TABLE OF CONTENTS PART I 1 ITEM 1. BUSINESS 1 GENERAL 1 EXCHANGE OFFER 1 PROJECT 2 THE EXPANDING PHILIPPINE AGRICULTURE SECTOR AND POWER MARKETS 4 AGRICULTURE 4 POWER 5 TERMS OF THE SECURITIES 5 GENERAL 5 PAYMENT OF PRINCIPAL AND INTEREST 6 PRIORITY OF PAYMENTS 7 DEBT SERVICE RESERVE FUND 7 OPTIONAL REDEMPTION 8 MANDATORY REDEMPTION 8 CHANGE IN CONTROL PUT 8 DISTRIBUTIONS 8 RANKING AND SECURITY FOR THE SECURITIES 9 RATINGS 9 NATURE OF RECOURSE ON THE SECURITIES 9 INCURRENCE OF ADDITIONAL DEBT 9 PRINCIPAL COVENANTS 11 INSURANCE 11 REGULATORY MATTERS 11 EMPLOYEES 11 ITEM 2. PROPERTIES 12 ITEM 3. LEGAL PROCEEDINGS 12 ITEM 4. SUBMISSION OF MATTERS TO A VOTE OF SECURITY HOLDERS 12 PART II 13 ITEM 5. MARKET FOR COMPANY'S EQUITY AND RELATED STOCKHOLDER MATTERS 13 ITEM 6. SELECTED FINANCIAL DATA 13 ITEM 7. MANAGEMENT'S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS 13 ITEM 8. FINANCIAL STATEMENTS AND SUPPLEMENTARY DATA 16 REPORT OF INDEPENDENT PUBLIC ACCOUNTANTS 17 BALANCE SHEETS 18 STATEMENTS OF OPERATIONS 19 STATEMENTS OF CHANGES IN STOCKHOLDERS' EQUITY 20 STATEMENTS OF CASH FLOW 21 NOTES TO FINANCIAL STATEMENTS 22 ITEM 9. CHANGES IN AND DISAGREEMENTS WITH ACCOUNTANTS ON ACCOUNTING AND FINANCIAL DISCLOSURE 28 PART III 29 ITEM 10. DIRECTORS AND EXECUTIVE OFFICERS OF THE COMPANY 29 ITEM 11. EXECUTIVE COMPENSATION 31 ITEM 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT 31 DESCRIPTION OF CAPITAL STOCK 31 PRINCIPAL HOLDERS 31 ITEM 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS 32 SIGNATURES 33 INDEX TO EXHIBITS 34 SECURITIES AND EXCHANGE COMMISSION WASHINGTON, D.C. 20549 FORM 10-K Annual Report Pursuant to Section 13 or 15 (d) of the Securities Exchange Act of 1934 For the fiscal year ended December 31, 1996 Commission File No. 333-00608 CE CASECNAN WATER AND ENERGY COMPANY, INC. (Exact name of registrant as specified in its charter) Philippines Not applicable (State or other (IRS Employer jurisdiction of incorporation Identification No.) or organization) 6750 Ayala Avenue, 24th Floor, Not applicable Makati, Manila, Philippines (Zip Code) (Address of principal executive offices) Registrant's telephone number, including area code: (632) 892-0276 Securities registered pursuant to Section 12(b) of the Act: N/A Securities registered pursuant to Section 12(g) of the Act: N/A Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days: Yes X No______ Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of Registrant's knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. [ X ] All Common Stock of the Company is held by the original shareholders. Accordingly there is no market value. 767,162 shares of Common Stock, $0.038 par value, were outstanding on March 17, 1997. Documents incorporated by reference: N/A PART I Item 1. Business General CE Casecnan Water and Energy Company, Inc. ("Company" or "CE Casecnan") is a privately held Philippine corporation formed in September of 1994 solely to develop, construct, own and operate the Casecnan Project, a multi-purpose irrigation and hydroelectric power facility with a rated capacity of approximately 150 Megawatts ("MW") located on the island of Luzon in the Republic of the Philippines (the "Casecnan Project"). The Company is an indirect subsidiary of CalEnergy Company, Inc. ("CalEnergy") and Peter Kiewit Sons, Inc. ("Kiewit"). Currently CalEnergy and Kiewit collectively own approximately 70% of the Company. Each of two minority shareholders of the Company currently owns approximately 15% of the outstanding capital stock of the Company. The shares held by the minority shareholders may be reduced in certain circumstances and such reduction would result in a corresponding increase in the number of shares of the Company held by affiliates of CalEnergy and Kiewit. CalEnergy was formed in 1971 and is engaged in the exploration for, and development and operation of, environmentally responsible independent power production facilities worldwide utilizing geothermal resources or other energy sources, such as hydroelectric, natural gas, oil and coal. CalEnergy is an international provider of energy services, with over 5,000 net MW of electrical generating capacity in operation, under construction or in development in the United States, the Philippines, Indonesia and the United Kingdom. CalEnergy is publicly traded on the New York, London and Pacific stock exchanges under the symbol "CE", and has a current market capitalization of approximately $2 billion and had assets of approximately $5.7 billion as of December 31, 1996. Kiewit is a large privately held construction, mining and telecommunications company with hydroelectric, mining and tunneling experience and 1996 revenues of approximately $3 billion and is headquartered in Omaha, Nebraska. Kiewit beneficially owns approximately 32% of CalEnergy's common stock through indirect subsidiaries. The Securities (described herein) are recourse only to the Company. Neither CalEnergy nor Kiewit have guaranteed directly or indirectly the payment or performance of any company obligations. The Company's principal executive office is located at 6750 Ayala Avenue, 24th Floor, Makati, Metro Manila, Philippines, and its telephone number is 632 892 0276. The Company's principal office will be located in Pantabangan in the Province of Nueva Ecija, Philippines. Exchange Offer In June 1996, the Company exchanged (i) $125,000,000 aggregate principal amount of Series A Securities for an equal principal amount of New Series A Securities, and (ii) $171,500,000 aggregate principal amount of Series B Securities for an equal amount of New Series B Securities. The Series A Securities and Series B Securities are sometimes referred to herein as the "Old Securities", and the New Series A Securities and the New Series B Securities are sometimes referred to herein as the "New Securities". The New Securities are the obligations of the Company evidencing the same indebtedness as the Old Securities and will be entitled to the benefits of the Indenture, which governs both the Old Securities and the New Securities. The form and terms (including principal amount, interest rate, maturity and ranking) of the New Securities are the same as the form and terms of the Old Securities, except that (i) the New Securities have been registered under the Securities Act and therefore will not be subject to certain restrictions on transfer applicable to the Old Securities and will not be entitled to registration rights, and (ii) the New Securities will not provide for any increase in the interest rate thereon. Simultaneously with the offering of the Old Securities the Company also issued and sold $75,000,000 aggregate principal amount of LIBOR Plus 3.00% Senior Secured Floating Rate Notes Due November 15, 2002 ("FRNs") that rank pari passu with and share the collateral on a pro rata basis with the Old Securities and the New Securities and are entitled to the benefits of the Indenture and the Depositary Agreement. The Old Securities, New Securities, FRNs and Additional Securities are collectively referred to herein as the "Securities". Project The Casecnan Project is located in the central part of the island of Luzon. It will consist generally of diversion structures in the Casecnan and Denip Rivers that will divert water into a tunnel of approximately 23 kilometers (including the intake adit from the Denip to the Casecnan River), with a diameter of approximately 6.5 meters. The tunnel will transfer the water from the Casecnan and Denip Rivers into the Pantabangan Reservoir for irrigation and hydroelectric use in the Central Luzon area. An underground hydroelectric powerhouse located at the end of the water tunnel and before the Pantabangan Reservoir will house a power plant consisting of approximately 150 MW of newly installed rated electrical capacity. A tailrace discharge tunnel of approximately three kilometers will deliver water from the water tunnel and the new powerhouse to the Pantabangan Reservoir, providing additional water for irrigation and increasing the potential electrical generation at two downstream existing hydroelectric facilities of the Philippine National Power Corporation ("NPC"), the government-owned and controlled corporation that is the primary supplier of electricity in the Philippines. In early 1994, President Fidel Ramos recognized the need for an irrigation and hydroelectric project that would provide increased water flows for irrigation to the rice growing area of Central Luzon, would be environmentally sound, technically feasible and economically viable, and would involve no flooding or relocation of local residents. At that time, he directed the Philippine Department of Agriculture and NPC to work together with other interested agencies to develop a combined irrigation and hydroelectric project. Shortly thereafter, the Philippine government was approached by the Company with a proposal for a project to be developed in the Casecnan area on a build-own- operate-transfer ("BOOT") basis, that is, an arrangement under which the Company as developer would agree to build, own and operate the Casecnan Project during an approximately four-year construction period and a twenty-year cooperation period, after which ownership and operation of the Project would be transferred to the Philippine National Irrigation Administration ("NIA") and NPC at no cost. After conclusion of a public solicitation for competing proposals, NIA selected the Company as the BOOT developer and entered into the Project Agreement with the Company. The Casecnan Project was subsequently designated a high priority project under Republic Act No. 529 by the National Economic and Development Authority of the Philippines. CE Casecnan is developing the Casecnan Project under the terms of the Project Agreement between CE Casecnan and NIA. Under the Project Agreement, CE Casecnan will develop, finance and construct the Casecnan Project over an estimated four-year construction period, and thereafter own and operate the Casecnan Project for 20 years (the "Cooperation Period"). During the Cooperation Period, NIA is obligated to accept all deliveries of water and energy, and so long as the Casecnan Project is physically capable of operating and delivering in accordance with agreed levels set forth in the Project Agreement, NIA will pay CE Casecnan a guaranteed fee for the delivery of water and a guaranteed fee for the delivery of electricity, regardless of the amount of water or electricity actually delivered. In addition, NIA will pay a fee for all electricity delivered in excess of a threshold amount up to a specified amount. NIA will sell the electric energy it purchases to NPC, although NIA's obligations to CE Casecnan under the Project Agreement are not dependent on NPC's purchase of the electricity from NIA. All fees to be paid by NIA to CE Casecnan are payable in U.S. dollars. The guaranteed fees for the delivery of water and energy are expected to provide approximately 70% of CE Casecnan's revenues. The Project Agreement provides for additional compensation to CE Casecnan upon the occurrence of certain events, including increases in Philippine taxes and adverse changes in Philippine law. Upon the occurrence and during the continuance of certain force majeure events, including those associated with Philippines political action, NIA may be obligated to buy the Casecnan Project from CE Casecnan at a buy out price expected to be in excess of the aggregate principal amount of the outstanding CE Casecnan debt securities, together with accrued but unpaid interest. At the end of the Cooperation Period, the Casecnan Project will be transferred to NIA and NPC for no additional consideration on an "as is" basis. The Republic of the Philippines has provided a Performance Undertaking under which NIA's obligations under the Project Agreement are guaranteed by the full faith and credit of the Republic of the Philippines. The Project Agreement and the Performance Undertaking provide for the resolution of disputes by binding arbitration in Singapore under international arbitration rules. NIA's payment obligations under the Project Agreement are expected to be the Company's sole source of operating revenues. Because of the Company's dependence on NIA, any material failure of NIA to fulfill its obligations under the Project Agreement and any material failure of the Republic of the Philippines to fulfill its obligations under the Performance Undertaking would significantly impair the ability of the Company to meet its obligations under the Securities. The Casecnan Project is being constructed on a joint and several basis by Hanbo Corporation and Hanbo Engineering & Construction Co. Ltd. (formerly known as You One Engineering & Construction Co., Ltd., and herein referred to as "HECC"), both of which are South Korean corporations, pursuant to a fixed- price, date-certain, turnkey construction contract (the "Turnkey Construction Contract"). Hanbo Corporation and HECC (sometimes collectively referred to as the "Contractor") are under common ownership control. Hanbo Corporation is an international construction company. HECC, which recently emerged from a court- administered receivership, is a contractor with over 25 years experience in tunnel construction, using both the drill-and-blast and tunnel boring machine ("TBM") methods. The Contractor's obligations under the Turnkey Construction Contract are guaranteed by Hanbo Iron & Steel Company, Ltd. ("Hanbo Steel"), a large South Korean steel company. In addition, the Contractor's obligations under the Turnkey Construction Contract are secured by an irrevocable standby letter of credit issued by Korea First Bank ("KFB") in the approximate amount of $118 million. The total cost of the Casecnan Project, including development, construction, testing and startup, is estimated to be approximately $495 million. Early in 1997, CE Casecnan was advised that Hanbo Corporation and Hanbo Steel had each filed to seek court receivership protection in Korea but that HECC had not filed for receivership protection and was believed to be solvent. In March 1997, the Company was informed that HECC filed for receivership protection. CE Casecnan has recently received confirmation from HECC that it intends to fully perform its obligations under the Turnkey Construction Contract and complete the Casecnan Project on schedule and within the budget. However, although HECC is currently performing the work, no assurances can be given that HECC will remain able to perform fully its obligations under the Turnkey Construction Contract. CE Casecnan is presently reviewing its rights, obligations and potential remedies in respect of the recent developments regarding the co-Contractor and the guarantor and is presently unable to speculate as to the ultimate effect of such developments on CE Casecnan. KFB has recently reconfirmed to CE Casecnan that it will honor its obligations under the Casecnan Project letter of credit and also has stated its support for the successful completion of the Casecnan Project and has previously offered to extend a working capital facility to HECC. However, until a receiver for HECC is appointed, it is unclear whether such a working capital facility can be utilized and whether there will be any constraints imposed on HECC's performance of the work. Moody's Investors Service recently issued a ratings downgrade of KFB's senior debt from Baa1 to Baa2. CE Casecnan financed a portion of the costs of the Casecnan Project through the issuance of $125,000,000 of its 11.45% Senior Secured Series A Notes due 2005 and $171,500,000 of its 11.95% Senior Secured Series B Bonds due 2010 and $75,000,000 of its Secured Floating Rate Notes due 2002, pursuant to an indenture dated November 27, 1995, as amended to date (the "Casecnan Indenture"). Although no default has yet occurred under the Casecnan Indenture as a result of the announced receivership of HECC, CE Casecnan will continue to closely monitor the Hanbo group and KFB developments and project construction status and develop appropriate contingency plans. If Contractor materially fails to perform its obligations under the Turnkey Construction Contract or if KFB were to fail to honor its obligations under the Casecnan letter of credit, such actions could have a material adverse effect on the Casecnan Project and CE Casecnan. The Casecnan Project will capture and divert excess water in the Casecnan watershed by means of concrete, in-stream diversion weirs and transfer that water through a transbasin tunnel to an existing underutilized water storage reservoir at Pantabangan. During the water transfer, the elevation differences between the two watersheds will allow electrical energy to be generated at a new 150 MW rated capacity power plant, which will be constructed in a powerhouse cavern located at the end of the water tunnel. Since the water has been determined to remain suitable for irrigation throughout the Casecnan Project operations of capturing, diverting and transferring the water, other than removing sediments at the diversion structures, no treatment will be required. Once in the reservoir at Pantabangan, the water will be under the control of, and for the use of, NIA. The Casecnan Project's diversion structures will be capable of storing flows from the Casecnan and Denip Rivers over a number of hours, and then discharging that stored water through the transbasin tunnel and new powerhouse during the 12 hours (8:00 a.m. through 8:00 p.m.) coinciding with peak electrical demand hours. Tunnel flows and water depths behind the diversion structures will be regulated by in-tunnel valves in front of the powerhouse turbines controlled by the operators at the powerhouse control room. The Company has applied for all material permits required for the construction of the Project and has obtained or expects to receive all these permits. The Company also has applied for or expects at the appropriate time to apply for, and it either has obtained or expects to receive by the relevant time, all permits necessary during the course of construction and to operate the Casecnan Project in accordance with the Project Agreement. Many permits contain conditions, and are subject to laws, legal interpretations or policies that could change. As with any major construction effort, the construction of the Casecnan Project involves various uncertainties, including availability of materials and labor, labor relations issues, possible inclement weather, unforeseen engineering, environmental or geological issues, and unanticipated difficulties in obtaining any of the requisite licenses or permits, any of which could give rise to delays or cost overruns or cause the Casecnan Project to perform at less than its expected level. In addition, there are no assurances that the Company will achieve the projected operational levels or that unexpected events will not interrupt development of the Casecnan Project or impede in any way the operations of the Casecnan Project once completed. The Expanding Philippine Agriculture Sector and Power Markets Agriculture The agricultural sector has played an important role in the sustained growth of the Philippines economy, accounting for approximately 23% of gross domestic product and employing approximately 46% of the economically active population in 1994. The Philippine government has a policy objective to provide necessary agriculture infrastructure for farmers to increase productivity of important agricultural crops, such as rice, in order to attain self-sufficiency and eliminate the need to rely on imports of rice which consume foreign exchange reserves. NIA supports agricultural production and rural development by providing water and irrigation services to the Philippine agricultural sector. NIA is responsible for the implementation of irrigation development programs and the operation, maintenance and administration of all national irrigation systems in the Philippines. One of NIA's mandates is to provide and facilitate the procurement and delivery of irrigation water to farmers in Central Luzon. The Casecnan watershed is one of the last remaining substantial sources of water available to provide irrigation water to Central Luzon, the most significant rice-producing region in the Philippines. NIA estimates that the Casecnan Project will divert sufficient water to irrigate the equivalent of at least 50,000 additional hectares of agricultural land in the Central Luzon Valley, which could produce an additional 465,000 tons or more of rice per year with a direct annual net production value to the Philippines of approximately 2.03 billion pesos (U.S. $80 million). The increased production resulting from the additional irrigation water is expected to contribute significantly to the Philippines' goal to become self-sufficient in rice production. Power According to NPC's 1995 Power Development Program (1995- 2005)("PDP"), industrial growth, a rising standard of living, and an expanding power distribution network have resulted in increased demand for electrical power in the Philippines by an average of 6% per year since 1987. NPC has projected that over the next ten years the need for additional generating capacity in the Philippines will exceed 14,000 MW. With NPC projecting that electricity demand will increase approximately 13% annually between 1996-2000 and approximately 11% annually for 2001-2005, the government of the Philippines has taken steps to accelerate private power investment in an attempt to enable supply to keep up with demand. As a result of government action, many new power projects have come on-line during the past two years, but capacity shortages are still anticipated over the next several years. Elimination of power shortages through increases in production from plans such as the Casecnan Project should contribute to further industrial growth and economic stability in the Philippines. TERMS OF THE SECURITIES General The New Securities were issued pursuant to the Exchange offer which applied to the recapitalization of $296,500,000 aggregate principal amount of the Old Securities. The New Securities will be obligations of the Company evidencing the same indebtedness as the Old Securities and will be entitled to the benefits of the Indenture, which governs both the Old Securities and the New Securities. The form and terms (including principal amount, interest rate, maturity and ranking) of the New Securities are the same as the form and terms of the Old Securities, except that (i) the New Securities have been registered under the Securities Act and therefore will not be subject to certain restrictions on transfer applicable to the Old Securities and will not be entitled to registration rights, and (ii) the New Securities will not provide for any increase in the interest rate thereon. Simultaneously with the offering of the Old Securities the Company also issued and sold $75,000,000 aggregate principal amount of LIBOR Plus 3.00% Senior Secured Floating Rate Notes Due November 15, 2002 ("FRNs") that rank pari passu with and share the collateral on a pro rata basis with the Old Security and the New Securities and are entitled to the benefits of the Indenture and the Depositary Agreement. The Securities are direct obligations of the Company, secured by the Company Collateral. Payment of Principal and Interest Interest on the Old Securities and New Securities will be payable semiannually on each May 15 and November 15 (the "Old Securities and New Securities Interest Payment Date"), commencing May 15, 1996, to the registered Holders thereof at the close of business on the May 1 and November 1, as the case may be, preceding each Old Securities and New Securities Interest Payment Date. Holders of Old Securities whose Old Securities are accepted for exchange will not receive any payment in respect of accrual and unpaid interest on such Old Securities. The initial average life of the Series A Securities was 8.84 years, and the initial average life of the Series B Securities was 11.57 years. The $125,000,000 principal of the 11.45% New Series A Securities due November 15, 2005 are payable in semiannual installments, commencing May 15, 2003, as follows: Percentage of Principal Payment Date Amount Payable May 15, 2003 13.50% November 15, 2003 13.50% May 15, 2004 17.00% November 15, 2004 17.00% May 15, 2005 19.50% November 15, 2005 19.50% The $171,500,000 principal of the 11.95% New Series B Securities due November 15, 2010 are payable in semiannual installments, commencing May 15, 2002, as follows: Percentage of Principal Payment Date Amount Payable May 15, 2002 2.50% November 15, 2002 2.50% May 15, 2003 2.25% November 15, 2003 2.25% May 15, 2004 2.00% November 15, 2004 2.00% May 15, 2005 1.75% November 15, 2005 1.75% May 15, 2006 10.50% November 15, 2006 10.50% May 15, 2007 11.00% November 15, 2007 11.00% May 15, 2008 11.00% November 15, 2008 11.00% May 15, 2009 4.00% November 15, 2009 4.00% May 15, 2010 5.00% November 15, 2010 5.00% The FRNs, which were not a part of the Exchange Offer, rank pari passu with and share the collateral on a pro rata basis with the Old Securities and the New Securities, and are entitled to the benefits of the Indenture and the Depositary Agreement. The FRNs have been issued in the principal amount of $75,000,000, bear interest from their date of issuance at the rate equal to LIBOR plus 3.00% per annum, and have final maturity of principal of November 15, 2002. The principal of the FRNs will be payable in semiannual installments, commencing November 15, 2000, as follows: Percentage of Principal Payment Date Amount Payable November 15, 2000 25.00% May 15, 2001 19.50% November 15, 2001 20.00% May 15, 2002 18.00% November 15, 2002 17.50% Interest on the FRNs will be payable quarterly on each February 15, May 15, August 15, and November 15, commencing on February 15, 1996, to the registered Holders thereof at the close of business on the preceding February 1, May 1, August 1, and November 1, as the case may be. After Completion of the Casecnan Project (as defined in the Turnkey Construction Contract), the FRNs are subject to optional redemption, in whole or in part, pro rata, at par plus accrued interest upon 30 days notice, on any FRN interest payment date. Priority of Payments Prior to Completion, all net proceeds of the Securities and any Liquidated Damages Proceeds will be deposited in the Construction Fund and disbursed to pay for budgeted construction or restoration costs, including interest and, if applicable, principal on the Securities. After Completion, except as otherwise provided for with respect to mandatory redemptions and Loss Proceeds, all revenues received by the Company from the Project will be paid into the Revenue Fund maintained by the Depositary (other than certain peso payments required to be used for VAT payments to the Republic of the Philippines). Amounts paid into the Revenue Fund shall be distributed in the following order of priority: (a) to pay Operating and Maintenance Costs; (b) to pay certain administrative costs of the agents for the Secured Parties under the Financing Documents; (c) to pay principal of, premium (if any) and interest on the Securities (including any increased costs necessary to gross up such payments for certain withholding taxes and other assessments to charges), and principal and interest on other Senior Debt, if any; (d) to cause the Debt Service Reserve Fund to equal the Debt Service Reserve Fund Required Balance, as defined below; (e) to pay indemnification expenses and other expenses to the Secured Parties and certain other costs, and (f) to the Distribution Fund or Distribution Suspense Fund, as applicable. Debt Service Reserve Fund At Completion, the Company will establish a Debt Service Reserve Fund for the benefit of the Holders of the Securities, which will be funded in cash from any remaining shareholder capital contributions in the Capital Contribution Fund or, to the extent required, from operating revenues as described under "Priority of Payments" above. Such amounts will be deposited into the Debt Service Reserve Fund from time to time to the extent required to cause it to equal the Debt Service Reserve Fund Required Balance which is intended to approximate the highest amount of the payments of principal and interest to be made on the Securities during any semiannual period over the subsequent three years. Optional Redemption On and after the seventh anniversary of the Closing, the Old Series A Securities and New Series A Securities are subject to optional redemption, in whole and not in part, at par plus accrued interest to the Redemption Date. The Old Series B Securities and New Series B Securities are subject to optional redemption, at any time, in whole or in part, pro rata, at par plus accrued interest to the Redemption Date plus a premium, calculated to "make whole" to comparable U.S. treasury securities plus 150 basis points. After completion, the FRN's are subject to optional redemption, in whole or in part, pro rata at par plus accrued interest, on any FRN interest payment date. The Company also has the option to redeem the Securities, in whole or in part, at par plus accrued interest at any time if, as a result of any change in Philippine tax law or in the application or interpretation of Philippine tax law occurring after the date of issuance of the Securities, the Company is required to pay certain additional amounts described in the Indenture. Mandatory Redemption The Securities are subject to mandatory redemption, pro rata, at par plus accrued interest to the Redemption Date, (a) upon the receipt by the Company of Loss Proceeds that exceed $15 million in respect of certain events of property or casualty loss or similar events, unless the funds are to be utilized by the Company for an Approved Restoration Plan; or (b) upon the receipt by the Company of proceeds realized in connection with a Project Agreement Buyout. Change in Control Put Upon the occurrence of a Change of Control each Holder will have the right to require the Company to repurchase all or any part of such Holder's Securities at a purchase price in cash equal to 101% of the principal amount thereof, plus accrued interest to the date of repurchase in accordance with the procedures set forth in the Indenture. There is no assurance that upon a Change in Control the Company will have sufficient funds to repurchase the Securities. Distributions Prior to Completion, there will be no distributions to the Company or its shareholders. After Completion, distributions may be made only from and to the extent of monies on deposit in the Distribution Fund or Distribution Suspense Fund. Distributions are subject to the prior satisfaction of the following conditions: (a) the amounts contained in the Principal Fund and the Interest Fund will be equal to or greater than the aggregate scheduled principal and interest payments next due on the Securities; (b) no Default or Event of Default under the Indenture shall have occurred and be continuing; (c) the Debt Service Coverage Ratio for the preceding 12- month period is equal to or greater than 1.35 to 1 as certified by an officer of the Company; (d) the projected Debt Service Coverage Ratio of the Securities for the succeeding 12-month period is equal to or greater than 1.35 to 1, as certified by an officer of the Company; and (e) the Debt Service Reserve Fund has a balance equal to or greater than the Debt Service Reserve Fund Required Balance. Ranking and Security for the Securities The Old Securities and the FRNs were, and the New Securities and Additional Securities are, Senior Debt of the Company and are secured by (a) an assignment of all revenues received by the Company from the Project; (b) a collateral assignment of all material contracts; (c) a Lien on any accounts and funds on deposit under the Depositary Agreement; (d) a pledge of approximately 100% of the capital stock of the Company, subject to release in certain circumstances relating to accessing political risk insurance for the benefit of the shareholders; and (e) a Lien on all other material assets and property interests of the Company. The Securities will rank pari passu with and will share the Collateral on a pro rata basis with certain other Senior Secured Debt, if any (provided that the Debt Service Reserve Fund shall be collateral solely for the obligations under the Securities). The proceeds of any political risk insurance covering the capital investment will not be part of the collateral for the Securities. While under the Indenture the Company may incur certain Permitted Debt senior to the Securities, it has no present intention to do so. Ratings Moody's and Standard & Poor's have assigned the Securities ratings of "Ba2" and "BB", respectively. There is no assurance that any such credit rating will remain in effect for any given period of time or that such rating will not be lowered, suspended or withdrawn entirely by the applicable Rating Agency, if, in such Rating Agency's judgment, circumstances so warrant. Recently, Standard & Poor's placed the Securities on CreditWatch with negative implications. Any such lowering, suspension or withdrawal of any rating may have a Material Adverse Effect on the market price or marketability of the Securities. Nature of Recourse on the Securities The Company's obligations to make payments of principal or, premium, if any, and interest on the Old Securities and FRNs were, and on the New Securities and Additional Securities are, obligations solely of the Company secured solely by the Collateral. Neither the shareholders of the Company nor any Affiliate, including CalEnergy and Kiewit, incorporator, officer, director or employee thereof or of the Company guaranteed the payment of the Old Securities, the New Securities or the FRNs, nor have any obligation with respect to payment of the Securities or Additional Securities, except to the extent that affiliates of CalEnergy and Kiewit who are stockholders of the Company have pledged their capital stock in the Company as security for the notes and bonds issued by the Company. As a result, payment of the Company's obligations depends upon the availability of sufficient revenues from the Company's business after the payment of operating expenses. Incurrence of Additional Debt The Company shall not incur any Debt other than "Permitted Debt." "Permitted Debt" means: (a) The Securities; (b) After Completion, Debt incurred to finance the making of capital improvements to the Casecnan Project required to maintain compliance with applicable law or anticipated changes therein; provided that no such Debt may be incurred unless at the time of incurrence the Independent Engineer confirms as reasonable (i) a certification by the Company (containing customary assumptions and qualifications) that the proposed capital improvements are reasonably expected to enable the Casecnan Project to comply with applicable or anticipated legal requirements and (ii) the calculations of the Company that demonstrate, after giving effect to the incurrence of such Debt, the minimum project Debt Service Coverage Ratio (x) for the next four consecutive fiscal quarters, commencing with the quarter in which such Debt is incurred, taken as one annual period, and (y) for each subsequent fiscal year through the Final Maturity Date, will not be less than 1.3 to 1; (c) After Completion, Debt incurred to finance the making of capital improvements to the Casecnan Project not required by applicable law, so long as after giving effect to the incurrence of such Debt (i) no Default or Event of Default has occurred and is continuing, and (ii)(A) the Independent Engineer confirms as reasonable (I) a certification by the Company (containing customary assumptions and qualifications) that the proposed capital improvements are technically feasible and prudent and (II) the calculations of the Company that demonstrate, after giving effect to the incurrence of such Debt, (x) the minimum project Debt Service Coverage Ratio for the next four consecutive fiscal quarters, commencing with the quarter in which such Debt is incurred, taken as one annual period, and in every fiscal year thereafter, will not be less than 1.4 to 1 and (y) the average projected Debt Service Coverage Ratio for all succeeding fiscal years until the Final Maturity Date will not be less than 1.7 to 1, or (B) the Rating Agencies confirm that the incurrence of such Debt will not result in a Rating Downgrade. (d) After Completion, Working Capital Debt in an aggregate amount outstanding at any time not to exceed $5 million; (e) Debt incurred in connection with certain permitted interest rate and currency hedging arrangements; (f) Subordinated Debt from Affiliates in an aggregate amount not to exceed $150 million prior to Completion and $100 million after Completion, which shall be used to finance capital, operating or other costs with respect to the Project; (g) Debt incurred for purposes for which Permitted Liens may be incurred; (h) Debt contemplated to be incurred pursuant to the Casecnan Project Documents, including obligations in connection with any letter of credit in an aggregate amount outstanding at any time not to exceed $15 million; (i) Purchase Money Debt and other ordinary course trade Debt to support operation and maintenance of the Casecnan Project, in an aggregate amount at any time not to exceed $35 million; (j) Permitted Refinancing Debt, if, as certified by an authorized officer of the Company at the time of incurrence, (A)(i) after giving effect to the incurrence of such Debt, (x) the minimum projected Debt Service Coverage Ratio for the next four consecutive fiscal quarters in which such Debt is incurred, taken as one annual period, and in every fiscal year thereafter, will not be less than 1.5 to 1, and (y) for each subsequent fiscal year through the Final Maturity Date, the average project Debt Service Coverage Ratio will not be less than 2.0 to 1, and (ii) the final maturity and average life of the Debt incurred each exceed those of the Debt remaining, (B) each principal payment equals that of each corresponding principal payment of the Debt being replaced or (C) the Rating Agencies confirm that the incurrence of such Debt will not result in a Rating Downgrade; and (k) Debt incurred by the Company prior to Completion as necessary for financing, engineering, construction, completion, testing and start-up of the Project in accordance with an Approved Completion Plan in order to achieve Completion ("Pre- Completion Additional Debt"), provided that (i) the Rating Agencies confirm that the incurrence of such Debt will not result in a Rating Downgrade; or (ii)(A) the Independent Engineer has confirmed (subject to customary assumptions and qualifications) as reasonable the technical feasibility of the Approved Completion Plan including a certification that (subject to customary assumptions and qualifications) the net proceeds of such Debt and other funds available to the Company (from Liquidated Damages Proceeds or otherwise) are reasonably expected to be sufficient to fund the costs of reaching Completion; and (B) the Company certifies at the time of incurrence (with customary assumptions and qualifications) that (x) the Approved Completion Plan is technically feasible and prudent, (y) after giving effect to the incurrence of such Debt, the minimum projected Debt Service Coverage Ratio for the four fiscal quarters commencing with the quarter that commences immediately after the projected date of commercial operation of the Casecnan Project, taken as one annual period, and in every fiscal year thereafter, will not be less than 1.3 to 1, and (z) after giving effect to incurrence of such Debt, the average projected Debt Service Coverage Ratio for all succeeding Fiscal Years until the Final Maturity Date will not be less than 1.5 to 1. Principal Covenants Principal covenants under the Indenture require the Company, subject to certain exceptions and qualifications, (a) not to incur (i) any Debt except Permitted Debt or (ii) any Lien upon any of its assets except Permitted Liens; (b) not to enter into any transaction of merger or consolidation, change its form of organization, liquidate, wind-up or dissolve itself; (c) not to enter into non-arm's length transactions or agreements with Affiliates; (d) not to engage in any business other than as contemplated by the Indenture; (e) not to enter into certain change orders under the Turnkey Construction Contract or amend the Approved Construction Budget and Schedule (or an Approved Completion Plan), or amend, terminate or otherwise modify any material Project Document to which it is a party, except as permitted under the Indenture; (f) not to sell, lease or transfer any property or assets material to the Casecnan Project except in the ordinary course of business; (g) to construct the Casecnan Project in accordance with the Approved Construction Budget and Schedule; (h) to operate and maintain the Casecnan Project in accordance with the Approved Operation and Maintenance Budget; (i) to maintain insurance as required under the Indenture; and (j) to enter into an interest rate agreement for the FRNs, within 30 days of Closing, at a LIBOR cap of up to 7.5%. Insurance The Company maintains insurance with respect to the Casecnan Project of a type and in such amounts as are generally carried by companies engaged in similar businesses and owning similar projects that are financed in a similar manner. These coverages will include casualty insurance, including flood and earthquake coverage, business interruption insurance, primary and excess liability insurance, automobile insurance and workers compensation insurance. However, the proceeds of such insurance may not be adequate to cover reduced revenues, increased expenses or other liabilities arising from the occurrence of catastrophic events. Moreover, there can be no assurance that such insurance coverage will be available in the future at commercially reasonable rates or that the amounts for which the Company will be insured will cover all losses. Nevertheless, the Company will not reduce or cancel coverages if the Insurance Consultant determines it is not reasonable to do so and insurance is available on commercially reasonable terms. Regulatory Matters The Company is subject to a number of Philippine statutory and regulatory standards and required and desirable approvals, including those relating to energy and environmental laws. Many permits and regulatory approvals are required and desirable for the construction and operation of the Casecnan Project. A number of these permits and regulatory approvals have not yet been obtained. Some of the permits and regulatory approvals that have been obtained contain conditions, and a number of the permits and approvals not yet obtained may contain conditions when they are issued. Delay in receipt of or failure to obtain these permits or approvals or to satisfy any of these conditions could delay completion of the construction of the Casecnan Project, restrict the operation of the Casecnan Project, or result in additional costs or taxes. The adoption of new laws, policies or regulations, or changes in the interpretation or application of existing laws, policies and regulations, that modify the present regulatory environment could have a material adverse effect on the Company's ability to construct or operate the Casecnan Project and could trigger the Company's right to sell the Project to NIA. Upon such sale, the Securities will be subject to mandatory redemption. Employees After Completion, the Casecnan Project is expected to employ approximately 25 people, consisting of operations, maintenance, logistics, compliance, and engineering personnel, including some personnel presently employed by CalEnergy, Kiewit or their respective Affiliates. At the powerhouse control room, personnel will monitor, direct and control the operations and maintenance of the whole Casecnan Project. The control room will be staffed 24 hours per day and will be the contact point for the Casecnan Project's customers and others. At the diversion structures, personnel will be responsible to ensure that the trash racks at the tunnel intakes are kept clean and maintained and that excessive sediment build-up behind the structure is prevented. Item 2. Properties CE Casecnan does not separately own or lease office space but has arranged for a separate suite at the offices of CalEnergy's affiliate in Manila. Item 3. Legal Proceedings There is no litigation pending or, to the knowledge of the Company, threatened that, if adversely determined, would have a material adverse effect on the business, operations, properties or financial condition of the Company. Item 4. Submission of Matters to a Vote of Security Holders. Not Applicable. PART II Item 5. Market for Company's Equity and Related Stockholder Matters. Not Applicable. Item 6. Selected Financial Data Dollars in Thousands Except Per Share Amounts Year Ended December 31, 1996 1995 1994 Total revenue $ 25,611 $ 2,494 $ --- Expenses 42,852 4,340 --- Loss before provision for income taxes (17,241) (1,846) --- Net loss to common stockholders (13,211) (1,200) --- Net loss per share - primary (17.22) (2.09) --- Total assets 490,162 501,160 2,349 Total liabilities 380,737 378,524 1,799 Notes and bonds payable 371,500 371,500 --- Stockholders' equity 109,425 122,636 550 Item 7. Management's Discussion and Analysis of Financial Condition and Results of Operations, Dollars in thousands expect per share amounts Results of Operations: The Company is in the construction stage and has not yet started commercial operations as of December 31, 1996. The quarter and year ended December 31, 1996 revenue of $5,905 and $25,611, respectively, consists of interest income from cash received from bond proceeds and equity contributions. The quarter and year ended December 31, 1996 interest expense of $11,439 and $45,746 less amounts capitalized of $1,481 and $3,843 and amortization of bond issue costs of $239 and $949 are related to the notes and bonds payable issued by the Company in the fourth quarter of 1995. Liquidity and Capital Resources: In November 1995 the Company closed the financing and commenced construction of the Casecnan Project, a combined irrigation and 150 net MW hydroelectric power generation project located in the central part of the island of Luzon in the Republic of the Philippines. CE Casecnan which is presently indirectly owned as to approximately 35% of its equity by CalEnergy and approximately 35% by Kiewit, is developing the Casecnan Project under the terms of the Project Agreement ("Project Agreement") between CE Casecnan and the National Irrigation Administration ("NIA"). Under the Project Agreement, CE Casecnan will develop, finance and construct the Casecnan Project over an estimated four-year construction period, and thereafter own and operate the Casecnan Project for 20 years (the "Cooperation Period"). During the Cooperation Period, NIA is obligated to accept all deliveries of water and energy, and so long as the Casecnan Project is physically capable of operating and delivering in accordance with agreed levels set forth in the Project Agreement, NIA will pay CE Casecnan a guaranteed fee for the delivery of water and a guaranteed fee for the delivery of electricity, regardless of the amount of water or electricity actually delivered. In addition, NIA will pay a fee for all electricity delivered in excess of a threshold amount up to a specified amount. NIA will sell the electric energy it purchases to the Philippine National Power Corporation ("NPC"), although NIA's obligations to CE Casecnan under the Project Agreement are not dependent on the purchase of the electricity from NIA by NPC. All fees to be paid by NIA to CE Casecnan are payable in U.S. dollars. The guaranteed fees for the delivery of water and energy are expected to provide approximately 70% of CE Casecnan's revenues. The Project Agreement provides for additional compensation to CE Casecnan upon the occurrence of certain events, including increases in Philippine taxes and adverse changes in Philippine law. Upon the occurrence and during the continuance of certain force majeure events, including those associated with Philippines political action, NIA may be obligated to buy the Casecnan Project from CE Casecnan at a buy out price expected to be in excess of the aggregate principal amount of the outstanding CE Casecnan debt securities, together with accrued but unpaid interest. At the end of the Casecnan Cooperation Period, the Casecnan Project will be transferred to NIA and NPC for no additional consideration on an "as is" basis. The Republic of the Philippines has provided a Performance Undertaking under which NIA's obligations under the Project Agreement are guaranteed by the full faith and credit of the Republic of the Philippines. The Project Agreement and the Performance Undertaking provide for the resolution of disputes by binding arbitration in Singapore under international arbitration rules. The Casecnan Project is being constructed on a joint and several basis by Hanbo Corporation and Hanbo Engineering & Construction Co. Ltd. (formerly known as You One Engineering & Construction Co., Ltd., and herein referred to as "HECC"), both of which are South Korean corporations, pursuant to a fixed- price, date-certain, Turnkey Construction Contract (the "Turnkey Construction Contract"). Hanbo Corporation and HECC (sometimes collectively referred to as the "Contractor") are under common ownership control. Hanbo Corporation is an international construction company. HECC, which recently emerged from a court- administered receivership, is a contractor with over 25 years experience in tunnel construction, using both the drill-and-blast and tunnel boring machine ("TBM") methods. The Contractor's obligations under the Turnkey Construction Contract are guaranteed by Hanbo Iron & Steel Company, Ltd. ("Hanbo Steel"), a large South Korean steel company. In addition, the Contractor's obligations under the Turnkey Construction Contract are secured by an unconditional, irrevocable standby letter of credit issued by Korea First Bank ("KFB") in the approximate amount of $118,000. The total cost of the Casecnan Project, including development, construction, testing and startup, is estimated to be approximately $495,000. The current capital structure consists of term loans of $371,500 and $123,836 in equity contributions. As of December 31, 1996 the Company has incurred costs of $63,359. Cash, restricted cash and restricted investments totaled $417,169 at December 31, 1996. Early in 1997, CE Casecnan was advised that Hanbo Corporation and Hanbo Steel had each filed to seek court receivership protection in Korea but that HECC had not filed for receivership protection and was believed to be solvent. In March 1997, the Company was informed that HECC filed for receivership protection. CE Casecnan has recently received confirmation from HECC that it intends to fully perform its obligations under the Turnkey Construction Contract and complete the Casecnan Project on schedule and within the budget. However, although HECC is currently performing the work, no assurances can be given that HECC will remain able to perform fully its obligations under the Turnkey Construction Contract. CE Casecnan is presently reviewing its rights, obligations and potential remedies in respect of the recent developments regarding the co-Contractor and the guarantor and is presently unable to speculate as to the ultimate effect of such developments on CE Casecnan. KFB has recently reconfirmed to CE Casecnan that it will honor its obligations under the Casecnan Project letter of credit and also has stated its support for the successful completion of the Casecnan Project and has previously offered to extend a working capital facility to HECC. However, until a receiver for HECC is appointed, it is unclear whether such a working capital facility can be utilized and whether there will be any constraints imposed on HECC's performance of the work. Moody's Investors Service recently issued a ratings downgrade of KFB's senior debt from Baa1 to Baa2. CE Casecnan financed a portion of the costs of the Casecnan Project through the issuance of $125,000 of its 11.45% Senior Secured Series A Notes due 2005 and $171,500 of its 11.95% Senior Secured Series B Bonds due 2010 and $75,000 of its Secured Floating Rate Notes due 2002, pursuant to an indenture dated November 27, 1995, as amended to date (the "Casecnan Indenture"). Although no default has occurred under the Casecnan Indenture as a result of the announced receivership of Hanbo Corporation, CE Casecnan will continue to closely monitor the Hanbo group and KFB developments and project construction status and develop appropriate contingency plans. If Contractor materially fails to perform its obligations under the Turnkey Construction Contract and if KFB were to fail to honor its obligations under the Casecnan letter of credit, such actions could have a material adverse effect on the Casecnan Project and CE Casecnan. The securities are senior debt of the Company and are secured by a collateral assignment of all revenues received from the Project, a collateral assignment of all material contracts, a lien on any accounts and funds on deposit under a Deposit and Disbursement Agreement, a pledge of 100% of the capital stock of the Company and a lien on all other material assets and property. The securities rank pari passu with and will share the collateral on a pro rata basis with other senior secured debt, if any. The securities are subject to certain optional and mandatory redemption schemes as provided for in the offering circular. The debt covenants contain certain restrictions as to incurrence of additional indebtedness; merger, consolidation, dissolution, or any significant change in corporate structure; non-arm's length transactions or agreements with affiliates; material change in the Turnkey Construction Contract; and sale, lease, or transfer of properties material to the Project, among others. The financial statements of the Company were prepared in United States Dollar amounts. Gains or losses from translation of monetary assets and liabilities in foreign currencies are not material. Item 8. Financial Statements and Supplementary Data Report of Independent Public Accountants Balance Sheets, December 31, 1996 and 1995 Statements of Operations for the Years Ended December 31, 1996 and 1995 Statements of Changes in Stockholders' Equity for the Period from Inception (September 21, 1994) to December 31, 1996 Statements of Cash Flows for the Years Ended December 31, 1996 and 1995 and for the Period from Inception (September 21, 1994) to December 31, 1996 Notes to Financial Statements REPORT OF INDEPENDENT PUBLIC ACCOUNTANTS The Stockholders and the Board of Directors CE Casecnan Water and Energy Company, Inc. We have audited the accompanying balance sheets of CE Casecnan Water and Energy Company, Inc. (a company in the development stage) as of December 31, 1996 and 1995, and the related statements of operations for the years then ended, changes in stockholders' equity for the period from date of inception (September 21, 1994) to December 31, 1996, and cash flows for the years then ended and for the period from inception (September 21, 1994) to December 31, 1996. These financial statements are the responsibility of the Company's management. Our responsibility is to express an opinion on these financial statements based on our audits. We conducted our audits in accordance with auditing standards generally accepted in the United States of America. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are fee of material misstatement. An audit includes examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements. An audit also includes assessing the accounting principles used and significant estimates made by management, as well as evaluating the overall financial statement presentation. We believe that our audits provide a reasonable basis for our opinion. In our opinion, the financial statements referred to above present fairly, in all material respects, the financial position of CE Casecnan Water and Energy Company, Inc. as of December 31, 1996 and 1995, and the results of its operations and its cash flows for the periods then ended, and the period from inception (September 21, 1994) to December 31, 1996, in conformity with accounting principles generally accepted in the United States of America. SYCIP, GORRES, VELAYO & CO. An Arthur Andersen Member Firm 6760 Ayala Avenue Makati City, Philippines January 16, 1997 CE CASECNAN WATER AND ENERGY COMPANY, INC. BALANCE SHEETS (in thousands, except share and per share amounts) ________________________________ December 31, December 31, 1996 1995 ASSETS Cash $ 32 $ 1,696 Restricted cash and short-term investments 144,12 2 235,851 Accrued interest and other receivables 4,958 2,820 Restricted investments 273,015 238,465 Bond issue costs, net 12,566 13,342 Development costs 50,793 8,340 Deferred income tax 4,676 646 Total assets $490,162 $501,160 LIABILITIES AND STOCKHOLDERS' EQUITY Liabilities: Accounts payable and accrued expenses $ 8,803 $ 5,951 Advances from an affiliate 434 1,073 Notes and bonds payable 371,500 371,500 Total liabilities 380,737 378,524 Commitments and contingencies Stockholders' equity: Common stock - par value $0.038 per share, authorized 2,148,000 shares, issued and outstanding 767,162 shares at December 31, 1996 and December 31, 1995, respectively 29 29 Additional paid in capital 123,807 123,807 Accumulated deficit (14,411) (1,200) Total stockholders' equity 109,425 122,636 Total liabilities and stockholders' equity $490,162 $501,160 The accompanying notes are an integral part of these financial statements. CE CASECNAN WATER AND ENERGY COMPANY, INC. STATEMENTS OF OPERATIONS (in thousands, except share and per share amounts) ________________________________ Year Ended Year Ended December 31, December 31, 1996 1995 Revenues: Interest and other income $25,611 $ 2,494 Total revenues 25,611 2,494 Costs and expenses: Interest expense 45,746 4,349 Less interest capitalized (3,843) (84) Amortization of bond issue costs 949 75 Total cost and expenses 42,852 4,340 Loss before income taxes (17,241) (1,846) Deferred income tax benefit 4,030 646 Net loss to common stockholders $(13,211) $(1,200) Net loss per share - primary $ (17.22) $ (2.09) Average number of common and common equivalent shares outstanding 767,162 575,372 The accompanying notes are an integral part of these financial statements. CE CASECNAN WATER AND ENERGY COMPANY, INC. STATEMENTS OF CHANGES IN STOCKHOLDERS' EQUITY For the Period from Inception (September 21,1994) to December 31, 1996 (in thousands, except share and per share amounts) ________________________________ Outstanding Additional Common Common Paid-in Accumulated Shares Stock Capital Deficit Total Balance, September 21, 1994 - $ - $ - $ - $ - Issuance of common shares at $0.038 par value 537,014 20 530 - 550 Balance, December 31, 1994 537,014 20 530 - 550 Additional issuance of stock (Note 7) 230,148 9 - - 9 Additional paid-in capital (Note 5) - - 123,277 - 123,277 Net loss - - - (1,200) (1,200) Balance, December 31, 1995 767,162 29 123,807 (1,200) 122,636 Net loss - - - (13,211) (13,211) Balance, December 31,1996 767,162 $ 29 $123,807 $(14,411) $109,425 The accompanying notes are an integral part of these financial statements. CE CASECNAN WATER AND ENERGY COMPANY, INC. STATEMENTS OF CASH FLOWS (in thousands) ________________________________ From Inception Year Ended Year Ended (September 21, 1994) December 31, December 31, to December 31, 1996 1995 1996 Cash flows from operating activities: Net loss $(13,211) $(1,200) $ (14,411) Adjustments to reconcile net cash flow from operating activities: Provision for deferred income tax benefit (4,030) (646) (4,676) Amortization of bond issue costs 949 75 1,024 Increase in accrued interest and other receivables (2,138) (2,820) (4,958) Increase in accounts payable and accrued expenses 1,828 4,266 6,094 Net cash flows from operating activities (16,602) (325) (16,927) Cash flows from investing activities: Additions to development costs (42,453) (6,541) (50,793) Decrease (increase) in restricted cash and short-term investments 91,729 (235,851) (144,122) Increase in restricted investments (34,550) (238,465) (273,015) Increase in accounts payable and accrued expenses related to development activities 1,303 1 ,406 2,709 Net cash flows from investing activities 16,029 (479,451) (465,221) Cash flows from financing activities: Issuance of bonds payable - 371,500 371,500 Proceeds from issuance of capital stock - 9 29 Additional paid-in capital - 123,277 123,807 Bond issue costs (173) (13,417) (13,590) Accrued expense related to financing activities (279) 279 - Advances from an affiliate (639) (726) 434 Net cash flows from financing activities (1,091) 480,922 482,180 Net increase (decrease) in cash and cash equivalents (1,664) 1,146 32 Cash and cash equivalents at beginning of period 1,696 550 - Cash and cash equivalents at end of period $ 32 $ 1,696 $ 32 Supplemental disclosure of cash flow information Interest paid during the year (net of amount capitalized) $40,074 $ - $ 40,074 The accompanying notes are an integral part of these financial statements. CE CASECNAN WATER AND ENERGY COMPANY, INC. NOTES TO FINANCIAL STATEMENTS (in thousands, except share and per share amounts) ________________________________ 1. Organization The Company was registered with the Philippine Securities and Exchange Commission on September 21, 1994, with a fiscal year which ends on December 31. Its primary purpose is to design, develop, construct, erect, assemble, commission, operate and own a hydroelectric power plant and the related facilities for conversion into electricity of water provided by and under contract with the Philippine Government or any government-owned or controlled corporation. The Company has a contract with the Philippine Government, through the National Irrigation Administration (NIA) (a government-owned and controlled corporation), for the development and construction of a hydroelectric power plant and related facilities under a build-own-operate-transfer agreement, covering a 20-year cooperation period with "take-or- pay" obligations for water and electricity. At the end of the 20-year cooperation period, the combined irrigation and 150 net MW hydroelectric power generation project (the Casecnan Project) will be transferred to the Philippine Government at no cost. The Philippine Government also signed a performance undertaking which, among others, affirms and guarantees the obligations of NIA under the contract. Construction of the Casecnan Project has commenced in 1995 and related costs are included in the Development Costs account. The Company is in the development stage and has not yet started commercial operations as of December 31, 1996. After the completion of the aforementioned project, the Company will be owned as follows: 35% by CalEnergy Company, Inc. (CECI), through its wholly owned subsidiary, CE Casecnan Ltd.; 35% by Kiewit Energy International (Kiewit); 15% by LaPrairie Group Contractors (International) Ltd. (LaPrairie); and 15% by San Lorenzo Ruiz Builders & Developers Group, Inc. (San Lorenzo Ruiz), subject to adjustment based upon the economics of the Casecnan Project at commencement of commercial operations. 2. United States Dollar Financial Statements The financial statements of the Company were prepared in United States dollar amounts. Gains or losses resulting from translation of monetary assets and liabilities in foreign currencies are not material. 3. Summary of Significant Accounting Policies Restricted Cash and Short-term Investments Investments other than restricted cash are primarily commercial paper and money market securities. Restricted cash includes similar securities and mortgage-backed securities. The Company classifies investments and accounts for changes in their fair value in accordance with Financial Accounting Standards (FAS) No. 115 "Accounting for Certain Investments in Debt and Equity Securities." Since the Company has the positive intent and ability to hold all of its investments to maturity, these are classified as held to maturity and recorded at amortized cost. The carrying amount of investments as of December 31, 1996 approximates their fair value which is based on quoted market prices as provided by the financial institution holding the investments. Bond Issue Costs Bond issue costs consist of costs incurred in the issuance of senior secured notes and bonds and are amortized over the term of the notes and bonds using the effective interest rate method. Development Costs Costs related to the development and construction of the hydroelectric power plant and related facilities are capitalized and will be amortized over a period of 20 years from the start of its commercial operations. Interest Capitalization Interest and other financial charges are capitalized as part of the cost of capital projects. Interest is capitalized to the extent of incurred construction and development costs. Foreign Exchange Transactions The Company prepares its financial statements in United States dollar amounts. Transactions conducted in foreign currencies (Philippine pesos) are recorded based on the prevailing rates of exchange at transaction dates. Monetary assets and liabilities denominated in foreign currencies (Philippine pesos) are restated in the financial statements at the exchange rates prevailing at the balance sheet date. Income Tax Deferred tax assets and liabilities are recognized for the future tax consequences attributable to differences between financial reporting bases of assets and liabilities and their related tax bases. Deferred tax assets and liabilities are measured using the tax rates expected to apply to taxable income in the years in which those temporary differences are expected to be recovered or settled. A valuation allowance is provided for deferred tax assets which is more likely than not that a tax benefit will not be realized. Notes and Bonds Payable The Company classifies in notes and bonds payable and accounts for changes in their fair value in accordance with FAS No. 107 "Disclosures about Fair Value of Financial Instruments". The carrying amount of the Company's notes and bonds payable is a reasonable estimate of its fair value as interest rates are variable based on prevailing market rates. 4. Advances from an Affiliate This account represents noninterest-bearing cash advances from CE Casecnan Ltd., a stockholder, f for the construction of the Project. 5. Notes and Bonds Payable On November 27, 1995, the Company issued US$371,500 worth of notes and bonds to finance t he construction of the Project. These consist of US$75,000 Senior Secured Floating Rate Notes (FRNs) due 2002; US$125,000 Senior Secured Series A Notes (Series A Notes) with interest at 11.45% due 2005; and US$171,500 Senior Secured Series B Bonds (Series B Bonds) with interest at 11.95% due 2010. For the year ended December 31, 1996, the notes and bonds had effective interest rates of 9.29%, 12.12% and 12.56% for FRNs, Series A Notes and Series B Bonds, respectively, inclusive of the effect of bond issue cost amortization. Quarterly interest payments for the FRNs commenced on February 15, 1996, and semiannual interest payments for Series A Notes and Series B Bonds commenced on May 15, 1996. Semiannual installments for principal payments will commence on November 15, 2000, May 15, 2003 and May 15, 2002 for the FRNs, Series A Notes and Series B Bonds, respectively. The repayment schedule is as follows: Floating Rates Series A Series B Notes Notes Bonds Total 2000 $18,750 $ --- $ --- $18,750 2001 29,625 --- --- 29,625 2002 26,625 --- 8,575 35,200 2003 --- 33,750 7,718 41,468 2004 --- 42,500 6,860 49,360 2005 --- 48,750 6,002 54,752 2006 --- --- 36,015 36,015 2007 --- --- 37,730 37,730 2008 --- --- 37,730 37,730 2009 --- --- 13,720 13,720 2010 --- --- 17,150 17,150 $75,000 $125,000 $171,500 $371,500 The securities are senior debt of the Company and are secured by an assignment of all revenues received from the Project, a collateral assignment of all material contracts, a lien on any accounts and funds on deposit under a Deposit and Disbursement Agreement, a pledge of 100% of the capital stock of the Company and a lien on all other material assets and property interests of the Company. The securities rank pari passu with and will share the collateral on a pro rata basis with other senior secured debt, if any. The securities are subject to certain optional and mandatory redemption schemes as provided for in the offering circular. The debt covenants contain certain restrictions as to incurrence of additional indebtedness; merger, consolidation, dissolution, or any significant change in corporate structure; non-arm's length transactions or agreements with affiliates; material change in the Turnkey Construction Contract (see Note 8); sale, lease, or transfer of properties material to the Project, among others. In connection with the foregoing secured indebtedness, the Company, on November 27, 1995, entered into a Deposit and Disbursement Agreement with Chemical Trust Company of California (Chemical Trust) and Kiewit whereby Chemical Trust will act as a depositary and a collateral agent. As a depositary agent, it will hold moneys, instruments and securities pledged by the Company to the collateral agent. The terms of this agreement require the establishment of several funds which include a Capital Contribution Fund. CE Casecnan Ltd. and Kiewit deposited an aggregate capital contribution of approximately US$123,300 to the fund which will be strictly used to fund the construction of the Project when the proceeds from the Series A Notes and Series B Bonds have been fully utilized. 6. Income Tax The Company's deferred tax asset amounting to $4,676 (net of valuation allowance of $2,004) and $646 as of December 31, 1996 and 1995, respectively, consists mainly of the difference between the financial reporting basis and the tax reporting basis for development costs. 7. Capital Stock On October 26, 1995, the Company issued 230,148 shares to LaPrairie and San Lorenzo Ruiz out of the Company's unsubscribed portion of its authorized capital stock. LaPrairie and San Lorenzo Ruiz initially formed a venture to pursue the opportunity of developing a water and energy project in the Casecnan Basin. After securing preliminary indications of interest from the Philippine Government, LaPrairie and San Lorenzo Ruiz sought out other shareholders to form a new entity capable of financing and building the Project. In consideration of their role in initiating the Project and delivering the opportunity to the Company and, in the case of San Lorenzo Ruiz, performing development assistance, LaPrairie and San Lorenzo Ruiz retained an ownership interest in the Company. 8. Commitments, Contingencies and Other Matters In November 1995, the Company closed the financing and commenced construction of the Casecnan Project, a combined irrigation and 150 MW hydroelectric power generation project (the "Casecnan Project") located in the central part of the island of Luzon in the Republic of the Philippines. The Casecnan Project will consist generally of diversion structures in the Casecnan and Denip Rivers that will divert water into a tunnel of approximately 23 kilometers. The tunnel will transfer the water from the Casecnan and Denip Rivers in the Pantabangan Reservoir for irrigation and hydroelectric use in the Central Luzon area. An underground power house located at the end of the water tunnel and before the Pantabangan Reservoir will house a power plant consisting of approximately 150 MW of newly installed rated electrical capacity. A tailrace tunnel of approximately three kilometers will deliver water from the water tunnel and the new powerhouse to the Pantabangan Reservoir, providing additional water for irrigation and increasing the potential electrical generation at two downstream existing hydroelectric facilities of the National Power Corporation of the Philippines ("NPC"). The Company is developing the Casecnan Project under the terms of the Project Agreement between the Company and the National Irrigation Administration ("NIA"). Under the Project Agreement, the Company will develop, finance and construct the Casecnan Project over an estimated four-year construction period, and thereafter own and operate the Casecnan Project for 20 years (the "Cooperation Period"). During the Cooperation Period, NIA is obligated to accept all deliveries of water and energy, and so long as the Casecnan Project is physically capable of operating and delivering in accordance with agreed levels set forth in the Project Agreement, NIA will pay the Company a guaranteed fee for the delivery of water and a guaranteed fee for the delivery of electricity, regardless of the amount of water or electricity actually delivered. In addition, NIA will pay a fee for all electricity delivered in excess of a threshold amount up to a specified amount. NIA will sell the electric energy it purchases to NPC, although NIA's obligations to the Company under the Project Agreement are not dependent on NPC's purchase of the electricity from NIA. All fees to be paid by NIA to the Company are payable in U.S. dollars. The guaranteed fees for the delivery of water and energy are expected to provide approximately 70% of the Company's revenues. The Project Agreement provides for additional compensation to the Company upon the occurrence of certain events, including increases in Philippine taxes and adverse changes in Philippine law. Upon the occurrence and during the continuance of certain force majeure events, including those associated with Philippines political action, NIA may be obligated to buy the Casecnan Project from the Company at a buy out price expected to be in excess of the aggregate principal amount of the outstanding Company debt securities, together with accrued but unpaid interest. At the end of the Cooperation Period, the Casecnan Project will be transferred to NIA and NPC for no additional consideration on an "as is" basis. The Republic of the Philippines has provided a Performance Undertaking under which NIA's obligations under the Project Agreement are guaranteed by the full faith and credit of the Republic of the Philippines. The Project Agreement and the Performance Undertaking provide for the resolution of disputes by binding arbitration in Singapore under international arbitration rules. The Casecnan Project is being constructed on a joint and several basis by Hanbo Corporation and Hanbo Engineering & Construction Co. Ltd. (formerly known as You One Engineering & Construction Co., Ltd., and herein referred to as "HECC"), both of which are South Korean corporations, pursuant to a fixed-price, date-certain, turnkey construction contract (the "Turnkey Construction Contract"). Hanbo Corporation and HECC (sometimes collectively referred to as the "Contractor") are under common ownership control. Hanbo Corporation is an international construction company. HECC, which recently emerged from a court-administered receivership, is a contractor with over 25 years experience in tunnel construction, using both the drill-and-blast and tunnel boring machine ("TBM") methods. The Contractor's obligations under the Turnkey Construction Contract are guaranteed by Hanbo Iron & Steel Company, Ltd. ("Hanbo Steel"), a large South Korean steel company. In addition, the Contractor's obligations under the Turnkey Construction Contract are secured by an unconditional, irrevocable standby letter of credit issued by Korea First Bank ("KFB") in the approximate amount of $118 million. The total cost of the Casecnan Project, including development, construction, testing and startup, is estimated to be approximately $495 million. The Company was recently advised that Hanbo Corporation and Hanbo Steel had each filed to seek court receivership protection in Korea. At the present time, all of the construction work on the Casecnan Project is being performed by the second contractor which is party to the Turnkey Construction Contract, HECC. Although HECC, Hanbo Corporation and Hanbo Steel are under common ownership control, HECC has not filed for receivership protection and is believed to be solvent. However, no assurances can be given that HECC will not file for receivership due to the foregoing developments or that it will remain solvent and able to perform fully its obligations under the Turnkey Construction Contract. The work on the Casecnan Project, which commenced in 1995, is presently continuing on schedule and within the budget. The Company is presently reviewing its rights, obligations and potential remedies in respect of the recent developments regarding the co-Contractor and the guarantor and is presently unable to speculate as to the ultimate effect of such developments on the Company. However, the Company has recently received confirmation from HECC that it intends to fully perform its obligations under the Turnkey Construction Contract and complete the Casecnan Project on schedule and within the budget. Additionally, it has been reported that the South Korean government has informed the Philippine government that the South Korean government will take appropriate actions to support HECC's completion of the Casecnan Project. KFB has recently reconfirmed to the Company that it will honor its obligations under the Casecnan Project letter of credit and also has stated its support for the successful completion of the Casecnan Project. However, Moody's Investors Service has recently issued a warning for a possible rating downgrade for Korea First Bank because of the possible impact of the Hanbo Steel receivership on the substantial loans KFB previously made to Hanbo Steel. In a related development, the South Korean government has recently announced that it would provide some funding to assist Hanbo Steel's creditor banks (including Korea First Bank) and its subcontractors. The Company financed a portion of the costs of the Casecnan Project through the issuance of $125,000 of its 11.45% Senior Secured Series A Notes due 2005, $171,500 of its 11.95% Senior Secured Series B Notes due 2010, and $75,000 of its FRNs pursuant to an indenture dated November 27, 1995, as amended to date (the "Casecnan Indenture"). Although no default has occurred under the Casecnan Indenture as a result of the announced receivership of Hanbo Corporation, the Company will continue to closely monitor the Hanbo group and KFB developments and project construction status and develop appropriate contingency plans. If HECC were to materially fail to perform its obligations under the Turnkey Construction Contract and if KFB were to fail to honor its obligations under the Casecnan letter of credit, such actions could have a material adverse effect on the Casecnan Project and the Company. However, based on the information presently available to it, the Company does not presently expect that either such event will occur. CE Casecnan's ability to make payments on any of its existing and future obligations is dependent on NIA and the Republic of the Philippines' performance of their obligations under the Project Agreement and the Performance Undertaking, respectively. No shareholders, partners or affiliates of CE Casecnan, including CECI and Kiewit, and no directors, officers or employees of CE Casecnan will guarantee or be in any way liable for payment of CE Casecnan's obligations. As a result, payment of CE Casecnan's obligations depends upon the availability of sufficient revenues from CE Casecnan's business after the payment of operating expenses. NIA's payments of obligations under the Project Agreement are expected to be CE Casecnan's sole source of operating revenues. Because of CE Casecnan's dependence on NIA, any material failure of NIA to fulfill its obligations under the Project Agreement and any material failure of the Republic of the Philippines to fulfill its obligations under the Performance Undertaking would significantly impair the ability of CE Casecnan to meet its existing and future obligations. There were no material outstanding lawsuits as of December 31, 1996. 9. Registration with the Board of Investments (BOI) The Company is registered with the BOI of the Philippines as a new operator of a hydroelectric power plant with pioneer status under the Omnibus Investment Code of 1987 (Executive Order No. 226). Under the terms of the registration, the Company is entitled to certain incentives which include an income tax holiday for a minimum of six years; tax and duty free importation of capital equipment; tax credits on domestic capital equipment; and exemption from custom duties and national internal revenue taxes for the importation and unrestricted use of the consigned equipment for the development, construction, start-up, testing and operation of the power plant. The registration also requires, among others, the maintenance of a debt-to-equity ratio not exceeding 75:25 commencing from the start of commercial operations. Item 9: Changes in and Disagreements with Accountants on Accounting and Financial Disclosure Not Applicable PART III Item 10. Directors and Executive Officers of the Company The following table sets forth the names, ages, and positions of the directors and executive officers of the Company: NAME AGE POSITION David L. Sokol 40 Director, Chairman and Chief Executive Officer Donald M. O'Shei, Jr. 38 Director, Vice Chairman, President and Chief Operating Officer, Asia Gregory E. Abel 34 Executive Vice President and Chief Accounting Officer Douglas L. Anderson 39 Assistant Vice President Edward F. Bazemore 60 Vice President - Human Resources Vincent R. Fesmire 56 Vice President - Construction James A. Flores 43 Assistant Treasurer Brian Hankel 34 Treasurer Scott LaPrairie 39 Director Steven A. McArthur 39 Director, Senior Vice President and General Counsel Ruby S. Nitorreda 33 Director and Assistant Corporate Secretary Elizabeth B. Opena 27 Director Jose R. Sandejas 59 Director and Corporate Secretary Robert S. Silberman 39 Senior Vice President, Strategic Planning & Implementation James D. Stallmeyer 39 Vice President and General Counsel, Asia John G. Sylvia 39 Director, Senior Vice President and Chief Financial Officer Russ L. Tenney 43 Director and Vice President, Philippine Operations Oscar Violago 52 Director Each of the nine directors of the Company is elected annually and holds office until a successor is elected. Executive officers are chosen from time to time by vote of the Board of Directors. Pursuant to the terms of the Stockholders Agreement, CE Casecnan Ltd. is entitled to elect four of the nine directors, KEIL Casecnan Ltd. is entitled to elect three of the directors, and each of the minority investors is entitled to elect one director. David L. Sokol. In addition to serving as a Director and Chairman and Chief Executive Officer of the Company, Mr. Sokol has been a director of CalEnergy since March 1991 and currently the Chairman and Chief Executive Officer of CalEnergy. Mr. Sokol also held the title of President of CalEnergy from April 19, 1993 until January 21, 1995. Mr. Sokol was Chairman, President, and Chief Executive Officer of CalEnergy from February 1991 until January 1992. Mr. Sokol was the President and Chief Operating Officer, as well as a director, of JWP, Inc. from January 27, 1992 until October 1, 1992. From November 1990 until February 1991, Mr. Sokol was the President and Chief Executive Officer of Kiewit Energy, Inc. From 1983 until November of 1990, Mr. Sokol was the President and Chief Executive Officer of Ogden Projects, Inc. Donald M. O'Shei, Jr. In addition to serving as a Director, Vice Chairman and President and Chief Operating Officer, Asia of the Company, Mr. O'Shei is President and Chief Operating Officer of CalEnergy Asia. Mr. O'Shei joined the Company in August 1992. Prior to 1997, he served as General Manager_Indonesia and Vice President of CE International Investments, Ltd. for the Company. From 1991 to 1992, he was employed by Proven Alternatives Capital Corporation as a Financial Analyst. Prior to 1991, Mr. O'Shei served in the U.S. Army in the Special Forces, Airborne and Pathfinder Units. Gregory E. Abel. In addition to serving as Executive Vice President and Chief Accounting Officer of the Company, Mr. Abel is President and Chief Operating Officer of CalEnergy Europe and Chief Accounting Officer of CalEnergy. Mr. Abel joined CalEnergy in 1992. Mr. Abel is a Chartered Accountant and from 1984 to 1992 he was employed by Price Waterhouse. As a Manager in the San Francisco office of Price Waterhouse, he was responsible for clients in the energy industry. Douglas L. Anderson. In addition to serving as Assistant Vice President for the Company, Mr. Anderson is General Counsel, CalEnergy Americas and Assistant Secretary and Assistant General Counsel of CalEnergy. Mr. Anderson joined CalEnergy in February 1993. From 1990 to 1993 Mr. Anderson was a business attorney with Fraser, Stryker, Vaughn, Meusey, Olson, Boyer & Bloch, P.C. in Omaha and from 1987 through 1989 Mr. Anderson was a principal in the firm Anderson & Anderson. Prior to that, from 1985 to 1987, he was an attorney for Foster, Swift, Collins & Coey, P.C. in Lansing, Michigan. Edward F. Bazemore. In addition to serving as Vice President - Human Resources for the Company, he also serves in the same capacity for CalEnergy. Mr. Bazemore joined CalEnergy in July 1991. Prior to that he was Vice President, Human Resources from 1989 to 1991 at Ogden Projects, Inc., Director of Human Resources for Ricoh Corporation and Director of Industrial Relations for Scripto, Inc. Vincent R. Fesmire. In addition to serving as Vice President - Construction for the Company, Mr. Fesmire is Vice President, Construction and Engineering for CalEnergy. Mr. Fesmire joined CalEnergy in October 1993. Prior to that Mr. Fesmire was employed for 19 years at Stone & Webster, an engineering firm. James A. Flores. In addition to serving as Assistant Treasurer for the Company, Mr. Flores is Manager, Project Finance for CalEnergy. Mr. Flores joined CalEnergy in May 1994. Prior to that Mr. Flores was employed at Mellon Bank in Pittsburgh, PA from 1981 to 1994 and Citibank in 1980 and Manufacturers Hanover Trust from 1977 to 1979. Brian Hankel. In addition to serving as Treasurer for the Company, he also serves in that capacity for CalEnergy. Mr. Hankel joined CalEnergy in February 1992 as a Treasury Analyst and became Assistant Treasurer in 1996. Prior to joining CalEnergy, Mr. Hankel was employed at FirsTier Bank. Scott LaPrairie. In addition to serving as a Director of the Company, Mr. LaPrairie is President and Chief Executive Officer of the LaPrairie Group of Companies. Steven A. McArthur. In addition to serving as a Director, Senior Vice President and General Counsel of the Company, Mr. McArthur is a Senior Vice President, General Counsel, and Secretary of CalEnergy. Mr. McArthur joined CalEnergy in February of 1991. From 1988 to 1991 he was an attorney in the Corporate Finance Group at Shearman & Sterling in San Francisco. From 1984 to 1988, Mr. McArthur was an attorney in the Corporate Finance Group at Winthrop, Stimson, Putnam & Roberts in New York. Ruby S. Nitorreda. In addition to serving as a Director and Assistant Corporate Secretary of the Company, Ms. Nitorreda is an attorney with the law firm of Quisumbing Torres & Evangelista. Jose R. Sandejas. In addition to serving as a Director and Corporate Secretary of the Company, Mr. Sandejas is a partner with the law firm of Quisumbing Torres & Evangelista. Robert S. Silberman. In addition to serving as Senior Vice President, Strategic Planning and Implementation of the Company, Mr. Silberman is Senior Vice-President - Strategic Planning & Implementation of CalEnergy. Mr. Silberman has served as Executive Assistant to the Chairman and Chief Executive Officer of International Paper, as Director of Project Finance and Implementation for the Ogden Corporation, and as a Project Manager in Business Development for Allied-Signal, Inc. He has also served as the Assistant Secretary of the Army for the United States Department of Defense. James D. Stallmeyer. In addition to serving as Vice President and General Counsel, Asia of the Company, Mr. Stallmeyer is Assistant General Counsel of CalEnergy and General Counsel of CalEnergy Asia. Mr. Stallmeyer joined the Company in 1993. Mr. Stallmeyer practiced in the public finance and banking areas at Chapman and Cutler in Chicago from 1984 to 1987 and in the corporate finance department from 1989 to 1993. Prior to that, Mr. Stallmeyer was an attorney in the public finance department of the Chicago office of Skadden, Arps, Slate, Meagher & Flom in 1987 and 1988 and was a legal writing instructor at the University of Illinois College of Law in 1988 and 1989. John G. Sylvia. In addition to serving as Senior Vice President and Chief Financial Officer of the Company, Mr. Sylvia is a Senior Vice President and Chief Financial Officer of CalEnergy. Mr. Sylvia joined CalEnergy in 1988. From 1985 to 1988, Mr. Sylvia was a Vice President in the San Francisco office of the Royal Bank of Canada, with responsibility for corporate and capital markets banking. From 1986 to 1990, Mr. Sylvia served as an Adjunct Professor of Applied Economics at the University of San Francisco. From 1982 to 1985, Mr. Sylvia was a Vice-President with Bank of America National Trust and Savings Association. Russ Tenney. In addition to serving as Vice President- Philippine Operations and Director of the Company, Mr. Tenney is Vice-President/General Manager, Philippines of CalEnergy and previously served as a Vice President of Magma Power Company. Oscar Violago. In addition to serving as a Director of the Company, Mr. Violago is President of San Lorenzo Ruiz Builders and Developers Group, Inc. of Metro Manila, the Philippines. Item 11. EXECUTIVE COMPENSATION None of the executive officers or directors of the Company receives compensation from the Company for services as officers or directors of the Company. All directors are reimbursed for their expenses in attending board and committee meetings. Item 12. SECURITY OWNERSHIP OF CERTAIN BENEFICIAL OWNERS AND MANAGEMENT Description of Capital Stock As of December 31, 1996, the authorized capital stock of the Company consisted of 2,148,000 shares of common stock, par value 1.00 peso per share (the "Common Stock"), of which 767,162 shares were outstanding. There is no public trading market for the Common Stock. As of December 31, 1996 there were 13 holders of record of the Common Stock. Holders of Common Stock are entitled to one vote per share on any matter coming before the stockholders for a vote. The Indenture contains certain restrictions on the payment of dividends with respect to the Common Stock. Principal Holders The following table sets forth information with respect to the shares of common stock owned of record and beneficially by all persons who own of record or are know by the Company to own beneficially more than 5% of the common stock and by all directors and officers of the Company as a group. Number Of Percentage Of Name and Address of Owner Shares Owned* Common Stock Owned 1. CE Casecnan, Ltd.(1) 268,503 35%(2) a Bermuda corporation c/o Conyers Dill & Pearman Clarendon House P.O. Box 666 Hamilton, Bermuda HM CX 2. Kiewit Energy International (Bermuda) Ltd.(3) 268,502 35%(2) a Bermuda corporation c/o Appleby Spurling & Kempe Cedar House 41 Cedar House HM 179 Hamilton, Bermuda HM EX 3. LaPrairie Group Contractors (International), Ltd. 115,074 15%(4) a Barbados corporation c/o P.O. . Box 690C Bridgetown, Barbados 4. San Lorenzo Ruiz Builders and Developers Group, Inc. 115,074 15%(4) a Philippine corporation Violago Compound 222 East Rodriguez Avenue Quezon City, Philippines *In addition, each director of the Company owns one share in the Company as required by Philippine law. (1) CalEnergy wholly owns CE International Investments, Inc., a Delaware corporation, which wholly owns CE Casecnan, Ltd., a Bermuda corporation, which is the registered owner of the shares. (2) Number of shares owned subject to upward adjustment based on projected level of financial return to CalEnergy from the Project calculated at the time of Completion. (3) Kiewit, through subsidiaries, wholly owns Kiewit Energy International (Bermuda) Ltd., a Bermuda corporation, which is the registered owner of the shares. (4) Number of shares owned subject to downward adjustment based on projected level of financial return to CalEnergy from the Project calculated at the time of Completion. Neither of the minority shareholders will have a major role in the development, construction or operation of the project. Item 13. CERTAIN RELATIONSHIPS AND RELATED TRANSACTIONS Not Applicable. SIGNATURES Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized, in the City of Omaha, State of Nebraska, on March 27, 1997. CE CASECNAN WATER AND ENERGY COMPANY, INC. By: /s/ Steven A. McArthur Steven A. McArthur Director and Senior Vice President Pursuant to the requirements of the Securities Exchange Act of 1934, the Company has caused this report to be signed by the following persons in the capacities and on the dates indicated: Signature Title Date David L. Sokol* Chairman of the Board of Directors, March 27,1997 David L. Sokol Chairman and Chief Executive Officer (Principal Executive Officer) Donald M. O'Shei Jr.* Director, Vice Chairman and President March 27, 1997 Donald M. O'Shei Jr. and Chief Operating Officer, Asia John G. Sylvia* Chief Financial Officer (Principal March 27, 1997 John G. Sylvia Financial Officer) Gregory E. Abel* Chief Accounting Officer (Principal March 27, 1997 Gregory E. Abel Accounting Officer) Steven A. McArthur Director and Senior Vice President March 27, 1997 Steven A. McArthur Russ L. Tenney* Director March 27, 1997 Russ L. Tenney Ruby S. Nitorreda* Director and Assistant Secretary March 27, 1997 Ruby S. Nitorreda *By: /s/ Steven A. McArthur Steven A. McArthur Attorney-in-Fact INDEX TO EXHIBITS Exhibit No. Description of Exhibit 3.1 Articles of Incorporation of the Company (incorporated by reference to Exhibit 3.1 the Company's Registration Statement on Form S-4, as amended, dated January 25, 1996 ("Form S-4"). 3.2 By-laws of the Company (incorporated by reference to Exhibit 3.2 the Company's Form S-4). 4.1(a) Trust Indenture, dated as of November 27, 1995, between Chemical Trust Company of California and the Company (incorporated by reference to Exhibit 4.1(a) the Company's Form S-4). 4.1(b) First Supplemental Indenture, dated as of April 10, 1996, between Chemical Trust Company of California and the Company (incorporated by reference to Exhibit 4.1(b) to the Company's Form S-4). 4.2 Exchange and Registration Rights Agreement, dated as of November 27, 1995, by and among CS First Boston Corporation, Bear Stearns & Co. Inc., Lehman Brothers Inc. and the Company (incorporated by reference to Exhibit 4.2 the Company's Form S-4). 4.3 Collateral Agency and Intercreditor Agreement, dated as of November 27, 1995, by and among Chemical Trust Company of California, Far East Bank & Trust Company and the Company (incorporated by reference to Exhibit 4.3 the Company's Form S-4). 4.4 Mortgage and Security Agreement, dated as of November 10, 1995, by and among CE Casecnan Ltd., Kiewit Energy International (Bermuda) Ltd., La Prairie Group Contractors (International) Ltd., San Lorenzo Ruiz Builders and Developers Group, Inc., Chemical Trust Company of California, Far East Bank & Trust Company and the Company (incorporated by reference to Exhibit 4.4 the Company's Form S-4). 4.6 Deposit and Disbursement Agreement, dated as of November 27, 1995, by and among the Company, Chemical Trust Company of California, Kiewit Energy Company and the Company (incorporated by reference to the Company's Form S-4). 4.7 Consent of NIA, dated as of November 10, 1995, to the assignment of the Amended and Restated Casecnan Project Agreement (incorporated by reference to Exhibit 4.7 to the Company's Form S-4). 4.8 Consent of the Republic of Philippines, dated November 10, 1995, to the assignment of the Performance Undertaking and the Amended and Restated Casecnan Project Agreement (incorporated by reference to Exhibit 4.8 to the Company's Form S-4). 4.9 Consent of Hanbo Corporation and You One Engineering and Construction Company, Ltd., dated as of November 17, 1995, to the assignment of the Engineering, Procurement and Construction Contract (incorporated by reference to Exhibit 4.9 to the Company's Form S-4). 4.10 Consent of Hanbo Steel, dated as of November 17, 1995, to the assignment of the Guaranty of Engineering, Procurement and Construction Contract (incorporated by reference to Exhibit 4.10 to the Company's Form S-4). 4.11 Notification, dated as of November 27, 1995, from the Company to Korea First Bank, of the assignment of the Irrevocable Letter of Credit (incorporated by reference to Exhibit 4.11 to the Company's Form S-4). 10.1 Amended and Restated Casecnan Project Agreement, dated as of June 26, 1995, between the National Irrigation Administration and the Company (incorporated by reference to Exhibit 10.1 the Company's Form S-4). 10.2 Performance Undertaking, dated as of July 20, 1995, executed by the Secretary of Finance on behalf of the Republic of the Philippines (incorporated by reference to Exhibit 10.2 to the Company's Form S-4). 10.3 Engineering, Procurement and Construction Contract, dated as of October 10, 1995, by and among Hanbo Corporation, You One Engineering and Construction Company, Ltd. and the Company (incorporated by reference to Exhibit 10.3 the Company's Form S-4) 10.4 Master Equipment Lease Agreement, dated as of November 1, 1995, between You One Engineering and Construction Company, Ltd. and the Company (incorporated by reference to Exhibit 10.4 the Company's Form S-4). 10.5 Sublease Agreement No. 1, dated as of November 1, 1995, between You One Engineering and Construction Company, Ltd. and the Company (incorporated by reference to Exhibit 10.5 the Company's Form S-4). 10.6 Guaranty of Engineering, Procurement and Construction Contract, dated as of November 13, 1995, by Hanbo Steel guaranteeing the performance of the obligations of Hanbo Corporation and You One Engineering and Construction Company, Ltd. under the Engineering Procurement and Construction Contract (incorporated by reference to Exhibit 10.6 to the Company's Form S-4). 10.7 Korea First Bank Irrevocable Letter of Credit issued to the Company in the aggregate principal amount of U.S.$117,850,000.00 to support the obligations of Hanbo Corporation and You One Engineering and Construction Company, Ltd. under the Engineering, Procurement and Construction Contract (incorporated by reference to Exhibit 10.7 to the Company's Form S-4). 24 Power of Attorney 27 Financial Data Schedule