31.0 million in 2014, 20132017, 2016 and 2012, respectively, in short-term investments, and sold $21.5 million, $7.4 million and $26.4 million in 2014, 2013 and 2012,2015, respectively.  Short-term investments consistconsisted primarily of U.S. Treasury bills with various financial institutions that are backed by the federal government.and marketable equity securities.

 

WeDuring 2017, we used $14.6$66.2 million in cash for acquisitions, primarily related to FGC and Coastal.  During 2016, we used $11.0 million in cash for the Vadnaisacquisitions of Mueller and Surber/Ram-Fab/Williams acquisitionsNorthern, and in 2014 and $2.32015, we used $22.3 million in cash for the FSSI acquisition in 2013 and $86.2 million in cash for the Sprint, Silva, Saxon and Q3C acquisitions during 2012.Aevenia acquisition.

 

Financing activities

 

Financing activities providedused cash of $9.9$22.9 million in 2014.2017. Significant transactions impacting cash flows from financing activities included:

 

·

$55.0 million in new and refinanced notes secured by our equipment;

·

$62.1 million in repayment of long-term debt and capital leases;

·

Repurchase of common stock of $5.0 million;

·

Dividend payments of $11.3 million to our stockholders; and

·

$1.1 million in proceeds from the issuance of 65,429 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.

·$58.5

Financing activities used cash of $28.5 million in new and refinanced notes secured by our equipment;

·$35.1 million in repayment of long-term debt and the repayment of $3.3 million in capital leases;

·$1.6 million in payments of accumulated earnings to the Blythe non-controlling interest holder;

·Dividend payments of $7.5 million to our stockholders during the year ended December 31, 2014;

·Repurchase of common stock for $2.8 million; and

·$1.7 million in proceeds2016. Significant transactions impacting cash flows from the issuance of 77,455 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.financing activities included:

 

·

$45.0 million in new and refinanced notes secured by our equipment;

·

$58.5 million in repayment of long-term debt and capital leases;

·

Repurchase of common stock of $5.0 million;

·

Dividend payments of $11.4 million to our stockholders; and

·

$1.4 million in proceeds from the issuance of 85,907 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.

42


48



Table of Contents

Financing activities provided cash of $21.8 million in 2015. Significant transactions impacting cash flows from financing activities included:

·

$50.3 million in new and refinanced notes secured by our equipment and by a mortgage note on two buildings;

·

$25.0 million in new debt under our Additional Senior Note Agreement;

·

$45.2 million in repayment of long-term debt and capital leases;

·

Dividend payments of $9.8 million to our stockholders; and

·

$1.6 million in proceeds from the issuance of 96,828 shares of common stock purchased by the participants in the Primoris Long-term Retention Plan.

Debt Activities

 

Debt ActivitiesRevolving Credit Facility

 

Credit Facility

As of December 31, 2014, the Company had a revolvingOn September 29, 2017, we entered into an amended and restated credit facility, amended on December 12, 2014agreement (the “Credit Agreement”) with The PrivateBank and Trust Company,CIBC Bank USA, as administrative agent (the “Administrative Agent”) and co-lead arranger, The Bank of the West, as co-lead arranger, and IBERIABANK Corporation.  On December 12, 2014, the Credit Agreement was amended to include two additional lenders, Branch Banking and Trust Company, IBERIABANK, Bank of America, and UMBSimmons Bank N.A. (the “Lenders”)., which increased our borrowing capacity from $125.0 million to $200.0 million. The Credit Agreement isconsists of a $125$200.0 million revolving credit facility whereby the Lenders agreeagreed to make loans on a revolving basis from time to time and to issue letters of credit for up to the $125$200.0 million committed amount. The termination date of the Credit Agreement is December 28, 2017.September 29, 2022.

 

The principal amount of any loans under the Credit Agreement will bear interest at either: (i) LIBOR plus an applicable margin as specified in the Credit Agreement (based on the Company’sour senior debt to EBITDA ratio as that term is defined in the Credit Agreement), or (ii) the Base Rate (which is the greater of (a) the Federal Funds Rate plus 0.5%0.50% or (b) the prime rate as announced by the Administrative Agent). Quarterly non-useNon-use fees, letter of credit fees and administrative agent fees are payable at rates specified in the Credit Agreement.

 

The principal amount of any loan drawn under the Credit Agreement may be prepaid in whole or in part at any time, with a minimum prepayment of $5 million, at any time, potentially subject to make-whole provisions.$5.0 million.

 

The Credit Agreement includes customary restrictive covenants for facilities of this type, as discussed below.

 

Commercial letters of credit outstanding were $4.7$19.5 million at December 31, 2014 and $5.1 million at December 31, 2013.2017.  Other than commercial letters of credit, there were no borrowings under this line ofthe Credit Agreement or the previous credit agreement during the twelve months ended DecemberDecmeber 31, 2014, leaving2017, and available borrowing capacity at $120.3 million at December 31, 2014.2017 was $180.5 million.

 

Senior Secured Notes and Shelf Agreement

 

On December 28, 2012, the Companywe entered into a $50$50.0 million Senior Secured Notes purchase (“Senior Notes”) and a $25$25.0 million private shelf agreement (the “Notes Agreement”) by and among the Company,us, The Prudential Investment Management, Inc. and certain Prudential affiliates (the “Noteholders”).  On June 3, 2015, the Notes Agreement was amended to provide for the issuance of additional notes of up to $75.0 million over the next three year period ending June 3, 2018 (“Additional Senior Notes”).

 

The Senior Notes amount was funded on December 28, 2012.  The Senior Notes are due December 28, 2022 and bear interest at an annual rate of 3.65%, paid quarterly in arrears. Annual principal payments of $7.1 million are required from December 28, 2016 through December 28, 2021 with a final payment due on December 28, 2022. The principal amount may be prepaid, with a minimum prepayment of $5$5.0 million, at any time, subject to make-whole provisions.

 

49


Table of Contents

On July 25, 2013, the Companywe drew the full $25$25.0 million available under the Notes Agreement.  The notes are due July 25, 2023 and bear interest at an annual rate of 3.85% paid quarterly in arrears.  Seven annual principal payments of $3.6 million are required from July 25, 2017 with a final payment due on July 25, 2023.

 

On November 9, 2015, we drew $25.0 million available under the Additional Senior Notes Agreement.  The notes are due November 9, 2025 and bear interest at an annual rate of 4.6% paid quarterly in arrears.  Seven annual principal payments of $3.6 million are required from November 9, 2019 with a final payment due on November 9, 2025.

Loans made under both the Credit Agreement and the Notes Agreement are secured by our assets, including, among others, our cash, inventory, goods, equipment (excluding equipment subject to permitted liens), and accounts receivable. All of our domestic subsidiaries have issued joint and several guaranties in favor of the Lenders and Noteholders for all amounts under the Credit Agreement and Notes Agreement.

 

Both the Credit Agreement and the Notes Agreement contain various restrictive and financial covenants including, among others, minimum tangible net worth, senior debt to debt/EBITDA ratio and debt service coverage requirements and a minimum balance for unencumbered net book value for fixed assets.requirements. In addition, the agreements include restrictions on investments, change of control provisions and provisions in the event the Company disposeswe dispose more than 20% of itsour total assets.

 

The Company wasWe were in compliance with the covenants for the Credit Agreement and the Notes Agreement at December 31, 2014.2017.

 

43



Table of ContentsCanadian Credit Facility

 

Canadian Credit Facility

The Company hasWe have a demand credit facility for $8.0 million in Canadian dollars with a Canadian bank for purposes of issuing commercial letters of credit in Canada.  The credit facility has an annual renewal and provides for the issuance of commercial letters of credit for a term of up to five years. The facility provides for an annual fee of 1% for any issued and outstanding commercial letters of credit. Letters of credit can be denominated in either Canadian or U.S. dollars. At December 31, 2014 and December 31, 2013,2017, letters of credit outstanding totaled $2.6 million and $2.3$0.5 million in Canadian dollars, respectively.dollars.  At December 31, 2014,2017, the available borrowing capacity was $5.4$7.5 million in Canadian dollars.  The credit facility contains a working capital restrictive covenant for our Canadian subsidiary, OnQuest Canada, ULC. At December 31, 2014,2017, OnQuest Canada, ULC was in compliance with the covenant.

 

Contractual Obligations

 

As of December 31, 2014,2017, we had $245.2$259.2 million of outstanding long-term debt and capital lease obligations.  Thereobligations, and there were no short-term borrowings.

 

A summary of contractual obligations as of December 31, 2014 were2017 was as follows:

 

 

 

Total

 

1 Year

 

2 - 3 Years

 

4 - 5 Years

 

After 5 Years

 

 

 

(In Millions)

 

Long-term debt and capital lease obligations

 

$

245.2

 

$

40.6

 

$

88.2

 

$

72.5

 

$

43.9

 

Interest on long-term debt (1)

 

24.0

 

6.2

 

9.5

 

5.4

 

2.9

 

Equipment operating leases

 

12.5

 

7.0

 

3.9

 

1.0

 

0.6

 

Contingent consideration obligations

 

6.9

 

5.9

 

1.0

 

 

 

Real property leases

 

12.5

 

3.5

 

5.4

 

3.3

 

0.3

 

Real property leases—related parties

 

9.2

 

1.4

 

2.9

 

2.0

 

2.9

 

 

 

$

310.3

 

$

64.6

 

$

110.9

 

$

84.2

 

$

50.6

 

Letters of credit

 

$

6.9

 

$

6.9

 

$

 

$

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Total

    

1 Year

    

2 - 3 Years

    

4 - 5 Years

    

After 5 Years

 

 

 

(In Millions)

 

Long-term debt and capital lease obligations

 

$

259.2

 

$

65.5

 

$

113.0

 

$

58.1

 

$

22.6

 

Interest on long-term debt (1)

 

 

24.4

 

 

7.1

 

 

9.4

 

 

4.4

 

 

3.5

 

Pension plan withdrawal liability

 

 

4.7

 

 

4.7

 

 

 —

 

 

 —

 

 

 —

 

Equipment operating leases

 

 

31.1

 

 

13.6

 

 

14.9

 

 

2.6

 

 

 —

 

Contingent consideration obligations

 

 

0.7

 

 

0.7

 

 

 —

 

 

 —

 

 

 —

 

Real property leases

 

 

13.2

 

 

5.0

 

 

6.4

 

 

1.8

 

 

 —

 

 

 

$

333.3

 

$

96.6

 

$

143.7

 

$

66.9

 

$

26.1

 

Letters of credit

 

$

19.8

 

$

19.8

 

$

 —

 

$

 —

 

$

 —

 


(1)The interest amount represents interest payments for our fixed rate debt assuming that principal payments are made as originally scheduled.

 

50


Table of Contents

The table does not include potential obligations under multi-employer pension plans in which some of our employees participate.  Our multi-employer pension plan contribution rates are generally specified in our collective bargaining agreements, and contributions are made to the plans based on employee payrolls.  Our obligations for future periods cannot be determined because we cannot predict the number of employees that we will employ at any given time nor the plans in which they may participate.

 

We may also be required to make additional contributions to multi-employer pension plans if they become underfunded, and these contributions will be determined based on our union payroll.  The Pension Protection Act of 2006 added special funding and operational rules for multi-employer plans that are classified as “endangered,” “seriously endangered” or “critical” status.  Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, which may require additional contributions from employers.  The amounts of additional funds that we may be obligated to contribute cannot be reasonably estimated and is not included in the table above.

 

In November 2011, Rockford, ARB and Q3C, along with other members of the Pipe Line Contractors Association (“PLCA”) including ARB, Rockford and Q3C (prior to the acquisition in 2012), withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan (the “Plan”(“Plan”).  The Company withdrew from the PlanThese withdrawals were made in order to mitigate itsadditional liability in connection with the Plan, which is significantly underfunded.  The Companyunderfunded Plan. We recorded a withdrawal liability of $7.5 million, which was increased to $7.6 million after the acquisition of Q3C.  During the first quarter of 2016, we received a final payment schedule.  As a result of payments made and based on information provided by the Plan.  However, the Plan has asserted that the PLCA members did not effect a proper withdrawal in 2011.  The Company believes that a legally effective withdrawal occurred in November 2011 and has recorded the withdrawal liability on that basis.  In May 2014, the Plan asserted thatthis schedule, the liability was $11.7 million.  Without agreeing to the amount, the Company has made monthly payments, which are being expensed, including interest, totaling $733 throughrecorded at December 31, 2014.  See Note 17 — “Multiemployer Plans” of2017 was $4.7 million. We expect to pay the Notesremaining liability balance during 2018 and have no plans to Consolidated Financial Statements included in Item 8 of this Form 10-K.withdraw from any other agreements.

 

We have also excluded from the table any interest and fees associated with letters of credit and commitment fees under our credit facility since these amounts are unknown and variable.

 

44



Table of ContentsRelated Party Transactions

 

Related Party Transactions

Prior to March 2017, Primoris has entered into leasing transactions withleased three properties in California from Stockdale Investment Group, Inc. (“SIGI”).  Brian Pratt, our Chief Executive Officer, President andOur Chairman of the Board of Directors, andwho is our largest stockholder, holdsand his family hold a majority interest and is the chairman, president and chief executive officer and a director of SIGI. John M. Perisich,In March 2017, we exercised a right of first refusal and purchased the SIGI properties.  The purchase was approved by our Executive Vice PresidentBoard of Directors for $12.8 million.  We assumed three mortgage notes totaling $4.2 million with the remainder paid in cash. During the years ended December 31, 2017, 2016 and General Counsel, is secretary2015, we paid $0.2 million, $0.8 million, and $0.8 million, respectively, in lease payments to SIGI for the use of SIGI.these properties.

 

Primoris leases properties from SIGI at the following locations:

·Bakersfield, California (lease expires October 2022)

·Pittsburg, California (lease expires April 2023)

·San Dimas, California (lease expires March 2019)

·Pasadena, Texas (lease was mutually terminated asother individuals that were past sellers of August 31, 2014)

Primoris leases a property from Roger Newnham, a former owner and current manager of our subsidiary, OnQuest Canada, ULC. The property is located in Calgary, Canada.

Primoris leases a property from Lemmie Rockford, one of the Rockford sellers, which commenced November 1, 2011.  The property is located in Toledo, Washington.  The lease expires in January 2016.

Primoris leases a property from Quality RE Partners, owned by three of the Q3C selling shareholders, of whom twoacquisitions or are current employees, including Jay Osborn, President of Q3C.employees.  The property is located in Little Canada, Minnesota.

Further information regarding related party transactions can be found in Note 20 — “Related Party Transactions” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K.

We believe that the amounts that we pay for the leases approximate terms that we could obtain from independent third parties.  In addition, any new leases, extensions of lease termsleased are not material and changes in lease terms or amounts must beeach arrangement was approved in advance by the independent directors of the Board of Directors Audit Committee.Directors.

 

Off Balance Sheet Transactions

 

As is common in our industry, we enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected on our balance sheet. We have no off-balance sheet financing arrangement with variable interest entities.  The following representrepresents transactions, obligations or relationships that could be considered material off-balance sheet arrangements.

 

·

At December 31, 2017, we had letters of credit outstanding of $19.8 million under the terms of our credit agreements.  These letters of credit are used by our insurance carriers to ensure reimbursement for amounts that they are disbursing on our behalf, such as beneficiaries under our self-funded insurance program. In addition, from time to time, certain customers require us to post a letter of credit to ensure payments to our subcontractors or guarantee performance under our contracts. Letters of credit reduce our borrowing availability under our Credit Agreement and Canadian Credit Facility.  If these letters of credit were drawn on by the beneficiary, we would be required to reimburse the issuer of the letter of credit, and we may be required to record a charge to earnings for the reimbursement.  We do not believe that it is likely that any material claims will be made under a letter of credit.

·Letters of credit issued under our lines of credit. At December 31, 2014, we had letters of credit outstanding of $6.9 million, primarily for international projects in our Energy segment and for providing security to our insurance carriers.  These letters of credit are used by some of our vendors to ensure reimbursement for amounts that they are disbursing on our behalf, such as beneficiaries under our self-funded insurance program.  In addition, from time to time, certain customers require us to post a letter of credit to ensure payments to our subcontractors or guarantee performance under our contracts.  Letters of credit reduce our borrowing availability under our Credit Agreement and Canadian Credit Facility.  If these letters of credit were drawn on by the beneficiary, we would be required to reimburse the issuer of the letter of credit, and we may be required to record a charge to earnings for the reimbursement.  We do not believe that it is likely that any material claims will be made under a letter of credit.

51


 

·We enter into non-cancellable operating leases for some of our facilities, equipment and vehicles, including leases with related parties.  At December 31, 2014, equipment operating leases had a remaining commitment of $12.4 million and facility rental commitments were $21.7 million.

·Employment agreements which provide for compensation and benefits under certain circumstances and which may contain a change of control clause.  We may be obligated to make payments under the terms of these agreements.

·In the ordinary course of our business, we may be required by our customers to post surety bid or completion bonds in connection with services that we provide. At December 31, 2014, we had $1.5 billion in outstanding bonds.  We do not believe that it is likely that we would have to fund material claims under our surety arrangements.

45



Table of Contents

 

·

We enter into non-cancellable operating leases for some of our facilities, equipment and vehicles, including leases with related parties.  At December 31, 2017, equipment operating leases had a remaining commitment of $31.1 million and facility rental commitments were $13.2 million. Accounting treatment of operating leases will change in accordance with ASU 2016-02 “Leases (Topic 842)”, effective January 1, 2019.

·

·

In the ordinary course of our business, we may be required by our customers to post surety bid or completion bonds in connection with services that we provide. At December 31, 2017, we had $705.7 million in outstanding bonds, based on the remaining contract value to be recognized on bonded jobs.  We do not believe that it is likely that we would have to fund material claims under our surety arrangements.

·

Certain of our subsidiaries are parties to collective bargaining agreements with unions.  In most instances, these agreements require that we contribute to multi-employer pension and health and welfare plans.  For many plans, the contributions are determined annually and required future contributions cannot be determined since contribution rates depend on the total number of union employees and actuarial calculations based on the demographics of all participants.  The Employee Retirement Income Security Act of 1974 (ERISA), as amended by the Multi-Employer Pension Amendments Act of 1980, subject employers to potential liabilities in the event of an employer’s complete or partial withdrawal of an underfunded multi-employer pension plan.  The Pension Protection Act of 2006 added new funding rules for plan years after 2007 for multi-employer plans that are classified as “endangered”, “seriously endangered”, or “critical” status.  As discussed in Note 17 — “Multiemployer Plans” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K, we have recognized a withdrawal liability for one plan.  We currently do not anticipate withdrawal from any other multi-employer pension plans.  Withdrawal liabilities or requirements for increased future contributions could negatively impact our results of operations and liquidity; and health and welfare plans.  For many plans, the contributions are determined annually and required future contributions cannot be determined since contribution rates depend on the total number of union employees and actuarial calculations based on the demographics of all participants.  The Employee Retirement Income Security Act of 1974 (ERISA), as amended by the Multi-Employer Pension Amendments Act of 1980, subject employers to potential liabilities in the event of an employer’s complete or partial withdrawal of an underfunded multi-employer pension plan.  The Pension Protection Act of 2006 added new funding rules that are classified as “endangered”, “seriously endangered”, or “critical” status.  As discussed in Note 13 — “Commitments and Contingencies” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K, we have recognized a withdrawal liability for one plan.  We currently do not anticipate withdrawal from any other multi-employer pension plans.  Withdrawal liabilities or requirements for increased future contributions could negatively impact our results of operations and liquidity.

·

We enter into employment agreements with certain employees which provide for compensation and benefits under certain circumstances and which may contain a change of control clause.  We may be obligated to make payments under the terms of these agreements.

·

From time to time, we make other guarantees, such as guaranteeing the obligations of our subsidiaries.

 

·Other guarantees that we make from time to time, such as guaranteeing the obligations of our subsidiaries.

Receivable Collection Actions

 

As do all construction contractors, we negotiate payments with our customers from time to time, and we may encounter delays in receiving payments from our customers.  However,We have been engaged in 2014,dispute resolution to collect money we encountered unusual situationsbelieve we are owed for two construction projects completed in 2014.  Because of uncertainties associated with two contracts.  In one instance, ARB Industrial performed work on a solar plant in the Mojave Desert.  Based on our concerns about eventual collectability for the cost-reimbursable contract and in spite of many assurances of payment from the owner, we chose to recognize revenue equal to cost.  At the endprojects, including uncertainty of the project,amounts that would be collected, we used a zero profit margin approach to recording revenues during the owner chose not to pay the final amounts due totaling $33.8 million.  We are currently engaged in alternative dispute resolution as required by the contract.  The owner has bonded around the liens that we filed, and we believe that action will enhance collectability of amounts due at the end of the dispute process.construction period for both projects.

 

In addition, PPS constructedFor the first project, a large capital pipeline forcost reimbursable contract, we have recorded a customer in Texas.  During the early stagesreceivable of the project, we became concerned that the customer would not pay us for ancillary items as we believe is required by the contract.  As$32.9 million with a result of our concerns about eventual collectability, we chose to recognize revenue equal to cost.  We have initiated legal action and filed liens to collect our $29.3 million receivable.

The Company has specific reservesreserve of approximately $27$17.9 million included in billings“Billings in excess of costs and estimated earningsearnings..While  At this time, we believe that in both instances we are owedcannot predict the full amount of the receivable, there can be no guarantee of the final amount that we receive orwill collect nor the timing of aany collection. The dispute resolution for the receivable initially required international arbitration; however, in the first half of 2016, the two matters.owner sought bankruptcy protection in U.S. bankruptcy court. We have initiated litigation against the sureties who have provided lien and stop payment release bonds for the total amount owed. A trial date has been tentatively set for the second quarter of 2018. 

 

2015For the second project, we had recorded a receivable of $17.9 million.  During the third quarter 2016, we settled the dispute with an exchange of general releases and receipt of $38.0 million in cash. We changed our zero estimate of profit and accounted for the settlement as a change in accounting estimate which resulted in recognizing revenues of approximately $27.5 million and gross profit of approximately $26.7 million in the third quarter of 2016.

52


Table of Contents

2018 Outlook

 

We continue to believe that we have marketour end markets will continue their growth opportunities in 2015 in all of2018.  Our backlog at December 31, 2017 was $2.6 billion.  We anticipate potential changes to the industries that we serve.  However, while the United States economy has improved over the past few years, increasinglypreviously stringent regulatory and environmental requirements for many of our client’sclients’ infrastructure improvementsprojects, which may improve the timing and certainty of the significant reduction inprojects.  While fluctuating oil prices in the last half of 2014 have createdcreate uncertainty as to the timing of the opportunities.some of our opportunities, we are beginning to see preliminary bidding activity for larger gas, oil and derivatives projects.  We believe that we havePrimoris has the financial and operational capabilitiesstrength to meet either short-term delays or the short-term challenges, and weimpact of significant increases in work.  We continue to be optimistic about both short and longer-term opportunities.  Our view of the outlook for our major end markets currently is as follows:

 

·Construction of petroleum and natural gas and natural gas liquid pipelines — We expect that the continuing decrease in oil prices will decrease activities in all of the shale basins reducing the need for gathering lines for the near future.  We expect that production from the shale formations will continue to increase in the near future and that the current disconnect between production and processing locations provides opportunities for our underground construction operations serving midstream companies, primarily Rockford ARB Underground and PPS.

·

Construction of petroleum, natural gas, and natural gas liquid pipelines — While we have recently seen signs of a recovery in the price of oil, we expect that activities in most if not all of the shale basins will remain at reduced levels until a higher oil price is sustained, reducing any upstream work such as gathering lines and petroleum transport pipelines for the near future.  If production from the shale formations continues to increase in the near future, the current disconnect between production and processing locations would provide opportunities for our Pipeline segment.  We expect that the efforts by gas utilities to move shale gas from the Marcellus region to Florida and other Atlantic states could continue to provide significant opportunity over the next 2-3 years.

 

·Inspection and replacement of utility infrastructure — We expect that continuing safety enhancements to the gas utility infrastructure will provide opportunities for our ARB Underground operations.  We also expect that ongoing gas utility repair and maintenance opportunities will benefit Q3C and PPS.

·

Inspection, maintenance and replacement of gas utility infrastructure —We expect that ongoing safety enhancements to the gas utility infrastructure will provide continuing opportunities for our Utilities segment, especially in California, as well as in the Midwest.  We also expect that ongoing gas utility repair and maintenance opportunities will continue to grow.

 

·Construction of natural gas-fired power plants and heavy industrial plants — We expect continued construction opportunities for both base-load and peaker power plants; however, we are aware that concerns expressed in California that power plants are not “acceptable” for environmental reasons may impact short-term construction opportunities.  However, the continuing population growth, the impact of shutting the San Onofre nuclear facility and the regulatory mandate to use less ocean water for cooling power generation facilities means that absent invention of a new source of energy, power plants will need to be constructed at some future date.  In addition, the current low price of natural gas could result in the conversion of coal-fired power plants and conversion and expansion at chemical plants and industrial facilities.  These opportunities would benefit our ARB industrial group, JCG industrial group and Saxon.

·

Construction of natural gas-fired power plants and heavy industrial plants — We expect continued construction opportunities for both base-load and peak shaving power plants; however, we are aware that concerns expressed in California over gas fired power plants as not “acceptable” for environmental reasons may impact the timing of near term construction opportunities.  We believe that based on continuing population growth, the intermittency of renewable power resources and the environmental requirements limiting using ocean water for cooling, power plants will be needed in spite of vocal opposition to “non-green” sources.  In addition, the current low price of natural gas could result in the conversion of coal-fired power plants and conversion and expansion at chemical plants and industrial facilities in other parts of the United States.  These opportunities would benefit our Power segment.

 

·Construction of alternative energy facilities — We anticipate continued construction opportunities as state governments remain committed to renewable power standards, primarily benefitting ARB industrial.

·

Construction of alternative energy facilities, wind farms, solar energy — We anticipate continued construction opportunities as state governments remain committed to renewable power standards, primarily benefitting our Power segment.

 

46


·

Transportation infrastructure construction opportunities — We believe that passing of longer term highway funding by the federal government in 2015, results of the 2016 federal election, and voter approval of highway funding proposition 7 in Texas will provide increased opportunity for our heavy civil and highway groups especially in Texas.  We expect that opportunities in the Louisiana market may improve but will remain at depressed levels except for specific programs.  This market primarily impacts the operations of our Civil segment. 


Table of Contents

 

·Transportation infrastructure construction opportunities — We believe that this market has seen a decrease in new contract opportunities in most of the United States, including in the Louisiana market.  However, we expect continuing increases in Texas.  The transportation market would primarily impact the operations of JCG.

·

Liquefied Natural Gas Facilities—We believe the LNG opportunities for rail, barge, and other transportation needs will continue to grow, although such growth may be at a slow pace.  This market will primarily impact our Civil and Power segments.  We further believe the existing large scale LNG export facilities currently being planned will require services that will benefit our Pipeline segment for field services.

 

Please note that our 20152018 outlook and 20152018 financial results could be adversely impacted by themany factors including those discussed in Item 1A “Risk Factors” in this Annual Report on Form 10-K.  This 2015 outlook“2018 Outlook” consists

53


Table of Contents

of forward-looking statements and should be read in conjunction with the cautions about forward looking statements found at the beginning of this Annual Report on Form 10-K.

 

Backlog

 

For companies in the construction industry, backlog can be an indicator of future revenue streams.  Different companies define and calculate backlog in different manners.  For the Company,We define backlog is defined as a combination of: (1) anticipated revenue from the uncompleted portions of existing contracts for which we have known revenue amounts for fixed pricefixed-price and fixed unit priceunit-price contracts (“Fixed Backlog”), and (2) the estimated revenues on master service agreements (“MSA”)MSA work for the next four quarters (“MSA Backlog”).  We normally do not include time-and-equipment, time-and-materials and cost reimbursable plus fee contracts in the calculation of backlog, since their ultimatefinal revenue amount is difficult to estimate in advance.  However, we will include these types of contracts in backlog if the customer specifies an anticipated revenue amount.

 

The two components of backlog, Fixed Backlog and MSA Backlog, are detailed below.

 

Fixed Backlog

 

Fixed Backlog by operatingreporting segment and the changes in Fixed Backlog for the periods ending December 31, 2014, 20132017, 2016 and 20122015 were as follows, in millions:(in millions):

 

Segment

 

Beginning Fixed
Backlog at
December 31,
2013

 

Contract
Additions to
Fixed Backlog

 

Revenue
Recognized from
Fixed Backlog

 

Ending Fixed
Backlog
at December 31,
2014

 

Revenue
Recognized from
Non-Fixed Backlog
Projects

 

Total Revenue
for 12 months
ended December 31,
2014

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

West

 

$

224.6

 

$

576.7

 

$

564.0

 

$

237.3

 

$

400.1

 

$

964.1

 

East

 

1,017.7

 

468.8

 

476.8

 

1,009.7

 

13.1

 

489.9

 

Energy

 

240.7

 

594.7

 

534.4

 

301.0

 

97.8

 

632.2

 

Total

 

$

1,483.0

 

$

1,640.2

 

$

1,575.2

 

$

1,548.0

 

$

511.0

 

$

2,086.2

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Beginning Fixed

    

 

 

    

 

 

    

Ending Fixed

    

Revenue

    

Total Revenue

 

 

 

Backlog at

 

Contract

 

Revenue

 

Backlog

 

Recognized from

 

for 12 Months

 

 

 

December 31, 

 

Additions to

 

Recognized from

 

at December 31, 

 

Non-Fixed Backlog

 

ended December 31, 

 

Reportable Segment

 

2016

 

Fixed Backlog

 

Fixed Backlog

 

2017

 

Projects

 

2017

 

Power

 

$

469.6

 

$

464.7

 

$

552.1

 

$

382.2

 

$

54.0

 

$

606.1

 

Pipeline

 

 

1,019.4

 

 

194.1

 

 

435.8

 

 

777.7

 

 

29.8

 

 

465.6

 

Utilities

 

 

31.5

 

 

252.4

 

 

225.2

 

 

58.7

 

 

581.3

 

 

806.5

 

Civil

 

 

605.9

 

 

493.0

 

 

492.9

 

 

606.0

 

 

8.9

 

 

501.8

 

Total

 

$

2,126.4

 

$

1,404.2

 

$

1,706.0

 

$

1,824.6

 

$

674.0

 

$

2,380.0

 

 

Segment

 

Beginning Fixed
Backlog at
December 31,
2012

 

Contract
Additions to
Fixed Backlog

 

Revenue
Recognized from
Fixed Backlog

 

Ending Fixed
Backlog
at December 31,
2013

 

Revenue
Recognized from
Non-Fixed Backlog
Projects

 

Total Revenue
for 12 months
ended December 31,
2013

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

West

 

$

361.3

 

$

622.4

 

$

759.1

 

$

224.6

 

$

392.2

 

$

1,151.4

 

East

 

888.8

 

531.6

 

402.7

 

1,017.7

 

27.7

 

430.4

 

Energy

 

96.1

 

437.3

 

292.8

 

240.7

 

69.6

 

362.4

 

Total

 

$

1,346.2

 

$

1,591.3

 

$

1,454.6

 

$

1,483.0

 

$

489.6

 

$

1,944.2

 

 

Segment

 

Beginning Fixed
Backlog at
December 31,
2011

 

Contract
Additions to
Fixed Backlog

 

Revenue
Recognized from
Fixed Backlog

 

Ending Fixed
Backlog
at December 31,
2012

 

Revenue
Recognized from
Non-Fixed Backlog
Projects

 

Total Revenue
for 12 months
ended December 31,
2012

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

West

 

$

326.8

 

$

684.5

 

$

650.0

 

$

361.3

 

$

182.8

 

$

832.8

 

East

 

789.0

 

518.1

 

418.3

 

888.8

 

51.7

 

470.0

 

Energy

 

49.7

 

227.2

 

180.8

 

96.1

 

58.1

 

238.9

 

Total

 

$

1,165.5

 

$

1,429.8

 

$

1,249.1

 

$

1,346.2

 

$

292.6

 

$

1,541.7

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Beginning Fixed

    

 

 

    

 

 

    

Ending Fixed

    

Revenue

    

Total Revenue

 

 

 

Backlog at

 

Contract

 

Revenue

 

Backlog

 

Recognized from

 

for 12 months

 

 

 

December 31,

 

Additions to

 

Recognized from

 

at December 31, 

 

Non-Fixed Backlog

 

ended December 31, 

 

Reportable Segment

 

2015

 

Fixed Backlog

 

Fixed Backlog

 

2016

 

Projects

 

2016

 

Power

 

$

549.3

 

$

345.1

 

$

424.8

 

$

469.6

 

$

53.8

 

$

478.6

 

Pipeline

 

 

225.6

 

 

1,161.9

 

 

368.1

 

 

1,019.4

 

 

33.8

 

 

401.9

 

Utilities

 

 

42.8

 

 

140.7

 

 

152.0

 

 

31.5

 

 

485.2

 

 

637.2

 

Civil

 

 

699.5

 

 

370.9

 

 

464.5

 

 

605.9

 

 

14.7

 

 

479.2

 

Total

 

$

1,517.2

 

$

2,018.6

 

$

1,409.4

 

$

2,126.4

 

$

587.5

 

$

1,996.9

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

Beginning Fixed

    

 

 

    

 

 

    

Ending Fixed

    

Revenue

    

Total Revenue

 

 

 

Backlog at

 

Contract

 

Revenue

 

Backlog

 

Recognized from

 

for 12 months

 

 

 

December 31, 

 

Additions to

 

Recognized from

 

at December 31, 

 

Non-Fixed Backlog

 

ended December 31, 

 

Reportable Segment

 

2014

 

Fixed Backlog

 

Fixed Backlog

 

2015

 

Projects

 

2015

 

Power

 

$

393.5

 

$

569.1

 

$

413.3

 

$

549.3

 

$

53.0

 

$

466.3

 

Pipeline

 

 

161.5

 

 

322.1

 

 

258.0

 

 

225.6

 

 

41.4

 

 

299.4

 

Utilities

 

 

10.7

 

 

152.8

 

 

120.7

 

 

42.8

 

 

466.3

 

 

587.0

 

Civil

 

 

982.2

 

 

282.0

 

 

564.7

 

 

699.5

 

 

12.0

 

 

576.7

 

Total

 

$

1,547.9

 

$

1,326.0

 

$

1,356.7

 

$

1,517.2

 

$

572.7

 

$

1,929.4

 

 

Revenues recognized from non-Fixed Backlog projects shown above are generated by MSA projects and projects completed under time-and-equipment, time-and-materials and cost-reimbursable-plus-fee contracts.contracts or are revenue from the sale of construction materials, such as rock or asphalt to outside third parties or sales of water services.

 

54


Table of Contents

At December 31, 2014,2017, our total Fixed Backlog was $1.55$1.82 billion, representing an increasea decrease of $64.9$301.8 million, or 4.4%14.2%, from $1.48$2.13 billion as of December 31, 2013.  We expect that approximately 60% of the total Fixed Backlog at December 31, 2014, will be recognized as revenue during 2015, with approximately $237 million expected for the West segment, $402 million for the East segment and $283 million for the Energy segment.2016.

 

47



Table of Contents

MSA and Total Backlog

 

The following table outlines historical MSA revenues for the twelve months ending December 31, 2014, 20132017, 2016 and 2012 ($ in2015 (in millions):

 

Year:

 

MSA Revenues

 

2012

 

411.5

 

2013

 

462.6

 

2014

 

502.0

 

 

 

 

 

 

Year:

    

MSA Revenues

 

2017

 

$

665.3

 

2016

 

 

576.2

 

2015

 

 

565.1

 

 

MSA Backlog includes anticipated MSA revenues for the next twelve months.  We determined estimatedestimate MSA revenues based on historical trends, anticipated seasonal impacts and estimates of customer demand based on communications withinformation from our customers.

 

The following table shows the makeup ofour estimated MSA Backlog at December 31, 2017, 2016 and 2015 by reportable segment (in millions):

 

 

 

 

 

 

 

 

 

 

 

 

MSA Backlog

 

MSA Backlog

 

MSA Backlog

 

 

at December 31, 

 

at December 31, 

 

at December 31, 

Reportable Segment:

 

2017

 

2016

 

2015

Power

 

$

40.8

 

$

42.3

 

$

42.7

Pipeline

 

 

35.3

 

 

33.2

 

 

56.0

Utilities

 

 

680.5

 

 

575.0

 

 

468.0

Civil

 

 

18.2

 

 

21.0

 

 

4.0

Total

 

$

774.8

 

$

671.5

 

$

570.7

Total Backlog

The following table shows total backlog both Fixed(Fixed Backlog andplus MSA Backlog,Backlog), by operatingreportable segment at December 31, 20142017, 2016 and 2015 (in millions).:

 

Segment:

 

Fixed Backlog at
December 31,
2014

 

MSA Backlog
at December 31,
2014

 

Total Backlog
at December 31,
2014

 

 

 

 

 

 

 

 

 

West

 

$

237.3

 

$

396.1

 

$

633.4

 

East

 

1,009.7

 

3.4

 

1,013.1

 

Energy

 

301.0

 

45.4

 

346.4

 

Total

 

$

1,548.0

 

$

444.9

 

$

1,992.9

 

 

 

 

 

 

 

 

 

 

 

 

 

Reportable Segment:

 

 

2017

 

2016

 

2015

 

Power

 

 

$

423.0

 

$

511.9

 

$

592.0

 

Pipeline

 

 

 

813.0

 

 

1,052.6

 

 

281.6

 

Utilities

 

 

 

739.2

 

 

606.5

 

 

510.8

 

Civil

 

 

 

624.2

 

 

626.9

 

 

703.5

 

Total

 

 

$

2,599.4

 

$

2,797.9

 

$

2,087.9

 

 

We expect that during 2015,2018, we will recognize as revenue approximately 100%72% of the West segment total backlog at December 31, 2014, approximately 40%2017, comprised of backlog of approximately: 86% of the East segment backlog and approximately 95%Power segment; 53% of the Energy segment backlog.Pipeline segment; 100% of the Utilities segment; and 55% of the Civil segment.

 

Backlog should not be considered a comprehensive indicator of future revenues, as a percentage of our revenues are derived from projects that are not part of a backlog calculation.  The backlog estimates include amounts from estimated MSA revenues, but our customers are not contractually obligated to purchase an amount of services from us under the MSAs.  Any of our contracts, MSA, fixed pricefixed-price or fixed unit price,unit-price, may be terminated by our customers on relatively short notice. In the event of a project cancellation, we may be reimbursed for certain costs, but typically we have no contractual right to the total revenues reflected in backlog.  Projects may remain in backlog for extended periods of time as a result of customer delays, regulatory requirements or project specific issues.  Future revenues from projects completed under time-and-equipment, time-and-materials and cost-reimbursable-plus-fee contracts aremay not be included in our estimated backlog amount.

 

55


Table of Contents

Effects of Inflation and Changing Prices

 

Our operations are affected by increases in prices, whether caused by inflation or other economic factors. We attempt to recover anticipated increases in the cost of labor, equipment, fuel and materials through price escalation provisions in certain major contracts or by considering the estimated effect of such increases when bidding or pricing new work or by entering into back-to-back contracts with suppliers and subcontractors.

 

ITEM 7A.QUANTITATIVE AND QUALITATIVE DISCLOSURES ABOUT MARKET RISK

 

In the ordinary course of business, we are exposed to risks related to market conditions. These risks primarily include fluctuations in foreign currency exchange rates, interest rates and commodity prices. We may seek to manage these risks through the use of financial derivative instruments. These instruments may include foreign currency exchange contracts and interest rate swaps.

 

We do not execute transactions or use financial derivative instruments for trading or speculative purposes. We generally enter into transactions with counter parties that are generally financial institutions in a matter to limit significant exposure with any one party.

 

48



Table of ContentsAt December 31, 2017, we had no derivative financial instruments.

 

The carrying amounts for cash and cash equivalents, accounts receivable, short term investments, short-term debt, accounts payable and accrued liabilities shown in the consolidated balance sheetsConsolidated Balance Sheets approximate fair value at December 31, 2014 and 2013,2017, due to the generally short maturities of these items. At December 31, 2014 and 2013, we held short term investments which were primarily in four to six month certificates of deposits (“CDs”) and CDs purchased through the CDARS (Certificate of Deposit Account Registry Service) process and U.S. Treasury bills with various financial institutions that are backed by the federal government.  We expect to hold our investments to maturity.

 

At December 31, 2014,2017, all of our long-term debt was subject to fixed interest rates.

 

At December 31, 2014 and 2013, we had no derivative financial instruments.

ITEM 8.FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA

 

Our financial statements, supplementary financial data and financial statement schedules are included in a separate section at the end of this Annual Report on Form 10-K. The financial statements, supplementary data and schedules are listed in the index on page F-1 of this Annual Report on Form 10-K and are incorporated herein by reference.

 

ITEM 9.CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE

 

None.

 

ITEM 9A.  CONTROLS AND PROCEDURES

 

Evaluation of Disclosure Controls and Procedures

 

We maintain disclosure controls and procedures that are designed to ensure that information required to be disclosed in our reports under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the SEC’s rules and forms, and that such information is accumulated and communicated to management, including our Chief Executive Officer (“CEO”) and Executive Vice President, Chief Financial Officer (“CFO”), as appropriate, to allow for timely decisions regarding required disclosure. In designing and evaluating our disclosure controls and procedures, our management recognizes that any system of controls and procedures, no matter how well designed and operated, can only provide only reasonable assurance of achieving the desired control objectives, as ours are designed to do, and our management necessarily is required to apply its judgment in evaluating the cost-benefit relationship of possible controls and procedures. The Company’sOur disclosure controls and procedures are designed to provide reasonable assurance of achieving their stated objectives.

 

56


Table of Contents

In connection with the preparation of this Annual Report on Form 10-K, as of December 31, 2014,2017, an evaluation was performed under the supervision and with the participation of our management, including our CEO and CFO, of the effectiveness of the design and operation of our disclosure controls and procedures (as defined in Rule 13a-15(e) and 15d-15(e) under the Exchange Act). Based on that evaluation, as of the end of the period covered by this Annual Report on Form 10-K, our CEO and CFO concluded that our disclosure controls and procedures were effective at the reasonable assurance level to ensure that the information required to be disclosed by us in our reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the SEC’s rules and forms, and to ensure that the information required to be disclosed by us in reports that we file or submit under the Exchange Act is accumulated and communicated to our management, including our CEO and CFO, as appropriate, to allow timely decisions regarding required disclosures.

 

Management’s Annual Report on Internal Control Over Financial Reporting

 

Our management is responsible for establishing and maintaining adequate internal control over financial reporting as defined in Rules 13a-15(f) and 15d-15(f) under the Exchange Act. Our internal control over financial reporting is designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. Our internal control over financial reporting includes those policies and procedures that:

 

(i)pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of our assets;

(i)

pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of our assets;

 

(ii)provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that our receipts and expenditures are being made only in accordance with authorizations of our management and directors; and

(ii)

provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that our receipts and expenditures are being made only in accordance with authorizations of our management and directors; and

 

(iii)provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of our assets that could have a material effect on our financial statements.

(iii)

provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of our assets that could have a material effect on our financial statements.

 

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

 

49



TableUnder the supervision and with the participation of Contents

Management assessedour management, including our CEO and evaluatedCFO, our management conducted an evaluation of the effectiveness of our internal control over financial reporting as of December 31, 2014. In making2017. Management based this assessment management usedon the criteria set forthframework in “Internal Control–Integrated Framework (2013)” issued by the Committee of Sponsoring Organizations of the Treadway Commission in Internal Control—Integrated Framework (1992).Commission. Based on the results of management’s assessment andthat evaluation, our CEO and CFO believeconcluded that our internal control over financial reporting iswas effective as of December 31, 2014.2017.  Management reviewed the results of its assessment with the Audit Committee of our Board of Directors.

 

As discussed in Note 4 — Business Combinations“Business Combinations” of the Notes to Consolidated Financial Statements included in Item 8 of this Form 10-K, we acquired SurberFlorida Gas Contractors on July 28, 2014May 26, 2017 and Ram-FabCoastal Field Services on August 29, 2014.June 16, 2017.

 

We have excluded SurberFGC and Ram-FabCoastal from our assessment of the effectiveness of our internal control over financial reporting as of December 31, 2014.2017.  The combined SurberFlorida Gas Contractors and Ram-FabCoastal Field Services financial statements in aggregate constitute approximately 0.7%2.0% of total assets (excluding approximately $1.8$43.5 million of goodwill and intangible assets, which were integrated into the Company’sour systems and control environment), and approximately 0.3%1.4% of total revenues and approximately 0.4% of pre-tax income (excluding approximately $0.3 million of amortization of intangible assets, which was integrated into the Company’s systems and control environment) of the consolidated financial statement amounts as of and for the year ended December 31, 2014.2017.

57


Table of Contents

Independent Registered Public Accounting Firm Report

 

TheMoss Adams LLP, the independent registered public accounting firm that audited our consolidated financial statements containedincluded in this annual reportAnnual Report on Form 10-K, has issued a report on our internal control over financial reporting as of December 31, 2017. The report, which expresses an audit reportunqualified opinion on the effectiveness of our internal control over financial reporting.reporting as of December 31, 2017, is included in “Item 8.  Financial Statements and Supplemental Data” under the heading “Report of Independent Registered Public Accounting Firm.”

 

ITEM 9B.OTHER INFORMATION

 

None.

50


58



Table of Contents

PART III

 

ITEM 10.DIRECTORS, EXECUTIVE OFFICERS AND CORPORATE GOVERNANCE

 

Directors

 

Information relating to the officers and directors of our company, other corporate governance matters and other information required under this Item 10 is set forth in our Proxy Statement for our 20152018 Annual Meeting of Stockholders (“Proxy Statement”) and the information is incorporated herein by reference. The following is a listing of certain information regarding our executive officers.

 

Executive Officers

 

Brian Pratt.David King.  Mr. PrattKing has beenserved as our President and Chief Executive Officer since August 2015 and Chairmanhas served as one of the Boardour Directors since July 2008.May 2015.  Mr. PrattKing directs strategy, establishes goals and oversees our operations.  Prior to that, he served as theMr. King was our Executive Vice President, Chief ExecutiveOperating Officer and Chairman of the Board of Former Primoris and its predecessor, ARB, Inc., a California corporation, since 1983. He assumed operational and financial control of ARB in 1983.March 2014.  Prior to joining Primoris, Mr. King spent several years at CB&I, most recently as President of Lummus Engineered Products.  From 2010 to 2013 he was President of CB&I Project Engineering & Construction based in The Hague, Netherlands responsible for P&L operations worldwide.  From 2009 to 2010 he was Group Vice President for Downstream Operations for CB&I Lummus located in The Woodlands, Texas.   Mr. King also managed and helped establish the merger with the former shell companyGlobal Services Group for CB&I in 2008 Mr. Pratt was majority owner of Primoris. Mr. Prattto 2009.  He has over 30 years of hands-on operations and managementextensive EPF&C industry experience in energy-related projects, LNG, offshore, pipelines, refining, petrochemicals, gas processing, oil sands, synthesis gas and gas-to-liquids. Mr. King received his bachelor’s degree in Mechanical Engineering from Texas Tech University, an MBA from the construction industry.University of Texas, Tyler, and an Advanced Executive Management Degree from Insead University in Fontainebleau, France.  Mr. Pratt completed four years of courses in Civil Engineering at California Polytechnic College in Pomona in 1974. Mr. PrattKing is 6265 years old.

 

Peter J. Moerbeek.  Mr. Moerbeek was named as our Executive Vice President, Chief Financial Officer effective February 6, 2009. He has served as one of our Directors since July 2008. Previously, he served as Chief Executive Officer of a private-equity funded company engaged in the acquisition and operation of water and wastewater utilities. As a founder of the company from June 2006 to February 2007, he was involved in raising equity capital for the company. From August 1995 to June 2006, Mr. Moerbeek held several positions with publicly traded Southwest Water Company, including a Director from 2001 to 2006; President and Chief Operating Officer from 2004 to 2006; President of the Services Group from 1997 to 2006; Secretary from 1995 to 2004; and Chief Financial Officer from 1995 to 2002. From 1989 to 2005, Mr. Moerbeek was the Chief Financial and Operations Officer for publicly-traded Pico Products, Inc. Mr. Moerbeek received a B.S. in Electrical Engineering in 1969 and a MBA in 1971 from the University of Washington. Mr. Moerbeek is 6770 years old.

 

David King.Thomas E. McCormick.  Mr. King has beenMcCormick was named as our Executive Vice President, Chief Operating Officer, since March 2014.  Prior to joining Primoris, Mr. King spent several years at CB&I, most recently as President of Lummus Engineered Products.  From 2010 to 2013 he was President of CB&I Project Engineering & Construction based in The Hague, Netherlands responsible for P&L operations worldwide.  From 2009 to 2010 he was Group Vice President for Downstream Operations for CB&I Lummus located in The Woodlands, Texas.   Mr. King also managed and helped establish the Global Services Group for CB&I in 2008 to 2009.effective April 7, 2016.  He has extensive EPF&Cengineering & construction industry experience in projects for many energy-related projects, LNG, offshore,end markets, including pipelines, refining, petrochemicals, gas processing, LNG, oil sands synthesis gas and gas-to-liquids.industrial gases.  Since February 2007, he has held a variety of executive positions with CB&I.  Such positions included President for Oil & Gas, Senior Vice President – Gas Processing & Oil Sands, Global Vice President –Downstream Operations, and Vice President Operations. Prior to 2007, Mr. King received his bachelor’sMcCormick worked for more than 17 years at BE&K Engineering on a variety of heavy civil projects. Mr. McCormick has a Bachelor of Science degree in MechanicalCivil Engineering from Texas TechFlorida State University an MBA from the University of Texas, Tyler, and an Advanced Executive Management Degree from Insead University in Fontainebleau, France.  Mr. KingMcCormick is 6255 years old.

 

John M. Perisich.  Mr. Perisich has served as our Executive Vice President and General Counsel effective May 3, 2013.  He previously served as our Senior Vice President and General Counsel from July 2008. Prior to that, he served as Vice President and General Counsel of Primoris Corporation beginning in  February 2006, and priorprevious to that was Vice President and General Counsel of Primoris.Primoris Corporation and its predecessor, ARB, Inc. Mr. Perisich joined ARB in 1995. Prior to joining ARB, Mr. Perisich practiced law at Klein, Wegis, a full service law firm based in Bakersfield, California. He received a B.A. degree from UCLA in 1987, and a J.D. from the University of Santa Clara in 1991. Mr. Perisich is 5053 years old.

59


Table of Contents

ITEM 11.EXECUTIVE11.EXECUTIVE COMPENSATION

 

Information required under this Item 11 is set forth in our Proxy Statement and is incorporated herein by reference, except for the information set forth under the caption, “Compensation Committee Report” of our Proxy Statement, which specifically is not incorporated herein by reference.

 

ITEM 12.SECURITY12.SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT AND RELATED STOCKHOLDER MATTERS

 

Information required under this Item 12 is set forth in our Proxy Statement and is incorporated herein by reference.

 

ITEM 13.CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS, AND DIRECTOR INDEPENDENCE

 

The information required under this Item 13 is set forth in our Proxy Statement and is incorporated herein by reference.

 

ITEM 14.PRINCIPAL ACCOUNTING FEES AND SERVICES

 

Information regarding principal accounting fees and services and other information required under this Item 14 is set forth in our Proxy Statement and is incorporated herein by reference.

51


60



Table of Contents

PART IV

 

PART IV

ITEM 15.  EXHIBITS, FINANCIAL STATEMENT SCHEDULES

 

(A)We have filed the following documents as part of this Report:

 

1.

Consolidated Balance Sheets of Primoris Services Corporation and subsidiaries as of December 31, 2017 and 2016 and the related Consolidated Statements of Income, Stockholders’ Equity and Cash Flows for the years ended December 31, 2017, 2016 and 2015.

1.Consolidated Balance Sheets of Primoris Services Corporation and subsidiaries as of December 31, 2014 and 2013 and the related Consolidated Statements of Income, Stockholders’ Equity and Cash Flows for the years ended December 31, 2014, 2013 and 2012.

2.

Report of Moss Adams LLP, independent registered public accounting firm, related to the consolidated financial statements in part (A)(1) above.

3.

Notes to the consolidated financial statements in part (A)(1) above.

4.

List of exhibits required by Item 601 of Regulation S-K.  See part (B) below.

 

2.Report of Moss Adams LLP, independent registered public accounting firm, related to the consolidated financial statements in part (A)(1) above.

3.Notes to the consolidated financial statements in part (A)(1) above.

4.List of exhibits required by Item 601 of Regulation S-K.  See part (B)        below.

(B)The following is a complete list of exhibits filed as part of this Report, some of which are incorporated herein by reference from certain other of our reports, registration statements and other filings with the SEC, as referenced below:

 

Exhibit No.

Exhibit No.

Description

 

 

 

Exhibit 2.1

 

Agreement and Plan of Merger, dated February 19, 2008, by and among Rhapsody Acquisition Corp., Primoris Corporation and certain stockholders of Primoris Corporation (1)(incorporated by reference to Exhibit 10.1 to our Current Report on Form 8-K, as filed with the SEC on February 20, 2008)

 

 

 

Exhibit 2.2

 

First Amendment to Agreement and Plan of Merger, dated May 15, 2008, by and among Rhapsody Acquisition Corp., Primoris Corporation and certain stockholders of Primoris Corporation (2)(incorporated by reference to Exhibit 2.2 to our Registration Statement on Form S-4/A (Amendment No. 3) (File No. 333-150343), as filed with the SEC on July 1, 2008)

 

 

 

Exhibit 2.3

 

Membership Interest Purchase Agreement, dated July 1, 2010, by and between Primoris Services Corporation, Kealine Holdings LLC and WesPac Energy LLC (3)(incorporated by reference to Exhibit 2.1 to our Current Report on Form 8-K, as filed with the SEC on July 8, 2010)

 

 

 

Exhibit 2.4

 

Agreement and Plan of Merger, dated November 8, 2010, by and among Primoris Services Corporation, a Delaware corporation, Primoris Merger Sub, Inc., a Delaware corporation and a wholly-owned subsidiary of Primoris Services Corporation, Rockford Holdings Corporation, a privately-held Delaware corporation, all of the stockholders of Rockford Holdings Corporation and Christopher S. Wallace as representative of the stockholders of Rockford Holdings Corporation (4)(incorporated by reference to Exhibit 2.1 to our Current Report on Form 8-K, as filed with the SEC on November 12, 2010)

61


Table of Contents

 

 

 

Exhibit No.

Description

Exhibit 2.5

 

Stock Purchase Agreement, dated November 8, 2012, by and among Primoris Services Corporation, a Delaware corporation, Q3 Contracting Inc., a privately-held Minnesota corporation, all of the shareholders of Q3 Contracting Inc. and Jay P. Osborn as representative of the shareholders of Q3 Contracting Inc. (5)(incorporated by reference to Exhibit 2.1 to our Current Report on Form 8-K, as filed with the SEC on November 15, 2012)

 

 

 

Exhibit 3.1

 

Fourth Amended and Restated Certificate of Incorporation of Primoris Services Corporation, dated May 21, 2009 (6)(incorporated by reference to Exhibit 3.1 to our Quarterly Report on Form 10-Q, as filed with the SEC on August 12, 2009)

 

 

 

Exhibit 3.2

 

Amended and Restated Bylaws of Primoris Services Corporation (7)(incorporated by reference to Exhibit 3.2 to our Current Report on Form 8-K, as filed with the SEC on August 6, 2008)

 

 

 

Exhibit 3.3

 

Certificate of Designations, Powers, Preferences and Rights of the Series A Non-Voting Contingent Convertible Preferred Stock of Primoris Services Corporation, dated December 14, 2009 (8)(incorporated by reference to Exhibit 3.1 to our Current Report on Form 8-K, as filed with the SEC on December 17, 2009)

 

 

 

Exhibit 4.1

 

Specimen Common Stock Certificate (9)(incorporated by reference to Exhibit 4.2 to our Registration Statement on Form S-1 (File No. 333-134694), as filed with the SEC on June 2, 2006)

 

 

 

Exhibit 10.1

 

2008 Long-Term Equity Incentive Plan (incorporated by reference to Annex C to our Registration Statement on Form S-4/A (Amendment No. 4) (File No. 333-150343), as filed with the SEC on July 9, 2008) (#)(10)

 

 

 

Exhibit 10.2

 

2013 Equity Incentive Plan (incorporated by reference to Appendix A to our Definitive Proxy Statement on Schedule 14A filed with the SEC on April 9, 2013) (#)(11)

 

 

 

Exhibit 10.3

 

LoanAmended and SecurityRestated Credit Agreement, dated October 28, 2009,September 29, 2017, by and betweenamong Primoris Services Corporation and The PrivateBankCIBC Bank USA, Bank of the West, Branch Banking and Trust Company, (12)IBERIABANK, Bank of America, and Simmons Bank. (incorporated by reference to Exhibit 10.1 to our Quarterly Report on Form 10-Q, as filed with the SEC on November 6, 2017)

 

 

 

Exhibit 10.4

 

First Amendment to Loan and SecurityCredit Agreement, dated January 14, 2010,December 28, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company, (13)The Bank of the West and IBERIABANK Corporation (incorporated by reference to Exhibit 10.1 to our Current Report on Form 8-K, as filed with the SEC on January 7, 2013)

 

 

 

Exhibit 10.5

 

SecondWaiver and Amendment to Loan and Security Agreement, dated Septemberas of April 30, 2010,2013, by and among Primoris Services Corporation and The PrivateBank and Trust Company (13)and other financial institutions party to the Credit Agreement. (incorporated by reference to Exhibit 10.2 to our Current Report on Form 8-K, as filed with the SEC on December 18, 2014)

62


Table of Contents

 

 

 

Exhibit No.

Description

Exhibit 10.6

 

Master LoanSecond Amendment and SecurityWaiver Agreement, dated Juneas of August 25, 2010,2014, by and between Stellaris, LLCamong Primoris Services Corporation and Banc of

52The PrivateBank and Trust Company and other financial institutions party to the Credit Agreement. (incorporated by reference to Exhibit 10.3 to our Current Report on Form 8-K, as filed with the SEC on December 18, 2014)



Table of Contents

America Leasing & Capital, LLC (14)

 

 

 

Exhibit 10.7

 

Master Loan and SecurityThird Amendment to Credit Agreement, dated August 31, 2009,as of December 12, 2014, by and between Stellaris, LLCamong Primoris Services Corporation and Fifth ThirdThe PrivateBank and Trust Company, The Bank (14)of the West, IBERIABANK Corporation, Branch Banking and Trust Company and UMB Bank, N.A. (incorporated by reference to Exhibit 10.1 to our Current Report on Form 8-K, as filed with the SEC on December 18, 2014)

 

 

 

Exhibit 10.8

 

Purchase Trading Plan Agreement, dated September 7, 2010, by and between Primoris Services Corporation and CJS Securities, Inc. (15)

Exhibit 10.9

Loan Agreement, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.10

Note, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.11

Collateral Schedule No. 1, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.12

Guaranty, dated December 29, 2010, by and between Primoris Services Corporation and RBS Asset Finance, Inc. (16)

Exhibit 10.13

Third Amendment to Loan and Security Agreement, dated March 3, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (17)

Exhibit 10.14

Fourth Amendment to Loan and Security Agreement, dated October 20, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (18)

Exhibit 10.15

Credit Agreement, dated September 23, 2011, by and among Primoris Services Corporation and Bank of the West (19)

Exhibit 10.16

Fifth Amendment to Loan and Security Agreement, dated November 28, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (19)

Exhibit 10.17

Loan and Security Agreement, dated November 30, 2011, by and among Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.18

Business Purpose Promissory Note, dated November 30, 2011, by and among Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.19

Schedule A-1 Equipment Collateral, dated November 30, 2011, by and between Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.20

Amendment No. 3 to the Master Loan and Security Agreement Loan and Security Agreement, dated November 30, 2011, by and among James Construction Group LLC, Stellaris LLC, ARB Inc. and Fifth Third Bank (19)

Exhibit 10.21

Promissory Note, dated November 30, 2011, by and among James Construction Group LLC, Stellaris LLC, ARB Inc. and Fifth Third Bank (19)

Exhibit 10.22

Master Loan and Security Agreement, dated December 21, 2011, by and among ARB, Inc. and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.23

Equipment Security Note, dated December 21, 2011, by and among ARB, Inc., Stellaris LLC, Rockford Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.24

Addendum to Master Loan and Security Agreement, dated December 21, 2011, by and among ARB, Inc., Stellaris LLC, Rockford Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.25

Guaranty, dated December 21, 2011, by and among Primoris Services Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.26

General Indemnity Agreement, dated January 24, 2012, by and among Primoris Services Corporation,

53



Table of Contents

ARB, Inc. ARB Structures, Inc., OnQuest, Inc., OnQuest Heaters, Inc. Born Heaters Canada ULC, Cardinal Contractors, Inc., Cardinal Southeast, Inc., Stellaris, LLC, GML Coatings, LLC, James Construction Group, LLC, Juniper Rock Corporation, Rockford Corporation; Alaska Continental Pipeline, Inc., All Day Electric Company, Inc. Primoris Renewables, LLC, Rockford Pipelines Canada, Inc. and Chubb Group of Insurance Companies (21)(incorporated by reference to Exhibit 10.51 to our Annual Report on Form 10-K, as filed with the SEC on March 5, 2012)

 

 

 

Exhibit 10.2710.9

 

Fifth Amendment to Loan and Security Agreement, dated April 4, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (22)

Exhibit 10.28

Equipment Security Note, dated June 20, 2012, by and among Stellaris, LLC, James Construction Group, LLC and Banc of America Leasing & Capital, LLC (23)

Exhibit 10.29

Amendment Number 1 to Master Loan and Security Agreement, dated June 20, 2012, by and among Stellaris, LLC, James Construction Group, LLC and Banc of America Leasing & Capital, LLC (23)

Exhibit 10.30

Seventh Amendment to Loan and Security Agreement, dated July 18, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (24)

Exhibit 10.31

Eighth Amendment to Loan and Security Agreement, dated October 29, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (25)

Exhibit 10.32

Master Loan and Security Agreement, dated November 1, 2012, by and between Stellaris, LLC and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.33

Amendment to Master Loan and Security Agreement, dated November 7, 2012, by and among Stellaris, LLC, James Construction Group, LLC, Miller Springs Materials, LLC, Primoris Energy Services Corporation and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.34

Equipment Security Note, dated November 1, 2012, by and among Stellaris, LLC, James Construction Group, LLC, Miller Springs Materials, LLC, Primoris Energy Services Corporation and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.35

Loan Agreement, dated December 13, 2012, by and between Stellaris, LLC and Q3 Contracting, Inc. and RBS Asset Finance, Inc. (27)

Exhibit 10.36

Note, dated December 13, 2012, by and among Stellaris, LLC and Q3 Contracting, Inc. and RBS Asset Finance, Inc. (27)

Exhibit 10.37

Guaranty, dated December 13, 2012, by and among Primoris Services Corporation and RBS Asset Finance, Inc. (27)

Exhibit 10.38

Credit Agreement, dated December 28, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company, The Bank of the West and IBERIABANK Corporation (28)

Exhibit 10.39

Note Purchase and Private Shelf Agreement, dated December 28, 2012, by and among Primoris Services Corporation and Prudential Investment Management, Inc. and certain Prudential affiliates (28)(incorporated by reference to Exhibit 10.2 to our Current Report on Form 8-K, as filed with the SEC on January 7, 2013)

 

 

 

Exhibit 10.4010.10

 

Promissory Note, dated June 11,2013, by and among Stellaris, LLC and Fifth Third Bank pursuant to the Master Loan and Security Agreement dated August 31, 2009 (30)

Exhibit 10.41

Master Loan and Security Agreement, dated June 13, 2013, by and among Stellaris, LLC, James Construction Group, LLC, Rockford Corporation and Wells Fargo Equipment Finance, Inc. and Loan Schedules, dated June 13, 2013 (30)

Exhibit 10.42

Confirmation of Acceptance Agreement, dated June 13, 2013, by and among Primoris Services Corporation and Prudential Investment Management, Inc. and certain Prudential affiliates pursuant to the Note Purchase and Private Shelf Agreement, dated December 28, 2012 and five 3.85% Senior Secured Notes, Series B, due July 25, 2023 (30)

54



Table of Contents

(incorporated by reference to Exhibit 10.43

Loan Agreement, dated September 17, 2013, by and among Stellaris, LLC, James Construction Group LLC and Rockford Corporation and RBS Asset Finance, Inc. (31)10.3 to our Quarterly Report on Form 10-Q, as filed with the SEC on August 7, 2013)

 

 

 

Exhibit 10.4410.11

 

Loan and SecurityThird Letter Amendment to Shelf Agreement, dated September 20, 2013,as of June 3, 2015, by and between PNC Equipment Finance, LLCamong Primoris Services Corporation and Stellaris LLCPrudential Investment Management, Inc. and Q3 Contracting, Inc. (31)each other Holder (as defined in the Shelf Agreement). (incorporated by reference to Exhibit 10.1 to our Current Report on Form 8-K, as filed with the SEC on June 9, 2015)

 

 

 

Exhibit 10.4510.12

 

Contribution Agreement, dated as of September 30, 2013, by and among WesPac Energy LLC, Kealine Holdings LLC, Primoris Services Corporation and WesPac Midstream LLC and Highstar WesPac Main Interco LLC and Highstar WesPac Prism/IV-A Interco LLC (31)(incorporated by reference to Exhibit 10.3 to our Quarterly Report on Form 10-Q, as filed with the SEC on November 5, 2013)

 

 

 

Exhibit 10.4610.13

 

Master LoanAgreement for Services, dated August 1, 2015, by and Securityamong Primoris Services Corporation and Brian Pratt. (incorporated by reference to Exhibit 10.56 to our Annual Report on Form 10-K, as filed with the SEC on February 29, 2016) (#)

63


Table of Contents

Exhibit No.

Description

Exhibit 10.14

Employment Agreement, dated December 6, 2013August 1, 2015, by and between Stellaris, LLCamong Primoris Services Corporation and Banc of America Leasing & Capital, LLC (32)David L. King. (incorporated by reference to Exhibit 10.57 to our Annual Report on Form 10-K, as filed with the SEC on February 29, 2016) (#)

 

 

 

Exhibit 10.4710.15

 

Equipment Security Note, dated as of December 6, 2013, by and between Stellaris, LLC, ARB, Inc. James Construction Group, LLC, and Rockford Corporation and Banc of America Leasing & Capital, LLC (32)

Exhibit 10.48

Master SecurityEmployment Agreement, dated September 18, 2014, by and among Primoris Services Corporation, Rockford Corporation and Key Equipment Finance, a division of KeyBank National Association. (33)

Exhibit 10.49

Promissory Note and Collateral Schedule No. 1, dated September 18, 2014, by and between Primoris Energy Services Corporation, Rockford Corporation and Key Equipment Finance, a division of KeyBank National Association. (33)

Exhibit 10.50

Master Loan and Security Agreement, dated September 19, 2014, by and among Fifth Third Bank and Primoris Services Corporation, James Construction Group, LLC and Q3 Contracting, Inc. (33)

Exhibit 10.51

Amendment No. 1 to Master Loan and Security Agreement, dated as of September 23, 2014, by and among Fifth Third Bank and Stellaris LLC. (33)

Exhibit 10.52

Promissory Note, dated September 19, 2014, by and among Primoris Services Corporation, James Construction Group, LLC, Q3 Contracting, Inc. and Fifth Third Bank. (33)

Exhibit 10.53

Third Amendment to Credit Agreement, dated as of December 12, 2014,April 5, 2016, by and among Primoris Services Corporation and The PrivateBank and Trust Company, The Bank ofThomas McCormick. (incorporated by reference to Exhibit 99.2 to our Current Report on Form 8-K, as filed with the West, IBERIABANK Corporation, Branch Banking and Trust Company and UMB Bank, N.A. (34)

Exhibit 10.54

Waiver and Amendment Agreement, dated as ofSEC on April 30, 2014, by and among Primoris Services Corporation and The PrivateBank and Trust Company and other financial institutions party to the Credit Agreement. (34)

Exhibit 10.55

Second Amendment and Waiver Agreement, dated as of August 25, 2014, by and among Primoris Services Corporation and The PrivateBank and Trust Company and other financial institutions party to the Credit Agreement. (34)8, 2016) (#)

 

 

 

Exhibit 14.1

 

Code of Ethics and Business Conduct (29)(incorporated by reference to Exhibit 14.1 to our Annual Report on Form 10-K, as filed with the SEC on March 11, 2010)

 

 

 

Exhibit 21.1

 

Subsidiaries and equity investments of Primoris Services Corporation (*)

 

 

 

Exhibit 23.1

 

Consent of Moss Adams LLP (*)

 

 

 

Exhibit 31.1

 

Certification of chief executive officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 (*)

 

 

 

Exhibit 31.2

 

Certification of chief financial officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 (*)

 

 

 

Exhibit 32.1

 

Certification of chief executive officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 (*)

 

 

 

Exhibit 32.2

 

Certification of chief financial officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 (*)

 

 

 

Exhibit 101 INS

 

XBRL Instance Document (*)

Exhibit 101 SCH

 

XBRL Taxonomy Extension Schema Document (*)

55



Table of Contents

Exhibit 101 CAL

 

XBRL Taxonomy Extension Calculation Linkbase Document (*)

Exhibit 101 LAB

 

XBRL Taxonomy Extension Label Linkbase Document (*)

Exhibit 101 PRE

 

XBRL Taxonomy Extension Presentation Linkbase Document (*)

Exhibit 101 DEF

 

XBRL Taxonomy Extension Definition Linkbase Document (*)

 


(#)Management contract or compensatory plan, contract or arrangement.

(*)Filed herewith.

64


 

(*)  Filed herewith.

(1)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on February 20, 2008, and such exhibit is incorporated herein by reference.

(2)

Filed as an exhibit to our Registration Statement on Form S-4/A (Amendment No. 3) (File No. 333-150343), as filed with the SEC on July 1, 2008, and such exhibit is incorporated herein by reference.

(3)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 8, 2010, and such exhibit is incorporated herein by reference.

(4)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 12, 2010, and such exhibit is incorporated herein by reference.

(5)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 15, 2012, and such exhibit is incorporated herein by reference.

(6)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on August 12, 2009, and such exhibit is incorporated herein by reference.

(7)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on August 6, 2008, and such exhibit is incorporated herein by reference.

(8)

Filed as exhibit to our Current Report on Form 8-K, as filed with the SEC on December 17, 2009, and such exhibit is incorporated herein by reference.

(9)

Filed as an exhibit to our Registration Statement on Form S-1 (File No. 333-134694), as filed with the SEC on June 2, 2006, and such exhibit is incorporated herein by reference.

(10)

Attached as an annex to our Registration Statement on Form S-4/A (Amendment No. 4) (File No. 333-150343), as filed with the SEC on July 9, 2008, and such annex is incorporated herein by reference.

(11)

Attached as Appendix A to our Definitive Proxy Statement on Schedule 14A filed with the SEC on April 9, 2013, and such Appendix is incorporated herein by reference.

(12)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 4, 2009, and such exhibit is incorporated herein by reference.

(13)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on October 6, 2010, and such exhibit is incorporated herein by reference.

(14)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 1, 2010, and such exhibit is incorporated herein by reference.

(15)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on September 8, 2010, and such exhibit is incorporated herein by reference.

(16)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on January 6, 2011, and such exhibit is incorporated herein by reference.

(17)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 16, 2011, and such exhibit is incorporated herein by reference.

(18)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on October 25, 2011, and such exhibit is incorporated herein by reference.

(19)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 14, 2011, and such exhibit is incorporated herein by reference.

(20)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 30, 2011, and such exhibit is incorporated herein by reference.

(21)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 5, 2012, and such exhibit is incorporated herein by reference.

(22)

Filed as an exhibit to our Annual Report on Form 10-Q, as filed with the SEC on May 9, 2012, and such exhibit is incorporated herein by reference.

(23)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on June 28, 2012, and such exhibit is incorporated herein by reference.

(24)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 23, 2012, and such exhibit is incorporated herein by reference.

(25)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 2, 2012, and such exhibit is

56



Table of Contents

 

 

incorporated herein by reference.

(26)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 9, 2012, and such exhibit is incorporated herein by reference.

(27)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 18, 2012, and such exhibit is incorporated herein by reference.

(28)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on January 7, 2013, and such exhibit is incorporated herein by reference.

(29)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 11, 2010, and such exhibit is incorporated herein by reference.

(30)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on August 7, 2013, and such exhibit is incorporated herein by reference.

(31)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on November 5, 2013, and such exhibit is incorporated herein by reference.

(32)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 3, 2014, and such exhibit is incorporated herein by reference.

(33)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on November 7, 2014, and such exhibit is incorporated herein by reference.

(34)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 18, 2014, and such exhibit is incorporated herein by reference.

 

57SIGNATURES



Table of Contents

SIGNATURES

 

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Registrant has duly caused this Report to be signed on its behalf by the undersigned, thereunto duly authorized.

 

Primoris Services Corporation (Registrant)

 

BY:

/s/ BRIAN PRATT

DAVID L. KING

BY:

/s/ PETER J. MOERBEEK

 

Brian Pratt

David L. King

 

Peter J. Moerbeek

President and Chief Executive Officer

 

Executive Vice President, Chief Financial Officer

(Principal Executive Officer)

(Principal Financial and Accounting Officer)

 

 

 

 

Date:

March 16, 2015

February 26, 2018

 

 

 

Pursuant to the requirements of the Securities Exchange Act of 1934, this Report has been signed by the following persons on behalf of the Registrant and in the capacities indicated and on the date indicated.

 

BY:

/s/ BRIAN PRATT

 

 

Brian Pratt

 

 

Chairman of the Board of Directors

BY:

/s/ DAVID L. KING

David L. King

Director

 

 

 

 

BY:

/s/ PETER J. MOERBEEK

 

 

Peter J. Moerbeek

 

 

Director

 

 

 

 

BY:

/s/ PETER C. BROWN

 

 

Peter C. Brown

 

 

Director

 

 

 

 

BY:

/s/ STEPHEN C. COOK

 

 

Stephen C. Cook

 

 

Director

 

 

 

 

BY:

/s/ JOHN P. SCHAUERMAN

John P. Schauerman

Director

BY:

/s/ ROBERT A. TINSTMAN

 

 

Robert A. Tinstman

 

 

Director

 

 

 

 

BY:

/s/ THOMAS E. TUCKER

 

 

Thomas E. Tucker

 

 

Director

 

 

 

 

Date:

March 16, 2015February 26, 2018

 

 

58

65


 


Table of Contents

PRIMORIS SERVICES CORPORATION

 

INDEX TO FINANCIAL STATEMENTS

 

Page

Page

Report of Independent Registered Public Accounting Firm

F-2

Consolidated Balance Sheets as of December 31, 20142017 and 20132016

F-4

Consolidated Statements of Income for the Years Ended December 31, 2014, 20132017, 2016 and 20122015

F-5

Consolidated Statements of Stockholders’ Equity for the Years Ended December 31, 2014, 20132017, 2016 and 20122015

F-6

Consolidated Statements of Cash Flows for the Years Ended December 31, 2014, 20132017, 2016 and 20122015

F-7

Notes to Consolidated Financial Statements

F-9

 

F-1



Table of Contents

REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM

 

The Board of Directors and Stockholders

Primoris Services Corporation

Opinions on the Financial Statements and Internal Control over Financial Reporting

 

We have audited the accompanying consolidated balance sheets of Primoris Services Corporation (the “Company”) as of December 31, 20142017 and 2013, and2016, the related consolidated statements of income, stockholders’ equity, and cash flows for each of the three years in the period ended December 31, 2014.2017, and the related notes (collectively referred to as the “consolidated financial statements”). We also have audited the Company’s internal control over financial reporting as of December 31, 2014,2017, based on criteria established in Internal Control - Integrated Framework (1992)(2013) issued by the Committee of Sponsoring Organizations of the Treadway Commission. As describedCommission (COSO).

In our opinion, the consolidated financial statements referred to above present fairly, in Management’s Annual Report on Internal Control Over Financial Reporting, management excluded fromall material respects, the consolidated financial position of the Company as of December 31, 2017 and 2016, and the consolidated results of its assessment a portionoperations and its cash flows for each of the three years in the period ended December 31, 2017, in conformity with accounting principles generally accepted in the United States of America. Also in our opinion, the Company maintained, in all material respects, effective internal control over financial reporting at Ram-Fab, LLC (“Ram-Fab”), acquired in August 2014 and Surber Roustabout, LLC (“Surber”), acquired in July 2014, and whose financial statements constitute approximately 0.7% of total assets (excluding approximately $1.8 million of goodwill and intangible assets, which were integrated into the Company’s systems and control environment), approximately 0.3% of total revenues, and approximately 0.4% of pre-tax income (excluding approximately $0.3 million of amortization of intangible assets, which were integrated into the Company’s systems and control environment) of the consolidated financial statement amounts as of and for the year ended December 31, 2014.  Accordingly, our audit did not include the internal control over financial reporting at Ram-Fab and Surber.  2017, based on criteria established in Internal Control - Integrated Framework (2013) issued by COSO.

Basis for Opinions

The Company’s management is responsible for these consolidated financial statements, for maintaining effective internal control over financial reporting, and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Management’s Annual Report on Internal Control Over Financial Reporting appearing under Item 9A. Our responsibility is to express an opinion on thesethe Company’s consolidated financial statements and an opinion on the Company’s internal control over financial reporting based on our audits. We are a public accounting firm registered with the Public Company Accounting Oversight Board (United States) (“PCAOB”) and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

 

We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States).PCAOB. Those standards require that we plan and perform the audits to obtain reasonable assurance about whether the consolidated financial statements are free of material misstatement, whether due to error or fraud, and whether effective internal control over financial reporting was maintained in all material respects.

Our audits of the consolidated financial statements included performing procedures to assess the risks of material misstatement of the consolidated financial statements, whether due to error or fraud, and performing procedures to respond to those risks. Such procedures included examining, on a test basis, evidence supportingregarding the amounts and disclosures in the consolidated financial statements, assessingstatements. Our audits also included evaluating the accounting principles used and significant estimates made by management, andas well as evaluating the overall presentation of the consolidated financial statement presentation.statements. Our audit of internal control over financial reporting included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, and testing and evaluating the design and operating effectiveness of internal control based on the assessed risk. Our audits also included performing such other procedures as we considered necessary in the circumstances. We believe that our audits provide a reasonable basis for our opinions.

 

F-2As discussed in Management’s Annual Report on Internal Control Over Financial Reporting, on May 26, 2017 and June 16, 2017, the Company acquired Florida Gas Contractors and Coastal Field Services, respectively. For the purposes of assessing internal control over financial reporting, management excluded Florida Gas Contractors and Coastal Field Services, whose financial statements collectively constitute 2.0% of the Company’s consolidated total assets (excluding $43.5 million of goodwill and intangible assets, which were integrated into the Company’s control environment) and 1.4% of consolidated net revenues, as of and for the year ended December 31, 2017. Accordingly, our audit did not include the internal control over financial reporting of Florida Gas Contractors and Coastal Field Services.


F-2



Table of Contents

Definition and Limitations of Internal Control Over Financial Reporting

 

A company’s internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company’s internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company’s assets that could have a material effect on the consolidated financial statements.

 

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

 

In our opinion, the consolidated financial statements referred to above present fairly, in all material respects, the consolidated financial position of Primoris Services Corporation as of December 31, 2014 and 2013, and the consolidated results of its operations and its cash flows for each of the three years in the period ended December 31, 2014, in conformity with generally accepted accounting principles in the United States of America. Also in our opinion, Primoris Services Corporation maintained, in all material respects, effective internal control over financial reporting as of December 31, 2014, based on criteria established in Internal Control - Integrated Framework (1992) issued by the Committee of Sponsoring Organizations of the Treadway Commission.

/s/ Moss Adams LLP

Irvine,

Los Angeles, California

March 16, 2015February 26, 2018

 

F-3We have served as the Company’s auditor since 2006.


F-3



Table of Contents

PRIMORIS SERVICES CORPORATION

CONSOLIDATED BALANCE SHEETS

(In Thousands, Except Share Amounts)

 

 

 

 

 

 

 

 

 

December 31,

 

 

December 31, 

 

 

2014

 

2013

 

    

2017

    

2016

 

ASSETS

 

 

 

 

 

 

 

 

 

 

 

 

Current assets:

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

139,465

 

$

196,077

 

Short-term investments

 

30,992

 

18,686

 

Customer retention deposits and restricted cash

 

481

 

5,304

 

Cash and cash equivalents ($60,256 and $7,045 related to VIEs. See Note 12)

 

$

170,385

 

$

135,823

 

Customer retention deposits

 

 

1,000

 

 

481

 

Accounts receivable, net

 

337,382

 

304,955

 

 

 

358,175

 

 

388,000

 

Costs and estimated earnings in excess of billings

 

68,654

 

57,146

 

 

 

160,092

 

 

138,618

 

Inventory and uninstalled contract materials

 

58,116

 

51,829

 

 

 

40,922

 

 

49,201

 

Deferred tax assets

 

13,555

 

13,133

 

Prepaid expenses and other current assets

 

31,720

 

12,654

 

 

 

12,640

 

 

18,985

 

Total current assets

 

680,365

 

659,784

 

 

 

743,214

 

 

731,108

 

Property and equipment, net

 

271,431

 

226,512

 

 

 

311,777

 

 

277,346

 

Intangible assets, net

 

39,581

 

45,303

 

 

 

44,800

 

 

32,841

 

Goodwill

 

119,410

 

118,626

 

 

 

153,374

 

 

127,226

 

Other long-term assets

 

400

 

468

 

 

 

2,575

 

 

2,046

 

Total assets

 

$

1,111,187

 

$

1,050,693

 

 

$

1,255,740

 

$

1,170,567

 

LIABILITIES AND STOCKHOLDERS’ EQUITY

 

 

 

 

 

 

 

 

 

 

 

 

Current liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

Accounts payable

 

$

128,793

 

$

127,302

 

 

$

140,943

 

$

168,110

 

Billings in excess of costs and estimated earnings

 

158,595

 

173,365

 

 

 

159,034

 

 

112,606

 

Accrued expenses and other current liabilities

 

83,401

 

91,079

 

 

 

111,387

 

 

108,006

 

Dividends payable

 

2,062

 

1,805

 

 

 

3,087

 

 

2,839

 

Current portion of capital leases

 

1,650

 

3,288

 

 

 

132

 

 

188

 

Current portion of long-term debt

 

38,909

 

28,475

 

 

 

65,464

 

 

58,189

 

Current portion of contingent earnout liabilities

 

5,901

 

5,000

 

 

 

716

 

 

 —

 

Total current liabilities

 

419,311

 

430,314

 

 

 

480,763

 

 

449,938

 

Long-term capital leases, net of current portion

 

657

 

2,295

 

 

 

196

 

 

15

 

Long-term debt, net of current portion

 

204,029

 

191,051

 

 

 

193,351

 

 

203,150

 

Deferred tax liabilities

 

19,484

 

10,092

 

 

 

13,571

 

 

9,830

 

Long-term contingent earnout liabilities, net of current portion

 

1,021

 

4,233

 

Other long-term liabilities

 

12,899

 

14,260

 

 

 

5,676

 

 

9,064

 

Total liabilities

 

657,401

 

652,245

 

 

 

693,557

 

 

671,997

 

Commitments and contingencies

 

 

 

 

 

Commitments and contingencies (See Note 13)

 

 

 

 

 

 

 

Stockholders’ equity

 

 

 

 

 

 

 

 

 

 

 

 

Preferred stock—$.0001 par value, 1,000,000 shares authorized, none issued and outstanding at December 31, 2014 and 2013

 

 

 

Common stock—$.0001 par value; 90,000,000 shares authorized; 51,561,396 and 51,571,394 issued and outstanding at December 31, 2014 and 2013, respectively

 

5

 

5

 

Common stock—$.0001 par value; 90,000,000 shares authorized; 51,448,753 and 51,576,442 issued and outstanding at December 31, 2017 and December 31, 2016

 

 

 5

 

 

 5

 

Additional paid-in capital

 

160,186

 

159,196

 

 

 

160,502

 

 

162,128

 

Retained earnings

 

293,628

 

238,216

 

 

 

395,961

 

 

335,218

 

Non-controlling interest

 

(33

)

1,031

 

Noncontrolling interest

 

 

5,715

 

 

1,219

 

Total stockholders’ equity

 

453,786

 

398,448

 

 

 

562,183

 

 

498,570

 

Total liabilities and stockholders’ equity

 

$

1,111,187

 

$

1,050,693

 

 

$

1,255,740

 

$

1,170,567

 

 

See accompanying notes.

F-4


F-4



Table of Contents

PRIMORIS SERVICES CORPORATION

CONSOLIDATED STATEMENTS OF INCOME

(In Thousands, Except Per Share Amounts)

 

 

Year Ended December 31,

 

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

2012

 

 

 

 

 

 

 

 

 

 

 

Revenues

 

$

2,086,194

 

$

1,944,220

 

$

1,541,734

 

Cost of revenues

 

1,850,154

 

1,688,205

 

1,349,024

 

 

Year Ended December 31, 

 

 

2017

    

2016

    

2015

 

Revenue

 

$

2,379,995

 

$

1,996,948

 

$

1,929,415

 

Cost of revenue

 

 

2,101,561

 

 

1,795,641

 

 

1,709,542

 

Gross profit

 

236,040

 

256,015

 

192,710

 

 

 

278,434

 

 

201,307

 

 

219,873

 

Selling, general and administrative expenses

 

132,248

 

130,778

 

96,424

 

 

 

172,146

 

 

140,842

 

 

151,703

 

Impairment of goodwill

 

 

 —

 

 

2,716

 

 

401

 

Operating income

 

103,792

 

125,237

 

96,286

 

 

 

106,288

 

 

57,749

 

 

67,769

 

Other income (expense):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income (loss) from non-consolidated entities

 

5,264

 

(4,836

)

186

 

Investment income

 

 

5,817

 

 

 —

 

 

 —

 

Foreign exchange gain (loss)

 

374

 

153

 

(36

)

 

 

253

 

 

202

 

 

(763)

 

Other income (expense)

 

(757

)

4,804

 

(870

)

Other income (expense), net

 

 

484

 

 

(315)

 

 

1,723

 

Interest income

 

88

 

110

 

157

 

 

 

587

 

 

149

 

 

56

 

Interest expense

 

(6,433

)

(5,892

)

(3,619

)

 

 

(8,146)

 

 

(8,914)

 

 

(7,688)

 

Income before provision for income taxes

 

102,328

 

119,576

 

92,104

 

 

 

105,283

 

 

48,871

 

 

61,097

 

Provision for income taxes

 

(38,646

)

(44,896

)

(33,837

)

 

 

(28,433)

 

 

(21,146)

 

 

(23,946)

 

Net income

 

$

63,682

 

$

74,680

 

$

58,267

 

 

 

76,850

 

 

27,725

 

 

37,151

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Less net income attributable to noncontrolling interests

 

$

(526

)

(5,020

)

(1,511

)

 

 

(4,496)

 

 

(1,002)

 

 

(279)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income attributable to Primoris

 

$

63,156

 

$

69,660

 

$

56,756

 

 

$

72,354

 

$

26,723

 

$

36,872

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Dividends per common share

 

$

0.150

 

$

0.135

 

$

0.120

 

 

$

0.225

 

$

0.220

 

$

0.205

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

 

Basic

 

$

1.22

 

$

1.35

 

$

1.10

 

 

$

1.41

 

$

0.52

 

$

0.71

 

Diluted

 

$

1.22

 

$

1.35

 

$

1.10

 

 

$

1.40

 

$

0.51

 

$

0.71

 

 

 

 

 

 

 

 

Weighted average common shares outstanding:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

51,607

 

51,540

 

51,391

 

 

 

51,481

 

 

51,762

 

 

51,647

 

Diluted

 

51,747

 

51,610

 

51,406

 

 

 

51,741

 

 

51,989

 

 

51,798

 

 

See accompanying notes.

F-5


F-5



Table of Contents

PRIMORIS SERVICES CORPORATION

CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

(In Thousands, Except Share Amounts)

 

 

 

 

 

Additional

 

 

 

Non

 

Total

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Common Stock

 

Paid-in

 

Retained

 

Controlling

 

Stockholders’

 

 

 

 

 

 

 

Additional

 

 

 

 

Non

 

Total

 

 

Shares

 

Amount

 

Capital

 

Earnings

 

Interest

 

Equity

 

 

Common Stock

 

Paid-in

 

Retained

 

Controlling

 

Stockholders’

 

Balance, December 31, 2011

 

51,059,132

 

$

5

 

$

150,003

 

$

124,924

 

$

 

$

274,932

 

Net income

 

 

 

 

56,756

 

1,511

 

58,267

 

Issuance of shares to employees and directors

 

139,465

 

 

2,173

 

 

 

2,173

 

Issuance of shares to sellers of Sprint

 

62,052

 

 

980

 

 

 

980

 

Issuance of earnout shares to Rockford sellers

 

232,637

 

 

3,450

 

 

 

3,450

 

Dividends

 

 

 

 

(6,163

)

 

(6,163

)

Repurchase of stock

 

(89,600

)

 

(1,001

)

 

 

(1,001

)

Balance, December 31, 2012

 

51,403,686

 

$

5

 

$

155,605

 

$

175,517

 

$

1,511

 

$

332,638

 

    

Shares

    

Amount

    

Capital

    

Earnings

    

Interest

    

Equity

 

Balance, December 31, 2014

 

51,561,396

 

$

 5

 

$

160,186

 

$

293,628

 

$

(33)

 

$

453,786

 

Net income

 

 

 

 

69,660

 

5,020

 

74,680

 

 

 —

 

 

 —

 

 

 —

 

 

36,872

 

 

279

 

 

37,151

 

Issuance of shares to employees and directors

 

153,579

 

 

3,062

 

 

 

3,062

 

 

114,744

 

 

 —

 

 

2,096

 

 

 —

 

 

 —

 

 

2,096

 

Amortization of Restricted Stock Units

 

 

 

366

 

 

 

366

 

 

 —

 

 

 —

 

 

1,050

 

 

 —

 

 

 —

 

 

1,050

 

Issuance of shares as part of Q3C acquisition

 

29,273

 

 

463

 

 

 

463

 

Cancelled shares for redemption of note receivable

 

(15,144

)

 

(300

)

 

 

(300

)

Dividend equivalent Units accrued - Restricted Stock Units

 

 —

 

 

 —

 

 

12

 

 

(12)

 

 

 —

 

 

 —

 

Distribution of non-controlling entities

 

 

 

 

 

(5,500

)

(5,500

)

 

 —

 

 

 —

 

 

 —

 

 

 —

 

 

(29)

 

 

(29)

 

Dividends

 

 

 

 

(6,961

)

 

(6,961

)

 

 —

 

 

 —

 

 

 —

 

 

(10,589)

 

 

 —

 

 

(10,589)

 

Balance, December 31, 2013

 

51,571,394

 

$

5

 

$

159,196

 

$

238,216

 

$

1,031

 

$

398,448

 

Balance, December 31, 2015

 

51,676,140

 

$

 5

 

$

163,344

 

$

319,899

 

$

217

 

$

483,465

 

Net income

 

 

 

 

63,156

 

526

 

63,682

 

 

 —

 

 

 —

 

 

 —

 

 

26,723

 

 

1,002

 

 

27,725

 

Issuance of shares to employees and directors

 

90,002

 

 

2,897

 

 

 

2,897

 

 

108,102

 

 

 —

 

 

2,133

 

 

 —

 

 

 —

 

 

2,133

 

Amortization of Restricted Stock Units

 

 

 

934

 

 

 

934

 

 

 —

 

 

 —

 

 

1,627

 

 

 —

 

 

 —

 

 

1,627

 

Dividend equivalent Units accrued — Restricted Stock Units

 

 

 

3

 

(3

)

 

 

Dividend equivalent Units accrued - Restricted Stock Units

 

 —

 

 

 —

 

 

23

 

 

(23)

 

 

 —

 

 

 —

 

Repurchase of stock

 

(100,000

)

 

(2,844

)

 

 

(2,844

)

 

(207,800)

 

 

 —

 

 

(4,999)

 

 

 —

 

 

 —

 

 

(4,999)

 

Distribution of non-controlling entities

 

 

 

 

 

(1,590

)

(1,590

)

Dividends

 

 

 

 

 

(7,741

)

 

(7,741

)

 

 —

 

 

 —

 

 

 —

 

 

(11,381)

 

 

 —

 

 

(11,381)

 

Balance, December 31, 2014

 

51,561,396

 

$

5

 

$

160,186

 

$

293,628

 

$

(33

)

$

453,786

 

Balance, December 31, 2016

 

51,576,442

 

$

 5

 

$

162,128

 

$

335,218

 

$

1,219

 

$

498,570

 

Net income

 

 —

 

 

 —

 

 

 —

 

 

72,354

 

 

4,496

 

 

76,850

 

Issuance of shares to employees and directors

 

88,661

 

 

 —

 

 

2,210

 

 

 —

 

 

 —

 

 

2,210

 

Amortization of Restricted Stock Units

 

 —

 

 

 —

 

 

1,126

 

 

 —

 

 

 —

 

 

1,126

 

Dividend equivalent Units accrued - Restricted Stock Units

 

 —

 

 

 —

 

 

37

 

 

(37)

 

 

 —

 

 

 —

 

Repurchase of stock

 

(216,350)

 

 

 —

 

 

(4,999)

 

 

 —

 

 

 —

 

 

(4,999)

 

Dividends declared

 

 —

 

 

 —

 

 

 —

 

 

(11,574)

 

 

 —

 

 

(11,574)

 

Balance, December 31, 2017

 

51,448,753

 

$

 5

 

$

160,502

 

$

395,961

 

$

5,715

 

$

562,183

 

 

See accompanying notes.

F-6


F-6



Table of Contents

PRIMORIS SERVICES CORPORATION

CONSOLIDATED STATEMENTS OF CASH FLOWS

(In Thousands)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended

 

 

Year Ended December 31,

 

 

December 31, 

 

 

2014

 

2013

 

2012

 

    

2017

    

2016

    

2015

 

Cash flows from operating activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income

 

$

63,682

 

$

74,680

 

$

58,267

 

 

$

76,850

 

$

27,725

 

$

37,151

 

Adjustments to reconcile net income to net cash provided by (used in) operating activities:

 

 

 

 

 

 

 

Adjustments to reconcile net income to net cash provided by operating activities:

 

 

 

 

 

 

 

 

 

 

Depreciation

 

50,918

 

42,421

 

29,080

 

 

 

57,614

 

 

61,433

 

 

58,408

 

Amortization of intangible assets

 

7,504

 

7,467

 

6,543

 

 

 

8,689

 

 

6,597

 

 

6,793

 

Intangible asset impairment

 

 

808

 

 

Goodwill and intangible asset impairment

 

 

477

 

 

2,716

 

 

401

 

Stock-based compensation expense

 

934

 

367

 

 

 

 

1,126

 

 

1,627

 

 

1,050

 

Gain on short-term investments

 

 

(5,817)

 

 

 —

 

 

 —

 

Gain on sale of property and equipment

 

(1,895

)

(1,406

)

(2,752

)

 

 

(4,434)

 

 

(4,677)

 

 

(2,116)

 

(Income) from non-consolidated entities

 

(5,264

)

(97

)

(186

)

Impairment expense for non-consolidated entities

 

 

4,932

 

 

Other than temporary basis difference for non-consolidated entities

 

 

3,975

 

 

Distributions received from non-consolidated entities

 

 

2,821

 

1,358

 

Net deferred tax liabilities (assets)

 

8,970

 

(12,582

)

(879

)

 

 

3,741

 

 

10,905

 

 

(7,004)

 

Other non-cash items

 

 

203

 

 

174

 

 

165

 

Changes in assets and liabilities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Customer retention deposits and restricted cash

 

4,823

 

30,073

 

(3,887

)

Customer retention deposits

 

 

(519)

 

 

2,117

 

 

(2,117)

 

Accounts receivable

 

(29,659

)

(36,860

)

(52,092

)

 

 

40,546

 

 

(65,806)

 

 

19,528

 

Costs and estimated earnings in excess of billings

 

(11,508

)

(15,445

)

5,426

 

 

 

(20,894)

 

 

(22,163)

 

 

(47,499)

 

Other current assets

 

(25,767

)

(14,774

)

(1,341

)

 

 

16,976

 

 

17,491

 

 

4,784

 

Other long term assets

 

72

 

 

 

Other long-term assets

 

 

28

 

 

(1,792)

 

 

189

 

Accounts payable

 

921

 

(25,131

)

34,338

 

 

 

(30,547)

 

 

42,934

 

 

(5,086)

 

Billings in excess of costs and estimated earnings

 

(14,770

)

14,473

 

20,639

 

 

 

45,981

 

 

(27,519)

 

 

(19,619)

 

Contingent earnout liabilities

 

(4,145

)

(14,900

)

(1,435

)

 

 

(484)

 

 

 —

 

 

(6,722)

 

Accrued expenses and other current liabilities

 

(7,354

)

15,824

 

3,176

 

 

 

(972)

 

 

14,492

 

 

11,729

 

Other long-term liabilities

 

(1,361

)

1,107

 

2,138

 

 

 

378

 

 

(3,677)

 

 

(1,658)

 

Net cash provided by operating activities

 

36,101

 

77,753

 

98,393

 

 

 

188,942

 

 

62,577

 

 

48,377

 

Cash flows from investing activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Purchase of property and equipment

 

(87,954

)

(87,050

)

(37,395

)

 

 

(79,782)

 

 

(58,027)

 

 

(67,097)

 

Proceeds from sale of property and equipment

 

5,814

 

7,865

 

9,035

 

 

 

8,736

 

 

9,603

 

 

9,889

 

Purchase of short-term investments

 

(33,770

)

(23,110

)

(6,869

)

 

 

(13,588)

 

 

 —

 

 

 —

 

Sale of short-term investments

 

21,464

 

7,448

 

26,428

 

 

 

19,405

 

 

 —

 

 

30,992

 

Cash received from the sale of equity method investments

 

6,439

 

 

 

Cash paid for acquisitions

 

(14,596

)

(2,273

)

(86,207

)

 

 

(66,205)

 

 

(10,997)

 

 

(22,302)

 

Net cash used in investing activities

 

(102,603

)

(97,120

)

(95,008

)

 

 

(131,434)

 

 

(59,421)

 

 

(48,518)

 

Cash flows from financing activities:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Proceeds from issuance of long-term debt

 

58,519

 

107,609

 

94,471

 

 

 

55,000

 

 

45,000

 

 

75,278

 

Repayment of capital leases

 

(3,276

)

(4,618

)

(9,021

)

 

 

(322)

 

 

(793)

 

 

(1,336)

 

Repayment of long-term debt

 

(35,107

)

(35,896

)

(26,633

)

 

 

(61,816)

 

 

(57,719)

 

 

(43,927)

 

Repayment of subordinated debt

 

 

 

(17,501

)

Proceeds from issuance of common stock purchased by management under long-term incentive plan

 

1,671

 

1,455

 

1,240

 

Payment of debt issuance costs for amended and restated credit agreement

 

 

(631)

 

 

 —

 

 

 —

 

Proceeds from issuance of common stock purchased under a long-term incentive plan

 

 

1,148

 

 

1,440

 

 

1,621

 

Cash distribution to non-controlling interest holder

 

(1,590

)

(5,500

)

 

 

 

 —

 

 

 —

 

 

(29)

 

Repurchase of common stock

 

(2,844

)

 

(1,001

)

 

 

(4,999)

 

 

(4,999)

 

 

 —

 

Dividends paid

 

(7,483

)

(5,157

)

(7,695

)

 

 

(11,326)

 

 

(11,384)

 

 

(9,809)

 

Net cash provided by (used in) financing activities

 

9,890

 

57,893

 

33,860

 

 

 

 

 

 

 

 

Net cash (used in) provided by financing activities

 

 

(22,946)

 

 

(28,455)

 

 

21,798

 

Net change in cash and cash equivalents

 

(56,612

)

38,526

 

37,245

 

 

 

34,562

 

 

(25,299)

 

 

21,657

 

Cash and cash equivalents at beginning of year

 

196,077

 

157,551

 

120,306

 

Cash and cash equivalents at end of the year

 

$

139,465

 

$

196,077

 

$

157,551

 

Cash and cash equivalents at beginning of the period

 

 

135,823

 

 

161,122

 

 

139,465

 

Cash and cash equivalents at end of the period

 

$

170,385

 

$

135,823

 

$

161,122

 

 

See accompanying notes.

F-7


F-7



Table of Contents

PRIMORIS SERVICES CORPORATION

CONSOLIDATED STATEMENTS OF CASH FLOWS (Continued)

(In Thousands)

 

SUPPLEMENTAL DISCLOSURES OF CASH FLOW INFORMATION

 

 

Year Ended December 31,

 

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

2012

 

 

Year Ended December 31, 

 

Cash paid during the year for:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

2017

    

2016

    

2015

 

Cash paid:

 

 

 

 

 

 

 

 

 

 

Interest

 

$

6,432

 

$

5,532

 

$

3,004

 

 

$

7,965

 

$

8,819

 

$

7,688

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Income taxes, net of refunds received

 

$

57,613

 

$

48,126

 

$

31,404

 

 

$

25,984

 

$

8,624

 

$

18,696

 

 

SUPPLEMENTAL DISCLOSURE OF NONCASH INVESTING AND FINANCING ACTIVITIES

 

 

Year Ended December 31,

 

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

2012

 

 

Year Ended December 31, 

 

 

 

 

 

 

 

 

    

2017

    

2016

    

2015

 

Obligations incurred for the acquisition of property and equipment

 

$

 

$

2,637

 

$

2,932

 

 

 

 

 

 

 

 

 

 

 

Obligations incurred for the acquisition of property

 

$

4,163

 

$

 —

 

$

25

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Dividends declared and not yet paid

 

$

2,062

 

$

1,805

 

$

 

 

$

3,087

 

$

2,839

 

$

2,842

 

 

See accompanying notes.

F-8


F-8



Table of Contents

 

PRIMORIS SERVICES CORPORATION

NOTES TO CONSOLIDATED FINANCIAL STATEMENTS

Dollars in thousands, except share and per share amounts

 

Note 1—Nature of Business

 

Organization and operationsPrimoris Services Corporation is a holding company of various construction and product engineering subsidiaries.  The Company’sOur underground and directional drilling operations install, replace and repair natural gas, petroleum, telecommunications and water pipeline systems, including large diameter pipeline systems. The Company’sOur industrial, civil and engineering operations build and provide maintenance services to industrial facilities including power plants, petrochemical facilities, and other processing plants; construct multi-level parking structures; and engage in the construction of highways, bridges and other environmental construction activities. The Company isWe are incorporated in the State of Delaware, and itsour corporate headquarters are located at 2100 McKinney Avenue, Suite 1500, Dallas, Texas 75201.

 

Reportable Operating SegmentsFor a number of years and throughThrough the end of the second quarter 2014, the Companyyear 2016, we segregated itsour business into three operatingreportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment and the Engineering segment. In the thirdfirst quarter 2014, the Company reorganized its business2017, we changed our reportable segments to match the changes in the Company’sconnection with a realignment of our internal organization and management structure. The segment changes reflect the focus of our chief operating decision maker (“CODM”) on the range of services we provide to our end user markets. Our CODM regularly reviews our operating and financial performance based on these segments.

The current operatingreportable segments include:include the West Construction Services segmentPower, Industrial and Engineering (“West segment”Power”), which is unchanged from the previous segment, the East Construction ServicesPipeline and Underground (“Pipeline”) segment, (“East segment”), which is realigned from the previous East Construction ServicesUtilities and Distribution (“Utilities”) segment and the Energy segment, which included certain subsidiaries that were included as part of theCivil segment.  Segment information for prior year East Construction Services segment (“Energy segment”).  All prior period amounts related to the segment change haveperiods has been retrospectively reclassified throughout these quarterly financial statementsrestated to conform to the new segment presentation.  See Note 15 — 14 – “Reportable Operating Segments.Segments” for a brief description of the reportable segments and their operations.

 

The classification of revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our segments may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses were made.

F-9


Table of Contents

The following table lists the Company’sour primary operating subsidiariesbusiness units and their current and prior reportable operating segment:

 

Subsidiary

Operating Segment

Prior Operating Segment

ARB, Inc., including Stellaris, LLC (“ARB”)

 

West

West

ARB Structures, Inc.

West

West

Q3 Contracting, Inc. (“Q3C”)

West

West

Rockford Corporation (“Rockford”)

West

West

 

 

 

 

 

Vadnais Trenchless Services,Business Unit

Reportable Segment

Prior Reportable Segment

ARB Industrial (a division of ARB, Inc. (“Vadnais”); acquired in 2014

Power

 

West

 

ARB Structures

Power

West

Silva GroupPrimoris Power (formerly PES Saxon division)

Power

Energy

Primoris Renewable Energy (a division of Primoris AV)

Power

Energy

Primoris Industrial Constructors (formerly PES Industrial Division)

Power

Energy

Primoris Fabrication (a division of PES)

Power

Energy

Primoris Mechanical Contractors (a combination of a division of PES and Cardinal Contractors)

Power

Energy

OnQuest

Power

Energy

OnQuest Canada

Power

Energy

Primoris Design and Construction (“Silva”PD&C”); created 2017

Power

NA

Rockford Corporation (“Rockford”)

Pipeline

West

Vadnais Trenchless Services (“Vadnais Trenchless”)

Pipeline

West

Primoris Field Services (a division of PES Primoris Pipeline)

Pipeline

Energy

Primoris Pipeline (a division of PES Primoris Pipeline)

Pipeline

Energy

Primoris Coastal Field Services; created 2017

Pipeline

NA

ARB Underground (a division of ARB, Inc.)

Utilities

West

Q3 Contracting (“Q3C”)

Utilities

West

Primoris AV

Utilities

Energy

Primoris Distribution Services ("PDS"); created 2017

Utilities

NA

Primoris Heavy Civil (formerly JCG Heavy Civil Division)

Civil

 

East

 

East

Cardinal Contractors, Inc.Primoris I&M (formerly JCG Infrastructure & Maintenance Division)

Civil

 

East

 

East

BW Primoris LLC (“BWP”)Build Own Operate

Civil

 

East

 

East

James Construction Group, LLC (“JCG”):

JCG Heavy Civil Division

East

East

JCG Infrastructure and Maintenance Division

East

East

JCG Industrial Division

Energy

East

Primoris Energy Services Corporation (“PES”)

Energy

East

OnQuest, Inc.

Energy

Engineering

OnQuest, Canada, ULC (Born Heaters Canada, ULC prior to 2013)

Energy

Engineering

 

In 2012, PES purchased Sprint Pipeline Services, L.P. which  has operated using the Sprint name as a DBA from the acquisition through February 2015.  In accordance with the purchase agreement, the name of the former Sprint operating entity was changed to “Primoris Pipeline Services” (“PPS”) in March 2015.  In this Form 10-K, references to PPS are references to the Sprint operating entity.  PES acquired two subsidiaries, The Saxon Group (“Saxon”) in 2012 and Force Specialty Services, Inc. (“FSSI”) in 2013. Effective January 1, 2014, Saxon and FSSI  were merged into PES along with  the Industrial division of JCG.   Throughout this Form 10-K, references to PPS, FSSI, Saxon and James Industrial are to the divisions of PES for 2014, while the references for the years prior to 2014 are to the entities or divisions.

The Company ownsWe owned 50% of the Blythe Power Constructors joint venture (“Blythe”) created for the installation of a parabolic trough solar field and steam generation system in California, and its operations arehave been included as part of the West Construction ServicesPower segment.  The CompanyWe determined that in accordance with FASB Topic 810, the Company waswe were the primary beneficiary of a variable interest entity (“VIE”) and hashave consolidated the results of Blythe in itsour financial statements. The project has been completed, and the project warranty will expireexpired in May 2015, at which timeand dissolution of the Company anticipates terminating Blythe.  joint venture was completed in the third quarter of 2015. 

We own a 50% interest in two separate joint ventures, both formed in 2015.  The Carlsbad Power Constructors joint venture (“Carlsbad”) is engineering and constructing a gas-fired power generation facility, and the “ARB Inc. & B&M Engineering Co.” joint venture (“Wilmington”) is also engineering and constructing a gas-fired power generation facility.  Both projects are located in Southern California.  The joint venture operations are included as part of the Power segment.  As a result of determining that we are the primary beneficiary of the two VIEs, the results of the Carlsbad and Wilmington joint ventures are consolidated in our financial statements.  Both projects are expected to be completed in 2018.

Financial information for the joint ventures is presented in “Note 13—Note 12— Noncontrolling Interests.”

Interests”F-9



Table of Contents.

 

In January 2014, the Company created a wholly owned subsidiary, BW Primoris, LLC, a Texas limited liability company (“BWP”). BWP’s goal is to develop water projects, primarily in Texas, that will need the Company’s construction services.  On January 22, 2014, BWP entered into an agreement to purchase the assets and business of Blaus Wasser, LLC, a Wyoming limited liability company, for approximately $5 million.  During the first quarter of 2014, BWP entered into an intercompany construction contract with Cardinal Contractors, Inc. to build a small water treatment facility which will be owned by BWP.  When the treatment facility is completed, the facility will generate revenues through a take-or-pay contract with a west Texas municipal entity.  For 2014, all  intercompany revenue and profit of the project was eliminated, and at December 31, 2014, a total of $12.9 million has been capitalized as property, plant and equipment.

In May 2014, the Company created a wholly owned subsidiary, Vadnais Trenchless Services, Inc., a California company (“Vadnais”), which on June 5, 2014,  purchased the assets,  of Vadnais Corporation for $6.4 million.  a Vadnais Corporation was a general contractor specializing in micro-tunneling. The assets purchased were primarily equipment, building and land.   The purchase included  a contingent earnout on meeting certain operating targets.

During the third quarter 2014, the Company made three small purchases totaling $8.2 million acquiringFebruary 28, 2015, we acquired the net assets of Surber Roustabout, LLC (“Surber”), Ram-Fab, LLC (“Ram-Fab”) and Williams Testing, LLC (“Williams”). Surber and Ram-Fab operate as divisions of PES, and Williams is a division of Cardinal Contractors,Aevenia, Inc. Surber provides general oil and gas related construction activities in Texas; Ram-Fab is a fabricator of custom piping systems located in Arkansas; and Williams provides construction services related to sewer pipeline maintenance, rehabilitation and integrity testingfor $22.3 million. Aevenia operations are included in the Utilities segment.

On January 29, 2016, we acquired the net assets of Mueller Concrete Construction Company (“Mueller”) for $4.1 million and on November 18, 2016, we acquired the net assets of Northern Energy & Power (“Northern”) for $6.9 million. On June 24, 2016, we purchased property, plant and equipment from Pipe Jacking Unlimited, Inc. (“Pipe Jacking”), consisting of specialty directional drilling and tunneling equipment for $13.4 million. We determined this purchase did not meet the definition of a business as defined under ASC 805. Mueller operations are included in the Utilities segment, Northern operations are included in the Power segment, and Pipe Jacking operations are included in the Pipeline segment.

F-10


Table of Contents

On May 26, 2017, we acquired the net assets of Florida market.  The SurberGas Contractors (“FGC”) for $37.7 million; on May 30, 2017, we acquired certain engineering assets for approximately $2.3 million; and Ram-Fab purchases providedon June 16, 2017, we acquired the net assets of Coastal Field Services (“Coastal”) for a contingent earnout amounts as discussed$27.5 million. FGC operations are included in “Notethe Utilities segment, the engineering assets are included in the Power segment, and Coastal operations are included in the Pipeline segment.  See Note 4—Business Combinations”.

 

Unless specifically noted otherwise, as used throughout these consolidated financial statements, “Primoris”, “the Company”, “we”, “our”, “us” or “its” refers to the business, operations and financial results of the Company and its wholly-owned subsidiaries.

 

SeasonalityPrimoris’ results of operations are subject to quarterly variations. SomeMost of the variation is the result of winter weather, particularly rain, ice and snow, which can impact the Company’sour ability to perform construction services. The winterWhile the majority of our work is in the southern half of the United States, these seasonal impacts affect revenues and profitability since gas and other utilities defer routine replacement and repair during their period of peak demand.  Any quarter can be affected either negatively or positively by atypical weather also limits our ability to  perform pipeline integrity testing and routine maintenance for our utility customers’ underground systems sincepatterns in any part of the systems are used for heating.  In most years, utility owners obtain bids and award contracts for major maintenance, integrity and replacement work after the heating season, and the work must be completed by the following winter.country.  In addition, demand for new projects cantends to be lower during the early part of the year due to clients’ internal budget cycles.

Similarly, weather As a result, we usually experiences higher revenues and budget cycles affect our major pipeline projects and our heavy civil work with more construction activity completedearnings in the third and fourth quarters of most yearsthe year as compared to the first two quarters.  Whilequarters, with the majority of our industrial construction is performed in relatively warm weather climates in Californiafourth quarter revenues and earnings usually less than the Gulf Coast, adverse winter weather or significant weather events, such as hurricanes, can have a significant impact on quarterly financial results.third quarter revenues and earnings but higher than the second quarter revenues and earnings.

 

VariabilityIn addition to seasonality, the Company iswe are dependent on large construction projects, which tend not to be seasonal, but can fluctuate from year to year based on many factors including general economic conditions general market conditions forand client requirements. Our business may be affected by declines or delays in new projects or by client project schedules.  Because of the project and the Company’s ability to win contract awards.  The award and notice to proceed and eventual completioncyclical nature of large projects can have a significant impact onour business, the financial results for any period and may cause fluctuationsfluctuate from prior periods, can causeand our financial condition and operating results tomay vary from quarter-to-quarter. Accordingly, our operating results for any particular periodResults from one quarter may not be indicative of theits financial condition or operating results that can be expected for any other period.quarter or for an entire year.

 

Note 2—Summary of Significant Accounting Policies

 

Basis of presentationThe accompanying consolidated financial statements were prepared in accordance with accounting principles generally accepted in the United States (“GAAP”) and the financial statement rules and regulations of the Securities and Exchange Commission (“SEC”).  References for Financial Accounting Standards Board (“FASB”) standards are made to the FASB Accounting Standards Codification (“ASC”).

 

Certain reclassifications have been made to the prior year Consolidated Statements of Cash Flows and Notes to the Consolidated Financial Statements to conform to the current year presentation and had no impact on net income or earnings per share.  These reclassifications include the new segment presentation.

Principles of consolidationThe accompanying Consolidated Financial Statements include the accounts of the Company, itsPrimoris, our wholly-owned subsidiaries and the noncontrolling interests of the Blythe, Carlsbad and Wilmington joint venture, a variable interest entityventures, which are VIEs for which the Company iswe are the primary beneficiary as determined under the provisions of ASC Topic 810-10-45.810.  All intercompany balances and transactions have been eliminated in consolidation.

 

F-10Reclassification



Table of ContentsCertain previously reported amounts have been reclassified to conform to the current year presentation.

 

Use of estimatesThe preparation of the Company’sour Consolidated Financial Statements in conformity with GAAP requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and the disclosure of contingent assets and liabilities as of the date of the consolidated financial statements and the reported amounts of revenues and expenses during the reporting periods. As a construction contractor, the Company uses significantwe use estimates for costs to complete construction projects and the contract value of certain construction projects.  These estimates have a direct effect on gross profit as reported in these consolidated financial statements. Actual results could materially differ from the Company’sour estimates.

 

Operating cycle In the accompanying consolidated balance sheets,Consolidated Balance Sheets, assets and liabilities relating to long-term construction contracts (e.g. costs and estimated earnings in excess of billings, billings in excess of costs and estimated

F-11


Table of Contents

earnings) are considered current assets and current liabilities, since they are expected to be realized or liquidated in the normal course of contract completion, although completion may require more than one calendar year.

 

The Company hasConsequently, we have significant working capital invested in assets that may have a liquidation period extending beyond one year. The Company hasWe have claims receivable and retention due from various customers and others that are currently in dispute, the realization of which is subject to binding arbitration, final negotiation or litigation.litigation, all of which may extend beyond one calendar year.

 

Cash and cash equivalentsThe Company considersWe consider all highly liquid investments with an original maturity of three months or less when purchased as cash equivalents.

 

Short-term investmentsThe Company classifiesWe classify as short-term investments all securities or other assets acquired which have ready marketability and can be liquidated, if necessary, within the current operating cycle and which have readily determinable fair values. Short-term investments are classified as available for saletrading and are recorded at fair value using the specific identificationfirst-in, first-out method. Currently, the majority of the Company’sOur short-term investments are ingenerally short-term dollar-denominated bank deposits, and U.S. Treasury Bills in order to provide government backing of the investments.and marketable equity securities.

 

Customer retention depositsCustomer In some state jurisdictions, customer retention deposits consist of contract retention payments made by customers into bank escrow cash accounts with a bank as required in some state jurisdictions.required. Investments for these amounts are limited to highly graded U.S. and municipal government debt obligations, investment grade commercial paper and CDs, which limits credit risk on these balances. Escrow cash accounts are released to the Companyus by customers as projects are completed in accordance with contract terms.

 

Inventory and uninstalled contract materialsInventory consists of expendable construction materials and small tools that will be used in construction projects and is valued at the lower of cost, using first-in, first-out method, or market.net realizable value.  Uninstalled contract materials are certain job specific materials not yet installed, primarily for highway construction projects, which are valued using the specific identification method relating the cost incurred to a specific project.  In most cases, the Company isWe are able to invoice a state agency for the materials, but in most cases title hasdoes not yet passedpass to the state agency.agency until the materials are installed.

 

Business combinations—Business combinations are accounted for using the acquisition method of accounting.  We use the fair value of the assets acquired and liabilities assumed to account for the purchase price of businesses.  The determination of fair value requires estimates and judgments of future cash flow expectations to assign fair values to the identifiable tangible and intangible assets.  GAAP provides a “measurement period” of up to one year in which to finalize all fair value estimates associated with the acquisition of a business. Most estimates are preliminary until the end of the measurement period.  During the measurement period, any material, newly discovered information that existed at the acquisition date would be reflected as an adjustment to the initial valuations and estimates.  After the measurement date, any adjustments would be recorded as a current period income or expense.  Changes in deferred tax asset valuation allowances and acquired tax uncertainties after the measurement period are also recognized in net income.  Expenses incurred in connection with a business combination are expensed as incurred.

 

Contingent Earnout LiabilitiesAs part of certain acquisitions, we agreed to pay cash to certain sellers upon meeting specific operating performance targets for specified periods subsequent to the acquisition date.  Each quarter, we evaluate the fair value of the estimated contingency and record a non-operating charge for the change in the fair value.  Upon meeting the target, we reflect the full liability on the balance sheet and record a charge to “Selling, general and administration expense” for the change in the fair value of the liability from the prior period.   See Note 3 — “Fair Value Measurements” for further discussion.

Goodwill and other intangible assetsThe Company accountsWe account for goodwill in accordance with ASC Topic 350 “Intangibles — Goodwill and Other”.  Under ASC Topic 350, goodwill is not amortized but is subject to an annual impairment test, which we perform as of the first day of the fourth quarter of each year, with more frequent testing if indicators of potential impairment exist.  The impairment review is performed at the reporting unit level for those units with recorded goodwill. We can assess qualitative factors to determine if a quantitative impairment test of intangible assets is necessary.  Typically, however, we use the two-step impairment test outlined in ASC 350.  First, we compare the fair value of a reporting unit with its carrying amount. Fair value for the goodwill impairment test is determined utilizing a discounted cash flow analysis based on our financial plan discounted using our weighted average cost of capital and market indicators of terminal year

F-12


Table of Contents

cash flows. Other valuation methods may be used to corroborate the discounted cash flow method. If the carrying amount of a reporting unit is in excess of its fair value, goodwill is considered potentially impaired and further tests are performed to measure the amount of impairment loss. In December 2013,the second step of the goodwill impairment test, we compare the implied fair value of reporting unit goodwill with the carrying amount of the reporting unit’s goodwill. If the carrying amount of the reporting unit’s goodwill exceeds the implied fair value of that goodwill, an impairment loss is recognized in an amount equal to the carrying amount of goodwill over its implied fair value. The implied fair value of goodwill is determined in the same manner that the amount of goodwill recognized in a business combination was determined. We allocate the fair value of a reporting unit to all of the assets and liabilities of that unit, including intangible assets, as if the reporting unit had been acquired in a business combination. Any excess of the fair value of a reporting unit over the amounts assigned to its assets and liabilities represents the implied fair value of goodwill

During the third quarter of 2016, we made a decision to divest our Texas heavy civil business unit, a division of Primoris Heavy Civil within the Civil segment.  We engaged a financial advisor to assist in the marketing and sale of the business unit, and planned to continue operating the business unit until completion of a sale.  In April 2017, the Board of Directors determined that based on the information available, we would attain the best long-term value by withdrawing from the sales process and continuing to operate the business unit. In accordance with ASC 350, the planned divestiture triggered an analysis of the goodwill at Primoris Heavy Civil, resulting in a pretax, non-cash goodwill impairment charge of approximately $2.7 million in the third quarter of 2016.

In the fourth quarter of 2015, an impairment expense of $808$0.4 million was recorded relating to the FSSI intangible asset for customer relations reflecting the impairmentgoodwill attributed to Cardinal Contractors, Inc., which is part of the asset.  See Note 4 — “Business Combinationsfor further information.  Otherwise, there werePower Segment. 

There was no impairmentsimpairment of goodwill for the yearsyear ended December 31, 2014, 2013 and 2012.2017.

 

F-11



Table of Contents

Goodwill was recorded at our reporting units as follows:

Reporting Unit

 

Segment

 

December 31,
2014

 

December 31,
2013

 

Rockford

 

West

 

$

32,079

 

$

32,079

 

Q3C

 

West

 

13,160

 

13,160

 

JCG (includes JCG Heavy Civil and Infrastructure and Maintenance divisions)

 

East

 

42,866

 

42,866

 

Cardinal Contractors, Inc.

 

East

 

401

 

401

 

PES (includes PPS, JCG Industrial, FSSI, Saxon and Surber divisions)

 

Energy

 

28,463

 

27,679

 

OnQuest Canada, ULC

 

Energy

 

2,441

 

2,441

 

Total Goodwill

 

 

 

$

119,410

 

$

118,626

 

Income taxCurrent income tax expense is the amount of income taxes expected to be paid for the financial results of the current year. A deferred income tax liability or asset is established for the expected future tax consequences resulting from the differences in financial reporting and tax basisbases of assets and liabilities between GAAP and the tax codes. A valuation allowance is provided if it is more likely than not that some or all of the deferred tax assets will not be realized. Further, the Company providesWe provide for uncertain tax positions when such tax positions do not meet the recognition thresholds or measurement standards as set forth in ASC Topic 740. The difference between a tax position taken or expected to be taken on the Company’sour income tax returns and the benefit recognized on our financial statements is referred to as an unrecognized tax benefit. Amounts for uncertain tax positions are adjusted in periods when new information becomes available or when positions are effectively settled. The Company recognizesWe recognize accrued interest and penalties related to uncertain tax positions, if any, as a component of income tax expense.

 

Staff Accounting Bulletin (“SAB”) 118 provides guidance on accounting for uncertainties of the effects of the Tax Cuts and Jobs Act (the “Tax Act”).  Specifically, SAB 118 allows companies to record provisional estimates of the impact of the Tax Act during a one year “measurement period” similar to that used when accounting for business combinations. 

As a result of the Tax Act, we remeasured deferred tax assets and liabilities using the newly enacted tax rates and recorded a one-time net tax benefit of $9.4 million in the period ended December 31, 2017. This tax benefit is a provisional estimate that could be revised once we finalize our deductions for tax depreciation and executive compensation accruals. We may also revise our estimate based on any additional guidance issued by the U.S. Treasury Department, the U.S. Internal Revenue Service, and other standard-setting bodies.

Comprehensive incomeThe Company accountsWe account for comprehensive income in accordance with ASC Topic 220 “Comprehensive Income”, which specifies the computation, presentation and disclosure requirements for comprehensive income (loss). During the reported periods, the Companywe had no materialother comprehensive income.

 

Foreign operationsAt December 31, 2014, the Company2017, we had operations in Canada with assets aggregating approximately $11,505,$12.7 million, compared to $11,371$11.8 million at December 31, 2013.2016.  The Canadian operations had revenues of $19,840$8.3 million and incomea loss before tax of $3,183 for the year ending December 31, 2014; revenues of $15,993 and income before tax of $2,742$0.3 million for the year ended December 31, 2013, and2017; revenues of $10,915 $11.2 million

F-13


Table of Contents

and income before tax of $304$0.8 million for the year endingended December 31, 2012.2016, and revenues of $17.8 million and income before tax of $0.3 million for the year ended December 31, 2015.

 

Functional currencies and foreign currency translationThe Company uses We use the United States dollar as itsour functional currency in Canada for the Canadian operations of OnQuest Canada, as substantially all monetary transactions are made in U.S. dollars, and other significant economic facts and circumstances currently support that position. AsSince these factors may change, the Companywe periodically assesses itsassess our position with respect to the functional currency of itsour foreign subsidiary. Non-monetary balance sheet items and related revenue, gain, expense and loss accounts are remeasuredvalued using historical rates.  All other items are remeasured using the current exchange rate in effect at the balance sheet date. Foreign exchange gains of $374$0.2 million and $0.2 million in 2014, gains of $153 in 20132017 and 2016, respectively, and losses of $36$0.8 million in 20122015 are included in the other income or expense” Foreign exchange gain (loss)” line of the Consolidated Statements of Income.

 

Partnerships and joint ventures  — As is normal in the construction industry, the Company iswe are periodically a member of a partnership or a joint venture.  These partnerships or joint ventures are used primarily for the execution of single contracts or projects.  The Company’sOur ownership can vary from a small noncontrolling ownership to a significant ownership interest.  The Company evaluatesWe evaluate each partnership or joint venture to determine whether the entity is considered a variable interest entity (“VIE”)VIE as defined in FASB ASC Topic 810, and if a VIE, whether the Company iswe are the primary beneficiary of the VIE, which would require the Companyus to consolidate the VIE with the Company’sour financial statements.  When consolidation occurs, the Company accountswe account for the interests of the other parties as a noncontrolling interest and discloses the net income attributable to noncontrolling interests. See Note 12 — “Noncontrolling Interests" for further information.

 

Equity method of accounting The Company accountsWe account for itsour interest in an investment using the equity method of accounting per ASC Topic 323 if the Company iswe are not the primary beneficiary of a VIE or doesdo not have a controlling interest. The investment is recorded at cost and the carrying amount is adjusted periodically to recognize the Company’sour proportionate share of income or loss, additional contributions made and dividends and capital distributions received.  The Company recordsWe record the effect of any impairment or an other than temporary decrease in the value of its investment.

 

In the event a partially owned equity affiliate were to incur a loss and the Company’sour cumulative proportionate share of the loss exceeded the carrying amount of the equity method investment, application of the equity method would be suspended and the Company’sour proportionate share of further losses would not be recognized unless the Companywe committed to provide further financial support to the affiliate. The CompanyWe would resume application of the equity method once the affiliate became profitable and the Company’sour proportionate share of the affiliate’s earnings equals the Company’sour cumulative proportionate share of losses that were not recognized during the period the application of the equity method was suspended.

 

F-12



Table of Contents

See Note 8 — “Equity Method Investments” regarding impairments of investments in partially owned affiliates.

Cash concentrationThe Company places itsWe place our cash in short term U.S. Treasury bonds and certificates of deposit (“CDs”). At December 31, 20142017 and 2013, the Company2016, we had cash balances of $139.5$170.4 million and $196.1$135.8 million, respectively.  At December 31, 2014,2017, the $139.5$170.4 million of cash balance consisted of $121.5$155.4 million in U.S. Treasury bill funds, and the remaining $18.0 million was held with various financial institutions, some of which may not be backed by the federal government.government, and the remaining $15.0 million are held in high credit quality financial institutions in order to mitigate the risk of holding funds not backed by the federal government or in excess of federally backed limits.  At December 31, 2013,2016, the $196.1$135.8 million cash balance consisted of $182.5$100.5 million held in U.S. Treasury bill funds and $13.6$35.3 million with varioushigh credit quality financial institutions thatinstitutions. Cash balances associated with VIEs, which totaled $60.3 million and $7.0 million as of December 31, 2017 and December 31, 2016, respectively, are backed by federal government guaranties.not available for general corporate purposes.

 

Collective bargaining agreementsApproximately 34%52% of the Company’sour hourly employees, primarily consisting of field laborers, were covered by collective bargaining agreements in 2014.2017. Upon renegotiation of such agreements, the Companywe could be exposed to increases in hourly costs and work stoppages. Of the 8297 collective bargaining agreements to which the Company iswe are a party to, 4575 will require renegotiation during 2015.  The Company has2018.  We have not had a significant work stoppage in more than 20 years.

 

Multiemployer plansVarious subsidiaries in the West segment are signatories to collective bargaining agreements.  These agreements require that the Companywe participate in and contribute to a number of multiemployer benefit plans for itsour union employees at rates determined by the agreements. The trustees for each multiemployer plan determine the eligibility and allocations of contributions and benefit amounts, determine the types of benefits and administer the plan. Federal law

F-14


Table of Contents

requires that if the Companywe were to withdraw from an agreement, itwe would incur a withdrawal obligation. The potential withdrawal obligation may be significant. AnyIn accordance with GAAP, any withdrawal liability would be recorded when it is probable that a liability exists and can be reasonably estimated, in accordance with GAAP.estimated. In November 2011, the Companywe withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan, as discussed in Note 1413“Commitments and Contingencies.”  The Company hasContingencies”.  We have no plans to withdraw from any other agreements.

 

Worker’s compensation insuranceThe Company self-insuresWe self-insure worker’s compensation claims to a certain level. The CompanyWe maintained a self-insurance reserve totaling $22,270$18.5 million and $20,551$18.8 million at December 31, 20142017 and 2013,2016, respectively. The amount is included in “Accrued expenses and other current liabilities” on the accompanying Consolidated Balance Sheets. Claims administration expenses are charged to current operations as incurred.  Future payments may materially differ from these reserves.the reserve amounts.

 

Fair value of financial instrumentsThe consolidated financial statements include financial instruments for which the fair value may differ from amounts reflected on a historical basis. FinancialOur financial instruments of the Company consist of cash, accounts receivable, short-term investments, accounts payable and certain accrued liabilities.  These financial instruments generally approximate fair market value based on their short-term nature.  The carrying value of the Company’sour long-term debt approximates fair value based on comparison with current prevailing market rates for loans of similar risks and maturities.

 

The fair value of financial instruments is measured and disclosure is made in accordance with ASC Topic 820, “FairFair Value Measurements and Disclosures”Disclosures.

 

Revenue recognitionrecognition—

Fixed-price contracts — Historically,We generate revenue under a range of contracting options, including fixed-price, unit-price, time and material, and cost reimbursable plus fee contracts. A substantial portion of the Company’sour revenue has been generated underis derived from contracts that are fixed-price contracts. For fixed-price contracts, the Company recognizes revenues primarilyor unit-price, using the percentage-of-completion method, which may result in unevenmethod. For time and irregular results. material and cost reimbursable plus fee contracts, revenue is recognized primarily based on contractual terms. Generally, time and material and cost reimbursable contract revenues are recognized on an input basis, based on labor hours incurred and on purchases made.

In the percentage-of-completion method, estimated revenues,contract values, estimated contract valuescost at completion and total costs incurred to date are used to calculate revenues earned. Unforeseen events and circumstances can alter the estimate of the costs and potential profit associated with a particular contract.  Total estimated costs, and thus contract revenues and income, can be impacted by changes in productivity, scheduling, the unit cost of labor, subcontracts, materials and equipment. Additionally, external factors such as weather, client needs, client delays in providing permits and approvals, labor availability, governmental regulation and politics may affect the progress of a project’s completion and thus the timing of revenue recognition. 

To the extent that original cost estimates are modified, estimated costs to complete

F-13



Table of Contents

increase, delivery schedules are delayed, or progress under a contract is otherwise impeded, cash flow, revenue recognition and profitability from a particular contract may be adversely affected. As a significant change in one or more of these estimates could affect the profitability of our contracts, we review and update our contract-related estimates regularly. We recognize adjustments in estimated profit on contracts as changes in accounting estimates in the period in which the revisions are identified. Revenue and profit in future periods of contract performance are recognized using the adjusted estimate.

 

If at any time the estimate of contract profitability indicates an anticipated loss on a contract, the projected loss is recognized in full in the period it is identified and recognized as an “accrued loss provision” which is included in the accrued expenses and other current liabilities amount on the balance sheet. For contract revenue recognized under the percentage-of-completion method, the accrued loss provision is adjusted so that the gross profit for the contract remains zero in future periods. The Company considersprovision for estimated losses on uncompleted contracts was $10.1 million and $12.8 million at December 31, 2017 and 2016, respectively.

We consider unapproved change orders to be contract variations for which it has customer approval for a change incustomers have not agreed to both scope but for which it does not have an agreed upon price change.and price.  Costs associated with unapproved change orders are included in the estimated cost to complete the contracts and are treated as project costs as incurred. The Company recognizes revenue equal to costs incurred on unapprovedWe will recognize a change orders when realizationin contract value if we believe it is probable that the

F-15


Table of change order approval is probable.Contents

contract price will be adjusted and can be reliably estimated.  Unapproved change orders involve the use of estimates, and it is reasonably possible that revisions to the estimated costs and recoverable amounts may be required in future reporting periods to reflect changes in estimates or final agreements with customers.

 

The Company considersWe consider claims to be amounts it seeks,we seek, or will seek, to collect from customers or others for customer-caused changes in contract specifications or design, or other customer-related causes of unanticipated additional contract costs on which there is no agreement with customers on both scopecustomers. Claims can also be caused by non-customer-caused changes, such as rain or other weather delays.  Costs associated with claims are included in the estimated costs to complete the contracts and price changes.are treated as project costs when incurred.  Claims are included in revenue to the calculation of revenues whenextent we have a reasonable legal basis, the related costs have been incurred, realization is probable, and amounts can be reliably determined. Revenues in excess of contract costs incurred on claims are recognized when the amounts have been agreed upon with the customer.estimated.  Revenue in excess of contract costs from claims is recognized whenafter an agreement is reached with customers as to the value of the claims, which in some instances may not occur until after completion of work under the contract. Costs associated with

At December 31, 2017, we had unapproved change orders and claims are included in the estimated costs to completeexpected contract value that totaled approximately $67.8 million. These claims were in the contractsprocess of being negotiated in the normal course of business. Approximately $56.7 million of unapproved change orders and are treatedclaims had been recognized as project costs when incurred.

Other contract forms — The Company also uses unit-price, time and material, and cost reimbursable plus fee contracts.  For these jobs, revenue is recognized primarily based on contractual terms.  For example, time and material contract revenues are generally recognized on an input basis, based on labor hours incurred and on purchases made.  Similarly, unit price contracts generally recognize revenue on an output based measurement such as the completion of specific units at a specified unit price.

At any time during a fixed-price contract if an estimate of total contract cost indicates a loss on a contract, the projected loss is recognized in full at that time.  The loss amount is recognized as an “accrued loss provision” and is included in the accrued expenses and other liabilities amount on the balance sheet.  As thecumulative percentage-of-completion method is used to calculate revenues, the accrued loss provision is changed so that the gross profit for the contract remains zero in future periods.  If we anticipate that there will be a loss for unit price or cost reimbursable contracts, the projected loss is recognized in full at that time.

Changes in job performance, job conditions and estimated profitability, including those arising from final contract settlements, may result in revisions to costs and income. These revisions are recognized in the period in which the revisions are identified.basis through December 31, 2017.

 

In all forms of contracts, we estimate the Company estimates its collectability of contract amounts at the same time that it estimateswe estimate project costs.  If the Company anticipateswe anticipate that there may be issues associated with the collectability of the full amount calculated as revenues, the Companywe may reduce the amount recognized as revenue to reflect the uncertainty associated with realization of the eventual cash collection. For example, when a cost reimbursable project exceeds the client’s expected budget amount, the client frequently requests an adjustment to the final amount. Similarly, some utility clients reserve the right to audit costs for significant periods after performance of the work. In these situations, the Companywe may choose to defer recognition of a portion of the revenue up to the time thatuntil the client pays for the services.

 

The caption “Costs and estimated earnings in excess of billings” in the Consolidated Balance SheetSheets represents unbilled receivables which arise when revenues have been recorded but the amount will not be billed until a later date.  Balances represent:  (a) unbilled amounts arising from the use of the percentage-of-completion method of accounting which may not be billed under the terms of the contract until a later date or project milestone; (b) incurred costs to be billed under cost reimbursementreimbursable type contracts, (c)including amounts arising from routine lags in billing,billing; or (d)(c) the revenue associated with unapproved change orders or claims when realization is probable and amounts can be reliably determined.estimated.  For those contracts in which billings exceed contract revenues recognized to date, the excess amounts are included in the caption “Billings in excess of costs and estimated earnings”.

 

In accordance with applicable terms of certain construction contracts, retainage amounts may be withheld by customers until completion and acceptance of the project.  Some payments of the retainage may not be received for a significant period after completion of our portion of a project.  In some jurisdictions, retainage amounts are deposited into an escrow account.

 

Accounts receivableAccounts receivable and contract receivables are primarily with public and private companies and governmental agencies located in the United States. Credit terms for payment of products and services are extended to customers in the normal course of business and no interest is charged. Contract receivables are generally progress billings on projects, and as a result, are short term in nature.  The Company requiresGenerally, we require no collateral from itsour customers, but generally  filesfile statutory liens or stop notices on allany construction projects when collection problems are anticipated. While a project is underway, we estimate the Company estimates its collectability of contract amounts at the same time that it estimateswe estimate project costs.  As discussed in the “Revenue recognition” section above, realization of the eventual cash collection may be recognized as adjustments to revenues on athe contract revenue and profitability, otherwise, the Company useswe use the allowance method of accounting for losses from uncollectible accounts. Under this method an allowance is provided based upon historical experience and management’s evaluation of outstanding contract receivables at the end of each year. Receivables are written off in the period deemed uncollectible. The allowance for doubtful accounts at December 31, 20142017 and 20132016 was $540$0.5 million and $692,$1.0 million, respectively.

 

F-14


F-16



Table of Contents

Significant revision in contract estimateestimates  —  Revenue recognition is based on the percentage-of-completion method for firm fixed-price contracts. Under this method, the costs incurred to date as a percentage of total estimated costs are used to calculate revenue. Total estimated costs, and thus contract revenues and margin, are impacted by many factors, which can cause significant changes in estimates during the life cycle of a project.

 

For projects that were in process in at the end of the prior year, there can be a difference in revenues and profits that would have been recognized in the prior year, had current year estimates of costs to complete been known at the end of the prior year.

During the year ended December 31, 2014, certain contracts had revisions in cost estimates from those projected at December 31, 2013. If the revised estimates had been applied in the prior year, the gross profit earned on these contracts would have resulted in an increase of approximately $17,266 in gross profit in 2013. Similarly, had the revised estimates as of December 31, 2013 been applied in the prior year; the gross profit earned on these contracts would have resulted in an increase of approximately $10,867 in gross profit in 2012. The revised estimates for the year ended December 31, 2012 would have resulted in a gross profit increase of approximately $8,185 in the year 2011.

 

The following table presents the approximate financial impact of the changes in estimates that would have been reflected in the prior years 2013 and 2012 had the revised estimates been applied to the particular year.year (in thousands):

 

 

 

Estimated net impact of change in
estimate for year the year ended

 

 

 

2013

 

2012

 

 

 

 

 

 

 

Revised estimates in 2014 that impact 2013

 

$

17,266

 

$

 

Revised estimates in 2013 that impact 2012

 

(10,867

)

10,867

 

Revised estimates in 2012 that impact 2011

 

 

(8,185

)

Net impact to gross margin

 

$

6,399

 

$

2,682

 

EPS impact to year

 

$

0.077

 

$

0.032

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net impact of change in estimate

 

 

 

for the years ended December 31,

 

 

    

2017

    

2016

    

2015

 

Revised estimates in 2017 that impact 2016

 

$

6,435

 

$

(6,435)

 

$

 —

 

Revised estimates in 2016 that impact 2015

 

 

 —

 

 

1,685

 

 

(1,685)

 

Revised estimates in 2015 that impact 2014

 

 

 —

 

 

 —

 

 

(1,540)

 

Net impact to gross margin

 

$

6,435

 

$

(4,750)

 

$

(3,225)

 

EPS impact to year

 

$

0.09

 

$

(0.05)

 

$

(0.04)

 

 

During the third quarter 2016, we settled a dispute with a customer on collection of a receivable of $17.9 million, receiving $38.0 million in cash.  Prior to settlement, we recorded revenues with zero margin.  We recognized the settlement as a change in accounting estimate which resulted in recognizing revenues of approximately $27.5 million and gross profit of approximately $26.7 million in the third quarter of 2016.

In October 2016, we announced that we planned to divest our Texas heavy civil business unit, which operates as a division of Primoris Heavy Civil.  We engaged a financial advisor to assist in the marketing and sale of the business unit, and planned to continue operating the business unit until completion of a sale.  In April 2017, the Board of Directors determined that based on the information available, we would attain the best long-term value by withdrawing from the sales process and continuing to operate the business unit. As a result of the planned divestiture, we recorded a charge of $37.3 million during the third quarter of 2016. This charge includes a reduction of the expected profitability of certain projects in the Belton, Texas area for the division and a reduction of costs and estimated earnings in excess of billings and an increase to the reserve for anticipated job losses. 

The settlement of the disputed project and the charge related to the planned divestiture were not included in the table above.

Customer concentrationThe Company operatesWe operate in multiple industry segments encompassing the construction of commercial, industrial and public works infrastructure assets primarily throughout primarily the United States. Typically, the top ten customers in any one calendar year generate revenues in excess of 50% of total revenues; however, the group that comprise the top ten customers varies from year to year. See “Note 16Note 15Customer ConcentrationsConcentrations”for further discussion.

 

Property and equipmentProperty and equipment are recorded at cost and are depreciated using the straight-line method over the estimated useful lives of the related assets, usually ranging from three to thirty years. Maintenance and repairs are charged to expense as incurred. Significant renewals and betterments are capitalized. At the time of retirement or other disposition of property and equipment, the cost and accumulated depreciation are removed from the accounts, and any resulting gain or loss is reflected in operations.operating income.

 

The Company assessesWe assess the recoverability of property and equipment whenever events or changes in business circumstances indicate that the carrying amount of the asset may not be fully recoverable.  We perform an undiscounted operation cash flow analysis to determine if impairment exists.  The amount of property and equipment impairment, if any, is measured based on fair value and is

F-17


Table of Contents

charged to operations in the period in which property and equipment impairment is determined by management. As of December 31, 20142017 and 2013, the Company’s2016, our management has not identified any material impairment of its property and equipment.

 

Taxes collected from customersTaxesSales and use taxes collected from the Company’sour customers are recorded on a net basis.

 

Share-based payments and stock-based compensationIn July 2008,May 2013, the shareholders approved and the Companywe adopted the Primoris Services Corporation 2008 Long-term Incentive Equity Plan, which was replaced by the Primoris Services Corporation 2013 Long-term Incentive Equity Plan (“Equity Plan”) after approval of the shareholders and adoption by the Company on May 3, 2013..  Detailed discussion of shares issued under the Equity Plan are included in “Note 19.Note 18Deferred Compensation Agreements and Stock-Based Compensation.Compensation”

F-15 and in Note 22—



Table“Stockholders’ Equity”. Such share issuances include grants of Contents

The Company issued 77,455 sharesRestricted Stock Units to executives, issuance of stock in 2014 and 131,989 shares of stock in 2013 under the Equity Plan to certain senior managers and executives who, as partand issuances of the 2011 Primoris Long-Term Retention Plan (“LTR Plan”), may elect at the end of each yearstock to purchase Company common stock at a discounted amount using a portion of their annual bonuses.  For 2014 and 2013, the plan provided for a discount of 25% from the average daily closing price for the previous December.  The amount of the discount is treated as compensation to the participant. The shares were fully vested upon issuance and have a six-month restriction on any trades.

As part of the quarterly compensation of the non-employee members of the Board of Directors, the Company issued 12,547 shares of common stock during 2014 and 21,590 shares of common stock during 2013 under the Equity Plan.  The shares were fully vested upon issuance and have a one-year restriction on any trades.

On May 3, 2013, the Board of Directors granted 100,000 Restricted Stock Units (“Units”) to an executive under the Equity Plan.  Commencing annually on May 10, 2014 and ending April 30, 2017, the Units will vest in four equal installments subject to continuing employment of the executive.  On May 10, 2014, 25,000 of these Units vested.  On March 24, 2014, the Board of Directors granted 48,512 Units to another executive under the Equity Plan.  The Units will vest 50% on September 23, 2015 and the remaining 50% on March 23, 2017 subject to continuing employment of the executive.  Vesting in both grants is also subject to earlier acceleration, termination, cancellation or forfeiture as provided in the underlying Primoris Restricted Stock Unit agreement (“RSU Award Agreement”).  Each Unit represents the right to receive one share of the Company’s common stock when vested.

Under guidance of ASC Topic 718 “Compensation — Stock Compensation”, stock-based compensation cost is measured at the date of grant (utilizing the prior-day closing price), based on the calculated fair value of the stock-based award, and is recognized as expense over the employee’s requisite service period (generally the vesting period of the award).Directors.

 

The fair value of the Units was based on the closing market price of our common stock on the day prior to the date of the grant.  Stock compensation expense for the Units is being amortized using the straight-line method over the service period.  For the twelve months ended December 31, 2014, the Company recognized $934 in compensation expense.  At December 31, 2014, approximately $2.4 million of unrecognized compensation expense remains for the Units, which will be recognized over the next 2.3 years through April 30, 2017.

Vested Units accrue “Dividend Equivalents” (as defined in the Equity Plan) which will be accrued as additional Units.  At December 31, 2014, there were 110 Dividend Equivalent Units that were accrued based on 25,000 Units that vested on May 10, 2014.  The number of Dividend Equivalent Units are calculated based on the amount of dividends that would have been paid on the vested Units divided by the fair value of the Company’s stock on the record date each quarter end.

At December 31, 2014, there were 2,278,651 shares of common stock reserved to provide for the grant and exercise of all future stock option grants, stock appreciation rights (“SARS”), Units and grants of restricted shares under the Equity Plan. Other than the Units discussed above, there were no stock options, SARS or restricted shares of stock issued or outstanding at December 31, 2014.

Contingent Earnout LiabilitiesAs part of recent acquisitions, the Company has agreed to  pay cash to the sellers upon meeting certain operating performance targets for specified periods subsequent to the acquisition date.  Each quarter, the Company evaluates the fair value of the estimated contingency and records a non-operating charge for the change in the fair value.  Upon meeting the target, the Company reflects the full liability on the balance sheet and records as a charge to “Selling, general and administration expense” for the change in the fair value of the liability from the prior period.

Recently Issued Accounting Pronouncements

 

In February 2013, the Financial Accounting Standards Board (“FASB”) issued Accounting Standards Update (“ASU”) No. 2013-04, “Liabilities (Topic 405): Obligations Resulting from Joint and Several Liability Arrangements for Which the Total Amount of the Obligation Is Fixed at the Reporting Date (a consensus of the FASB Emerging Issues Task Force)”  (“ASU 2013-04”).  ASU 2013-04 provides guidance for the recognition, measurement, and disclosure of obligations resulting from joint and several liability arrangements for which the total amount of the obligation within the scope of this guidance is fixed at the reporting date. This ASU is an update to FASB ASC Topic 405, “Liabilities”.  The Company adopted this guidance as of January 1, 2014 which did not have a material impact on the Company’s consolidated financial statements.

In May 2014, the FASB issued ASU No. 2014-09, Revenue“Revenue from Contracts with Customers (Topic 606)”., with several clarifying updates issued during 2016 and 2017. The new standard is effective for reporting periods beginning after December 15, 2016 and early adoption is not permitted.2017. The comprehensive new standard will supersede existingall current revenue recognition guidancestandards and require revenue to be recognizedguidance.  Revenue recognition will occur when promised goods or services are transferred to customers in amounts that reflect the consideration to which the company expects to be entitled to in exchange for those goods or services. Adoption wouldThe mandatory adoption will require new qualitative and quantitative disclosures about the nature, amount, timing and

F-16



Table of Contents

uncertainty of revenue and cash flows arising from customer contracts, including significant judgments and changes in judgments, information about contract balances and performance obligations, and assets recognized from costs incurred to obtain or fulfill a contract. The guidancestandard permits two implementation approaches, one requiringthe “modified retrospective application of the new standard with restatement of prior years and one requiringmethod”, which requires prospective application of the new standard as a cumulative-effect adjustment. We will adopt this new standard using the modified retrospective method, which requires a cumulative-effect adjustment to retained earnings as of the date of adoption, if material.  The adoption will only apply to customer contracts that are not substantially complete as of January 1, 2018.

We have substantially completed our evaluation of the impact of adopting the standard on our financial position, results of operations, cash flows and related disclosures.  Based on our evaluation, the cumulative impact of adopting Topic 606 is expected to be immaterial and will not require an adjustment to retained earnings.  The impact to our results is not material because Topic 606 generally supports the recognition of revenue over time under the cost-to-cost method for the majority of our contracts, which is consistent with disclosureour current percentage of results under old standards. For the Company,completion revenue recognition model. 

We do not expect the new standard to materially affect the timing and amount of total revenue that can be recognized over the life of a construction project; however, the revenue recognized on a quarterly basis during the construction period may change. We believe that Topic 606 is likely to be more impactful to certain of our lump sum projects as a result of the following required changes from our current practices:

·

Performance obligations – Topic 606 requires a review of contracts and contract modifications to determine whether there are multiple performance obligations.  Each separate performance obligation must be accounted for as a distinct project, which could impact the timing of revenue recognition.  In connection with our evaluation, we discovered limited cases of multiple performance obligations which had minimal impact on revenue recognized to date.

·

Variable consideration – In accordance with Topic 606, revenue recognition must account for variable consideration, including potential liquidated damages and customer discounts. We generally assess the impact of liquidated damages as an estimated cost of the project.  The adoption of the new standard may affect the timing of the recognition of revenue for both liquidated damages and discounts.     

We do not expect Topic 606 to have a material impact on our Consolidated Balance Sheets, though we expect certain reclassifications among financial statement accounts to align with the new standard.  We also expect significant expanded disclosures relating to revenue recognized during each period.

F-18


Table of Contents

In February 2016, the FASB issued ASU 2016-02 “Leases (Topic 842)”. The ASU will require recognition of operating leases with lease terms of more than twelve months on the balance sheet as both assets for the rights and liabilities for the obligations created by the leases. The ASU will require disclosures that provide qualitative and quantitative information for the lease assets and liabilities recorded in the financial statements. The standard is effective for fiscal years beginning after December 15, 2018. We have already revised our credit agreements to address the impact of ASU 2016-02 and are currently evaluating other impacts of adopting the standard on our financial position, results of operations, cash flows, and related disclosures. See Note 13 — “Commitments and Contingencies”  for more information about the timing and amount of future operating lease payments, which we believe is indicative of the materiality of adoption of the ASU to our financial statements.

In March 2016, the FASB issued ASU 2016-09 “Compensation — Stock Compensation (Topic 718) — Improvements to Employee Share-Based Payment Accounting”. The ASU modifies the accounting for excess tax benefits and tax deficiencies associated with share-based payments by requiring that excess tax benefits or deficiencies be included in the income statement rather than in equity. Additionally, the tax benefits for dividends on share-based payment awards will also be reflected in the income statement. As a result of these modifications, the ASU requires that the tax-related cash flows resulting from share-based payments will be effectiveshown on the cash flow statement as operating activities rather than as financing activities. We adopted the ASU as of January 1, 2017, and the Company is currently evaluating the potentialit did not have a material impact of adoption and the implementation approach to be used.

In April 2014, the FASB issued ASU 2014-08 “Presentation of Financial Statements (Topic 205)) and Property, Plant, and Equipment (Topic 360)” which changes the requirement for reporting discontinued operations. A disposal of a component of an entity or a group of components of an entity will be required to be reported in discontinued operations if the disposal represents a strategic shift that has (or will have) a major effect on an entity’s operations and financial results when the entity or group of components of an entity meets the criteria to be classified as held for sale or when it is disposed of by sale or other than by sale. The update also requires additional disclosures about discontinued operations, a disposal of an individually significant component of an entity that does not qualify for discontinued operations presentation in the financial statements, and an entity’s significant continuing involvement with a discontinued operation. The update is effective prospectively for fiscal years beginning on or after December 15, 2014, including interim periods within those years. Early adoption is permitted, but only for disposals (or classifications as held for sale) that have not been reported in previously issued financial statements. The Company adopted this guidance effective January 1, 2015. This guidance will impact the disclosure and presentation of how we report any future disposals of components or groups of components of our business.

In August 2014, the FASB issued ASU 2014-15 “Presentation of Financial Statements — Going Concern (Subtopic 205-40)” to address the diversity in practice in determining when there is substantial doubt about an entity’s ability to continue as a going concern and when and how an entity must disclose certain relevant conditions and events. This update requires an entity to evaluate whether there are conditions or events, considered in the aggregate, that raise substantial doubt about the entity’s ability to continue as a going concern for a period of one year after the date that the financial statements are issued (or available to be issued). If such conditions or events exist, an entity should disclose that there is substantial doubt about the entity’s ability to continue as a going concern for a period of one year after the date that the financial statements are issued (or available to be issued), along with the principal conditions or events that raise substantial doubt, management’s evaluation of the significance of those conditions or events in relation to the entity’s ability to meet its obligations and management’s plans that are intended to mitigate those conditions or events. The guidance is effective for annual and interim periods ending after December 15, 2016. This guidance will impact the disclosure and presentation of how we report any substantial doubt about our ability to continue as a going concern, if such substantial doubt were to exist. The Company will adopt this guidance effective January 1, 2017.

In February 2015, the FASB issued ASU 2015-02 “Consolidation (Topic 810): Amendment to the Consolidation Analysis” which amends existing consolidation guidance, including amending the guidance related to determining whether an entity is a variable interest entity. The update is effective for interim and annual periods beginning after December 15, 2015, although early adoption is permitted. The guidance may be applied using a modified retrospective approach whereby the entity records a cumulative effect of adoption at the beginning of the fiscal year of initial application. A reporting entity may also apply the amendments on a full retrospective basis. The Company is currently evaluating the potential impact of this authoritative guidance on our consolidated financial statements.

 

In January 2017, the FASB issued ASU 2017-01, "Business Combinations (Topic 805): Clarifying the Definition of a Business" which changes the definition of a business to assist entities with evaluating when a set of transferred assets and activities is a business. ASU 2017-01 requires an entity to evaluate if substantially all of the fair value of the gross assets acquired is concentrated in a single identifiable asset or a group of similar identifiable assets; if so, the set of transferred assets and activities is not a business. ASU 2017-01 is effective for interim and annual reporting periods beginning after December 15, 2017. We do not expect the adoption of ASU 2017-01 to have any impact on our financial position, results of operations or cash flows.

In January 2017, the Financial Accounting Standards Board ("FASB") issued ASU 2017-04, "Simplifying the Test for Goodwill Impairment". ASU 2017-04 removes the second step of the goodwill impairment test, which requires a hypothetical purchase price allocation. A goodwill impairment will now be the amount by which a reporting unit's carrying value exceeds its fair value, not to exceed the carrying amount of goodwill. ASU 2017-04 is effective for interim and annual reporting periods beginning after December 15, 2019 and will be applied prospectively. We do not expect the adoption of ASU 2017-04 to have an impact on our financial position, results of operations or cash flows.

In May 2017, the FASB issued ASU 2017-09, “Compensation — Stock Compensation (Topic 718) — Scope of Modification Accounting”.  The ASU amends the scope of modification accounting for share-based payment arrangements.  The amendments in the ASU provide guidance on types of changes to the terms or conditions of share-based payment awards that would be required to apply modification accounting under ASC 718, “Compensation — Stock Compensation”.  The ASU is effective for interim and annual reporting periods beginning after December 15, 2017 with early adoption permitted. We do not expect the adoption of ASU 2017-09 to have an impact on our financial position, results of operations or cash flows

Other new pronouncements issued but not effective until after December 31, 2017 are not expected to have a material impact on our consolidated results of operations, financial position or cash flows.

Note 3—Fair Value Measurements

 

ASC Topic 820, “Fair Value Measurements and Disclosures” defines fair value, establishes a framework for measuring fair value in GAAP and requires certain disclosures about fair value measurements.  ASC Topic 820 addresses fair value GAAP for financial assets and financial liabilities that are re-measuredremeasured and reported at fair value at each reporting period and for non-financial assets and liabilities that are re-measuredremeasured and reported at fair value on a non-recurring basis.

 

In general, fair values determined by Level 1 inputs use quoted prices (unadjusted) in active markets for identical assets or liabilities. Fair values determined by Level 2 inputs use data points that are observable such as quoted

F-19


Table of Contents

prices, interest rates and yield curves. Fair values determined by Level 3 inputs are “unobservable data points” for the asset or liability and include situations where there is little, if any, market activity for the asset or liability.

 

F-17



Table of Contents

The following table presents, for each of the fair value hierarchy levels identified under ASC Topic 820, the Company’sour financial assets and certain liabilities that are required to be measured at fair value at December 31, 20142017 and 2013:2016 (in thousands):

 

 

 

 

 

Fair Value Measurements at Reporting Date

 

 

 

Amount
Recorded
on Balance
Sheet

 

Quoted Prices
in Active Markets
for Identical Assets
(Level 1)

 

Significant
Other
Observable
Inputs
(Level 2)

 

Significant
Unobservable
Inputs
(Level 3)

 

Assets as of December 31, 2014:

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

139,465

 

$

139,465

 

 

 

Short-term investments

 

$

30,992

 

$

30,992

 

 

 

Liabilities as of December 31, 2014:

 

 

 

 

 

 

 

 

 

Contingent consideration

 

$

6,922

 

 

 

$

6,922

 

 

 

 

 

 

 

 

 

 

 

Assets as of December 31, 2013:

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

196,077

 

$

196,077

 

 

 

Short-term investments

 

$

18,686

 

$

18,686

 

 

 

Liabilities as of December 31, 2013:

 

 

 

 

 

 

 

 

 

Contingent consideration

 

$

9,233

 

 

 

$

9,233

 

Short-term investments consist primarily of U.S. Treasury bills with various financial institutions that are backed by the federal government.

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Fair Value Measurements at Reporting Date

 

 

    

 

 

    

 

 

    

Significant

    

 

 

 

 

 

Amount

 

Quoted Prices

 

Other

 

Significant

 

 

 

Recorded

 

in Active Markets

 

Observable

 

Unobservable

 

 

 

on Balance

 

for Identical Assets

 

Inputs

 

Inputs

 

 

 

Sheet

 

(Level 1)

 

(Level 2)

 

(Level 3)

 

Assets as of December 31, 2017:

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

170,385

 

$

170,385

 

$

 —

 

$

 —

 

Liabilities as of December 31, 2017: 

 

 

 

 

 

 

 

 

 

 

 

 

 

Contingent consideration

 

$

716

 

$

 —

 

$

 —

 

$

716

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Assets as of December 31, 2016:

 

 

 

 

 

 

 

 

 

 

 

 

 

Cash and cash equivalents

 

$

135,823

 

$

135,823

 

$

 —

 

$

 —

 

Liabilities as of December 31, 2016: 

 

 

 

 

 

 

 

 

 

 

 

 

 

    None

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Other financial instruments of the Company not listed in the table consist of accounts receivable, accounts payable and certain accrued liabilities.  These financial instruments generally approximate fair value based on their short-term nature.  The carrying value of the Company’sour long-term debt approximates fair value based on comparison with current prevailing market rates for loans of similar risks and maturities.

 

The following table provides changes to the Company’sour contingent consideration liability Level 3 fair value measurements during the years ended December 31, 20142017 and 2013:2016 (in thousands):

 

 

Significant Unobservable Inputs
(Level 3)

 

 

 

2014

 

2013

 

Contingent Consideration Liability

 

 

 

 

 

Beginning balance

 

$

9,233

 

$

23,431

 

Additions to contingent consideration liability:

 

 

 

 

 

FSSI acquisition

 

 

702

 

Vadnais acquisition

 

679

 

 

Surber and Ram-Fab acquisitions

 

1,154

 

 

Change in fair value of contingent consideration liability

 

856

 

2,500

 

Reductions in the contingent consideration liability:

 

 

 

 

 

Payment to Rockford sellers for meeting performance targets

 

 

(6,900

)

Payment to Sprint sellers for meeting performance targets

 

 

(4,000

)

Payment to Q3C sellers for meeting performance targets

 

(5,000

)

 

Reduction due to non-attainment of performance targets

 

 

(6,500

)

Ending balance

 

$

6,922

 

$

9,233

 

 

 

 

 

 

 

 

 

 

 

Significant Unobservable Inputs

 

 

 

(Level 3)

 

Contingent Consideration Liability

    

2017

    

2016

 

Beginning balance, January 1,

 

$

 —

 

$

 —

 

Florida Gas Contractors acquisition

 

 

1,200

 

 

 —

 

Change in fair value of contingent consideration liability during year

 

 

(484)

 

 

 —

 

Ending balance, December 31, 

 

$

716

 

$

 —

 

 

On a quarterly basis, the Company assesseswe assess the estimated fair value of the contractual obligation to pay the contingent consideration and any changes in estimated fair value are recorded as othera non-operating expense or incomecharge in the Company’s statementour Statement of income.Income.  Fluctuations in the fair value of contingent consideration are impacted by two unobservable inputs, management’s estimate of the probability (which has ranged from 33% to 100%) of the acquired company meeting the contractual operating performance target and the estimated discount rate (a rate that approximates the Company’sour cost of capital). Significant changes in either of those inputs in isolation would result in a different fair value measurement.  Generally, a change in the assumption of the probability of meeting the performance target is accompanied by a directionally similar change in the fair value of contingent consideration liability, whereas a change in assumption used of the estimated discount rate is accompanied by a directionally opposite change in the fair value of contingent consideration liability.

 

Note 4—Business Combinations

2014 Acquisitions

In May 2014,Upon meeting the Company createdtarget, we reflect the full liability on the balance sheet and record a wholly-owned subsidiary, Vadnais Trenchless Services, Inc., a California corporation (“Vadnais”)charge to “Selling, general and on June 5, 2014,administration expense” for the Company purchased certain assets from Vadnais Corporation, a general contractor specializingchange in micro-tunneling.  The assets were purchased for their estimated fair value of $6,355 in cash and included equipment, building and land.  In addition, upon meeting certain operating targets, the sellers will receive a contingent earnout of $900.  In the fourth quarter of 2014, the purchase agreement was amended to adjust the earn-out period from a one-year period to a two-year period ending September 30, 2016 with a potential earnout of $450 in each year.  The estimated fair value of the amended agreementliability from the prior period. 

The May 2017 acquisition of the potentialFlorida Gas Contractors included an earnout of $1.5 million payable in May 2018, contingent consideration on the acquisition date was $679.  Though the Company initially indicated that it had finalized its estimate of fair value for the contingent consideration and intangible assets as of the third quarter 2014, due to the amended purchase agreement, the Company adjusted theupon meeting certain performance targets. The estimated fair value of the contingent consideration on the acquisition date from $729was $1.2 million. Under ASC 805, we are required to $679.  The purchase was accounted for usingestimate the fair value of contingent consideration based on facts and circumstances that existed as of the acquisition methoddate and remeasure to fair value at each reporting date until the contingency is resolved. As a result of accounting.that remeasurement, we reduced the fair value of the contingent

F-20


 

F-18



Table of Contents

consideration in the fourth quarter of 2017 related to the FGC performance target contemplated in their purchase agreement, and decreased the liability by $0.5 million with a corresponding increase in non-operating income.

 

DuringWe paid $5.0 million to the third quarter 2014,sellers of Q3C in March 2015 based on achievement of their operating performance targets each year, as outlined in the Company made three small acquisitions totaling $8,244 acquiring the netpurchase agreement.

Note 4—Business Combinations

2017 Acquisitions

On May 26, 2017, we acquired certain assets of Surber, Ram-Fab, and Williams. Surber and Ram-Fab operate as divisions of PESFlorida Gas Contractors, a utility contractor specializing in underground natural gas infrastructure, for approximately $33.0 million in cash.  In addition, the Energy segment, and Williams is a division of Cardinal Contractors, Inc. in the East segment (the “Third Quarter Acquisitions”).  Surber provides general oil and gas related construction activities in Texas; Ram-Fab is a fabricator of custom piping systems located in Arkansas; and Williams provides construction services related to sewer pipeline maintenance, rehabilitation and integrity testing in the Florida market.  The Surber purchase provided forsellers could receive a contingent earnout amount of up to $1,800$1.5 million over a 3-yearone-year period ending May 26, 2018, based on meetingas of the achievement of certain operating targets, which had an estimated fair value of $955 on the acquisition date.  The Ram-Fab purchase included a $200 contingent earnout based on estimated earnings of a six-month operating project, which had an estimated fair value of $200 on the acquisition date.  All of the purchases were accounted for using the acquisition method of accounting. For Surber and Williams the Company has finalized its estimate of fair value for the contingent consideration and intangible assets, which resulted in no material change from the estimated values recorded at September 30, 2014. The amounts for Ram-Fab are preliminary pending completion of an appraisal.

Since the acquisition dates for the acquisitions through December 31, 2014, they contributed revenues of $9,300 and gross loss of $45.0.  Acquisition costs related to these acquisitions of $355 were expensed in 2014.

The fair value of the assets acquired and the liabilities assumed for the 2014 acquisitions is detailed in the section below “Schedule of Assets Acquired and Liabilities Assumed for 2014 and 2013 Acquisitions”.

2013 Acquisition - FSSI

On March 11, 2013, PES purchased the assets of FSSI, which specialized in turn-around work at refineries and chemical plants in the Gulf Coast area.  Based in the greater Houston, Texas area, FSSI’s location provided a presence and convenient access to refineries in south Texas, the Houston ship channel and Louisiana.

The acquisition of FSSI was accounted for using the acquisition method of accounting.  The fair value of the consideration for the acquisition was $2,377.  Consideration consisted of $1,675 in cash, of which $1,025 was paid at closing and $650 was paid in the second quarter 2013.  The agreement provided for three future potential payments, contingent upon FSSI meeting certain performance targets for the remainder of calendar year 2013 and calendar years 2014 and 2015.targets.  The estimated fair value of the potential contingent consideration on the acquisition date was $702.  At December 31, 2013, it was determined that$1.2 million.  FGC operates in the operations of FSSI did not meetUtilities segment and expands our presence in the performance targets.  Because the measurement date of the acquisition had passed, the contingent consideration balance of $760 was credited to non-operating income at December 31, 2013.

Florida and Southeast markets.  The purchase agreement also included a provision that PES make an up-front payment of $1,000 for a five-year employment, non-competition and non-solicitation agreement with a key employee.  If the employee terminated his employment or violated the agreement prior to the end of the five-year period, he would be required to repay the unamortized amount of the $1,000 payment.  This agreement was accounted for as a prepaid asset and was being amortized equally over a five-year period.

Theusing the acquisition method of accounting.  During the fourth quarter of 2017, we finalized the estimate of fair value of the FSSIacquired assets acquiredof FGC, which included $4.8 million of fixed assets; $3.3 million of working capital; $9.1 million of intangible assets; and $17.0 million of goodwill. In connection with the FSSI liabilities assumed is detailedFGC acquisition, we also paid $3.5 million to acquire certain land and buildings.  Intangible assets primarily consist of customer relationships.  Goodwill associated with the FGC acquisition principally consists of expected benefits from providing expertise for our construction efforts in the section below “Scheduleunderground utility business as well as the expansion of Assets Acquired and Liabilities Assumed for 2014 and 2013 Acquisitions”.

Because the operating results for FSSI did not meet the expected targets during the fourth quarter 2013, the Company made certain changes in FSSI management.  As a result of the changes, several adjustments were made toour geographic presence.  Goodwill also includes the value of certain FSSI assets and liabilities as of December 31, 2013.  First, the Company determinedassembled workforce that the value attributedFGC provides to the intangible asset for customer relationships was impaired and the remaining value of $808 of such asset was expensed in the fourth quarter 2013 to “Selling, general and administrative expenses”.  Second, the unamortized portion of the prepaid payment made to the employee of $850 was fully reserved as a fourth quarter 2013 charge to “Selling general and administrative expenses”.  Third, as discussed above, no remaining value was attributed for any future contingent consideration as of December 31, 2013, and $760 was credited to non-operating income in the fourth quarter 2013.  The Company believes the remaining fair value of the FSSI business was properly reflectedus.  Based on the balance sheet at December 31, 2013.

current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period.  From its March 11, 2013the acquisition date through December 31, 2013, FSSI2017, FGC contributed revenues of $4,946$15.5 million and gross margin of $3.8 million.

On May 30, 2017, we acquired certain engineering assets for approximately $2.3 million in cash which further enhances our ability to provide quality service for engineering and design projects.  The purchase was accounted for using the acquisition method of accounting.  The allocation of the total purchase price consisted of $0.2 million of fixed assets and $2.1 million of intangible assets. Intangible assets primarily consist of customer relationships. The operations of this acquisition were fully integrated into our operations and no separate financial results were maintained. Therefore, it is impracticable for us to report the amounts of revenues and gross profit included in the Consolidated Statements of Income.

On June 16, 2017, we acquired certain assets and liabilities of Coastal Field Services for approximately $27.5 million in cash.  Coastal provides pipeline construction and maintenance, pipe and vessel coating and insulation, and integrity support services for companies in the oil and gas industry.  Coastal operates in the Pipeline segment and increases our market share in the Gulf Coast energy market.  The purchase was accounted for using the acquisition method of accounting.  The preliminary allocation of the total purchase price consisted of $4.0 million of fixed assets; $4.6 million of working capital; $9.9 million of intangible assets; $9.3 million of goodwill; and $0.3 million of long-term capital leases. We continue to assess the final cutoff data and expect to finalize the estimate of fair value of the acquired assets of Coastal during 2018. Intangible assets primarily consist of customer relationships and tradename. Goodwill associated with the Coastal acquisition principally consists of expected benefits from providing expertise for our expansion of services in the pipeline construction and maintenance business. Goodwill also includes the value of the assembled workforce that Coastal provides to us. Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period.  From the acquisition date through December 31, 2017, Coastal contributed revenues of $17.9 million and gross margin of $3.2 million.

2016 Acquisitions

On January 29, 2016, we acquired certain assets and liabilities of Mueller Concrete Construction Company for $4.1 million. The purchase was accounted for using the acquisition method of accounting. During the second quarter of 2016, we finalized the estimate of fair value of the acquired assets of Mueller, which included $2.0 million of fixed assets, $2.0 million of goodwill and $0.1 million of inventory. Mueller operates within the Utilities segment.  Goodwill

F-21


Table of Contents

largely consists of expected benefits from providing foundation expertise for our construction efforts in underground line work, substations and telecom/fiber.  Goodwill also includes the value of the assembled workforce that Mueller provides to our business.  Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period.  The operations of Mueller were fully integrated into our operations and no separate financial results were maintained. Therefore, it is impracticable for us to report the amounts of revenues and gross profit included in the Consolidated Statements of Income.

On June 24, 2016, we purchased property, plant and equipment from Pipe Jacking Unlimited, Inc., consisting of specialty directional drilling and tunneling equipment for $13.4 million in cash. We determined this purchase did not meet the definition of a business as defined under ASC 805. The estimated fair value of the equipment was equal to the purchase price.  We believe the purchase of the equipment will aid in our pipeline construction projects and enhance the work provided to our utility clients. Pipe Jacking operations are included in the Pipeline segment.

On November 18, 2016, we acquired certain assets and liabilities of Northern Energy & Power for $6.9 million.  Northern operates in the Power segment and serves the renewable energy sector with a specific focus on solar photovoltaic installations in the United States.  The purchase was accounted for using the acquisition method of accounting.  During the second quarter of 2017, we finalized our estimated fair value of the acquired assets of Northern, which resulted in a $0.1 million reduction in goodwill compared to amounts previously recorded.  The allocation of the total purchase price included $3.0 million of intangible assets, $3.7 million of goodwill and $0.1 million of fixed assets.  Intangible assets consist of customer relationships.  Goodwill is derived from the expected benefits of services in the renewable energy sector with a specific focus on Solar Photovoltaic installations in the United States. Goodwill also includes the value of the assembled workforce that Northern provides to our business.  Based on the current tax treatment, goodwill will be deductible for income tax purposes over a fifteen-year period. For the year ended December 31, 2017, Northern contributed revenues of $19.1 million and gross profit of $164.  Acquisition costs related$1.1 million. From the acquisition date through December 31, 2016, Northern contributed revenues of $2.0 million and gross margin of $0.6 million.

2015 Acquisitions

On February 28, 2015, we acquired the net assets of Aevenia, Inc. (“Aevenia”) for $22.3 million in cash, which operates as part of our Utilities segment.  The acquisition provides electrical construction expertise and provides a greater presence and convenient access to the FSSIcentral plains area of the United States. The purchase was accounted for using the acquisition method of $89 were expensed in 2013.accounting.  The allocation of the total purchase price consisted of $11.2 million of fixed assets; $2.1 million of working capital; $3.8 million of intangible assets; and $5.2 million of goodwill. Goodwill largely consists of expected benefits from providing electrical construction expertise for us and the greater presence and convenient access to the central plains area of the United States. Goodwill also includes the value of the assembled workforce that Aevenia provides to our business. For the year ended December 31, 2017, Aevenia contributed revenues of $24.5 million and gross profit of $1.4 million. For the year ended December 31, 2016, Aevenia contributed revenues of $26.4 million and gross profit of $1.0 million.  From the acquisition date through December 31, 2015, Aevenia contributed revenues of $23.7 million and gross margin of $2.4 million.

 

F-19



Table of Contents

Summary of Cash Paid for Acquisitions for the years ended December 31, 2014 and 2013

 

The following table summarizes the cash paid for acquisitions under ASC 805 for the years ended December 31, 20142017, 2016, and 2013.2015 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

Year ended December 31, 

 

 

    

2017

    

2016

    

2015

 

Coastal — purchased June 16, 2017

 

$

27,519

 

$

 —

 

$

 —

 

Engineering — purchased May 30, 2017

 

 

2,315

 

 

 —

 

 

 —

 

Florida Gas — purchased May 26, 2017

 

 

36,492

 

 

 —

 

 

 —

 

Northern — purchased November 18, 2016

 

 

(121)

*

 

6,889

 

 

 —

 

Mueller — purchased January 29, 2016

 

 

 

 

 

4,108

 

 

 —

 

Aevenia — purchased February 28, 2015

 

 

 —

 

 

 —

 

 

22,302

 

Cash paid

 

$

66,205

 

$

10,997

 

$

22,302

 

 

 

 

Year ended December 31,

 

 

 

2014

 

2013

 

 

 

 

 

 

 

FSSI — purchased March 11, 2013

 

$

 

$

1,675

 

Q3C — additional cash paid August 2013 for prior year November 2012 purchase

 

 

598

(*)

Vadnais — purchased June 5, 2014

 

6,355

 

 

Surber — purchased July 28, 2014

 

3,642

 

 

Ram-Fab — purchased August 29, 2014

 

3,569

 

 

Williams — purchased September 19, 2014

 

1,030

 

 

 

 

$

14,596

 

$

2,273

 

F-22


 


Table of Contents

(*)

*  In August 2013, additionalthe second quarter of 2017, we finalized the estimated fair value of the Northern acquisition, which resulted in receipt of $0.1 million in cash of $598 was paid to the Q3C sellers and goodwill was increased to $13,160a reduction in 2013.goodwill.

 

Schedule of Assets Acquired and Liabilities Assumed for 2014 and 2013 Acquisitions

 

The following table summarizes the fair value of the assets acquired and the liabilities assumed at the acquisitions date:acquisition date (in thousands):

 

 

 

 

 

 

 

 

 

 

 

Year ended December 31, 

 

 

2017

    

2016

    

2015

 

 

Acquisitions

 

Acquisitions

 

Acquisitions

 

Accounts receivable

$

10,721

 

$

1,606

 

$

2,734

 

Costs and estimated earnings in excess of billings

 

580

 

 

 —

 

 

 —

 

Inventory and other assets

 

2,352

 

 

64

 

 

1,476

 

Property, plant and equipment

 

12,402

 

 

2,133

 

 

11,173

 

Intangible assets

 

21,125

 

 

3,000

 

 

3,850

 

Goodwill

 

26,269

 

 

5,781

 

 

5,152

 

Accounts payable

 

(3,380)

 

 

(726)

 

 

(743)

 

Billings in excess of costs and estimated earnings

 

(447)

 

 

 —

 

 

 —

 

Accrued expenses

 

(2,096)

 

 

(861)

 

 

(1,340)

 

Total

$

67,526

 

$

10,997

 

$

22,302

 

 

 

 

2014

 

2013

 

 

 

Vadnais

 

Third Quarter

 

FSSI

 

 

 

Acquisitions

 

Acquisitions

 

Acquisition

 

 

 

 

 

 

 

 

 

Cash

 

$

 

$

3

 

$

 

Accounts receivable

 

 

2,768

 

 

Inventory and other assets

 

 

711

 

302

 

Prepaid expenses

 

 

57

 

 

Property, plant and equipment

 

6,355

 

5,447

 

448

 

Other assets

 

 

4

 

 

Intangible assets

 

679

 

1,100

 

1,600

 

Goodwill

 

 

784

 

1,087

 

Accounts payable

 

 

(570

)

(1,060

)

Accrued expenses

 

 

(905

)

 

Total

 

$

7,034

 

$

9,399

 

$

2,377

 

Identifiable Tangible Assets.  SignificantFor each of the acquisitions, significant identifiable tangible assets acquired include accounts receivable, inventory and fixed assets, consisting primarily of construction equipment, for each of the acquisitions. The Companyequipment. We determined that the recorded value of accounts receivable and inventory reflect fair value of those assets. The CompanyWe estimated the fair value of fixed assets on the effective dates of the acquisitions using a market approach, based on comparable market values for similar equipment of similar condition and age.

 

Identifiable Intangible Assets.  We estimated and usedgenerally use the assistance of an independent third party valuation specialist to determineestimate the fair value of the intangible assets acquired for the acquisitions.  The fair value measurements of the intangible assets were based primarily on significant unobservable inputs and thus represent a Level 3 measurement as defined in Note 3 — “Fair Value Measurements”. Based on the Company’sour assessment, the acquired intangible asset categories, fair value and average amortization periods, generally on a straight-line basis, and fair values are as follows:follows (in thousands):

 

 

 

 

 

2014 Fair Value

 

2013 Fair Value

 

 

 

Amortization
Period

 

Vadnais
Acquisition

 

Third Quarter
2014
Acquisitions

 

FSSI
Acquisition

 

Tradename

 

3 to 10 years

 

$

 

$

650

 

$

550

 

Non-compete agreements

 

2 to 5 years

 

 

250

 

100

 

Customer relationships

 

5 to 10 years

 

679

 

200

 

950

(*)

Total

 

 

 

$

679

 

$

1,100

 

$

1,600

 


 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Amortization

 

2017

 

2016

 

2015

 

 

    

Period

    

Fair Value

    

Fair Value

    

Fair Value

 

Tradename

 

1 to 3 years

 

$

2,150

 

$

 —

 

$

 —

 

Non-compete agreements

 

2 to 5 years

 

 

550

 

 

 —

 

 

1,350

 

Customer relationships

 

5 to 10 years

 

 

18,150

 

 

3,000

 

 

2,500

 

Other

 

3 years

 

 

275

 

 

 —

 

 

 —

 

Total

 

 

 

$

21,125

 

$

3,000

 

$

3,850

 

(*)  At December 31, 2013, the Company determined the value attributed to the customer relationships was impaired and the net book value of the intangible of $850 was expensed to “Selling, general and administrative expenses” at December 31, 2013.

F-20



Table of Contents

 

The fair value of the tradename was determined based on the “relief from royalty” method.  A royalty rate was selected based on consideration of several factors, including external research of third party trade name licensing agreements and their royalty rate levels, and management estimates.  The useful life was estimated at five years for FSSI and ten years for the Third Quarter 2014 acquisitions based on management’s expectation for continuing value of the tradename in the future.

 

The fair value for the non-compete agreements was valued based on a discounted “income approach” model, including estimated financial results with and without the non-compete agreements in place.  The agreements were analyzed based on the potential impact of competition that certain individuals could have on the financial results, assuming the agreements were not in place.  An estimate of the probability of competition was applied and the results were compared to a similar model assuming the agreements were in place.

 

The customer relationships were valued utilizing the “excess earnings method” of the income approach.  The estimated discounted cash flows associated with existing customers and projects were based on historical and market participant data. Such discounted cash flows were net of fair market returns on the various tangible and intangible assets that are necessary to realize the potential cash flows.

 

Goodwill. Goodwill for Surber largely consists

F-23


Table of expected benefits from the geographic expansion into the growing Midland/Permian Basin area of Texas and to the expansion of offerings for the Energy segment to include more pipeline and station work and a greater presence and convenient access to south Texas, the Houston ship channel and Louisiana. Goodwill is also attributable to FSSI’s expertise in turn-around work for refineries and chemical plants, as well as the opportunity to extend our infrastructure operations and other synergies of the combined companies. Goodwill also includes the value of the assembled workforce of the various acquired businesses.Contents

Based on the current tax treatment of the acquisitions, the goodwill and other intangible assets associated with them are deductible for income tax purposes over a fifteen-year period.

Supplemental Unaudited Pro Forma Information

 

In accordance with ASC 805, we are combining theThe following pro forma information for the Vadnaistwelve months ended December 31, 2017 and Third Quarter Acquisitions (“the Acquisitions”). The following pro forma information2016 presents theour results of operations of the Acquisitions combined, as if the Acquisitions2017 acquisitions of FGC and Coastal and the 2016 acquisitions of Mueller and Northern had each occurred at the beginning of 2013.2016.  The supplemental pro forma information has been adjusted to include:

 

·

the pro forma impact of amortization of intangible assets and depreciation of property, plant and equipment, based on the purchase price allocations; and

·the pro forma impact of amortization of intangible assets and depreciation of property, plant and equipment, based on the fair values assigned to the purchased assets;

·the pro forma impact of the expense associated with the amortization of the discount for the fair value of the contingent consideration for potential earnout liabilities that may be achieved in 2015 and 2016 for the Vadnais acquisition and 2015 through 2017 for the Third Quarter Acquisitions.

·the pro forma tax effect of both the income before income taxes and the pro forma adjustments, calculated using a tax rate of 39.0% for the years ended 2014 and 2013.

·

the pro forma tax effect of both the income before income taxes and the pro forma adjustments, calculated using a tax rate of 28.2% and 44.2% for the years ended December 31, 2017 and 2016, respectively.

 

The pro forma results are presented for illustrative purposes only and are not necessarily indicative of, or intended to represent, the results that would have been achieved had the Acquisitionsvarious acquisitions been completed on January 1, 2013.2016. For example, the pro forma results do not reflect any operating efficiencies and associated cost savings that the Companywe might have achieved with respect to the acquisitions.acquisitions (in thousands):

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 

 

 

 

2017

    

2016

 

 

 

(unaudited)

 

(unaudited)

 

Revenues

 

$

2,406,062

 

$

2,092,872

 

Income before provision for income taxes

 

$

107,055

 

$

57,280

 

Net income attributable to Primoris

 

$

73,626

 

$

31,415

 

 

 

 

 

 

 

 

 

Weighted average common shares outstanding:

 

 

 

 

 

 

 

Basic

 

 

51,481

 

 

51,762

 

Diluted

 

 

51,741

 

 

51,989

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

Basic

 

$

1.43

 

$

0.61

 

Diluted

 

$

1.42

 

$

0.60

 

 

 

 

2014

 

2013

 

 

 

(unaudited)

 

(unaudited)

 

Revenues

 

$

2,110,072

 

$

1,974,760

 

Income before provision for income taxes

 

$

101,948

 

$

114,197

 

Net income attributable to Primoris

 

$

62,924

 

$

66,379

 

 

 

 

 

 

 

Weighted average common shares outstanding:

 

 

 

 

 

Basic

 

51,607

 

51,540

 

Diluted

 

51,747

 

51,610

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

Basic

 

$

1.22

 

$

1.29

 

Diluted

 

$

1.22

 

$

1.29

 

F-21



Table of Contents

 

Note 5—Accounts Receivable

 

The following is a summary of accounts receivable at December 31:31 (in thousands):

 

 

 

2014

 

2013

 

Contracts receivable, net of allowance for doubtful accounts of $540 and $692 for 2014 and 2013, respectively

 

$

287,806

 

$

257,354

 

Retention

 

49,104

 

47,054

 

 

 

336,910

 

304,408

 

Other accounts receivable

 

472

 

547

 

 

 

$

337,382

 

$

304,955

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

Contracts receivable, net of allowance for doubtful accounts of $480 at December 31, 2017 and $1,030 at December 31, 2016, respectively

 

$

286,113

 

$

340,871

 

Retention receivable

 

 

66,586

 

 

46,394

 

 

 

 

352,699

 

 

387,265

 

Other accounts receivable

 

 

5,476

 

 

735

 

 

 

$

358,175

 

$

388,000

 

 

Note 6—Costs and Estimated Earnings on Uncompleted Contracts

 

Costs and estimated earnings on uncompleted contracts consist of the following at December 31:31 (in thousands):

 

 

 

 

 

 

 

 

2014

 

2013

 

 

2017

 

2016

Costs incurred on uncompleted contracts

 

$

5,194,769

 

$

4,741,249

 

 

$

6,040,678

 

$

5,391,124

Gross profit recognized

 

613,510

 

582,430

 

 

 

519,173

 

 

456,871

 

5,808,279

 

5,323,679

 

 

 

6,559,851

 

 

5,847,995

Less: billings to date

 

(5,898,220

)

(5,439,898

)

 

 

(6,558,793)

 

 

(5,821,983)

 

$

(89,941

)

$

(116,219

)

 

$

1,058

 

$

26,012

 

F-24


Table of Contents

This amount is included under the following captions in the accompanying consolidated balance sheetsConsolidated Balance Sheets at December 31 under the following captions:(in thousands):

 

 

 

 

 

 

 

 

 

2017

 

2016

Costs and estimated earnings in excess of billings

 

$

160,092

 

$

138,618

Billings in excess of cost and estimated earnings

 

 

(159,034)

 

 

(112,606)

 

 

$

1,058

 

$

26,012

 

 

 

2014

 

2013

 

Costs and estimated earnings in excess of billings

 

$

68,654

 

$

57,146

 

Billings in excess of cost and estimated earnings

 

(158,595

)

(173,365

)

 

 

$

(89,941

)

$

(116,219

)

 

Note 7—Property and Equipment

 

The following is a summary of property and equipment at December 31:31 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

Useful Life

 

    

2017

    

2016

    

Useful Life

 

Land and buildings

 

$

40,604

 

$

36,883

 

30 years

 

 

$

82,755

 

$

56,878

 

Buildings 30 Years

 

Leasehold improvements

 

11,267

 

7,958

 

Lease life

 

 

 

12,601

 

 

12,147

 

Lease Life

 

Office equipment

 

3,651

 

3,171

 

3 - 5 years

 

 

 

8,888

 

 

8,083

 

3 - 5 Years

 

Construction equipment

 

308,915

 

247,997

 

3 - 7 years

 

 

 

392,454

 

 

368,241

 

3 - 7 Years

 

Transportation equipment

 

83,845

 

67,550

 

3 - 18 years

 

 

 

101,855

 

 

98,113

 

3 - 18 Years

 

Construction in progress

 

 

16,336

 

 

2,321

 

 

 

 

448,282

 

363,559

 

 

 

 

 

614,889

 

 

545,783

 

 

 

Less: accumulated depreciation and amortization

 

(176,851

)

(137,047

)

 

 

 

 

(303,112)

 

 

(268,437)

 

 

 

Net property and equipment

 

$

271,431

 

$

226,512

 

 

 

Property and equipment, net

 

$

311,777

 

$

277,346

 

 

 

 

Note 8—Equity Method Investments

 

WesPac Energy LLC and WesPac Midstream LLC

 

On July 1, 2010, the Company acquired a 50% membership interest in WesPac Energy LLC (“WesPac”), a Nevada limited liability company, from Kealine Holdings, LLC (“Kealine”), a Nevada limited liability company, with Kealine retaining a remaining 50% membership interest. WesPac developed pipeline

Note 8—Goodwill and terminal projects, primarily for the oil and gas industry.

F-22



Table of Contents

On September 30, 2013, WesPac, Kealine and the Company entered into an agreement (the “Midstream Agreement”) with Highstar Capital IV, LP (“Highstar”), to form a new entity, WesPac Midstream LLC, a Delaware limited liability company (“Midstream”), with WesPac contributing project assets to Midstream and Highstar investing $6,082 in cash.Intangible Assets

 

The Company accountedchange in goodwill by segment for 2017 and 2016 was as follows (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Power

 

Pipeline

 

Utilities

 

Civil

 

Total

 

Balance at January 1, 2016

 

$

20,731

 

$

42,252

 

$

18,312

 

$

42,866

 

$

124,161

 

Goodwill acquired during the year

 

 

3,781

 

 

 —

 

 

2,000

 

 

 —

 

 

5,781

 

Goodwill impairment

 

 

 —

 

 

 —

 

 

 —

 

 

(2,716)

 

 

(2,716)

 

Balance at December 31, 2016

 

$

24,512

 

$

42,252

 

$

20,312

 

$

40,150

 

$

127,226

 

Goodwill acquired during the year

 

 

 —

 

 

9,269

 

 

17,000

 

 

 —

 

 

26,269

 

Purchase price allocation adjustments

 

 

(121)

 

 

 —

 

 

 —

 

 

 —

 

 

(121)

 

Balance at December 31, 2017

 

$

24,391

 

$

51,521

 

$

37,312

 

$

40,150

 

$

153,374

 

During the investment usingthird quarter of 2016, we made a decision to divest our Texas heavy civil business unit, a division of Primoris Heavy Civil within the equity methodCivil segment.  We engaged a financial advisor to assist in the marketing and sale of accountingthe business unit, and planned to continue operating the business unit until completion of a sale.  In April 2017, the Board of Directors determined that based on the information available, we would attain the best long-term value by withdrawing from the sales process and continuing to operate the business unit.  We will aggressively pursue claims for five Texas Department of Transportation projects that resulted in significant losses recorded its proportionate sharein 2016.  However, there can be no assurance as to the final amounts collected. In accordance with ASC 350, the planned divestiture triggered an analysis of operating expenses.  Duringthe goodwill at Primoris Heavy Civil, resulting in a pretax, non-cash goodwill impairment charge of approximately $2.7 million in the third quarter of 2016.

In the fourth quarter of 2013,2015, an impairment expense of $0.4 million was recorded relating to the Company recorded non-cash impairment charges and wrote-offgoodwill attributed to Cardinal Contractors, Inc., which is part of the total value of its equity investment of $4,932.Power Segment. 

 

In 2014, the Company entered into negotiations with the membersThere was no impairment of Midstream, and in August 2014, the Company entered into a redemption agreementgoodwill for the sale of all of the Company’s ownership in both WesPac and Midstream for a total of $5,250 in cash, which was recorded as income from non-consolidated entities.

St.—Bernard Levee Partners

The Company purchased a 30% interest in St. — Bernard Levee Partners (“Bernard”) in 2009 for $300 and accounted for this investment using the equity method.  Bernard engaged in construction activities in Louisiana, and all work was completed in January 2013. The Company’s share of Bernard distributions for the yearsyear ended December 31, 2014 and 2013, was $0 and $145, respectively.2017.

 

Alvah, Inc.

F-25


 

As partTable of its acquisition of Q3C in November 2012, the Company acquired a 49% membership interest in Alvah, Inc., a California corporation (“Alvah”).  Alvah is engaged in electrical contracting activities, primarily in Northern California, and has worked as a subcontractor for ARB both prior to and subsequent to the Q3C acquisition.Contents

On February 5, 2014, the majority owner of Alvah, in accordance with the original investment agreement, elected to purchase the Company’s minority interest effective January 1, 2014 for a cash payment of $1,189.  At the time of the transaction, the Company recorded income adjustments of $14 related to the final sale in the first quarter of 2014.

Note 9—Intangible Assets

The table below summarizes the intangible asset categories, amounts and the average amortization periods, which are generally on a straight-line basis, at December 31:31 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Amortization

 

 

 

Amount

 

 

 

 

December 31, 2017

 

December 31, 2016

 

 

Period

 

 

 

2014

 

2013

 

    

Weighted Average Life

    

Gross Carrying Amount

    

Accumulated Amortization

    

Gross Carrying Amount

    

Accumulated Amortization

 

Tradename

 

3 to 10 years

 

 

 

$

18,194

 

$

21,023

 

 

9 years

 

$

32,175

 

$

(22,238)

 

$

30,485

 

$

(18,733)

 

Customer relationships

 

10 years

 

 

49,900

 

 

(16,338)

 

 

33,579

 

 

(13,439)

 

Non-compete agreements

 

2 to 5 years

 

 

 

1,074

 

2,575

 

 

5 years

 

 

1,900

 

 

(820)

 

 

2,250

 

 

(1,301)

 

Customer relationships

 

5 to 15 years

 

 

 

20,313

 

21,705

 

Other

 

3 years

 

 

275

 

 

(54)

 

 

 —

 

 

 —

 

 

 

 

Total

 

$

39,581

 

$

45,303

 

 

 

 

$

84,250

 

$

(39,450)

 

$

66,314

 

$

(33,473)

 

 

Amortization expense of intangible assets was $7,504, $7,467$8.7 million, $6.6 million and $6,543$6.8 million for the years ended December 31, 2014, 20132017, 2016 and 2012,2015, respectively. In the second quarter of 2017, we recorded a $0.5 million impairment charge related to our tradename intangible assets. Estimated future amortization expense for intangible assets as of December 31, 20142017 is as follows:

For the Years Ending
December 31,

 

Estimated
Intangible
Amortization
Expense

 

2015

 

$

6,414

 

2016

 

5,980

 

2017

 

5,703

 

2018

 

5,239

 

2019

 

3,388

 

Thereafter

 

12,857

 

 

 

$

39,581

 

F-23



Table of Contentsfollows (in thousands):

 

 

 

 

 

 

 

    

Estimated

 

 

 

Intangible

 

For the Years Ending

 

Amortization

 

December 31, 

 

Expense

 

2018

 

$

9,541

 

2019

 

 

9,193

 

2020

 

 

6,442

 

2021

 

 

5,203

 

2022

 

 

4,048

 

Thereafter

 

 

10,373

 

 

 

$

44,800

 

Note 10—9—Accounts Payable and Accrued Liabilities

 

At December 31, 20142017 and 2013,2016, accounts payable included retention amounts of approximately $9,285$13.5 million and $5,602,$10.6 million, respectively. These amounts due to subcontractors have been retained pending contract completion and customer acceptance of jobs.

 

The following is a summary of accrued expenses and other current liabilities at December 31:31 (in thousands):

 

 

 

 

 

 

 

 

2014

 

2013

 

 

2017

 

2016

Payroll and related employee benefits

 

$

37,261

 

$

36,556

 

 

$

45,708

 

$

43,768

Insurance, including self-insurance reserves

 

34,377

 

33,880

 

 

 

47,256

 

 

42,546

Reserve for estimated losses on uncompleted contracts

 

2,363

 

1,392

 

 

 

10,067

 

 

12,801

Corporate income taxes and other taxes

 

3,775

 

13,305

 

 

 

2,843

 

 

3,368

Accrued overhead cost

 

1,059

 

1,165

 

Other

 

4,566

 

4,781

 

 

 

5,513

 

 

5,523

 

$

83,401

 

$

91,079

 

 

$

111,387

 

$

108,006

 

Note 11—Capital Leases

 

The Company leasesNote 10—Capital Leases

We lease vehicles and certain equipment under capital leases. The economic substance of the leases is as a financing transaction for acquisition of the vehicles and equipment, and accordingly, the leases  are recorded as assets and liabilities. Included in depreciation expense is amortizationdepreciation of vehicles and equipment held under capital leases, amortized over their useful lives on a straight-line basis.

 

F-26


At December 31, 2014,2017, total assets under capital leases were $11,563,$3.1 million, accumulated depreciation was $6,311$1.9 million, and the net book value was $5,252.$1.2 million. For 2013,2016, total assets under capital leases were $12,942,$2.5 million, accumulated depreciation was $4,689$2.3 million, and the net book value of assets was $8,253.$0.2 million.

 

The following is a schedule by year of the future minimum lease payments required under capital leases together with their present value as of December 31:31 (in thousands):

 

2015

 

$

1,733

 

2016

 

672

 

 

 

 

2018

    

$

134

2019

 

 

98

2020

 

 

90

2021

 

 

11

2022

 

 

 —

Total minimum lease payments

 

$

2,405

 

 

$

333

Amounts representing interest

 

(98

)

 

 

(5)

Net present value of minimum lease payments

 

2,307

 

 

 

328

Less: current portion of capital lease obligations

 

(1,650

)

 

 

(132)

Long-term capital lease obligations

 

$

657

 

 

$

196

 

Note 12—Credit Arrangements

 

Note 11—Credit facilitiesArrangements

Long-term debt and long-term debtcredit facilities consist of the following at December 31:31 (in thousands):

 

 

 

2014

 

2013

 

 

 

 

 

 

 

Commercial equipment notes payable to various commercial equipment finance companies and banks with interest rates that range from 1.78% to 3.51% per annum. Monthly principal and interest payments are due in the amount of $2,521 per month until the maturity dates, which range from November 30, 2016 to December 13, 2020. The notes are secured by certain construction equipment of the Company

 

$

112,420

 

$

144,526

 

 

 

 

 

 

 

Commercial equipment notes payable to various commercial equipment finance companies and banks with interest rates that range from 1.94% to 2.75% per annum. Monthly principal and interest payments are due in the amount of $999 per month until the maturity dates, which range from March 31, 2019 to September 24, 2021. The notes are secured by certain construction equipment assets of the Company.

 

55,518

 

 

 

 

 

 

 

 

Senior Secured Notes payable to an insurance finance company, with an interest rate of 3.65% per annum. Quarterly interest payments began March 31, 2013. Principal repayments start on December 28, 2016 until the maturity date on December 28, 2022. The notes are secured by the assets of the Company

 

50,000

 

50,000

 

 

 

 

 

 

 

Senior Secured Notes payable to an insurance finance company, with an interest rate of 3.85% per annum. Quarterly interest payments began October 25, 2013. Principal repayments start on July 25, 2017 until the maturity date on July 25, 2023. The notes are secured by the assets of the Company

 

25,000

 

25,000

 

 

 

 

 

 

 

 

 

242,938

 

219,526

 

Less: current portion

 

(38,909

)

(28,475

)

Long-term debt, net of current portion

 

$

204,029

 

$

191,051

 

F-24Commercial Notes Payable and Mortgage Notes Payable


 

 

 

 

 

 

 

 

 

    

2017

 

2016

 

Commercial equipment notes

 

$

165,532

 

$

161,148

 

Mortgage notes

 

 

11,242

 

 

7,564

 

Revolving credit facility

 

 

 —

 

 

 —

 

Senior secured notes

 

 

82,143

 

 

92,858

 

Total debt

 

 

258,917

 

 

261,570

 

Unamortized debt issuance costs

 

 

(102)

 

 

(231)

 

Total debt, net

 

$

258,815

 

$

261,339

 

Less: current portion

 

 

(65,464)

 

 

(58,189)

 

Long-term debt, net of current portion

 

$

193,351

 

$

203,150

 

 

 

 

 

 

 

 

 


Table of Contents

Scheduled maturities of long-term debt are as follows:follows (in thousands):

 

 

 

 

 

 

    

Year Ending

 

 

 

December 31, 

 

2018

 

$

65,464

 

2019

 

 

62,014

 

2020

 

 

50,755

 

2021

 

 

33,939

 

2022

 

 

24,144

 

Thereafter

 

 

22,601

 

 

 

$

258,917

 

Commercial Notes Payable and Mortgage Notes Payable

 

 

 

Year Ending
December 31,

 

2015

 

$

38,909

 

2016

 

46,315

 

2017

 

41,282

 

2018

 

38,566

 

2019

 

33,965

 

Thereafter

 

43,901

 

 

 

$

242,938

 

From time to time, we enter into commercial equipment notes payable with various equipment finance companies and banks. At December 31, 2017, interest rates ranged from 1.78% to 3.51% per annum and maturity dates range from June 15, 2018 to December 15, 2022. The notes are secured by certain construction equipment.

 

F-27


We also entered into two secured mortgage notes payable to a bank in December 2015 totaling $8.0 million, with interest rates of 4.3% per annum and maturity dates of January 1, 2031. The mortgage notes are secured by two buildings.

During 2017, we acquired three properties from a related party and assumed mortgage notes secured by the properties totaling $4.2 million, with interest rates of 5.0% per annum and maturity dates of October 1, 2038.

Revolving Credit Facility

 

As of December 31, 2014, the Company had a revolvingOn September 29, 2017, we entered into an amended and restated credit facility, as amended on December 12, 2014agreement (the “Credit Agreement”) with The PrivateBank and Trust Company,CIBC Bank USA, as administrative agent (the “Administrative Agent”) and co-lead arranger, The Bank of the West, as co-lead arranger, and IBERIABANK Corporation, Branch Banking and Trust Company, IBERIABANK, Bank of America, and UMBSimmons Bank N.A. (the “Lenders”)., which increased our borrowing capacity from $125.0 million to $200.0 million. The Credit Agreement isconsists of a $125$200.0 million revolving credit facility whereby the Lenders agreeagreed to make loans on a revolving basis from time to time and to issue letters of credit for up to the $125$200.0 million committed amount. The termination date of the Credit Agreement is December 28, 2017.September 29, 2022. We capitalized $0.6 million of debt issuance costs during the third quarter of 2017 that is being amortized as interest expense over the life of the Credit Agreement.

 

The principal amount of any loans under the Credit Agreement will bear interest at either: (i) LIBOR plus an applicable margin as specified in the Credit Agreement (based on the Company’sour senior debt to EBITDA ratio as that term is defined in the Credit Agreement), or (ii) the Base Rate (which is the greater of (a) the Federal Funds Rate plus 0.5%0.50% or (b) the prime rate as announced by the Administrative Agent). Quarterly non-useNon-use fees, letter of credit fees and administrative agent fees are payable at rates specified in the Credit Agreement.

 

The principal amount of any loan drawn under the Credit Agreement may be prepaid in whole or in part at any time, with a minimum prepayment of $5 million, at any time, potentially subject to make-whole provisions.$5.0 million.

 

The Credit Agreement includes customary restrictive covenants for facilities of this type, as discussed below.

 

Commercial letters of credit outstanding were $4,659$19.5 million at December 31, 2014 and $5,074 at December 31, 2013.2017.  Other than commercial letters of credit, there were no borrowings under this line ofthe Credit Agreement or the previous credit agreement during the twelve months ended December 31, 2014,2017, and available borrowing capacity at December 31, 20142017 was $120,341.$180.5 million.

 

F-25



Table of Contents

Senior Secured Notes and Shelf Agreement

 

On December 28, 2012, the Companywe entered into a $50$50.0 million Senior Secured Notes purchase (“Senior Notes”) and a $25$25.0 million private shelf agreement (the “Notes Agreement”) by and among the Company,us, The Prudential Investment Management, Inc. and certain Prudential affiliates (the “Noteholders”). On June 3, 2015, the Notes Agreement was amended to provide for the issuance of additional notes of up to $75.0 million over the next three year period ending June 3, 2018 (“Additional Senior Notes”).

 

The Senior Notes amount was funded on December 28, 2012. The Senior Notes are due December 28, 2022 and bear interest at an annual rate of 3.65%, paid quarterly in arrears. Annual principal payments of $7.1 million are required from December 28, 2016 through December 28, 2021 with a final payment due on December 28, 2022. The principal amount may be prepaid, with a minimum prepayment of $5$5.0 million, at any time, subject to make-whole provisions.

 

On July 25, 2013, the Companywe drew the full $25$25.0 million available under the Notes Agreement.  The notes are due July 25, 2023 and bear interest at an annual rate of 3.85% paid quarterly in arrears.  Seven annual principal payments of $3.6 million are required from July 25, 2017 with a final payment due on July 25, 2023.

 

On November 9, 2015, we drew $25.0 million available under the Additional Senior Notes Agreement.  The notes are due November 9, 2025 and bear interest at an annual rate of 4.6% paid quarterly in arrears.  Seven annual principal payments of $3.6 million are required from November 9, 2019 with a final payment due on November 9, 2025.

F-28


Loans made under both the Credit Agreement and the Notes Agreement are secured by our assets, including, among others, our cash, inventory, goods, equipment (excluding equipment subject to permitted liens), and accounts receivable. All of our domestic subsidiaries have issued joint and several guaranties in favor of the Lenders and Noteholders for all amounts under the Credit Agreement and Notes Agreement.

 

Both the Credit Agreement and the Notes Agreement contain various restrictive and financial covenants including, among others, minimum tangible net worth, senior debt/EBITDA ratio and debt service coverage requirements and a minimum balance for unencumbered net book value for fixed assets.requirements. In addition, the agreements include restrictions on investments, change of control provisions and provisions in the event the Company disposeswe dispose more than 20% of itsour total assets.

 

The Company wasWe were in compliance with the covenants for the Credit Agreement and Notes Agreement at December 31, 2014.2017.

 

Canadian Credit Facility

 

The Company hasWe have a demand credit facility for $8,000$8.0 million in Canadian dollars with a Canadian bank for purposes of issuing commercial letters of credit in Canada.  The credit facility has an annual renewal and provides for the issuance of commercial letters of credit for a term of up to five years. The facility provides for an annual fee of 1%1.0% for any issued and outstanding commercial letters of credit. Letters of credit can be denominated in either Canadian or U.S. dollars. At December 31, 2014 and 2013,2017, letters of credit outstanding totaled $2,563 and $2,252$0.5 million in Canadian dollars, respectively.dollars.  At December 31, 2014,2017, the available borrowing capacity was $5,437$7.5 million in Canadian dollars.  The credit facility contains a working capital restrictive covenant for our Canadian subsidiary, OnQuest Canada, ULC.  At December 31, 2014,2017, OnQuest Canada, ULC was in compliance with the covenant.

 

Note 1312 — Noncontrolling Interests

 

The CompanyWe are currently participating in two joint ventures, each of which operates in the Power segment. Both joint ventures have been determined that the Blythe joint venture wasto be a variable interest entity (“VIE”)VIE and that the Company waswe were determined to be the primary beneficiary as a result of itsour significant influence over the joint venture operations.

 

The BlytheEach joint venture operating activities are included in the Company’s consolidated statements of income as follows for the years ended December 31:

 

 

2014

 

2013

 

 

 

 

 

 

 

Revenues

 

$

1,169

 

$

58,704

 

Net income attributable to noncontrolling interests

 

526

 

5,020

 

Since Blythe is a partnership, and consequently, no tax effect was recognized for the income.  Blythe made distributionsThe net assets of $1,590 to the non-controlling interestsjoint ventures are restricted for use by the specific project and $1,590 to the Company during the year ended December 31, 2014are not available for our general operations. 

The Carlsbad joint venture operating activities began in 2015 and $5.5 million to the non-controlling interests and $5.5 million to the Company during the prior year.  There were no capital contributions made duringare included in our Consolidated Statements of Income as follows for the years ended December 31 2014(in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

2017

    

2016

    

2015

Revenues

 

$

110,669

 

$

7,254

 

$

2,887

Net income attributable to noncontrolling interests

 

 

1,780

 

 

325

 

 

172

The Carlsbad joint venture made no distributions to the partners and 2013.we made no capital contributions to the Carlsbad joint venture during the years ending December 31, 2017 and 2016. The project has beenis expected to be completed and following the end of the project warranty period  in May 2015, Blythe will be terminated.2018.

 

F-26


F-29



The carrying value of the assets and liabilities associated with the operations of the Carlsbad joint venture are included in our Consolidated Balance Sheets at December 31 as follows (in thousands):

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

Cash

 

$

44,308

 

$

4,630

 

Accounts receivable

 

$

15,343

 

$

 —

 

Costs and estimated earnings in excess of billings

 

$

 —

 

$

124

 

Billings in excess of costs and estimated earnings

 

$

42,743

 

$

3,426

 

Accounts payable

 

$

12,352

 

$

286

 

Due to Primoris

 

$

 —

 

$

46

 

The Wilmington joint venture operating activities began in 2015 and are included in our Consolidated Statements of Income as follows for the years ended December 31 (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

    

2016

    

2015

 

Revenues

 

$

31,638

 

$

19,781

 

$

1,364

 

Net income attributable to noncontrolling interests

 

 

2,716

 

 

677

 

 

48

 

The Wilmington joint venture made no distributions to the partners and we made no capital contributions to the Wilmington joint venture during the years ending December 31, 2017 and 2016. The project is expected to be completed in 2018.

 

The carrying value of the assets and liabilities associated with the operations of the BlytheWilmington joint venture are included in the Company’s consolidated balance sheetsour Consolidated Balance Sheets at December 31 as follows:follows (in thousands):

 

 

2014

 

2013

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

Cash

 

$

60

 

$

3,025

 

 

$

15,948

 

$

2,415

 

Accounts receivable

 

 

1,085

 

 

$

598

 

$

4,242

 

Current liabilities

 

119

 

2,041

 

Billings in excess of costs and estimated earnings

 

$

1,480

 

$

2,572

 

Accounts payable

 

$

759

 

$

602

 

Due to Primoris

 

$

7,428

 

$

2,035

 

 

We participated in the Blythe joint venture created for the installation of a parabolic trough solar field and steam generation system in California, which was also determined to be a VIE and we were determined to be the primary beneficiary as a result of our significant influence over the joint venture operations. The net assetsBlythe joint venture project was completed; the project warranty expired in May 2015 and dissolution of the joint venture are restricted for use bywas completed in the projectthird quarter 2015. Revenues and are not available for general operations ofnet income attributable to the Company.joint venture were immaterial in 2015.

 

The following table summarizes the total balance sheet amounts for the two joint ventures, which are included in our Consolidated Balance Sheets( in thousands):

 

 

 

 

 

 

 

 

 

 

Joint Venture

 

Consolidated

 

At December 31, 2017

 

Amounts

 

Amounts

 

Cash

 

$

60,256

 

$

170,385

 

Accounts receivable

 

$

15,941

 

$

358,175

 

Accounts payable

 

$

13,111

 

$

140,943

 

Billings in excess of costs and estimated earnings

 

$

44,223

 

$

159,034

 

 

 

 

 

 

 

 

 

At December 31, 2016

 

 

 

 

 

 

 

Cash

 

$

7,045

 

$

135,823

 

Accounts receivable

 

$

4,242

 

$

388,000

 

Costs and estimated earnings in excess of billings

 

$

124

 

$

138,618

 

Accounts payable

 

$

888

 

$

168,110

 

Billings in excess of costs and estimated earnings

 

$

5,998

 

$

112,606

 

F-30


Note 14—13—Commitments and Contingencies

 

LeasesThe Company leasesWe lease certain property and equipment under non-cancelable operating leases, which expire at various dates through 2023.2024.  The leases require the Companyus to pay all taxes, insurance, maintenance, and utilities and are classified as operating leases in accordance with ASC Topic 840 “Leases”.

 

The future minimum lease payments required under non-cancelable operating leases are as follows:follows (in thousands):

For the Years Ending
December 31,

 

Real
Property

 

Real
Property
(Related
Party)

 

Equipment

 

Total
Commitments

 

2015

 

$

3,540

 

$

1,449

 

$

7,048

 

$

12,037

 

2016

 

2,771

 

1,469

 

2,614

 

6,854

 

2017

 

2,585

 

1,437

 

1,278

 

5,300

 

2018

 

2,212

 

1,146

 

501

 

3,859

 

2019

 

1,070

 

879

 

454

 

2,403

 

Thereafter

 

335

 

2,782

 

554

 

3,671

 

 

 

$

12,513

 

$

9,162

 

$

12,449

 

$

34,124

 

Leases identified above as related party leases represent property with entities related through common ownership by stockholders, officers, and directors of the Company.

 

 

 

 

 

 

 

 

 

 

 

 

    

 

 

    

 

 

    

 

 

 

 

 

 

 

 

 

 

 

 

 

 

For the Years Ending

 

Real

 

 

 

 

Total

 

December 31, 

 

Property

 

Equipment

 

Commitments

 

2018

 

$

5,027

 

$

13,581

 

$

18,608

 

2019

 

 

3,900

 

 

9,314

 

 

13,214

 

2020

 

 

2,464

 

 

5,563

 

 

8,027

 

2021

 

 

1,428

 

 

2,667

 

 

4,095

 

2022

 

 

331

 

 

11

 

 

342

 

Thereafter

 

 

 —

 

 

 —

 

 

 —

 

 

 

$

13,150

 

$

31,136

 

$

44,286

 

 

Total lease expense during the years ended December 31, 2014, 20132017, 2016 and 20122015 was $14,325, $14,533$25.5 million, $22.5 and $10,684, respectively, including amounts paid to related parties of $1,505, $1,556 and $1,342,$21.8 million, respectively.

 

Withdrawal liability for multiemployer pension planIn November 2011, Rockford and ARB, along with other members of the Pipe Line Contractors Association (“PLCA”)“PLCA” including ARB, Rockford and Q3C (prior to our acquisition in 2012), withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan (the “Plan”(“Plan”).  The Company withdrew from the PlanThese withdrawals were made in order to mitigate itsadditional liability in connection with the Plan, which is significantly underfunded.  The Companyunderfunded Plan.  We recorded a liability of $7,500 based on information provided by the Plan.  However, the Plan has asserted that the PLCA members did not affect a proper withdrawal in 2011.  The Company believes that a legally effective withdrawal occurred in November 2011 and has recorded the withdrawal liability on that basis.  In May 2014, the Plan asserted that the liability was $11.7 million.  Without agreeing to the amount and while initiating an appeal, the Company has made monthly payments, which are being expensed, including interest, totaling $733 through December 31, 2014.

Prior to the Company’s acquisition, Q3C had also withdrawn from the Plan.  In November 2012, Q3C estimated a withdrawal liability of $85.  In$7.5 million, which was increased to $7.6 million after the acquisition of Q3C.  During the first quarter of 2013, the Plan asserted that2016, we received a final payment schedule.  As a result of payments made and based on this schedule, the liability was $119.  Without agreeing to the amount, Q3C has made monthly payments, including interest, totaling $30 throughrecorded at December 31, 2014.

Letters of creditAs of December 31, 20142017 and 2013,2016 was $4.7 million and $5.7 million, respectively. We expect to pay the Company had total letters of credit outstanding of approximately $6,864remaining liability balance during 2018, and $7,696, respectively.  The outstanding amounts include the U.S. dollar equivalents for letters of credit issued in Canadian dollars.have no plans to withdraw from any other labor agreements.

 

LitigationNTTA settlementOn February 7, 2012, the Company waswe were sued in an action entitled North Texas Tollway Authority (“NTTA”), Plaintiff v. James Construction Group, LLC, and KBR, Inc., Defendants, v. Reinforced Earth Company, Third-Party Defendant (the “Lawsuit”). In the Lawsuit, the North Texas Tollway Authority (“NTTA”) alleged damages to a road and retaining wall that were constructed in 1999 on the George Bush Turnpike near Dallas, Texas, due to negligent construction by JCG.  The Lawsuit claimed

F-27



Table of Contents

that the cost to repair the retaining wall was approximately $5,400.  The NTTA also alleged that six other walls constructed on the project by JCG had the same potential exposure to failure.  For the past 18 months, the Company participated in Court-ordered mediation, and onOn February 25, 2015 the Lawsuit was settled, and we recorded a liability for an$17.0 million. A second defendant agreed to provide up to $5.4 million to pay for the total expected remediation cost of approximately $22.4 million.  We will use our settlement obligation to pay for a third-party contractor approved by the CompanyNTTA.  In the event that the total remediation costs exceed the $22.4 million, the second defendant would pay 20% of $9the excess amount and we would pay for 80% of the excess amount.  During 2017, we increased our liability by $1.9 million. During the years endedAs of December 31, 2014, 2013, and 2012, the Company recorded liability amounts of $3,000, $4,500 and $1,500, respectively.  The amounts recorded were the approximate amounts that the Company allocated2017, we have spent $3.7 million for negotiation purposes in the mediation process.remediation.  At December 31, 2017, our remaining accrual balance was $15.2 million.   

 

At December 31, 2014, the Company isLitigationWe have been engaged in dispute resolution to enforce collectioncollect money we believe we are owed for twoone construction projectsproject completed by the Company  in 2014.  Because of uncertainties associated with the project, including uncertainty of the amounts that would be collected, we used a zero profit margin approach to recording revenues during the construction period for the project.

For onethe project, a cost reimbursable contract, the Company haswe have recorded a receivable of $33.8$32.9 million and for the other project, the Company has recordedwith a receivable of $29.3 million.  At December 31, 2014, the Company has not recorded revenues in excess of cost for these two projects, however, the Company has specific reservesreserve of approximately $27$17.9 million included in “billings“Billings in excess of costs and estimated earnings.  At this time, the Companywe cannot predict the amount that itwe will collect nor the timing of any collection. The dispute resolution for the receivable initially required international arbitration; however, in the first half of 2016, the owner sought bankruptcy protection in U.S. bankruptcy court. We have initiated litigation against the sureties who have provided lien and stop payment release bonds for the total amount owed. A trial date has been tentatively set for the second quarter of 2018. 

F-31


Table of Contents

 

The Company isWe had been engaged in dispute resolution to collect money we believed was owed to us for another construction project completed  in 2014. During the third quarter 2016, we settled the dispute with an exchange of general releases and receipt of $38.0 million in cash.  We changed our zero estimate of profit and accounted for the settlement as a change in accounting estimate which resulted in recognizing revenues of approximately $27.5 million and gross profit of approximately $26.7 million in the third quarter of 2016.

We are subject to other claims and legal proceedings arising out of itsour business. The Company providesWe provide for costs related to contingencies when a loss from such claims is probable and the amount is reasonably determinable.estimable. In determining whether it is possible to provide an estimate of loss, or range of possible loss, the Company reviewswe review and evaluates itsevaluate our litigation and regulatory matters on a quarterly basis in light of potentially relevant factual and legal developments. If we determine an unfavorable outcome is not probable or reasonably estimable, we do not accrue for a potential litigation loss.

Management is unable to ascertain the ultimate outcome of other claims and legal proceedings; however, after review and consultation with counsel and taking into consideration relevant insurance coverage and related deductibles/self-insurance retention, management believes that it has meritorious defense to the claims and believes that the reasonably possible outcome of such claims will not, individually or in the aggregate, have a materially adverse effect on theour consolidated results of operations, financial condition or cash flowsflow.

SEC InquiryWe have been cooperating with an inquiry by the staff of the Company.Securities and Exchange Commission which appears to be focused on certain percentage-of-completion contract revenue recognition practices of the Company during the time period 2013 and 2014.  We are continuing to respond to the staff’s inquiries in connection with this matter.  At this stage, we are unable to predict when the staff’s inquiry will conclude or the outcome.

 

BondingAs of December 31, 2014, 20132017 and 2012, the Company2016, we had bid and completion bonds issued and outstanding totaling approximately $1,518,018, $1,458,744$705.7 million and $1,298,589,$680.0 million, respectively.

 

Note 15—14—Reportable Operating Segments

 

For a number of years and throughThrough the end of the second quarter 2014, the Companyyear 2016, we segregated itsour business into three operatingreportable segments: the Energy segment, the East Construction Services segment and the West Construction Services segment and the Engineering segment. In the thirdfirst quarter 2014, the Company reorganized its business2017, we changed our reportable segments to match the change in the Company’sconnection with a realignment of our internal organization and management structure. The segment changes during the quarter reflect the focus of our new chief operating officerCODM on the range of services we provide to our energy related customers, primarily in the Gulf Coast area (the “Energy segment”) and a continuing geographic view for the West and East segments. The chief operating officerend user markets. Our CODM regularly reviews the Company’sour operating and financial performance usingbased on these revised segments.

The operatingcurrent reportable segments include:include the West Construction Services segment (“West segment”), which is unchanged from the previousPower segment, the East Construction ServicesPipeline segment, (“East segment”), which is realigned from the previous East Construction ServicesUtilities segment, and the Energy segment (which includes the previous Engineering segment).  AllCivil segment. Segment information for prior period amounts related to the segment change haveperiods has been retrospectively reclassified throughout these consolidated financial statementsrestated to conform to the new segment presentation.

Each of our reportable segments is comprised of similar business units that specialize in services unique to the segment. Driving the new end-user focused segments are differences in the economic characteristics of each segment, the nature of the services provided by each segment; the production processes of each segment; the type or class of customer using the segment’s services; the methods used by the segment to provide the services; and the regulatory environment of each segment’s customers.

The classification of revenues and gross profit for segment reporting purposes can at times require judgment on the part of management. Our segments may perform services across industries or perform joint services for customers in multiple industries. To determine reportable segment gross profit, certain allocations, including allocations of shared and indirect costs, such as facility costs, equipment costs and indirect operating expenses were made.

The following is a brief description of each of the Company’s reportable segments and business activities.segments:

 

The WestPower segment includes the underground and industrial operations and construction services performed by ARB, ARB Structures, Inc., Rockford, Alaska Continental Pipeline, Inc., Q3C, Primoris Renewables, LLC, Juniper Rock Corporation, Stellaris, LLC and Vadnais, acquired in June 2014.  Most of the entities perform work primarily in California; however, Rockford operates throughout the United States and Q3Cspecializes in a range of services that include full EPC project delivery, turnkey construction, retrofits, upgrades, repairs, outages, and maintenance for entities in the petroleum, petrochemical, water, and other industries.

F-32


Table of Contents

The Pipeline segment operates throughout the United States and specializes in Coloradoa range of services, including pipeline construction, pipeline maintenance, pipeline facility work, compressor stations, pump stations, metering facilities, and other pipeline related services for entities in the petroleum and petrochemical industries.

The Utilities segment operates primarily in California, the Midwest, and the upper Midwest United States.  The Blythe joint venture is also included as a partSoutheast regions of the segment.  United States and specializes in a range of services, including utility line installation and maintenance, gas and electric distribution, streetlight construction, substation work, and fiber optic cable installation.

The WestCivil segment consists of businesses headquarteredoperates primarily in the western United States.

The East segment includesSoutheastern and Gulf Coast regions of the JCG Heavy Civil division, the JCG Infrastructure and Maintenance division, BW Primoris and the Cardinal Contractors, Inc. construction business, located primarily in the southeastern United States and specializes in the Gulf Coast region of the United States.

The Energy segment businesses are located primarily in the southeastern United Stateshighway and in the Gulf Coast region of the United States.  The segment includes the operations of the PES pipelinebridge construction, airport runway and gas facilitytaxiway construction, demolition, heavy earthwork, soil stabilization, mass excavation, and maintenance operations, the JCG Industrial division and the newly acquired Surber and Ram-Fab operations.  Additionally, the segment includes the OnQuest, Inc. and OnQuest Canada, ULC operations for the design and installation of high-performance furnaces and heaters for the oil refining, petrochemical and power generation industries.

F-28



Table of Contentsdrainage projects.

 

All intersegment revenues and gross profit, which were immaterial, have been eliminated in the following tables.

 

Segment Revenues

 

Revenue by segment for the years ended December 31, 2014, 20132017, 2016 and 20122015 was as follows:follows (in thousands):

 

 

 

Year Ended December 31,

 

 

 

2014

 

2013

 

2012

 

Business Segment

 

Revenue

 

% of
Revenue

 

Revenue

 

% of
Revenue

 

Revenue

 

% of
Revenue

 

West

 

$

964,093

 

46.2

%

$

1,151,433

 

59.2

%

$

832,860

 

54.0

%

East

 

489,926

 

23.5

%

430,438

 

22.1

%

469,963

 

30.5

%

Energy

 

632,175

 

30.3

%

362,349

 

18.7

%

238,911

 

15.5

%

Total

 

$

2,086,194

 

100.0

%

$

1,944,220

 

100.0

%

$

1,541,734

 

100.0

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

2015

 

 

 

 

 

 

% of

 

 

 

 

% of

 

 

 

 

% of

 

 

 

 

 

 

Total

 

 

 

 

Total

 

 

 

 

Total

 

Segment

    

Revenue

    

Revenue

    

Revenue

    

Revenue

 

Revenue

 

Revenue

 

Power

 

$

606,125

 

25.5%

 

$

478,653

 

24.0%

 

$

466,292

 

24.2%

 

Pipeline

 

 

465,570

 

19.5%

 

 

401,931

 

20.1%

 

 

299,365

 

15.5%

 

Utilities

 

 

806,523

 

33.9%

 

 

637,212

 

31.9%

 

 

587,047

 

30.4%

 

Civil

 

 

501,777

 

21.1%

 

 

479,152

 

24.0%

 

 

576,711

 

29.9%

 

Total

 

$

2,379,995

 

100.0%

 

$

1,996,948

 

100.0%

 

$

1,929,415

 

100.0%

 

 

Segment Gross Profit

 

Gross profit by segment for the years ended December 31, 2014, 20132017, 2016 and 20122015 was as follows:follows (in thousands):

 

 

 

Year Ended December 31,

 

 

 

2014

 

2013

 

2012

 

Business Segment

 

Gross Profit

 

% of
Segment
Revenue

 

Gross Profit

 

% of
Segment
Revenue

 

Gross Profit

 

% of
Segment
Revenue

 

West

 

$

143,468

 

14.9

%

$

190,747

 

16.6

%

$

119,328

 

14.3

%

East

 

25,749

 

5.3

%

24,309

 

5.6

%

40,185

 

8.6

%

Energy

 

66,823

 

10.6

%

40,959

 

11.3

%

33,197

 

13.9

%

Total

 

$

236,040

 

11.3

%

$

256,015

 

13.2

%

$

192,710

 

12.5

%

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

2015

 

 

    

 

 

    

% of

    

 

 

    

% of

 

 

 

    

% of

 

 

 

 

 

 

Segment

 

 

 

 

Segment

 

 

 

 

 

 

Segment

 

Gross Profit

 

Revenue

 

Gross Profit

 

Revenue

 

Gross Profit

 

Revenue

 

Power

 

$

65,675

 

10.8%

 

$

49,807

 

10.4%

 

$

53,620

 

11.5%

 

Pipeline

 

 

92,087

 

19.8%

 

 

68,100

 

16.9%

 

 

24,685

 

8.2%

 

Utilities

 

 

113,037

 

14.0%

 

 

100,071

 

15.7%

 

 

96,450

 

16.4%

 

Civil

 

 

7,635

 

1.5%

 

 

(16,671)

 

(3.5%)

 

 

45,118

 

7.8%

 

Total

 

$

278,434

 

11.7%

 

$

201,307

 

10.1%

 

$

219,873

 

11.4%

 

 

Segment Goodwill

The amount of goodwill recorded by segment at December 31, 2014 and 2013 was as follows:

Segment

 

2014

 

2013

 

West

 

$

45,239

 

$

45,239

 

East

 

43,267

 

43,267

 

Energy

 

30,904

 

30,120

 

Total

 

$

119,410

 

$

118,626

 

Geographic Region — Revenues and Total Assets

 

The majority of the Company’sour revenues are derived from customers in the United States and less thanwith approximately 1% is generated from sources outside of the United States.  ApproximatelyAt December 31, 2017 and 2016, approximately 1% of total assets were located outside of the United States.

 

Note 16—15—Customer Concentrations

 

The Company operatesWe operate in multiple industry segments encompassing the construction of commercial, industrial, and public works infrastructure assets primarily throughout primarily the United States.  Typically, the top ten customers in any one calendar year generate revenues in excess of 50% of total revenues and consist of a different group of customers in each year.

 

F-29


F-33



Table of Contents

During the years ended December 31, 2014, 20132017, 2016 and 2012, the Company2015, we generated 36.4%38.4%, 35.6%45.6% and 44.0%48.9%, of itsour revenues, respectively, from the following customers:customers (in thousands):

 

Description of
Customer’s

 

2014

 

2013

 

2012

 

Business

 

Amount

 

Percentage

 

Amount

 

Percentage

 

Amount

 

Percentage

 

Texas DOT

 

$

183,221

 

8.8

%

$

140,458

 

7.2

%

$

88,783

 

5.8

%

Petrochemical producer

 

164,634

 

7.9

%

*

 

*

 

*

 

*

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

2017

 

2016

 

2015

 

Description of Customer's Business

    

Segment

    

Amount

    

Percentage

    

Amount

    

Percentage

    

Amount

    

Percentage

 

State DOT

 

Civil

 

$

222,142

 

9.3%

 

$

193,049

 

9.7%

 

$

183,847

 

9.5%

 

Public gas and electric utility

 

Utilities

 

 

210,747

 

8.9%

 

 

184,002

 

9.2%

 

 

120,507

 

6.2%

 

Private gas and electric utility

 

145,677

 

7.0

%

104,828

 

5.4

%

*

 

*

 

 

Utilities

 

 

190,659

 

8.0%

 

 

201,443

 

10.1%

 

 

173,232

 

9.0%

 

Public gas and electric utility

 

144,567

 

6.9

%

153,908

 

7.9

%

224,845

 

14.6

%

Chemical/Energy producer

 

Power/Civil

 

 

160,995

 

6.8%

 

 

208,458

 

10.4%

 

 

173,931

 

9.0%

 

Pipeline operator

 

Pipeline

 

 

128,182

 

5.4%

 

 

*

 

*

 

 

*

 

*

 

Pipeline operator

 

Pipeline

 

 

*

 

*

 

 

123,055

 

6.2%

 

 

*

 

*

 

Pipeline operator

 

121,220

 

5.8

%

*

 

*

 

*

 

*

 

 

Pipeline

 

 

*

 

*

 

 

*

 

*

 

 

165,578

 

8.6%

 

Gas utility

 

*

 

*

 

143,171

 

7.4

%

86,786

 

5.6

%

 

Utilities

 

 

*

 

*

 

 

*

 

*

 

 

127,128

 

6.6%

 

Private gas and electric utility

 

*

 

*

 

*

 

*

 

106,804

 

6.9

%

Gas utility

 

*

 

*

 

149,794

 

7.7

%

*

 

*

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

$

912,725

 

38.4%

 

$

910,007

 

45.6%

 

$

944,223

 

48.9%

 

Louisiana DOT

 

*

 

*

 

*

 

*

 

170,899

 

11.1

%

 

$

759,319

 

36.4

%

$

692,159

 

35.6

%

$

678,117

 

44.0

%

 


(*)Indicates a customer with less than 5% of revenues during such period.

 

For the years ended December 31, 2014, 20132017, 2016 and 2012,2015, approximately 53.6%56.4%, 50.0%60.4% and 55.9%59.4%, respectively, of total revenues were generated from theour top ten customers of the Company in that year.  In each of the years, a different group of customers comprised the top ten customers by revenue.

 

At December 31, 2014,2017, approximately 10.0%4.3% of the Company’sour accounts receivable were due from one customer, and that customer provided 4.0%8.9% of the Company’sour revenues for the year ended December 31, 2014.2017. At December 31, 2013,2016, approximately 7.0%20.8% of the Company’sour accounts receivable were due from one customer, and that customer provided 7.4%6.2% of the Company’sour revenues for the year ended December 31, 2013.2016.

 

Note 1716 — Multiemployer Plans

 

Union PlansVarious subsidiaries in the West segment are signatories to collective bargaining agreements.  These agreements require that the Companywe participate in and contribute to a number of multiemployer benefit plans for itsour union employees at rates determined by the agreements.  The trustees for each multiemployer plan determine the eligibility and allocations of contributions and benefit amounts, determine the types of benefits and administer the plan.

 

The CompanyWe contributed $38,107, $42,919$46.9 million, $34.2 million, and $30,103,$34.3 million, to multiemployer pension plans for the years ended December 31, 2014, 20132017, 2016 and 2012,2015, respectively. These costs were charged to the related construction contracts in process.  Contributions during 20132017 increased from 2012 noticeablythe prior years as a result of the November 2012 acquisition of Q3C and increased volume of project activity.  The decrease in 2014 compared to 2013 was due to a decreasean increase in the number of man-hours worked by our union labor.

 

For the Company, theThe financial risks of participating in multiemployer plans are different from single-employer plans in the following respects:

 

·

Assets contributed to the multiemployer plan by one employer may be used to provide benefits to employees of other participating employers.

·Assets contributed to the multiemployer plan by one employer may be used to provide benefits to employees of other participating employers.

·

If a participating employer stops contributing to the plan, the unfunded obligations of the plan may be borne by the remaining participating employers.

·

If a participating employer chooses to stop participating in the plan, a withdrawal liability may be created based on the unfunded vested benefits for all employees in the plan.

 

·If a participating employer stops contributing to the plan, the unfunded obligations of the plan may be borne by the remaining participating employers.

·If a participating employer chooses to stop participating in the plan, a withdrawal liability may be created based on the unfunded vested benefits for all employees in the plan.

Under U.S. legislation regarding multiemployer pension plans, a companyan employer is required to pay an amount that represents its proportionate share of a plan’s unfunded vested benefits in the event of withdrawal from a plan or upon plan termination. The Company participates

F-34


Table of Contents

We participate in a number of multiemployer pension plans, and itsour potential withdrawal obligation may be significant.  Any withdrawal liability would be recorded when it is probable that a liability exists and can be reasonably estimated, in accordance with GAAP.  As discussed in Note 14—13—Commitments and Contingencies,” in 2011 the Companywe withdrew from the Central States Southeast and Southwest Areas Pension Fund multiemployer pension plan.  The Company hasWe have no plans to withdraw from any other labor agreements.

 

During the last three years, the Companywe made annual contributions to 8278 pension plans.  OneNone of the pension plans that the Companywe contributed to in 20142017 and 2016 listed us in the Companyplan’s Form 5500 as providing more than 5% of the plan’s total contributions.  Two of the pension plans that we contributed to in 2015 listed us in the plan’s Form 5500 as providing more than 5% of the plan’s total contributions.  The contribution to thatone plan was $5,239$2.2 million and $0.5 million for the twelve months ending December 31, 2014.   Two pension plans listed the Company on their Form 5500 as providing more than 5% of the plan’s total 2013 contributions.  The contributions for the two plans amounted to $1,427 for the twelve months ending December 31, 2013.  For 2012, the Company was not listed on any Form 5500 as providing more than 5% of the plan’s total contributions.  second plan.

Our participation in significant plans for the yearyears ended December 31, 20142017, 2016 and 20132015 is outlined in the table below.  The “EIN/Pension Plan Number” column provides the Employer Identification Number (“EIN”) and the three digit plan number.  The zone status“Zone Status” is based on the latest information that we received

F-30



Table of Contents

from the plan and is certified by the plan’s actuary.  Among other factors, plans in the red zone are generally less than 65 percent funded, plans in the yellow zone are less than 80 percent funded, and plans in the green zone are at least 80 percent funded.  The “FIP/RP Status Pending/Implemented” column indicates plans for which a financial improvement plan (“FIP”) or a rehabilitation plan (“RP”) is either pending or has been implemented.  The “Surcharge Imposed” column includes plans in a red zone status that require a payment of a surcharge in excess orof regular contributions.  The next column lists the expiration date of theour collective bargaining agreement related to which the plan is subject.plan. The table follows:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Collective

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

FIP/RP

 

 

 

Bargaining

 

 

 

 

 

 

 

 

 

 

 

EIN /

 

Pension Protection Act

 

Status

 

 

 

Agreement

 

 

 

 

 

 

 

 

 

 

 

EIN /
Pension Plan

 

Pension Protection Act Zone
Status

 

FIP/RP
Status
Pending /

 

Surcharge

 

Collective
Bargaining
Agreement
Expiration

 

Contributions of the Company

 

 

Pension Plan

 

 Zone Status

 

Pending /

 

Surcharge

 

Expiration

 

Contributions of the Company

 

Pension Fund Name

 

Number

 

2014

 

2013

 

Implemented

 

Imposed

 

Date

 

2014

 

2013

 

2012

 

    

Number

    

2017

    

2016

    

Implemented

    

Imposed

    

Date

    

2017

    

2016

    

2015

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Central Pension Fund of the International Union of Operating Engineers and Participating Employers

 

36-6052390/001

 

Green as of February 1, 2013

 

Green as of February 1, 2012

 

No

 

No

 

5/31/2017

 

$

6,204

 

$

7,286

 

$

2,206

 

 

36-6052390/001

 

Green as of February 1, 2016

 

Green as of February 1, 2015

 

No

 

No

 

5/31/2020

 

$

7,562

 

$

5,373

 

$

5,659

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Pipeline Industry Benefit Fund

 

73-6146433/001

 

Green as of January 1, 2016

 

Green as of January 1, 2015

 

No

 

No

 

5/31/2020

 

 

6,050

 

 

2,740

 

 

3,783

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Laborers International Union of North America National (Industrial) Pension Fund

 

52-6074345/001

 

Red as of January 1, 2013

 

Red as of January 1, 2012

 

Yes

 

No

 

5/31/2017

 

3,382

 

5,025

 

1,995

 

 

52-6074345/001

 

Red as of January 1, 2016

 

Red as of January 1, 2015

 

No

 

No

 

5/31/2020

 

 

4,658

 

 

2,415

 

 

3,287

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Southern California Pipetrades Trust Funds

 

51-6108443/001

 

Green as of January 1, 2013

 

Green as of January 1, 2012

 

No

 

No

 

7/30/2016

 

5,239

 

6,179

 

5,298

 

 

51-6108443/001

 

Green as of January 1, 2016

 

Green as of January 1, 2015

 

No

 

No

 

9/30/2022

 

 

3,219

 

 

2,614

 

 

2,180

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Pipeline Industry Benefit Fund

 

73-6146433/001

 

Green as of January 1, 2013

 

Green as of January 1, 2012

 

No

 

No

 

5/31/2017

 

2,686

 

4,605

 

1,747

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Laborers Pension Trust Fund for Northern California

 

94-6277608/001

 

Yellow as of June 10, 2013

 

Yellow as of June 10, 2012

 

Yes

 

No

 

6/30/2019

 

3,116

 

3,869

 

4,816

 

 

94-6277608/001

 

Yellow as of June 1, 2016

 

Yellow as of June 1, 2015

 

No

 

No

 

6/30/2019

 

 

2,945

 

 

3,598

 

 

3,150

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Construction Laborers Pension Trust for Southern California

 

43-6159056/001

 

Green as of January 1, 2013

 

Green as of January 1, 2012

 

No

 

No

 

6/30/2015

 

2,444

 

2,951

 

2,952

 

National Pension Fund

 

52-6152779

 

Yellow as of  July 1 2017

 

Yellow as of  July 1 2016

 

No

 

No

 

9/30/2022

 

 

2,548

 

 

2,161

 

 

2,106

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Operating Engineer Trust Funds

    

95-6032478/001

    

Yellow as of July 1, 2016

    

Yellow as of July 1, 2016

    

No

    

No

    

6/30/2019

    

 

2,448

    

 

1,643

    

 

1,401

 

 

 

 

 

 

 

 

 Contributions to significant plans

 

$

23,071

 

$

29,915

 

$

19,014

 

 

 

 

 

 

 

 

Contributions to significant plans

 

 

29,430

 

 

20,544

 

 

21,566

 

 

 

 

 

 

 

 

Contributions to other multiemployer plans

 

15,036

 

13,004

 

11,089

 

 

 

 

 

 

 

 

Contributions to other multiemployer plans

 

 

17,505

 

 

13,639

 

 

12,730

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 Total contributions made

 

$

38,107

 

$

42,919

 

$

30,103

 

 

 

 

 

 

 

 

Total contributions made

 

$

46,935

 

$

34,183

 

$

34,296

 

 

Note 18—17—Company Retirement Plans

 

401(k) PlanThe Company providesWe provide a 401(k) plan for itsour employees not covered by collective bargaining agreements. Under the plan, employees are allowed to contribute up to 100% of their compensation, within the Internal Revenue Service (“IRS”) prescribed annual limit.  We make employer match contributions of 100% of the first 3% and 50% of the next 2% of employee contributions, which vest immediately. We may, at the discretion of our Board of Directors, make an additional profit share contribution to the 401(k) plan. No such contributions were made during 2015 through 2017. Our contributions to the plan for the years ended December 31, 2017, 2016 and 2015 were $4.1 million, $3.9 million, and $3.7 million, respectively.   

F-35


OnQuest Canada, ULC RRSP-DPSP PlanWe provide a RRSP-DPSP plan (Registered Retirement Saving Plan—Deferred Profit Sharing Plan) for our employees of OnQuest Canada, ULC. There are two components to the plan. The Company makesRRSP portion is contributed by the employee, while our portion is paid to the DPSP. Under this plan, we make employer match contributions of 100% of the first 3% and 50% of the next 2% of employee contributions. The Company may, atEmployees vest in the discretionDPSP portion after one year of its Board of Directors, make an additional profit shareemployment. Our contribution to the 401(k) plan.  The Company’s contribution to the plan forDPSP during each of the years ended December 31, 2014, 20132017, 2016 and 2012 were $3,111, $2,771 and $2,267, respectively.2015 was $0.1 million.

 

Effective January 1, 2011, the members of the JCG 401(k) plan became eligible for entry into the Company plan and the JCG plan was terminated.  Effective October 1, 2011, the members of the Rockford 401(k) plan became eligible for entry into the Company plan and the Rockford plan was terminated.

The members of the Q3C 401(k) plan became eligible for entry into the Company plan on December 31, 2013 and the Q3C plan was terminated.  Employees of the other acquisitions made by the Company in 2012 through 2014 had no 401(k) plans prior to the acquisitions, and their employees became eligible for the Company plan.

OnQuest Canada, ULC RRSP-DPSP PlanThe Company provides a RRSP-DPSP plan (Registered Retirement Saving Plan—Deferred Profit Sharing Plan) for its employees of OnQuest Canada, ULC, not covered by collective bargaining agreements. There are two components to the plan. The RRSP portion is contributed to by the employee, while the Company portion is paid to the DPSP. Under this plan, the Company makes employer match contributions of 100% of the first 3% and 50% of the next 2% of employee contributions. Vesting in the DPSP portion is one year of employment. The Company’s contribution to the DPSP during the years ended December 31, 2014, 2013 and 2012 was $69, $70 and $69, respectively.

The Company hasWe have no other post-retirement benefits.

 

F-31



Table of Contents

Note 19—18—Deferred Compensation Agreements and Stock-Based Compensation

 

Primoris Long-Term Retention Plan (“LTR Plan”) —  The CompanyWe adopted a long-term retention plan for certain senior managers and executives.  The voluntary plan provides for the deferral of one half of the participant’s annual earned bonus for one year.  ExceptGenerally, except in the case of death, disability or involuntary separation from service, the deferred compensation is vested to the participant only if actively employed by the Companyus on the payment date of bonus amounts the following year.  The amount of compensation deferred under this plan is calculated each year.  Total deferred compensation liability under this plan as of December 31, 20142017 and 20132016 was $4,779$5.7 million and $4,984,$4.5 million, respectively.

 

Participants in the long term retention plan may elect to purchase Companyour common stock at a discounted price.  For bonuses earned in 20142017 and 2013,2016, the participants could use up to one sixth of their bonus amount to purchase shares of stock, whosestock. The purchase price was calculated as 75% of the average market closing price for the month of December 20142017 and 2013,January 2017, respectively.  The 25% discount is treated as compensation to the participant.

 

JCG Stakeholder Incentive Plan — In December 2014 and 2013, JCG maintained a deferred compensation plan for some senior management employees.  The plan provided for annual vesting over a five-year period.  Once vested and upon a triggering event, such as termination, death or disability, the deferred benefit amount plus interest is paid in equal monthly installments over three years.  The amount of compensation deferred under the plan is calculated each year.  In 2014, the terms of the plan were changed, and all accrued amounts will be paid to the employees as part of the LTR plan with 50% of the accrued amount added to the LTR payments to be made in 2015 and the remainder added to LTR payments to be made in 2016.  Total deferred compensation liability under this plan at December 31, 2014 and 2013 was $599 and $1,755, respectively.

Stock-based compensation —  In July 2008,May 2013, the shareholders approved and the Companywe adopted the Primoris Services Corporation 2008 Long-term Incentive Equity Plan, which was replaced by the Primoris Services Corporation 2013 Long-term Incentive Equity Plan (“Equity Plan”), after approval by the shareholders and adoption by the Company on May 3, 2013.

On May 3, 2013, the. Our Board of Directors has granted 100,000259,065 Restricted Stock Units (“Units”) to an executiveexecutives under the 2013 Long-term Incentive Equity Plan (the “Equity Plan”).  Commencing annually on May 10, 2014Plan. The grants were documented in RSU Award Agreements which provide for a vesting schedule and ending April 30, 2017, the Units will vest in four equal installments subject torequire continuing employment of the executive.  On May 10, 2014, 25,000 of these Units vested.  On March 24, 2014, the Board of Directors granted 48,512 Units to another executive under the Equity Plan.  The Units will vest 50% on September 23, 2015 and 50% on March 23, 2017, subject to continuing employment of the executive.  Vesting in both grants is alsoare subject to earlier acceleration, termination, cancellation or forfeiture as provided in the underlying Primoris Restricted Stock Unit agreement (“RSU Award Agreement”).  Each Unit representsAgreement.  The table below presents the right to receive one shareUnits activity for 2017:

 

 

 

 

 

 

 

Nonvested RSUs

    

Units

    

Weighted Average Grant Date Fair Value per Unit

 

Balance at December 31, 2016

 

149,809

 

$

24.70

 

Granted

 

10,000

 

 

22.90

 

Vested

 

(74,394)

 

 

25.53

 

Balance at December 31, 2017

 

85,415

 

 

23.76

 

During 2016, 100,553 Units were granted with a weighted-average grant-date fair value per unit of the Company’s common stock when vested.$23.87. There were no Units granted during 2015. The total fair value of Units that vested during 2017, 2016 and 2015 was $1.7 million, $0.6 million and $0.9 million, respectively

 

At December 31, 2017, a total of 173,650 Units were vested.  The vesting schedule for the remaining Units follows:

 

 

 

 

 

Number of Units

For the Years Ending December 31, 

 

to Vest

2018

 

28,471

2019

 

51,552

2020

 

5,392

 

 

85,415

F-36


Table of Contents

Under guidance of ASC Topic 718 “Compensation — Stock Compensation”, stock-based compensation cost is measured at the date of grant, (utilizing the prior-day closing price), based on the calculated fair value of the stock-based award, and is recognized as expense over the employee’s requisite service period (generally the vesting period of the award).

 

The fair value of the Units was based on the closing market price of our common stock on the day prior to the date of the grant. Stock compensation expense for the Units is being amortized using the straight-line method over the service period. For the yearstwelve months ended December 31, 20142017, 2016, and 2013, the Company2015, we recognized $934$1.1 million, $1.6 million, and $366,$1.1 million respectively, in compensation expense.  At December 31, 2014,2017, approximately $2.4$1.2 million of unrecognized compensation expense remains for the Units, which will be recognized over the next 2.3 years through April 30, 2017.a weighted average period of 1.6 years.

 

Vested Units accrue “Dividend Equivalents” (as defined in the Equity Plan) which will be accrued as additional Units.  At December 31, 2014, there were 1102017, a total of 3,097 Dividend Equivalent Units that were accrued on 25,000 Units that vested on April 30, 2014.accrued. 

 

Note 20—19—Related Party Transactions

 

Primoris has entered into leasing transactions withPrior to March 2017, we leased three properties in California from Stockdale Investment Group, Inc. (“SIGI”).  Brian Pratt, our Chief Executive Officer, President andOur Chairman of the Board of Directors, andwho is our largest stockholder, holdsand his family hold a majority interest and is the chairman, president and chief executive officer and a director of SIGI.  John M. Perisich,In March 2017, we exercised a right of first refusal and purchased the SIGI properties.  The purchase was approved by our Executive Vice President and General Counsel, is secretaryBoard of SIGI.

Primoris leases properties from SIGI atDirectors for $12.8 million.  We assumed three mortgage notes totaling $4.2 million with the following locations:

1.Bakersfield, California (lease expires October 2022)

2.Pittsburg, California (lease expires April 2023)

3.San Dimas, California (lease expires March 2019)

4.Pasadena, Texas (lease was mutually terminated as of August 31, 2014)

F-32



Table of Contents

remainder paid in cash. During the years ended December 31, 2014, 20132017, 2016 and 2012, the Company2015, we paid $862, $907$0.2 million, $0.8 million, and $929,$0.8 million, respectively, in lease payments to SIGI for the use of these properties.

 

Primoris leases a propertyWe lease properties from Roger Newnham, a former ownerother individuals that are current employees. The amounts leased are not material and current managereach arrangement was approved by the Board of our subsidiary, OnQuest Canada, ULC.  The property is located in Calgary, Canada.  During the years ended December 31, 2014, 2013 and 2012 Primoris paid $289, $295 and $292, respectively, in lease payments.  The current term of the lease is through December 31, 2017.Directors. 

 

Primoris leases a property from Lemmie Rockford, one of the Rockford sellers, which commenced November 1, 2011.  The property is located in Toledo, Washington.  During the years ended December 31, 2014, 2013 and 2012, Primoris paid $90, $90 and $90, respectively, in lease payments.  The current term of the lease is through January 13, 2016.

Primoris leases a property from Quality RE Partners, owned by three of the Q3C selling shareholders, of whom two are current employees, including Jay Osborn, President of Q3C.  The property is located in Little Canada, Minnesota.  During the years ended December 31, 2014 and 2013, the Company paid $264 and $264, respectively, in lease payments to Quality RE Partners.  The lease expires in October 2022.

As discussed in Note 8— “Equity Method Investments”, the Company owns several non-consolidated investments and has recognized revenues on work performed by the Company for those joint ventures.

Note 21—20—Income Taxes

 

The components of the provision for income taxes are as follows:follows (in thousands):

 

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

2012

 

    

2017

    

2016

    

2015

 

Current provision (benefit)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Federal

 

$

28,203

 

$

41,323

 

$

27,524

 

 

$

21,509

 

$

4,726

 

$

26,948

 

State

 

5,398

 

10,051

 

7,125

 

 

 

3,371

 

 

5,423

 

 

3,640

 

Foreign

 

1,074

 

772

 

67

 

 

 

(188)

 

 

92

 

 

362

 

 

$

34,675

 

$

52,146

 

$

34,716

 

 

 

 

 

 

 

 

 

 

24,692

 

 

10,241

 

 

30,950

 

Deferred provision (benefit)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Federal

 

3,586

 

(6,099

)

(451

)

 

 

1,958

 

 

11,560

 

 

(7,099)

 

State

 

457

 

(874

)

(366

)

 

 

1,219

 

 

(727)

 

 

155

 

Foreign

 

(72

)

67

 

(62

)

 

 

(36)

 

 

72

 

 

(60)

 

 

3,971

 

(6,906

)

(879

)

 

 

3,141

 

 

10,905

 

 

(7,004)

 

Change in valuation allowance

 

 

(344

)

 

 

 

600

 

 

 —

 

 

 —

 

Total

 

$

38,646

 

$

44,896

 

$

33,837

 

 

$

28,433

 

$

21,146

 

$

23,946

 

 

F-37


Table of Contents

A reconciliation of income tax expense compared to the amount of income tax expense that would result by applying the U.S. statutory federal statutory income tax rate related to pre-taxpretax income to the effective tax rate for the periods indicated is as follows:

 

 

 

2014

 

2013

 

2012

 

U.S. federal statutory income tax rate

 

35.00

%

35.00

%

35.00

%

State taxes, net of federal income tax impact

 

4.66

%

4.72

%

4.87

%

Foreign tax credit

 

(0.98

)%

(0.73

)%

(0.01

)%

Canadian income tax

 

0.98

%

0.73

%

0.01

%

Domestic production activities deduction

 

(3.07

)%

(3.67

)%

(2.97

)%

Nondeductible meals & entertainment

 

3.38

%

2.58

%

2.12

%

Other items

 

(2.01

)%

0.56

%

(1.67

)%

Effective tax rate on income before provision for income taxes excluding income attributable to noncontrolling interests

 

37.96

%

39.19

%

37.35

%

Impact of income from noncontrolling interests on effective tax rate

 

(0.19

)%

(1.65

)%

(0.61

)

Effective tax rate on income before provision for income taxes and noncontrolling interests

 

37.77

%

37.54

%

36.74

%

F-33


 

 

 

 

 

 

 

 

 

    

2017

    

2016

    

2015

 

U.S. federal statutory income tax rate

 

35.0 %

 

35.0 %

 

35.0 %

 

State taxes, net of federal income tax impact

 

2.9 %

 

6.4 %

 

4.2 %

 

Foreign tax credit

 

0.0 %

 

(0.4)%

 

(0.5)%

 

Canadian income tax (benefit) provision

 

(0.2)%

 

0.4 %

 

0.5 %

 

Domestic production activities deduction

 

(2.3)%

 

(1.1)%

 

(3.9)%

 

Nondeductible meals & entertainment

 

2.8 %

 

5.4 %

 

5.1 %

 

Other items

 

(0.7)%

 

(1.5)%

 

(1.0)%

 

Effective tax rate excluding the impact of the Tax Act and income attributable to noncontrolling interests

 

37.5 %

 

44.2 %

 

39.4 %

 

Deferred tax liability remeasurement benefit from the Tax Act

 

(9.3)%

 

0.0 %

 

0.0 %

 

Effective tax rate excluding income attributable to noncontrolling interests

 

28.2 %

 

44.2 %

 

39.4 %

 

Impact of income from noncontrolling interests on effective tax rate

 

(1.2)%

 

(0.9)%

 

(0.2)%

 

Effective tax rate

 

27.0 %

 

43.3 %

 

39.2 %

 


Table of Contents

 

Deferred income taxes are recognized for temporary differences between the financial reporting basisbases and tax bases of the assets and liabilities and their respective tax basis and operating losses, capital losses and tax credit carry-forwards based on enacted tax rates expected to be in effect when such amounts are realized or settled. However, deferred tax assets are recognized only to the extent that it is more likely than not that they will be realized based upon consideration of available evidence, including future reversals of existing taxable temporary differences, future projected taxable income, the length of the tax asset carryforward periods, and tax planning strategies.

 

During 2009, the Company recognized a capital loss related to the sale of its equity interest in ARB Arendal. A valuation allowance of $344 was provided against the Company’s deferred taxSAB 118 provides guidance on accounting for its capital loss carryforward as the Company believed that it was more likely than not that this capital loss would not be realized.  However, in the 2012 tax year, the Company generated sufficient capital gain to utilize the capital loss carryforward, resulting in the utilizationuncertainties of the deferred tax asset and removaleffects of the related valuation allowance.  No valuation allowance has been providedTax Act.  Specifically, SAB 118 allows companies to record provisional estimates of the Company’s remainingimpact of the Tax Act during a one year “measurement period” similar to that used when accounting for business combinations. 

As a result of the Tax Act, we remeasured deferred tax assets asand liabilities using the Company believes itnewly enacted tax rates and recorded a one-time net tax benefit of $9.4 million in the period ended December 31, 2017. This tax benefit is more likely than nota provisional estimate that these deferredcould be revised once we finalize our deductions for tax assets will be realized.depreciation and executive compensation accruals. We may also revise our estimate based on any additional guidance issued by the U.S. Treasury Department, the U.S. Internal Revenue Service, and other standard-setting bodies.

 

F-38


Table of Contents

The tax effect of temporary differences that give rise to deferred income taxes for the yearyears ended December 31, 20142017 and 20132016 are as follows:follows (in thousands):

 

 

 

 

 

 

 

 

 

2014

 

2013

 

    

2017

    

2016

 

Deferred tax assets:

 

 

 

 

 

 

 

 

 

 

 

 

Accrued compensation

 

$

3,323

 

$

5,804

 

Accrued workers compensation

 

$

6,460

 

$

6,561

 

 

 

6,197

 

 

9,855

 

Insurance reserves

 

3,698

 

3,448

 

Other accrued liabilities

 

15,729

 

20,466

 

State income taxes

 

654

 

1,551

 

Capital loss carryforward

 

1,139

 

 

 

 

 —

 

 

1,077

 

Foreign tax credit

 

575

 

522

 

 

 

1,456

 

 

1,349

 

Insurance reserves

 

 

2,544

 

 

3,248

 

Loss reserves

 

 

2,215

 

 

4,841

 

Pension liability

 

 

 —

 

 

1,979

 

State income taxes

 

 

2,233

 

 

2,011

 

Other

 

 

202

 

 

288

 

Total deferred tax assets

 

28,255

 

32,548

 

 

 

18,170

 

 

30,452

 

Deferred tax liabilities

 

 

 

 

 

 

 

 

 

 

 

 

Depreciation and amortization

 

(33,657

)

(28,844

)

 

 

(30,555)

 

 

(38,327)

 

Prepaid expenses and other

 

(527

)

(663

)

 

 

(586)

 

 

(1,955)

 

Total deferred tax liabilities

 

(34,184

)

(29,507

)

 

 

(31,141)

 

 

(40,282)

 

Total

 

$

(5,929

)

$

3,041

 

 

 

 

 

 

 

 

Valuation allowance

 

 

(600)

 

 

 —

 

 

 

 

 

 

 

 

Net deferred tax liabilities

 

$

(13,571)

 

$

(9,830)

 

 

InAs of December 31, 2017, the third quartertax effects of 2014, the Internal Revenue Service concluded an examinationstate net operating loss carryforwards were $0.8 million, state tax credit carryforwards were $1.1 million, and foreign tax credit carryforwards were $1.5 million. These carryforwards will begin to expire in 2021, 2025, and 2019, respectively. We determined it is more likely than not that a portion of our federal incomedeferred tax returns for 2011 and 2012 which didasset related to foreign tax credits will be not havebe realized; a material impact on our financial statements.  The Company’s federal income tax returns are no longer subject to examination for tax years before 2013.  The statutesvaluation allowance of limitation of state and foreign jurisdictions vary generally between 3 to 5 years.  Accordingly, the tax years 2009 through 2013 generally remain open to examination by the other taxing jurisdictions in which the Company operates.$0.6 million was recorded.

 

A reconciliation of the beginning and ending amounts and aggregate changes in the balancegross balances of unrecognized tax benefits for each period is as follows:follows (in thousands):

 

 

2014

 

2013

 

2012

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

    

2017

    

2016

    

2015

 

Beginning balance

 

$

5,382

 

$

72

 

$

467

 

 

$

 —

 

$

 —

 

$

456

 

Increases in balances for tax positions taken during the current year

 

 

1,340

 

 

 

 

592

 

 

 —

 

 

 —

 

Increases in balances for tax positions taken during prior years

 

 

3,993

 

 

 

 

 —

 

 

 —

 

 

 —

 

Settlements and effective settlements with tax authorities

 

(4,878

)

 

 

 

 

 —

 

 

 —

 

 

(456)

 

Lapse of statute of limitations

 

(48

)

(23

)

(395

)

 

 

 —

 

 

 —

 

 

 —

 

Total

 

$

456

 

$

5,382

 

$

72

 

 

$

592

 

$

 —

 

$

 —

 

 

The unrecognized tax benefits, if recognized, would not have a material impact on the Company’s effective tax rate.

The Company recognizesWe recognize accrued interest and penalties related to uncertain tax positions in income tax expense, which were not material for the three years presented were not material.presented.

We believe it is reasonably possible that decreases between $0 and $0.1 million of unrecognized tax benefits could occur in the next twelve months due to the expiration of statutes of limitation.

Our federal income tax returns are generally no longer subject to examination for tax years before 2014.  The statutes of limitation of state and foreign jurisdictions generally vary between 3 to 5 years.  Accordingly, the tax years 2012 through 2016 remain open to examination by the other taxing jurisdictions in which we operate.

F-39


Table of Contents

Note 21—Dividends and Earnings Per Share

We have paid or declared cash dividends during 2016 and 2017 as follows:

Declaration Date

Record Date

Payable Date

Amount Per Share

February 22, 2016

March 31, 2016

April 15, 2016

$

0.055

May 2, 2016

June 30, 2016

July 15, 2016

$

0.055

August 3, 2016

September 30, 2016

October 14, 2016

$

0.055

November 2, 2016

December 31, 2016

January 16, 2017

$

0.055

February 21, 2017

March 31, 2017

April 15, 2017

$

0.055

May 5, 2017

June 30, 2017

July 14, 2017

$

0.055

August 2, 2017

September 29, 2017

October 14, 2017

$

0.055

November 2, 2017

December 29, 2017

January 15, 2018

$

0.060

The payment of future dividends is contingent upon our revenues and earnings, capital requirements and our general financial condition, as well as contractual restrictions and other considerations deemed relevant by the Board of Directors.

 

The Company does not anticipate that there will be a material change intable below presents the balance of the unrecognized tax benefits within the next 12 months.

F-34



Table of Contents

Note 22—Earnings Per Share

The computation of basic and diluted earnings per share for the years ended December 31, 2014, 20132017, 2016 and 2012 follows:2015 follows (in thousands, except per share amounts):

 

 

 

 

 

 

 

 

 

 

 

2014

 

2013

 

2012

 

 

2017

    

2016

    

2015

Numerator:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Net income

 

$

63,682

 

$

74,680

 

$

58,267

 

Net income attributable to noncontrolling interests

 

(526

)

(5,020

)

(1,511

)

Net income attributable to Primoris

 

$

63,156

 

$

69,660

 

$

56,756

 

 

$

72,354

 

$

26,723

 

$

36,872

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Denominator (shares in thousands):

 

 

 

 

 

 

 

Denominator:

 

 

 

 

 

 

 

 

 

Weighted average shares for computation of basic earnings per share

 

51,607

 

51,540

 

51,391

 

 

 

51,481

 

 

51,762

 

 

51,647

Dilutive effect of shares issued to independent directors

 

2

 

3

 

11

 

 

 

 3

 

 

 3

 

 

 2

Dilutive effect of unvested restricted stock units (1)

 

138

 

66

 

 

Dilutive effect of shares issued to Q3C sellers (2)

 

 

1

 

4

 

Dilutive effect of restricted stock units (1)

 

 

257

 

 

224

 

 

149

Weighted average shares for computation of diluted earnings per share

 

51,747

 

51,610

 

51,406

 

 

 

51,741

 

 

51,989

 

 

51,798

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share attributable to Primoris:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

$

1.22

 

$

1.35

 

$

1.10

 

 

$

1.41

 

$

0.52

 

$

0.71

Diluted

 

$

1.22

 

$

1.35

 

$

1.10

 

 

$

1.40

 

$

0.51

 

$

0.71


(1)

Represents the effect of the grant of 259,065 shares of Restricted Stock Units and 3,097 vested Dividend Equivalent Units.

 


(1)Represents the effect of the grant of 100,000 shares of Restricted Stock Units on May 3, 2013 and 48,512 Units on March 24, 2014.Note 22—Stockholders’ Equity

 

(2)Represents the effect of the 29,273 unregistered shares of common stock issued in February 2013 as part of the purchase consideration for the Q3C acquisition in 2012.Common Stock

 

Note 23—Stockholders’ Equity

Common Stock

The Company isWe are authorized to issue 90,000,000 shares of $0.0001 par value common stock, of which 51,561,39651,448,753 and 51,571,39451,576,442 shares were issued and outstanding as of December 31, 20142017 and 2013,2016, respectively. As of December 31, 2014,2017, there were 364365 holders of record of our common stock.

 

In March 2014, the Company received $1,671 for 77,455We issued 65,429 shares of common stock in 2017, 85,907 shares of common stock in 2016, and 96,828 shares of common stock in 2015 under our LTR Plan. The shares were purchased by the participants in the LTR Plan with payments made to us of $1.1 million in 2017, $1.4 million in 2016, and issued$1.6 million in accordance with the Company’s Long-Term Retention Plan (“LTR Plan”).  The Company’s2015.  Our LTR Plan for managers and executives allows participants to use a portion of their annual bonus amount to purchase Companyour common stock at a discount from the market price.  The shares purchased in March 2014February 2017 were for bonus amounts earned in 20132016, and the number of shares was calculated at 75% of the average closing price of January 2017. The shares purchased in March 2016 were for bonus amounts earned in 2015, and the number of shares was calculated at 75% of the

F-40


Table of Contents

average closing price of December 2015. The shares purchased in March 2015 were for bonus amounts earned in 2014, and the number of shares was calculated at 75% of the average market price of December 2013.  In March 2013, the Company received $1,455 for 131,9892014. The shares of common stock issued under the LTR Plan for bonus amounts earned in the prior year.purchased have a six month trading restriction.

 

As part of the Company’s quarterly compensation for the non-employee members of the Board of Directors, the CompanyWe issued shares of common stock under the Equity Plan to the non-employee members of the Board of Directors as part of our quarterly compensation provided to the Directors.  Shares issued were as follows:

 

·6,172 shares in August 2014,

·6,375 shares in February 2014,

·9,110 shares in August 2013,

·12,480 shares in March 2013,

·15,280 shares in August 2012, and

·12,395 shares in February 2012.

·

11,448 shares in August 2017,

·

11,784 shares in February 2017,

·

11,745 shares in August 2016,

·

10,450 shares in February 2016,

·

9,748 shares in August 2015, and

·

8,168 shares in March 2015,

 

The shares were fully vested upon issuance and have a one-year trading restriction.

 

As part of the acquisition of Q3C, the Company issued 29,273 unregistered shares of stock on January 7, 2013 based on the average December 2012 closing prices, or $14.69 per share for a total value of $430.

As discussed in Note 19—18—Deferred Compensation Agreements and Stock-Based Compensation, the Board of Directors has granted a total of 148,512259,065 shares of Units under the Equity Plan.

 

F-35



Table of Contents

At December 31, 2014,2017, there were 2,278,6511,853,494 shares of common stock reserved to provide for the grant and exercise of all future stock option grants, SARS, Units and grants of restricted shares under the Equity Plan. Other than the Units discussed above, there were no stock options, SARS or restricted shares of stock issued or outstanding at December 31, 2014.2017.

 

The Company was provided 15,144 shares of Primoris common stock in exchange for the payment of a $300 note receivable associated with the February 2010 sale of the Company’s Ecuador business.  The note was fully reserved in 2010.  The shares, valued at $19.81 per share, were cancelled by the Company and the Company recorded the transaction as non-operating income in March 2013.Share Repurchase Plan

 

In February 2014,2017, our Board of Directors authorized a $5.0 million share repurchase program under which we could, depending on market conditions, share price and other factors, acquire shares of our common stock on the Company’sopen market or in privately negotiated transactions. During the month of March 2017, we purchased and cancelled 216,350 shares of stock for $5.0 million at an average cost of $23.10 per share.

In August 2016, our Board of Directors authorized a share repurchase program under which the Company,we, from time to time and depending on market conditions, share price and other factors, could acquire shares of itsour common stock on the open market or in privately negotiated transactions up to an aggregate purchase price of $23$5.0 million.   During the period from February 2014 through September 2014, the Companymonth of December 2016, we purchased and cancelled 100,000207,800 shares of stock for $2.8$5.0 million at an average cost of $28.44$24.02 per share.  This share repurchase program expired on December 31, 2014.

 

In May 2012, the Company’s Board of DirectorsThere were no share repurchases authorized a share repurchase program of up to an aggregate purchase price of $20 million.  During the period from May 2012 through June 2012, the Company purchased and cancelled 89,600 shares of stock for $1.0 million at an average cost of $11.17 per share.  This share repurchase program expired on December 31, 2012.in 2015.

 

Preferred Stock

 

The Company isWe are authorized to issue 1,000,000 shares of $0.0001 par value preferred stock.  No shares of Preferred Stock were outstanding at December 31, 2014 or 2013.2017, 2016, and 2015.

 

Warrants

 

At December 31, 20142017, 2016, and 2013,2015 there were no warrants outstanding.

 

F-41


Table of Contents

Note 24—23—Selected Quarterly Financial Information (Unaudited)

 

Selected unaudited quarterly consolidated financial information is presented in the following tables:tables (in thousands, except per share amounts):

 

 

 

Year Ended December 31, 2014

 

(In thousands, except per share data)

 

1st
Quarter

 

2nd
Quarter

 

3rd
Quarter

 

4th
Quarter

 

Revenues

 

$

470,074

 

$

515,291

 

$

613,237

 

$

487,592

 

Gross profit

 

49,757

 

61,194

 

75,473

 

49,616

 

Net income

 

11,265

 

16,003

 

27,390

 

9,024

 

Net income attributable to Primoris

 

10,833

 

16,003

 

27,390

 

8,930

 

 

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

Basic earnings per share

 

$

0.21

 

$

0.31

 

$

0.53

 

$

0.17

 

Diluted earnings per share

 

$

0.21

 

$

0.31

 

$

0.53

 

$

0.17

 

 

 

 

 

 

 

 

 

 

 

Weighted average shares outstanding (in thousands)

 

 

 

 

 

 

 

 

 

Basic

 

51,610

 

51,655

 

51,606

 

51,561

 

Diluted

 

51,714

 

51,804

 

51,759

 

51,710

 

 

 

Year Ended December 31, 2013

 

(In thousands, except per share data)

 

1st
Quarter

 

2nd
Quarter

 

3rd
Quarter

 

4th
Quarter

 

Revenues

 

$

409,995

 

$

445,013

 

$

551,333

 

$

537,879

 

Gross profit

 

46,096

 

59,537

 

75,465

 

74,917

 

Net income

 

10,040

 

15,893

 

23,193

 

25,554

 

Net income attributable to Primoris

 

9,770

 

15,564

 

21,845

 

22,481

 

 

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

Basic earnings per share

 

$

0.19

 

$

0.30

 

$

0.42

 

$

0.44

 

Diluted earnings per share

 

$

0.19

 

$

0.30

 

$

0.42

 

$

0.44

 

 

 

 

 

 

 

 

 

 

 

Weighted average shares outstanding (in thousands)

 

 

 

 

 

 

 

 

 

Basic

 

51,456

 

51,562

 

51,568

 

51,571

 

Diluted

 

51,467

 

51,626

 

51,671

 

51,671

 

 

Year Ended December 31, 2012

 

 

 

 

 

 

 

 

 

 

 

 

 

 

(In thousands, except per share data)

 

1st
Quarter

 

2nd
Quarter

 

3rd
Quarter

 

4th
Quarter

 

 

Year Ended December 31, 2017

 

    

1st

    

2nd

    

3rd

    

4th

 

 

Quarter

 

Quarter

 

Quarter

 

Quarter

 

Revenues

 

$

291,573

 

$

337,436

 

$

431,842

 

$

480,883

 

 

$

561,502

 

$

631,165

 

$

608,311

 

$

579,017

 

Gross profit

 

37,596

 

44,004

 

56,291

 

54,819

 

 

 

55,053

 

 

84,483

 

 

70,421

 

 

68,477

 

Net income

 

10,530

 

11,857

 

17,948

 

17,932

 

 

 

8,512

 

 

22,396

 

 

22,134

 

 

23,808

 

Net income attributable to Primoris

 

10,486

 

11,733

 

17,516

 

17,021

 

 

 

7,691

 

 

21,545

 

 

20,597

 

 

22,521

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic earnings per share

 

$

0.21

 

$

0.23

 

$

0.34

 

$

0.33

 

 

$

0.15

 

$

0.42

 

$

0.40

 

$

0.44

 

Diluted earnings per share

 

$

0.20

 

$

0.23

 

$

0.34

 

$

0.33

 

 

$

0.15

 

$

0.42

��

$

0.40

 

$

0.44

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average shares outstanding (in thousands)

 

 

 

 

 

 

 

 

 

Weighted average shares outstanding

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

51,096

 

51,435

 

51,398

 

51,404

 

 

 

51,594

 

 

51,437

 

 

51,441

 

 

51,449

 

Diluted

 

51,337

 

51,435

 

51,404

 

51,418

 

 

 

51,851

 

 

51,688

 

 

51,707

 

 

51,711

 

 

F-36


 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Year Ended December 31, 2016

 

 

    

1st

    

2nd

    

3rd

    

4th

 

 

 

Quarter

 

Quarter

 

Quarter

 

Quarter

 

Revenues

 

$

430,446

 

$

456,811

 

$

507,828

 

$

601,863

 

Gross profit

 

 

39,277

 

 

43,285

 

 

50,129

 

 

68,616

 

Impairment of goodwill

 

 

 —

 

 

 —

 

 

2,716

 

 

 —

 

Net income

 

 

2,916

 

 

5,287

 

 

4,756

 

 

14,766

 

Net income attributable to Primoris

 

 

2,693

 

 

5,056

 

 

4,504

 

 

14,470

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Earnings per share:

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic earnings per share

 

$

0.05

 

$

0.10

 

$

0.09

 

$

0.28

 

Diluted earnings per share

 

$

0.05

 

$

0.10

 

$

0.09

 

$

0.28

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Weighted average shares outstanding

 

 

 

 

 

 

 

 

 

 

 

 

 

Basic

 

 

51,725

 

 

51,772

 

 

51,780

 

 

51,771

 

Diluted

 

 

51,881

 

 

52,022

 

 

52,034

 

 

52,021

 


Table of Contents

 

Note 25���24—Subsequent EventsEvent

 

On February 28, 2015, the Company acquired Aevenia, Inc. (“Aevenia”), a subsidiary of Otter Tail Corporation for approximately $23 million in cash.  Headquartered in Moorhead, Minnesota, Aevenia is an energy and electrical construction company.  For the year ended December 31, 2014, Aevenia generated operating income of $4.2 million on revenues of $44.4 million.  The assets purchased and liabilities assumed on the acquisition date included $3.8 million in current assets, $1.1 million in current liabilities and $20.3 million in equipment, intangible assets and goodwill.  Due to the short period of time between the acquisition date and this report, the estimated values are preliminary and subject to change.

Aevenia specializes in overhead and underground line work, substations, telecom/fiber, and certain other client-specific on-demand call out services.  The majority of their work is delivered under unit-price Master Services Agreements (“MSAs”).  Aevenia has operations in Minnesota, North Dakota, South Dakota and Iowa.  The Company believes there are opportunities for Aevenia to grow sales by performing in-house work for other Primoris subsidiaries and expands the Company’s offerings to new geographies in the Midwest.  Aevenia will be re-branded as Primoris AV, Energy and Electrical Construction Corporation, and operate as part of Primoris’ Energy segment.

In addition, on February 24, 2015,21, 2018, the Board of Directors declared a cash dividend of $0.04$0.06 per common share for stockholders of record as of March 31, 2015,30, 2018, payable on or about April 15, 2015.13, 2018.

 

F-37



Table of Contents

 

EXHIBIT INDEX

Exhibit No.

Description

Exhibit 2.1

Agreement and Plan of Merger, dated February 19, 2008, by and among Rhapsody Acquisition Corp., Primoris Corporation and certain stockholders of Primoris Corporation (1)

Exhibit 2.2

First Amendment to Agreement and Plan of Merger, dated May 15, 2008, by and among Rhapsody Acquisition Corp., Primoris Corporation and certain stockholders of Primoris Corporation (2)

Exhibit 2.3

Membership Interest Purchase Agreement, dated July 1, 2010, by and between Primoris Services Corporation, Kealine Holdings LLC and WesPac Energy LLC (3)

Exhibit 2.4

Agreement and Plan of Merger, dated November 8, 2010, by and among Primoris Services Corporation, a Delaware corporation, Primoris Merger Sub, Inc., a Delaware corporation and a wholly-owned subsidiary of Primoris Services Corporation, Rockford Holdings Corporation, a privately-held Delaware corporation, all of the stockholders of Rockford Holdings Corporation and Christopher S. Wallace as representative of the stockholders of Rockford Holdings Corporation (4)

Exhibit 2.5

Stock Purchase Agreement, dated November 8, 2012, by and among Primoris Services Corporation, a Delaware corporation, Q3 Contracting Inc., a privately-held Minnesota corporation, all of the shareholders of Q3 Contracting Inc. and Jay P. Osborn as representative of the shareholders of Q3 Contracting Inc. (5)

Exhibit 3.1

Fourth Amended and Restated Certificate of Incorporation of Primoris Services Corporation, dated May 21, 2009 (6)

Exhibit 3.2

Amended and Restated Bylaws of Primoris Services Corporation (7)

Exhibit 3.3

Certificate of Designations, Powers, Preferences and Rights of the Series A Non-Voting Contingent Convertible Preferred Stock of Primoris Services Corporation, dated December 14, 2009 (8)

Exhibit 4.1

Specimen Common Stock Certificate (9)

Exhibit 10.1

2008 Long-Term Equity Incentive Plan (#)(10)

Exhibit 10.2

2013 Equity Incentive Plan (#)(11)

F-42



Table of Contents

Exhibit 10.3

Loan and Security Agreement, dated October 28, 2009, by and between Primoris Services Corporation and The PrivateBank and Trust Company (12)

Exhibit 10.4

First Amendment to Loan and Security Agreement, dated January 14, 2010, by and among Primoris Services Corporation and The PrivateBank and Trust Company (13)

Exhibit 10.5

Second Amendment to Loan and Security Agreement, dated September 30, 2010, by and among Primoris Services Corporation and The PrivateBank and Trust Company (13)

Exhibit 10.6

Master Loan and Security Agreement, dated June 25, 2010, by and between Stellaris, LLC and Banc of America Leasing & Capital, LLC (14)

Exhibit 10.7

Master Loan and Security Agreement, dated August 31, 2009, by and between Stellaris, LLC and Fifth Third Bank (14)

Exhibit 10.8

Purchase Trading Plan Agreement, dated September 7, 2010, by and between Primoris Services Corporation and CJS Securities, Inc. (15)

Exhibit 10.9

Loan Agreement, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.10

Note, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.11

Collateral Schedule No. 1, dated December 29, 2010, by and between Stellaris, LLC and RBS Asset Finance, Inc. (16)

Exhibit 10.12

Guaranty, dated December 29, 2010, by and between Primoris Services Corporation and RBS Asset Finance, Inc. (16)

Exhibit 10.13

Third Amendment to Loan and Security Agreement, dated March 3, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (17)

Exhibit 10.14

Fourth Amendment to Loan and Security Agreement, dated October 20, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (18)

Exhibit 10.15

Credit Agreement, dated September 23, 2011, by and among Primoris Services Corporation and Bank of the West (19)

Exhibit 10.16

Fifth Amendment to Loan and Security Agreement, dated November 28, 2011, by and among Primoris Services Corporation and The PrivateBank and Trust Company (19)

Exhibit 10.17

Loan and Security Agreement, dated November 30, 2011, by and among Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.18

Business Purpose Promissory Note, dated November 30, 2011, by and among Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.19

Schedule A-1 Equipment Collateral, dated November 30, 2011, by and between Stellaris LLC, James Construction Group LLC and JPMorgan Chase Bank, N.A. (19)

Exhibit 10.20

Amendment No. 3 to the Master Loan and Security Agreement Loan and Security Agreement, dated November 30, 2011, by and among James Construction Group LLC, Stellaris LLC, ARB Inc. and Fifth Third Bank (19)

Exhibit 10.21

Promissory Note, dated November 30, 2011, by and among James Construction Group LLC, Stellaris LLC, ARB Inc. and Fifth Third Bank (19)

Exhibit 10.22

Master Loan and Security Agreement, dated December 21, 2011, by and among ARB, Inc. and Banc of America Leasing & Capital, LLC (20)



Table of Contents

Exhibit 10.23

Equipment Security Note, dated December 21, 2011, by and among ARB, Inc., Stellaris LLC, Rockford Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.24

Addendum to Master Loan and Security Agreement, dated December 21, 2011, by and among ARB, Inc., Stellaris LLC, Rockford Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.25

Guaranty, dated December 21, 2011, by and among Primoris Services Corporation and Banc of America Leasing & Capital, LLC (20)

Exhibit 10.26

General Indemnity Agreement, dated January 24, 2012, by and among Primoris Services Corporation, ARB, Inc. ARB Structures, Inc., OnQuest, Inc., OnQuest Heaters, Inc. Born Heaters Canada ULC, Cardinal Contractors, Inc., Cardinal Southeast, Inc., Stellaris, LLC, GML Coatings, LLC, James Construction Group, LLC, Juniper Rock Corporation, Rockford Corporation; Alaska Continental Pipeline, Inc., All Day Electric Company, Inc. Primoris Renewables, LLC, Rockford Pipelines Canada, Inc. and Chubb Group of Insurance Companies (21)

Exhibit 10.27

Fifth Amendment to Loan and Security Agreement, dated April 4, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (22)

Exhibit 10.28

Equipment Security Note, dated June 20, 2012, by and among Stellaris, LLC, James Construction Group, LLC and Banc of America Leasing & Capital, LLC (23)

Exhibit 10.29

Amendment Number 1 to Master Loan and Security Agreement, dated June 20, 2012, by and among Stellaris, LLC, James Construction Group, LLC and Banc of America Leasing & Capital, LLC (23)

Exhibit 10.30

Seventh Amendment to Loan and Security Agreement, dated July 18, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (24)

Exhibit 10.31

Eighth Amendment to Loan and Security Agreement, dated October 29, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company (25)

Exhibit 10.32

Master Loan and Security Agreement, dated November 1, 2012, by and between Stellaris, LLC and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.33

Amendment to Master Loan and Security Agreement, dated November 7, 2012, by and among Stellaris, LLC, James Construction Group, LLC, Miller Springs Materials, LLC, Primoris Energy Services Corporation and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.34

Equipment Security Note, dated November 1, 2012, by and among Stellaris, LLC, James Construction Group, LLC, Miller Springs Materials, LLC, Primoris Energy Services Corporation and Banc of America Leasing & Capital, LLC (26)

Exhibit 10.35

Loan Agreement, dated December 13, 2012, by and between Stellaris, LLC and Q3 Contracting, Inc. and RBS Asset Finance, Inc. (27)

Exhibit 10.36

Note, dated December 13, 2012, by and among Stellaris, LLC and Q3 Contracting, Inc. and RBS Asset Finance, Inc. (27)

Exhibit 10.37

Guaranty, dated December 13, 2012, by and among Primoris Services Corporation and RBS Asset Finance, Inc. (27)

Exhibit 10.38

Credit Agreement, dated December 28, 2012, by and among Primoris Services Corporation and The PrivateBank and Trust Company, The Bank of the West and IBERIABANK Corporation (28)

Exhibit 10.39

Note Purchase and Private Shelf Agreement, dated December 28, 2012, by and among Primoris Services Corporation and Prudential Investment Management, Inc. and certain Prudential affiliates (28)

Exhibit 10.40

Promissory Note, dated June 11,2013, by and among Stellaris, LLC and Fifth Third Bank pursuant to the Master Loan and Security Agreement dated August 31, 2009 (30)



Table of Contents

Exhibit 10.41

Master Loan and Security Agreement, dated June 13, 2013, by and among Stellaris, LLC, James Construction Group, LLC, Rockford Corporation and Wells Fargo Equipment Finance, Inc. and Loan Schedules, dated June 13, 2013 (30)

Exhibit 10.42

Confirmation of Acceptance Agreement, dated June 13, 2013, by and among Primoris Services Corporation and Prudential Investment Management, Inc. and certain Prudential affiliates pursuant to the Note Purchase and Private Shelf Agreement, dated December 28, 2012 and five 3.85% Senior Secured Notes, Series B, due July 25, 2023 (30)

Exhibit 10.43

Loan Agreement, dated September 17, 2013, by and among Stellaris, LLC, James Construction Group LLC and Rockford Corporation and RBS Asset Finance, Inc. (31)

Exhibit 10.44

Loan and Security Agreement, dated September 20, 2013, by and between PNC Equipment Finance, LLC and Stellaris LLC and Q3 Contracting, Inc. (31)

Exhibit 10.45

Contribution Agreement, dated as of September 30, 2013, by and among WesPac Energy LLC, Kealine Holdings LLC, Primoris Services Corporation and WesPac Midstream LLC and Highstar WesPac Main Interco LLC and Highstar WesPac Prism/IV-A Interco LLC (31)

Exhibit 10.46

Master Loan and Security Agreement, dated December 6, 2013 by and between Stellaris, LLC and Banc of America Leasing & Capital, LLC (32)

Exhibit 10.47

Equipment Security Note, dated as of December 6, 2013, by and between Stellaris, LLC, ARB, Inc. James Construction Group, LLC, and Rockford Corporation and Banc of America Leasing & Capital, LLC (32)

Exhibit 10.48

Master Security Agreement, dated September 18, 2014, by and among Primoris Services Corporation, Rockford Corporation and Key Equipment Finance, a division of KeyBank National Association. (33)

Exhibit 10.49

Promissory Note and Collateral Schedule No. 1, dated September 18, 2014, by and between Primoris Energy Services Corporation, Rockford Corporation and Key Equipment Finance, a division of KeyBank National Association. (33)

Exhibit 10.50

Master Loan and Security Agreement, dated September 19, 2014, by and among Fifth Third Bank and Primoris Services Corporation, James Construction Group, LLC and Q3 Contracting, Inc. (33)

Exhibit 10.51

Amendment No. 1 to Master Loan and Security Agreement, dated as of September 23, 2014, by and among Fifth Third Bank and Stellaris LLC. (33)

Exhibit 10.52

Promissory Note, dated September 19, 2014, by and among Primoris Services Corporation, James Construction Group, LLC, Q3 Contracting, Inc. and Fifth Third Bank. (33)

Exhibit 10.53

Third Amendment to Credit Agreement, dated as of December 12, 2014, by and among Primoris Services Corporation and The PrivateBank and Trust Company, The Bank of the West, IBERIABANK Corporation, Branch Banking and Trust Company and UMB Bank, N.A. (34)

Exhibit 10.54

Waiver and Amendment Agreement, dated as of April 30, 2014, by and among Primoris Services Corporation and The PrivateBank and Trust Company and other financial institutions party to the Credit Agreement. (34)

Exhibit 10.55

Second Amendment and Waiver Agreement, dated as of August 25, 2014, by and among Primoris Services Corporation and The PrivateBank and Trust Company and other financial institutions party to the Credit Agreement. (34)

Exhibit 14.1

Code of Ethics and Business Conduct (29)

Exhibit 21.1

Subsidiaries and equity investments of Primoris Services Corporation (*)

Exhibit 23.1

Consent of Moss Adams LLP (*)



Table of Contents

Exhibit 31.1

Certification of chief executive officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 (*)

Exhibit 31.2

Certification of chief financial officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002 (*)

Exhibit 32.1

Certification of chief executive officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 (*)

Exhibit 32.2

Certification of chief financial officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002 (*)

Exhibit 101 INS

XBRL Instance Document (*)

Exhibit 101 SCH

XBRL Taxonomy Extension Schema Document (*)

Exhibit 101 CAL

XBRL Taxonomy Extension Calculation Linkbase Document (*)

Exhibit 101 LAB

XBRL Taxonomy Extension Label Linkbase Document (*)

Exhibit 101 PRE

XBRL Taxonomy Extension Presentation Linkbase Document (*)

Exhibit 101 DEF

XBRL Taxonomy Extension Definition Linkbase Document (*)


(#)  Management contract or compensatory plan, contract or arrangement.

(*)  Filed herewith.

(1)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on February 20, 2008, and such exhibit is incorporated herein by reference.

(2)

Filed as an exhibit to our Registration Statement on Form S-4/A (Amendment No. 3) (File No. 333-150343), as filed with the SEC on July 1, 2008, and such exhibit is incorporated herein by reference.

(3)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 8, 2010, and such exhibit is incorporated herein by reference.

(4)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 12, 2010, and such exhibit is incorporated herein by reference.

(5)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 15, 2012, and such exhibit is incorporated herein by reference.

(6)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on August 12, 2009, and such exhibit is incorporated herein by reference.

(7)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on August 6, 2008, and such exhibit is incorporated herein by reference.

(8)

Filed as exhibit to our Current Report on Form 8-K, as filed with the SEC on December 17, 2009, and such exhibit is incorporated herein by reference.

(9)

Filed as an exhibit to our Registration Statement on Form S-1 (File No. 333-134694), as filed with the SEC on June 2, 2006, and such exhibit is incorporated herein by reference.

(10)

Attached as an annex to our Registration Statement on Form S-4/A (Amendment No. 4) (File No. 333-150343), as filed with the SEC on July 9, 2008, and such annex is incorporated herein by reference.

(11)

Attached as Appendix A to our Definitive Proxy Statement on Schedule 14A filed with the SEC on April 9, 2013, and such Appendix is incorporated herein by reference.

(12)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 4, 2009, and such exhibit is incorporated herein by reference.

(13)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on October 6, 2010, and such exhibit is incorporated herein by reference.

(14)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 1, 2010, and such exhibit is incorporated herein by reference.

(15)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on September 8, 2010, and such exhibit is incorporated herein by reference.

(16)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on January 6, 2011, and such exhibit is incorporated herein by reference.

(17)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 16, 2011, and such exhibit is incorporated herein by reference.

(18)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on October 25, 2011, and such exhibit is incorporated herein by reference.

(19)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 14, 2011, and such exhibit is incorporated herein by reference.

(20)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 30, 2011, and such exhibit is incorporated herein by reference.



Table of Contents

(21)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 5, 2012, and such exhibit is incorporated herein by reference.

(22)

Filed as an exhibit to our Annual Report on Form 10-Q, as filed with the SEC on May 9, 2012, and such exhibit is incorporated herein by reference.

(23)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on June 28, 2012, and such exhibit is incorporated herein by reference.

(24)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on July 23, 2012, and such exhibit is incorporated herein by reference.

(25)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 2, 2012, and such exhibit is incorporated herein by reference.

(26)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on November 9, 2012, and such exhibit is incorporated herein by reference.

(27)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 18, 2012, and such exhibit is incorporated herein by reference.

(28)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on January 7, 2013, and such exhibit is incorporated herein by reference.

(29)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 11, 2010, and such exhibit is incorporated herein by reference.

(30)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on August 7, 2013, and such exhibit is incorporated herein by reference.

(31)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on November 5, 2013, and such exhibit is incorporated herein by reference.

(32)

Filed as an exhibit to our Annual Report on Form 10-K, as filed with the SEC on March 3, 2014, and such exhibit is incorporated herein by reference.

(33)

Filed as an exhibit to our Quarterly Report on Form 10-Q, as filed with the SEC on November 7, 2014, and such exhibit is incorporated herein by reference.

(34)

Filed as an exhibit to our Current Report on Form 8-K, as filed with the SEC on December 18, 2014, and such exhibit is incorporated herein by reference.