Energy Services of America (ESOA) 10-Q 2024 Q3 Quarterly report

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

WASHINGTON, D.C. 20549

FORM 10-Q

(Mark One)

☒ Quarterly report pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

For the quarterly period ended June 30, 2024.

Commission File Number: 001-32998

Energy Services of America Corporation

(Exact Name of Registrant as Specified in Its Charter)

Delaware	20-4606266
(State or Other Jurisdiction of Incorporation or Organization)	(I.R.S. Employer Identification Number)

75 West 3rd Ave., Huntington, West Virginia	25701
(Address of Principal Executive Office)	(Zip Code)

(304) 522-3868

(Registrant’s Telephone Number Including Area Code)

Securities Registered Pursuant to Section 12(b) of the Act:

Title of Each Class	Trading Symbols	Name of Each Exchange On Which Registered
Common Stock, Par Value $0.0001	ESOA	The Nasdaq Stock Market LLC

Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports) and (2) has been subject to such requirements for the past 90 days. YES ☒ NO ☐.

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). YES ☒ NO ☐.

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company, or an emerging growth company. See the definition of “large accelerated filer,” “accelerated filer”, “smaller reporting company”, or an “emerging growth company” in Rule 12b-2 of the Exchange Act. (Check one):

Large accelerated filer	☐	Accelerated filer	☐
Non-accelerated filer	☒	Smaller reporting company	☒
		Emerging growth company	☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act.  ☐

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).   YES ☐ NO ☒

As of August 9, 2024, there were 16,570,685 outstanding shares of the Registrant’s Common Stock.

Part 1: Financial Information
Item 1. Financial Statements (Unaudited):
Consolidated Balance Sheets	2
Consolidated Statements of Income	3
Consolidated Statements of Cash Flows	4
Consolidated Statements of Changes in Shareholders’ Equity	5
Notes to Unaudited Consolidated Financial Statements	6
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations	20
Item 3. Quantitative and Qualitative Disclosures About Market Risk	37
Item 4. Controls and Procedures	37
Part II: Other Information
Item 1. Legal Proceedings	38
Item 1A. Risk Factors	38
Item 2. Unregistered Sales of Equity Securities, Use of Proceeds and Issuer Purchases of Equity Securities	39
Item 5. Other Information	39
Item 6. Exhibits	40
Signatures	41

1

Part 1. Financial Information

Item 1. Financial Statements (Unaudited):

Energy Services of America Corporation

Consolidated Balance Sheets

Unaudited

	June 30,		September 30,
	2024		2023
Assets
Current assets
Cash and cash equivalents	$	14,537,867	$	16,431,572
Accounts receivable-trade		50,173,780		51,219,958
Allowance for doubtful accounts		(51,063)		(51,063)
Retainages receivable		10,279,019		7,589,749
Other receivables		1,122,220		516,968
Contract assets		21,046,114		15,955,220
Prepaid expenses and other		4,245,892		3,520,178
Total current assets		101,353,829		95,182,582
Property, plant and equipment, at cost		90,554,178		84,329,349
less accumulated depreciation		(52,703,476)		(47,799,840)
Total property and equipment, net		37,850,702		36,529,509
Right-of-use assets-operating leases		2,497,162		3,326,405
Intangible assets, net		3,058,673		3,383,099
Goodwill		4,087,554		4,087,554
Total assets	$	148,847,920	$	142,509,149
Liabilities and shareholders’ equity
Current liabilities
Current maturities of long-term debt	$	7,177,071	$	6,107,277
Lines of credit and short-term borrowings		10,259,700		19,847,470
Current maturities of operating lease liabilities		1,114,734		1,075,815
Accounts payable		19,445,674		22,026,639
Accrued expenses and other current liabilities		12,021,416		13,103,944
Contract liabilities		17,944,618		17,743,001
Income tax payable		5,691,264		—
Total current liabilities		73,654,477		79,904,146
Long-term debt, less current maturities		14,502,286		18,870,529
Long-term operating lease liabilities, less current maturities		1,372,062		2,274,975
Deferred tax liability		7,282,967		6,870,510
Total liabilities		96,811,792		107,920,160
Shareholders’ equity
Common stock, $.0001 par value Authorized 50,000,000 shares, 17,896,016 issued and 16,570,685 outstanding at June 30, 2024 and 17,885,615 issued and 16,567,185 outstanding at September 30, 2023		1,790		1,789
Treasury stock, 1,325,331 shares at June 30, 2024 and 1,318,430 shares at September 30, 2023		(133)		(132)
Additional paid in capital		60,282,921		60,288,745
Retained deficit		(8,248,450)		(25,701,413)
Total shareholders’ equity		52,036,128		34,588,989
Total liabilities and shareholders’ equity	$	148,847,920	$	142,509,149

The Accompanying Notes are an Integral Part of These Financial Statements

2

Energy Services of America Corporation

Consolidated Statements of Income

Unaudited

	Three Months Ended		Three Months Ended		Nine Months Ended		Nine Months Ended
	June 30,		June 30,		June 30,		June 30,
	2024		2023		2024		2023
Revenue	$	85,923,760	$	85,529,892	$	247,214,602	$	199,245,920
Cost of revenues		70,615,936		74,650,897		214,828,263		178,480,010
Gross profit		15,307,824		10,878,995		32,386,339		20,765,910
Selling and administrative expenses		6,815,191		5,283,617		21,335,862		16,487,502
Income from operations		8,492,633		5,595,378		11,050,477		4,278,408
Other income (expense)
Interest income		—		—		—		196
Other nonoperating expense		(27,446)		(72,338)		(33,935)		(163,525)
Income from lawsuit judgement		15,634,499		—		15,634,499		—
Interest expense		(546,960)		(639,888)		(1,771,560)		(1,713,862)
Gain on sale of equipment		571		30,136		292,166		47,073
		15,060,664		(682,090)		14,121,170		(1,830,118)
Income before income taxes		23,553,297		4,913,288		25,171,647		2,448,290
Income tax expense		6,039,670		1,497,742		6,724,653		767,970
Net income	$	17,513,627	$	3,415,546	$	18,446,994	$	1,680,320
Weighted average shares outstanding-basic		16,565,827		16,602,556		16,567,034		16,659,169
Weighted average shares-diluted		16,597,982		16,602,556		16,602,903		16,659,169
Earnings per share-basic	$	1.06	$	0.21	$	1.11	$	0.10
Earnings per share-diluted	$	1.06	$	0.21	$	1.11	$	0.10

The Accompanying Notes are an Integral Part of These Financial Statements

3

Energy Services of America Corporation

Consolidated Statements of Cash Flows

Unaudited

	Nine Months Ended		Nine Months Ended
	June 30,		June 30,
	2024		2023
Cash flows from operating activities:
Net income	$	18,446,994	$	1,680,320
Adjustments to reconcile net income to net cash provided by operating activities:
Accreted interest on PPP loans		75,380		74,613
Depreciation expense		6,338,224		5,356,166
Gain on sale of equipment		(292,166)		(47,073)
Provision for deferred taxes		412,457		699,932
Amortization of intangible assets		324,426		401,221
Accreted interest on notes payable		53,977		31,200
Vested restricted stock award compensation expense		35,556		—
Decrease (increase) in accounts receivable		1,046,178		(9,369,616)
Increase in retainage receivable		(2,689,270)		(2,881,285)
Increase in other receivables		(605,252)		(556,165)
(Increase) decrease in contract assets		(5,090,894)		3,910,675
(Increase) decrease in prepaid expenses and other		(725,714)		2,907,881
Decrease in accounts payable		(2,580,965)		(1,480,418)
Increase (decrease) in accrued expenses and other current liabilities		4,573,985		(969,652)
Increase in contract liabilities		201,617		10,548,603
Net cash provided by operating activities		19,524,533		10,306,402
Cash flows from investing activities:
Investment in property and equipment		(6,666,139)		(8,498,746)
Proceeds from sales of property and equipment		995,324		546,672
Net cash used in investing activities		(5,670,815)		(7,952,074)
Cash flows from financing activities:
Dividends on common stock		(994,031)		(833,360)
Treasury stock purchased		(41,380)		(219,615)
Borrowings on lines of credit and short-term debt, net of (repayments)		(9,663,150)		1,197,792
Proceeds from long-term debt		—		3,100,000
Principal payments on long-term debt		(5,048,862)		(3,988,057)
Net cash used in financing activities		(15,747,423)		(743,240)
(Decrease) increase in cash and cash equivalents		(1,893,705)		1,611,088
Cash and cash equivalents beginning of period		16,431,572		7,427,474
Cash and cash equivalents end of period	$	14,537,867	$	9,038,562
Supplemental schedule of noncash investing and financing activities:
Purchases of property & equipment under financing agreements	$	1,696,436	$	892,735
Prepaid insurance premiums financed	$	—	$	3,811,644
Operating lease right-of-use asset disposals, net of acquisitions in exchange for operating liabilities	$	(36,667)	$	2,618,530
Supplemental disclosures of cash flows information:
Cash paid during the year for:
Interest	$	1,690,100	$	1,636,404
Income taxes	$	1,251,818	$	—

The Accompanying Notes are an Integral Part of These Financial Statements

4

Energy Services of America Corporation

Consolidated Statements of Changes in Shareholders’ Equity

For the three and nine months ended June 30, 2024 and 2023

										Total
	Common Stock			Additional Paid		Retained		Treasury		Shareholders’
	Shares	Amount		in Capital		Deficit		Stock		Equity
Balance at September 30, 2023	16,567,185	$	1,789	$	60,288,745	$	(25,701,413)	$	(132)	$	34,588,989
Net income	—		—		—		2,042,195		—		2,042,195
Dividends on common stock ($0.06 per share on 16,567,185 shares)	—		—		—		(994,031)		—		(994,031)
Balance at December 31, 2023	16,567,185	$	1,789	$	60,288,745	$	(24,653,249)	$	(132)	$	35,637,153
Net loss	—		—		—		(1,108,828)		—		(1,108,828)
Vested restricted stock award	10,401		1		35,555		—		—		35,556
Balance at March 31, 2024	16,577,586		1,790		60,324,300		(25,762,077)		(132)		34,563,881
Net income	—		—		—		17,513,627		—		17,513,627
Treasury stock purchased by company	(6,901)		—		(41,379)		—		(1)		(41,380)
Balance at June 30, 2024	16,570,685	$	1,790	$	60,282,921	$	(8,248,450)	$	(133)	$	52,036,128

										Total
	Common Stock			Additional Paid		Retained		Treasury		Shareholders’
	Shares	Amount		in Capital		Deficit		Stock		Equity
Balance at September 30, 2022	16,667,185	$	1,789	$	60,508,350	$	(32,269,473)	$	(122)	$	28,240,544
Net income	—		—		—		138,374		—		138,374
Balance at December 31, 2022	16,667,185	$	1,789	$	60,508,350	$	(32,131,099)	$	(122)	$	28,378,918
Net loss	—		—		—		(1,873,600)		—		(1,873,600)
Dividends on common stock ($0.05 per share on 16,667,185 shares)	—		—		—		(833,360)		—		(833,360)
Treasury stock purchased by company	(32,181)		—		(71,652)		—		(3)		(71,655)
Balance at March 31, 2023	16,635,004	$	1,789	$	60,436,698	$	(34,838,059)	$	(125)	$	25,600,303
Net income	—		—		—		3,415,546		—		3,415,546
Treasury stock purchased by company	(67,819)		—		(147,953)		—		(7)		(147,960)
Balance at June 30, 2023	16,567,185	$	1,789	$	60,288,745	$	(31,422,513)	$	(132)	$	28,867,889

The Accompanying Notes are an Integral Part of These Financial Statements

5

ENERGY SERVICES OF AMERICA CORPORATION

NOTES TO UNAUDITED CONSOLIDATED FINANCIAL STATEMENTS

1.  BUSINESS AND ORGANIZATION

Energy Services of America Corporation (“Energy Services” or the “Company”), formed in 2006, is a contractor and service company that operates primarily in the mid-Atlantic and central regions of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical, and power industries. For the gas industry, the Company is primarily engaged in the construction, replacement and repair of natural gas pipelines and storage facilities for utility companies and private natural gas companies. Energy Services is involved in the construction of both interstate and intrastate pipelines, with an emphasis on the latter. For the oil industry, the Company provides a variety of services relating to pipeline, storage facilities and plant work. For the power, chemical, and automotive industries, the Company provides a full range of electrical and mechanical installations and repairs including substation and switchyard services, site preparation, equipment setting, pipe fabrication and installation, packaged buildings, transformers, and other ancillary work with regards thereto. Energy Services’ other pipeline services include corrosion protection services, horizontal drilling services, liquid pipeline construction, pump station construction, production facility construction, water and sewer pipeline installations, various maintenance and repair services and other services related to pipeline construction. The Company has also added the ability to install broadband and solar electric systems and perform civil and general contracting services.

C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes.

Nitro Construction Services, Inc. (“NCS”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R, and fire protection services to customers primarily in the automotive, chemical, and power industries. Revolt Energy, LLC (“Revolt”), a wholly owned subsidiary of NCS, performs residential solar installation projects. Nitro Electric Company, LLC (“Nitro Electric”), a wholly owned subsidiary of NCS, performs industrial electrical work and has a satellite office registered in Michigan. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of NCS, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by NCS and has no employees of its own. NCS and its subsidiaries will collectively be referred to “Nitro”.

All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

West Virginia Pipeline, Inc. (“West Virginia Pipeline” or “WVP”), a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. The employees of West Virginia Pipeline are non-union and are managed independently of the Company’s union subsidiaries.

SQP Construction Group, Inc. (“SQP”), a wholly owned subsidiary of Energy Services, operates as a general contractor primarily in West Virginia. SQP engages in the construction and renovation of buildings and other civil construction projects for state and local government agencies and commercial customers. As a general contractor, SQP manages the overall construction project and subcontracts most of the work. The employees of SQP are non-union and are managed independently of the Company’s union subsidiaries.

Tri-State Paving & Sealcoating, Inc. (“TSP” or “Tri-State Paving”), a wholly owned subsidiary of Energy Services, completed the acquisition of substantially all the assets of Tri-State Paving & Sealcoating, LLC (“Tri-State Paving, LLC”) on April 29, 2022. Tri-State Paving provides utility paving services to water distribution customers in the Charleston, West Virginia, Lexington, Kentucky, and Chattanooga, Tennessee markets. The employees of TSP are non-union and are managed independently of the Company’s union subsidiaries.

Ryan Construction Services Inc. (“Ryan Construction” or “RCS”), a wholly owned subsidiary of Energy Services, formed in August 2022 in connection with the acquisition of substantially all the assets of Ryan Environmental, LLC and Ryan Environmental Transport, LLC (collectively “Ryan Environmental”), provides directional drilling services for broadband service providers along with offering natural gas distribution services, cathodic protection and corrosion prevention services, and civil construction services. Ryan Construction operates primarily in West Virginia and Pennsylvania. The employees of RCS are non-union and are managed independently of the Company’s union subsidiaries.

6

Interim Financial Statements

The accompanying unaudited consolidated financial statements have been prepared pursuant to the rules and regulations of the Securities and Exchange Commission (“SEC”) and should be read in conjunction with the Company’s audited consolidated financial statements and footnotes thereto for the years ended September 30, 2023, and 2022 included in the Company’s Annual Report on Form 10-K filed with the SEC on January 16, 2024. Certain information and footnote disclosures normally included in annual financial statements prepared in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) have been omitted pursuant to the interim financial reporting rules and regulations of the SEC. The financial statements reflect all adjustments (consisting primarily of normal recurring adjustments) that are, in the opinion of management, necessary for a fair presentation of the Company’s financial position and results of operations. The operating results for the three and nine months ended June 30, 2024 and 2023 are not necessarily indicative of the results to be expected for the full year or any other interim period.

Principles of Consolidation

The consolidated financial statements of Energy Services include the accounts of Energy Services, its wholly owned subsidiaries West Virginia Pipeline, SQP, Ryan Construction, Tri-State Paving and C.J. Hughes and its subsidiaries. All significant intercompany accounts and transactions have been eliminated in the consolidation. Unless the context requires otherwise, references to Energy Services include Energy Services, West Virginia Pipeline, SQP, Ryan Construction, Tri-State Paving and C.J. Hughes and its subsidiaries.

Use of Estimates and Assumptions

The preparation of financial statements, in conformity with U.S. GAAP, requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent assets and liabilities at the date of the financial statements and the reported amounts of income and loss during the reporting period. Actual results could differ materially from those estimates.

2.  SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES

Please refer to Note 2 “Summary of Significant Accounting Policies” of the Consolidated Financial Statements in our Annual Report on Form 10-K for the year ended September 30, 2023, for a more detailed discussion of our significant accounting policies. There were no material changes to these significant accounting policies during the three and nine months ended June 30, 2024.

3.  ACCOUNTING FOR PAYCHECK PROTECTION PROGRAM LOANS

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the Paycheck Protection Program (“PPP”). On April 15, 2020, the Company and its subsidiaries, C.J. Hughes, Contractors Rental and Nitro, entered into separate PPP notes effective April 7, 2020, with United Bank as its lender (the “Lender”) in an aggregate principal amount of $13.1 million pursuant to the PPP (collectively, the (“PPP Loans”). In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

During April 2023, management received notification from the SBA that one of the Company’s forgiveness applications related to the PPP Loans was under review. As part of the review, the SBA requested additional payroll information. Additionally, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender. The Company recognizes that there is a possibility that the SBA could reverse its previous determination on the forgiveness of the PPP Loans. As a result of this uncertainty, the Company restated the previously issued audited financial statements of the Company for the fiscal years 2022 and 2021. The Company has recorded a short-term borrowing due to the SBA inquiry for the full $9.8 million, plus accrued interest for all periods presented.

7

During July 2023, management received notification from the SBA that two additional forgiveness applications related to the PPP Loans were under review. As part of the review, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender.

Borrowers must retain PPP documentation for at least six years after the date the loan is forgiven or paid in full, and the SBA and SBA Inspector General must be granted these files upon request. The SBA could revisit its forgiveness decision and determine that the Company does not qualify in whole or in part for loan forgiveness and demand repayment of the loans. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. Any penalties in addition to the potential repayment of the PPP Loans could negatively impact the Company’s business, financial condition and results of operations and prospects.

4.  REVENUE RECOGNITION

Our revenue is primarily derived from construction contracts that can span several quarters. We recognize revenue in accordance with Accounting Standards Codification (“ASC”) Topic 606, Revenue from Contracts with Customers (“ASC 606” or “Topic 606”) which provides for a five-step model for recognizing revenue from contracts with customers as follows:

● Identify the contract

● Identify performance obligations

● Determine the transaction price

● Allocate the transaction price

● Recognize revenue

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

● the completeness and accuracy of the original bid;

● costs associated with scope changes;

● changes in costs of labor and/or materials;

● extended overhead and other costs due to owner, weather and other delays;

● subcontractor performance issues;

● changes in productivity expectations;

● site conditions that differ from those assumed in the original bid;

● changes from original design on design-build projects;

● the availability and skill level of workers in the geographic location of the project;

● a change in the availability and proximity of equipment and materials;

● our ability to fully and promptly recover on affirmative claims and back charges for additional contract costs; and

● the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects, could have a significant effect on our profitability.

Our contract assets include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

8

Our contract liabilities consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses, if incurred, are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

5.  DISAGGREGATION OF REVENUE

The Company disaggregates revenue based on the following lines of service: (1) Gas & Water Distribution, (2) Gas & Petroleum Transmission, and (3) Electrical, Mechanical, & General services and construction. Our contract types are: Lump Sum, Unit Price, Cost Plus and Time and Materials (“T&M”). The following tables present our disaggregated revenue for the three and nine months ended June 30, 2024 and 2023:

	Three Months Ended June 30, 2024
					Electrical,
	Gas & Water		Gas & Petroleum		Mechanical, &		Total revenue
	Distribution		Transmission		General		from contracts
Lump sum contracts	$	—	$	—	$	30,678,722	$	30,678,722
Unit price contracts		22,536,366		16,687,458		579,567		39,803,391
Cost plus and T&M contracts		—		451,348		14,990,299		15,441,647
Total revenue from contracts	$	22,536,366	$	17,138,806	$	46,248,588	$	85,923,760
Earned over time	$	605,362	$	16,687,458	$	32,717,660	$	50,010,480
Earned at point in time		21,931,004		451,348		13,530,928		35,913,280
Total revenue from contracts	$	22,536,366	$	17,138,806	$	46,248,588	$	85,923,760

	Nine Months Ended June 30, 2024
					Electrical,
	Gas &Water		Gas & Petroleum		Mechanical, &		Total revenue
	Distribution		Transmission		General		from contracts
Lump sum contracts	$	—	$	—	$	86,311,693	$	86,311,693
Unit price contracts		53,892,952		53,580,598		3,290,437		110,763,987
Cost plus and T&M contracts		—		1,884,529		48,254,393		50,138,922
Total revenue from contracts	$	53,892,952	$	55,465,127	$	137,856,523	$	247,214,602
Earned over time	$	10,746,633	$	53,580,598	$	95,859,496	$	160,186,727
Earned at point in time		43,146,319		1,884,529		41,997,027		87,027,875
Total revenue from contracts	$	53,892,952	$	55,465,127	$	137,856,523	$	247,214,602

	Three Months Ended June 30, 2023
					Electrical,
	Gas & Water		Gas & Petroleum		Mechanical, &		Total revenue
	Distribution		Transmission		General		from contracts
Lump sum contracts	$	—	$	—	$	29,132,537	$	29,132,537
Unit price contracts		17,906,005		28,488,329		1,568,962		47,963,296
Cost plus and T&M contracts		—		—		8,434,059		8,434,059
Total revenue from contracts	$	17,906,005	$	28,488,329	$	39,135,558	$	85,529,892
Earned over time	$	7,738,419	$	28,488,329	$	35,991,934	$	72,218,682
Earned at point in time		10,167,586		—		3,143,624		13,311,210
Total revenue from contracts	$	17,906,005	$	28,488,329	$	39,135,558	$	85,529,892

9

	Nine Months Ended June 30, 2023
					Electrical,
	Gas & Water		Gas & Petroleum		Mechanical, &		Total revenue
	Distribution		Transmission		General		from contracts
Lump sum contracts	$	—	$	—	$	68,633,633	$	68,633,633
Unit price contracts		43,825,957		50,718,004		4,368,041		98,912,002
Cost plus and T&M contracts		—		—		31,700,285		31,700,285
Total revenue from contracts	$	43,825,957	$	50,718,004	$	104,701,959	$	199,245,920
Earned over time	$	21,328,177	$	50,718,004	$	97,618,445	$	169,664,626
Earned at point in time		22,497,780		—		7,083,514		29,581,294
Total revenue from contracts	$	43,825,957	$	50,718,004	$	104,701,959	$	199,245,920

6.  CONTRACT BALANCES

The Company’s accounts receivable consists of amounts that have been billed to customers and collateral is generally not required. Most of the Company’s contracts have monthly billing terms; however, billing terms for some are based on project completion. Payment terms are generally within 30 to 45 days after invoices have been issued. The Company attempts to negotiate two-week billing terms and 15-day payment terms on larger projects. The timing of billings to customers may generate contract assets or contract liabilities.

During the three and nine months ended June 30, 2024, we recognized revenue of $0.6 million and $16.0 million, respectively, that was included in the contract liability balance at September 30, 2023.

Accounts receivable-trade, net of allowance for doubtful accounts, contract assets and contract liabilities consisted of the following:

	June 30, 2024		September 30, 2023		Change
Accounts receivable-trade, net of allowance for doubtful accounts	$	50,122,717	$	51,168,895	$	(1,046,178)
Contract assets
Cost and estimated earnings in excess of billings	$	21,046,114	$	15,955,220	$	5,090,894
Contract liabilities
Billings in excess of cost and estimated earnings	$	17,944,618	$	17,743,001	$	201,617

7.  PERFORMANCE OBLIGATIONS

For the three and nine months ended June 30, 2024, there was no significant revenue recognized as a result of changes in contract transaction price related to performance obligations that were satisfied prior to September 30, 2023. Changes in contract transaction price can result from items such as executed or estimated change orders, and unresolved contract modifications and claims.

At June 30, 2024, the Company had $182.9 million in remaining unsatisfied performance obligations, in which revenue is expected to be recognized over the next twelve months.

10

8.  UNCOMPLETED CONTRACTS

Costs, estimated earnings, and billings on uncompleted contracts as of June 30, 2024 and September 30, 2023, are summarized as follows:

	June 30, 2024		September 30, 2023
Costs incurred on contracts in progress	$	347,023,673	$	287,347,650
Estimated earnings, net of estimated losses		55,753,948		38,976,895
		402,777,621		326,324,545
Less billings to date		399,676,125		328,112,326
	$	3,101,496	$	(1,787,781)
Costs and estimated earnings in excess of billed on uncompleted contracts	$	21,046,114	$	15,955,220
Less billings in excess of costs and estimated earnings on uncompleted contracts		17,944,618		17,743,001
	$	3,101,496	$	(1,787,781)

The Company’s unaudited backlog at June 30, 2024 and September 30, 2023 was $250.9 million and $229.8 million, respectively.

9.  FAIR VALUE MEASUREMENTS

The fair value measurement guidance of the Financial Accounting Standards Board (“FASB”) ASC 820, Fair Measurement defines fair value, establishes a framework for measuring fair value in accordance with accounting principles generally accepted in the United States of America (“U.S. GAAP”) and specifies disclosures about fair value measurements.

Under the FASB’s authoritative guidance on fair value measurements, fair value is the price that would be received to sell an asset or paid to transfer a liability in an orderly transaction between market participants at the measurement date. The fair value measurement guidance of the FASB ASC establishes a three-level hierarchy for fair value measurements based upon the transparency of inputs to the valuation of an asset or liability as of the measurement date. The three levels are defined as follows:

Level 1 — Quoted prices for identical assets and liabilities traded in active exchange markets, such as the New York Stock Exchange.

Level 2 — Observable inputs other than Level 1 including quoted prices for similar assets or liabilities, quoted prices in less active markets, or other observable inputs that can be corroborated by observable market data. Level 2 also includes derivative contracts whose value is determined using a pricing model with observable market inputs or can be derived principally from or corroborated by observable market data.

Level 3 — Unobservable inputs supported by little or no market activity for financial instruments whose value is determined using pricing models, discounted cash flow methodologies, or similar techniques, as well as instruments for which the determination of fair value requires significant management judgment or estimation; also includes observable inputs for nonbinding single dealer quotes not corroborated by observable market data.

A financial instrument’s categorization within the valuation hierarchy is based upon the lowest level of input that is significant to the fair value measurement.

The carrying amount for borrowings under the Company’s revolving credit facility approximates fair value because of the variable market interest rate charged to the Company for these borrowings. The fair value of the Company’s long term fixed-rate debt was estimated using a discounted cash flow analysis and a yield rate that was estimated based on the borrowing rates currently available to the Company for bank loans with similar terms and maturities. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $30.6 million at June 30, 2024 was $29.2 million. The fair value of the aggregate principal amount of the Company’s fixed-rate debt of $33.8 million at September 30, 2023 was $32.1 million.

11

All other current assets and liabilities are carried at net realizable value which approximates fair value because of their short duration to maturity.

10.  EARNINGS PER SHARE

The amounts used to compute the earnings per share for the three and nine months ended June 30, 2024 and 2023 are summarized below.

	Three Months Ended		Three Months Ended		Nine Months Ended		Nine Months Ended
	June 30, 2024		June 30, 2023		June 30, 2024		June 30, 2023
Net income	$	17,513,627	$	3,415,546	$	18,446,994	$	1,680,320
Weighted average shares outstanding-basic		16,565,827		16,602,556		16,567,034		16,659,169
Weighted average shares outstanding-diluted		16,597,982		16,602,556		16,602,903		16,659,169
Earnings per share available to common shareholders	$	1.06	$	0.21	$	1.11	$	0.10
Earnings per share available to common shareholders-diluted	$	1.06	$	0.21	$	1.11	$	0.10

11.  INCOME TAXES

The components of income taxes are as follows:

	Three Months Ended				Nine Months Ended
	June 30, 2024		June 30, 2023		June 30, 2024		June 30, 2023
Federal
Current	$	4,634,449	$	68,038	$	4,909,486	$	68,038
Deferred		63,072		1,104,844		320,800		542,938
Total		4,697,521		1,172,882		5,230,286		610,976
State
Current		1,324,128		—		1,402,710		—
Deferred		18,021		324,860		91,657		156,994
Total		1,342,149		324,860		1,494,367		156,994
Total income tax expense (benefit)	$	6,039,670	$	1,497,742	$	6,724,653	$	767,970

The Company’s income tax expense and deferred tax assets and liabilities reflect management’s best estimate of current and future taxes to be paid. Significant judgments and estimates are required in the determination of the consolidated income tax expense. The Company’s provision for income taxes is computed by applying a federal rate of 21.0% and a state rate of 6.0% to taxable income or loss after consideration of non-taxable and non-deductible items.

The effective income tax rate for the three and nine months ended June 30, 2024 was 25.6% and 30.5%, respectively, as compared to 26.7% and 31.4%, respectively, for the same period in 2023. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses.

Major items that can affect the effective tax rate include amortization of goodwill and intangible assets and non-deductible amounts for per diem expenses.

12

The income tax effects of temporary differences giving rise to the deferred tax assets and liabilities are as follows:

	June 30, 2024		September 30, 2023
Deferred tax liabilities
Property and equipment	$	7,681,483	$	8,141,025
Other		619,558		588,632
Total deferred tax liabilities	$	8,301,041	$	8,729,657
Deferred income tax assets
Accruals & Other	$	1,018,074	$	948,704
Net operating loss carryforward		—		910,443
Total deferred tax assets	$	1,018,074	$	1,859,147
Total net deferred tax liabilities	$	7,282,967	$	6,870,510

Deferred income taxes arise from temporary differences between the tax basis of assets and liabilities and their reported amounts in the consolidated financial statements, which will result in taxable or deductible amounts in the future. A valuation allowance is established when necessary to reduce deferred tax assets to the amount expected to be realized.

The Company had $0 and $3.0 million of federal net operating loss carryforwards at June 30, 2024 and September 30, 2023, respectively. The Company had state net operating loss carryforwards at June 30, 2024 and September 30, 2023, respectively that begin to expire in 2025, that were not significant.

The Company does not believe that it has any unrecognized tax benefits included in its consolidated financial statements that require recognition. The Company has not had any settlements in the current period with taxing authorities, nor has it recognized tax benefits as a result of a lapse of the applicable statute of limitations. The Company recognizes interest and penalties accrued related to unrecognized tax benefits, if applicable, in general and administrative expenses.

12.  SHORT-TERM AND LONG-TERM DEBT

Operating Line of Credit

On January 19, 2023, the Company received an amendment to its $15.0 million operating line of credit which increased the line of credit to $30.0 million with a maturity date of June 28, 2023. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%. On June 1, 2023, the agreement was renewed through June 28, 2024. The Company is working with its lender and expects the operating line of credit to be extended in the Company’s fourth quarter of fiscal year 2024.

The line of credit is limited to a borrowing base calculation as summarized below:

	June 30, 2024			September 30, 2023
Eligible borrowing base	$	18,971,952		$	23,942,868
Borrowed on line of credit		—			8,712,915
Line of credit balance available	$	—		$	15,229,953
Interest rate		8.5	%		8.5	%

The modified financial covenants for the quarter ended June 30, 2023, and all subsequent quarters, are below:

● Minimum tangible net worth of $28.0 million,

● Minimum traditional debt service coverage of 1.50x on a rolling twelve- month basis,

● Minimum current ratio of 1.20x,

● Maximum debt to tangible net worth ratio (“TNW”) of 2.75x,

13

● Each ratio and covenant shall be determined, tested, and measured as of each calendar quarter beginning June 30, 2023,

● The Company shall maintain a ratio of Maximum Senior Funded Debt (“SFD”) to Earnings before Interest, Taxes, Depreciation and Amortization (“EBDITA”) equal to or less than 3.5:1. SFD shall mean any funded debt or lease of the Company, other than subordinated debt. The covenant shall be tested quarterly, at the end of each fiscal quarter, with EBITDA based on the preceding four quarters.

The Company’s lender has agreed to omit the effect of the PPP loan restatement from the Company’s covenant compliance calculations while a final decision on PPP loan forgiveness remains in question. Thus, the Company was in compliance with all covenants at June 30, 2024. The Company projects to meet all covenant requirements for the next twelve months.

Insurance Premiums Financed

The Company financed its captive insurance policy premiums on a short-term basis through a financing company for the calendar year ended December 31, 2023. These insurance policies include workers’ compensation, general liability, automobile, umbrella, and equipment policies. The Company made a down payment in January 2023 and financed the remaining premium amount over eleven monthly payments. At June 30, 2024 and September 30, 2023, the remaining balance of the insurance premiums was $0 and $950,000, respectively.

For the calendar year beginning January 1, 2024, the Company’s insurance company is accepting quarterly payments on certain insurance policies and the Company has prepaid the balance of the remaining policies as of June 30, 2024. The Company has no insurance premiums financed as of June 30, 2024.

Paycheck Protection Program Loans

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the PPP. On April 15, 2020, the Company and its subsidiaries, C.J. Hughes, Contractors Rental and Nitro, entered into separate PPP notes effective April 7, 2020, with its Lender in an aggregate principal amount of $13.1 million pursuant to the PPP Loans. In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

During April 2023, management received notification from the SBA that one of the Company’s forgiveness applications related to the PPP Loans was under review. As part of the review, the SBA requested additional payroll information. Additionally, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender. The Company recognizes that there is a possibility that the SBA could reverse its previous determination on the forgiveness of the PPP Loans. As a result of this uncertainty, the Company restated the previously audited financial statements of the Company for the fiscal years 2022 and 2021. The Company has recorded a short-term borrowing due to the SBA inquiry for the full $9.8 million, plus accrued interest.

During July 2023, management received notification from the SBA that two additional forgiveness applications related to the PPP Loans were under review. As part of the review, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender.

Borrowers must retain PPP documentation for at least six years after the date the loan is forgiven or paid in full, and the SBA and SBA Inspector General must be granted these files upon request. The SBA could revisit its forgiveness decision and determine that the Company does not qualify in whole or in part for loan forgiveness and demand repayment of the loans. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. Any penalties in addition to the potential repayment of the PPP Loans could negatively impact the Company’s business, financial condition and results of operations and prospects.

14

A summary of short-term and long-term debt as of June 30, 2024 and September 30, 2023 is as follows:

	June 30, 2024		September 30, 2023
Line of credit payable to bank, monthly interest at 8.5%, final payment due by June 28, 2024, guaranteed by certain directors of the Company.	$	—	$	8,712,915
Equipment line of credit with a total of $9.3 million and $8.5 million of $9.3 million available borrowed at June 30, 2024 and September 30, 2023, respectively, fixed interest at 7.25% of outstanding balance due in monthly installments between June 1, 2023 and December 1, 2023. Payments of $202,809 due in monthly installments, including fixed interest at 7.25%, beginning January 2024 with final payment due February 2028, secured by equipment, guaranteed by certain directors of the Company.		8,260,545		8,487,085
Paycheck Protection Program loans from Small Business Administration, 1.0% simple interest, initially forgiven in the fiscal year ended September 30, 2021. Final forgiveness decision has not been determined.		10,259,700		10,184,320
Term note payable to United Bank, WV Pipeline acquisition, due in monthly installments of $64,853 interest at 4.25%, final payment due by March 25, 2026, secured by receivables and equipment, guaranteed by certain directors of the Company.		1,315,129		1,790,051
Notes payable to finance companies, due in monthly installments totaling $77,000 at June 30, 2024 and $50,000 at September 30, 2023, including interest ranging from 0.00% to 6.0%, final payments due July 2024 through August 2026, secured by equipment.		1,696,086		1,290,148
Note payable to finance company for insurance premiums financed, due in monthly installments totaling $327,000 in calendar year 2023 and $282,000 in calendar year 2022, including interest rate at 6.70%, final payment due December 2023.		—		950,235
Notes payable to bank, due in monthly installments totaling $7,848, including interest at 4.82%, final payment due November 2034 secured by building and property.		774,680		813,242
Notes payable to bank, due in monthly installments totaling $12,580, including interest at 9.5%, final payment due November 2025 secured by building and property, guaranteed by certain directors of the Company.		199,782		294,761
Notes payable to bank, due in monthly installments totaling $59,932, including fixed interest at 6.0%, final payment due October 2027 secured by receivables and equipment, guaranteed by certain directors of the Company.		2,172,105		2,601,404
Notes payable to David Bolton and Daniel Bolton, due in annual installments totaling $500,000, including interest at 3.25%, final payment due December 31, 2026, unsecured.		932,500		1,660,000
Notes payable to bank, interest at 4.25% of outstanding balance due in monthly installments between January 2021 and January 2022 with note payments beginning February 2022. Payments due in monthly installments totaling $68,150, including interest at 9.5%, final payment due January 2026, secured by equipment, guaranteed by certain directors of the Company.		1,380,317		1,873,831
Term note payable to United Bank, Tri-State Paving acquisition, due in monthly installments of $129,910, including interest at 4.50%, final payment due by June 1, 2027, secured by receivables and equipment, guaranteed by certain directors of the Company.		4,698,213		5,698,761
Notes payable to Corns Enterprises, $1,000,000 with fair value of $936,000, due in annual installments totaling $250,000, including interest at 3.50%, final payment due April 29, 2026, unsecured.		250,000		468,523
Total debt	$	31,939,057	$	44,825,276
Less current maturities		17,436,771		25,954,747
Total long term debt, less current maturities	$	14,502,286	$	18,870,529

15

13.  GOODWILL AND INTANGIBLE ASSETS

The Company follows the guidance of ASC Topic 350, Intangibles-Goodwill and Other, which requires a company to record an impairment charge based on the excess of a reporting unit’s carrying amount of goodwill over its fair value. Under the current guidance, companies can first choose to assess any impairment based on qualitative factors (Step 0). If a company fails this test or decides to bypass this step, it must proceed with a quantitative assessment of goodwill impairment. The Company did not have a goodwill impairment at June 30, 2024 or September 30, 2023.

A table of the Company’s goodwill as of and for the nine months ended June 30, 2024 and as of and for the twelve months ended September 30, 2023 is below:

	June 30, 2024		September 30, 2023
Beginning balance	$	4,087,554	$	4,087,554
Acquired		—		—
Ending balance	$	4,087,554	$	4,087,554

A table of the Company’s intangible assets subject to amortization is below:

				Accumulated		Accumulated		Amortization		Amortization		Amortization		Amortization
	Remaining Life			Amortization and		Amortization and		and Impairment		and Impairment		and Impairment		and Impairment
	(in months) at			Impairment at		Impairment at		Three Months		Nine Months		Three Months		Nine Months		Net Book Value		Net Book Value
	June 30,			June 30,		September 30,		Ended June 30,		Ended June 30,		Ended June 30,		Ended June 30,		at June 30,		at September 30,
Intangible assets:	2024	Original Cost		2024		2023		2024		2024		2023		2023		2024		2023
West Virginia Pipeline:
Customer Relationships	78	$	2,209,724		773,387	$	607,661		55,242		165,726		65,643		186,532	$	1,436,337	$	1,602,063
Tradename	78		263,584		92,273		72,500		6,591		19,773		6,591		19,773		171,311		191,084
Non-competes	—		83,203		83,203		83,203		—		—		—		10,397		—		—
Revolt Energy:
Employment agreement/non-compete	—		100,000		100,000		100,000		—		—		13,887		22,221		—		—
Tri-State Paving:
Customer Relationships	94		1,649,159		357,318		233,631		41,229		123,687		41,229		123,687		1,291,841		1,415,528
Tradename	94		203,213		44,029		28,789		5,080		15,240		5,080		15,241		159,184		174,424
Non-competes	—		39,960		39,960		39,960		—		—		3,390		23,370		—		—
Total intangible assets		$	4,548,843	$	1,490,170	$	1,165,744	$	108,142	$	324,426	$	135,820	$	401,221	$	3,058,673	$	3,383,099

The amortization on identifiable intangible assets for the three months ended June 30, 2024 and 2023 was $108,142 and $135,820, respectively. The amortization on identifiable intangible assets for the nine months ended June 30, 2024 and 2023 was $324,426 and $401,221, respectively.

Amortization expense associated with the identifiable intangible assets is expected to be as follows:

	Amortization Expense
July 2024 to June 2025	$	432,564
July 2025 to June 2026		432,564
July 2026 to June 2027		432,564
July 2027 to June 2028		432,564
July 2028 to June 2029		432,564
After		895,853
Total	$	3,058,673

14.  LEASE OBLIGATIONS

The Company leases office space for SQP for $1,500 per month. The lease, which was originally signed on March 25, 2021, is for a period of two years with five one-year renewals available immediately following the end of the base term. The Company has only committed to a one-year renewal and is evaluating the intent to renew for additional periods.

The Company had two lease agreements for construction equipment with a combined amount of $160,000 that were paid in full as of June 30, 2024. The leases had a term of twenty-two months with a stated interest rate of 0%, combined monthly installment payments of $6,645 and were cancellable at any time without penalty. The Company exercised the right to purchase the equipment at

16

the expiration of the leases by applying the two-month deposit paid. The related assets and finance lease obligations associated with these lease agreements had been included in the consolidated balance sheets within property, plant and equipment and long-term debt.

The Company has two right-of-use operating leases acquired on April 29, 2022, as part of the Tri-State Paving, LLC transaction. The first operating lease, for the Hurricane, West Virginia facility, had a net present value of $236,000 at inception, and a carrying value of $69,000 at June 30, 2024. The second operating lease, for the Chattanooga, Tennessee facility, had a net present value of $144,000 at inception, and a carrying value of $6,000 at June 30, 2024. The 4.5% interest rate on the operating leases is based on the Company’s incremental borrowing rate at inception.

The Company has a right-of-use operating lease with Enterprise Fleet Management, Inc. (Enterprise) acquired on August 11, 2022, as part of the Ryan Environmental acquisition. This lease agreement was initially for thirty-one vehicles with a net present value of $1.2 million. The Company had seventy-one vehicles on lease at June 30, 2024. The right-of-use operating lease has a carrying value of $2.2 million at June 30, 2024. Each vehicle leased under the master lease program has its own implicit rate ranging from 12.8% to 15.6%.

The Company has a right-of-use operating lease with RICA Developers, LLC acquired on August 12, 2022 and renewed for one year effective October 1, 2023. This lease, for the Bridgeport, West Virginia facility, had a net present value of $125,000 at inception and a carrying value of $21,000 at June 30, 2024. The 8.5% interest rate on the operating lease was based on the Company’s incremental borrowing rate at renewal.

The Company has a right-of-use operating lease acquired on March 28, 2023. This lease, for the Winchester, Kentucky facility, had a net present value of $290,000 at inception and a carrying value of $169,000 at June 30, 2024. The 7.75% interest rate on the operating lease is based on the Company’s incremental borrowing rate at inception.

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by reporting period due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the consolidated statements of income, was $3.3 million and $2.5 million, respectively, for the three months ended June 30, 2024 and 2023. Rental expenses were $12.0 million and $6.8 million, respectively, for the nine months ended June 30, 2024 and 2023.

Schedules related to the Company’s operating leases at June 30, 2024 can be found below:

Operating Lease-Weighted Average Remaining Term

		Present value of
		remaining
	Years left	liability		Lease end	Fiscal year end
Operating lease 1	0.8	$	68,835	3/31/2025	2025
Operating lease 2	0.1		5,593	7/31/2024	2024
Operating lease 3	3.5		2,221,690	12/31/2027	2028
Operating lease 4	0.3		21,373	9/30/2024	2024
Operating lease 5	1.8		169,305	3/31/2026	2026
		$	2,486,796
Weighted average remaining term			3.3 years

17

Operating Lease Maturity Schedule
July 2024 to June 2025	$	1,355,573
July 2025 to June 2026		818,791
July 2026 to June 2027		748,595
July 2027 to June 2028		374,298
		3,297,257
Less amounts representing interest		(810,461)
Present value of operating lease liabilities	$	2,486,796

	Three Months Ended		Nine Months Ended		Three Months Ended		Nine Months Ended
	June 30,		June 30,		June 30,		June 30,
Operating Lease Expense	2024		2024		2023		2023
Amortization
Operating lease 1	$	17,529	$	64,165	$	19,267	$	57,160
Operating lease 2		18,042		51,438		15,741		46,698
Operating lease 3		185,132		515,530		160,836		338,521
Operating lease 4		42,299		103,329		30,947		92,266
Operating lease 5		39,498		92,866		35,880		42,886
Total amortization		302,500		827,328		262,671		577,531
Interest
Operating lease 1		846		3,210		1,733		5,840
Operating lease 2		129		951		870		3,135
Operating lease 3		50,204		168,942		27,240		59,452
Operating lease 4		901		4,671		703		2,684
Operating lease 5		3,351		11,345		5,016		6,776
Total interest		55,431		189,119		35,562		77,887
Total amortization and interest	$	357,931	$	1,016,447	$	298,233	$	655,418

	Three Months Ended		Nine Months Ended		Three Months Ended		Nine Months Ended
	June 30,		June 30,		June 30,		June 30,
Cash Paid for Operating Leases	2024		2024		2023		2023
Operating lease 1	$	18,375	$	67,375	$	21,000	$	63,000
Operating lease 2		18,171		52,389		16,611		49,833
Operating lease 3		235,336		684,472		185,942		397,973
Operating lease 4		43,200		108,000		42,180		94,950
Operating lease 5		42,849		104,211		32,500		49,662
	$	357,931	$	1,016,447	$	298,233	$	655,418

18

15.  SUBSEQUENT EVENTS

On July 11, 2024, the Company’s Nitro subsidiary completed the acquisition of substantially all the physical assets of Heritage Painting, LLC, a West Virginia corporation located in Poca, West Virginia for $300,000 cash.

Management has evaluated all subsequent events for accounting and disclosure. There have been no other material events during the period, other than noted above, that would either impact the results reflected in the report or the Company’s results going forward.

19

ITEM 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

You should read the following discussion of the financial condition and results of operations of Energy Services in conjunction with the “Financial Statements” appearing in this report as well as the historical financial statements and related notes contained elsewhere herein. Among other things, those historical consolidated financial statements include more detailed information regarding the basis of presentation for the following information. The term “Energy Services” refers to the Company, West Virginia Pipeline, SQP, Tri-State Paving, Ryan Construction, and C.J. Hughes and C.J. Hughes’ wholly owned subsidiaries on a consolidated basis.

Forward Looking Statements

Within Energy Services’ (as defined below) consolidated financial statements and this Quarterly Report on Form 10-Q, there are included statements reflecting assumptions, expectations, projections, intentions, or beliefs about future events that are intended as “forward-looking statements” under the Private Securities Litigation Reform Act of 1995. You can identify these statements by the fact that they do not relate strictly to historical or current facts. They use words such as “anticipate,” “estimate,” “project,” “forecast,” “may,” “will,” “should,” “could,” “expect,” “believe,” “intend” and other words of similar meaning.

These forward-looking statements do not guarantee future performance and involve or rely on risks, uncertainties, and assumptions that are difficult to predict or beyond Energy Services’ control. Energy Services has based its forward-looking statements on management’s beliefs and assumptions based on information available to management at the time the statements are made. Actual outcomes and results may differ materially from what is expressed, implied, and forecasted by forward-looking statements and any or all of Energy Services’ forward-looking statements may turn out to be wrong. The accuracy of such statements can be affected by inaccurate assumptions and by known or unknown risks and uncertainties.

All the forward-looking statements, whether written or oral, are expressly qualified by these cautionary statements and any other cautionary statements that may accompany such forward-looking statements or that are otherwise included in this report. In addition, Energy Services does not undertake and expressly disclaims any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report or otherwise.

Company Overview

Energy Services of America Corporation (“Energy Services” or the “Company”), formed in 2006, is a contractor and service company that operates primarily in the mid-Atlantic and central regions of the United States and provides services to customers in the natural gas, petroleum, water distribution, automotive, chemical, and power industries. For the gas industry, the Company is primarily engaged in the construction, replacement and repair of natural gas pipelines and storage facilities for utility companies and private natural gas companies. Energy Services is involved in the construction of both interstate and intrastate pipelines, with an emphasis on the latter. For the oil industry, the Company provides a variety of services relating to pipeline, storage facilities and plant work. For the power, chemical, and automotive industries, the Company provides a full range of electrical and mechanical installations and repairs including substation and switchyard services, site preparation, equipment setting, pipe fabrication and installation, packaged buildings, transformers, and other ancillary work with regards thereto. Energy Services’ other pipeline services include corrosion protection services, horizontal drilling services, liquid pipeline construction, pump station construction, production facility construction, water and sewer pipeline installations, various maintenance and repair services and other services related to pipeline construction. The Company has also added the ability to install broadband and solar electric systems and perform civil and general contracting services.

Energy Services’ customers include many of the leading companies in the industries it serves, including:

TransCanada Corporation

NiSource, Inc.

Marathon Petroleum

Mountaineer Gas

American Electric Power

Toyota Motor Manufacturing

Bayer Chemical

Dow Chemical

Kentucky American Water

West Virginia American Water

Various state, county and municipal public service districts.

20

The majority of the Company’s customers are in West Virginia, Virginia, Ohio, Pennsylvania, and Kentucky. However, the Company also performs work in other states including Alabama, Michigan, Illinois, Tennessee, North Carolina, and Indiana.

Energy Services’ sales force consists of industry professionals with significant relevant sales experience, who utilize industry contacts and available public data to determine how to market the Company’s line of products most appropriately. The Company relies on direct contact between its sales force and customers’ engineering and contracting departments to obtain new business.

A substantial portion of the Company’s workforce are union members of various construction-related trade unions and are subject to separately negotiated collective bargaining agreements that expire at varying time intervals. The Company believes its relationship with its unionized workforce is good.

C.J. Hughes Construction Company, Inc. (“C.J. Hughes”), a wholly owned subsidiary of the Company, is a general contractor primarily engaged in pipeline construction for utility companies. Contractors Rental Corporation (“Contractors Rental”), a wholly owned subsidiary of C.J. Hughes, provides union building trade employees for projects managed by C.J. Hughes.

Nitro Construction Services, Inc. (“NCS”), a wholly owned subsidiary of C.J. Hughes, provides electrical, mechanical, HVAC/R, and fire protection services to customers primarily in the automotive, chemical, and power industries. Revolt Energy, LLC (“Revolt”), a wholly owned subsidiary of NCS, performs residential solar installation projects. Nitro Electric Company, LLC (“Nitro Electric”), a wholly owned subsidiary of NCS, performs industrial electrical work and has a satellite office registered in Michigan. Pinnacle Technical Solutions, Inc. (“Pinnacle”), a wholly owned subsidiary of NCS, operates as a data storage facility within Nitro’s office building. Pinnacle is supported by NCS and has no employees of its own. NCS and its subsidiaries will collectively be referred to “Nitro”.

All C.J. Hughes, Nitro, and Contractors Rental construction personnel are union members of various related construction trade unions and are subject to collective bargaining agreements that expire at varying time intervals.

West Virginia Pipeline, Inc. (“West Virginia Pipeline” or “WVP”), a wholly owned subsidiary of Energy Services, operates as a gas and water distribution contractor primarily in southern West Virginia. The employees of West Virginia Pipeline are non-union and are managed independently of the Company’s union subsidiaries.

SQP Construction Group, Inc. (“SQP”), a wholly owned subsidiary of Energy Services, operates as a general contractor primarily in West Virginia. SQP engages in the construction and renovation of buildings and other civil construction projects for state and local government agencies and commercial customers. As a general contractor, SQP manages the overall construction project and subcontracts most of the work. The employees of SQP are non-union and are managed independently of the Company’s union subsidiaries.

Tri-State Paving & Sealcoating, Inc. (“TSP” or “Tri-State Paving”), a wholly owned subsidiary of Energy Services, completed the acquisition of substantially all the assets of Tri-State Paving & Sealcoating, LLC (“Tri-State Paving, LLC”) on April 29, 2022. Tri-State Paving provides utility paving services to water distribution customers in the Charleston, West Virginia, Lexington, Kentucky, and Chattanooga, Tennessee markets. The employees of TSP are non-union and are managed independently of the Company’s union subsidiaries.

Ryan Construction Services Inc. (“Ryan Construction” or “RCS”), a wholly owned subsidiary of Energy Services, formed in August 2022 in connection with the acquisition of substantially all the assets of Ryan Environmental, LLC and Ryan Environmental Transport, LLC (collectively “Ryan Environmental”), provides directional drilling services for broadband service providers along with offering natural gas distribution services, cathodic protection and corrosion prevention services, and civil construction services. Ryan Construction operates primarily in West Virginia and Pennsylvania. The employees of RCS are non-union and are managed independently of the Company’s union subsidiaries.

The Company’s website address is www.energyservicesofamerica.com.

Seasonality: Fluctuation of Results

Our revenues and results of operations can and usually are subject to seasonal variations. These variations are the result of weather, customer spending patterns, bidding seasons and holidays. The first quarter of the calendar year is typically the slowest in terms

21

of revenues because inclement weather conditions cause delays in production and customers usually do not plan large projects during that time. While usually better than the first quarter, the second calendar year quarter often has some inclement weather which can cause delays in production, reducing the revenues the Company receives and/or increasing the production costs. The third and fourth calendar year quarters usually are less impacted by weather and usually have the largest number of projects underway. Many projects are completed in the fourth calendar year quarter and revenues are often impacted by customers seeking to either spend their capital budget for the year or scale back projects due to capital budget overruns.

In addition to the fluctuations discussed above, the pipeline industry can be highly cyclical, reflecting variances in capital expenditures in proportion to energy price fluctuations. As a result, our volume of business may be adversely affected by where our customers are in the cycle and thereby their financial condition as to their capital needs and access to capital to finance those needs.

Three and nine months ended June 30, 2024 and 2023 Overview

The following is an overview of results from operations for the three and nine months ended June 30, 2024 and 2023:

	Three Months Ended		Three Months Ended		Nine Months Ended		Nine Months Ended
	June 30,		June 30,		June 30,		June 30,
	2024		2023		2024		2023
Revenue	$	85,923,760	$	85,529,892	$	247,214,602	$	199,245,920
Cost of revenues		70,615,936		74,650,897		214,828,263		178,480,010
Gross profit		15,307,824		10,878,995		32,386,339		20,765,910
Selling and administrative expenses		6,815,191		5,283,617		21,335,862		16,487,502
Income from operations		8,492,633		5,595,378		11,050,477		4,278,408
Other income (expense)
Interest income		—		—		—		196
Other nonoperating expense		(27,446)		(72,338)		(33,935)		(163,525)
Income from lawsuit judgement		15,634,499		—		15,634,499		—
Interest expense		(546,960)		(639,888)		(1,771,560)		(1,713,862)
Gain on sale of equipment		571		30,136		292,166		47,073
		15,060,664		(682,090)		14,121,170		(1,830,118)
Income before income taxes		23,553,297		4,913,288		25,171,647		2,448,290
Income tax expense		6,039,670		1,497,742		6,724,653		767,970
Net income	$	17,513,627	$	3,415,546	$	18,446,994	$	1,680,320
Weighted average shares outstanding-basic		16,565,827		16,602,556		16,567,034		16,659,169
Weighted average shares-diluted		16,597,982		16,602,556		16,602,903		16,659,169
Earnings per share-basic	$	1.06	$	0.21	$	1.11	$	0.10
Earnings per share-diluted	$	1.06	$	0.21	$	1.11	$	0.10

22

Results of Operations for the Three and Nine Months Ended June 30, 2024 Compared to the Three and Nine Months Ended June 30, 2023

Revenues. A table comparing the Company’s revenues for the three and nine months ended June 30, 2024 compared to the three and nine months ended June 30, 2023 is below:

	Three Months Ended
	June 30, 2024		% of total		June 30, 2023		% of total		Change		% Change
Gas & Water Distribution	$	22,536,366	26.2	%	$	17,906,005	20.9	%		4,630,361	25.9	%
Gas & Petroleum Transmission		17,138,806	19.9	%		28,488,329	33.3	%		(11,349,523)	-39.8	%
Electrical, Mechanical, and General		46,248,588	53.8	%		39,135,558	45.8	%		7,113,030	18.2	%
Total	$	85,923,760	100.0	%	$	85,529,892	100.0	%		393,868	0.5	%

	Nine Months Ended
	June 30, 2024		% of total		June 30, 2023		% of total		Change		% Change
Gas & Water Distribution	$	53,892,952	21.8	%		43,825,957	22.0	%	$	10,066,995	23.0	%
Gas & Petroleum Transmission		55,465,127	22.4	%		50,718,004	25.5	%		4,747,123	9.4	%
Electrical, Mechanical, and General		137,856,523	55.8	%		104,701,959	52.5	%		33,154,564	31.7	%
Total	$	247,214,602	100.0	%		199,245,920	100.0	%	$	47,968,682	24.1	%

Total revenues increased by $394,000 to $85.9 million for the three months ended June 30, 2024, as compared to $85.5 million for the three months ended June 30, 2023. Total revenues increased by $48.0 million to $247.2 million for the nine months ended June 30, 2024, as compared to $199.2 million for the nine months ended June 30, 2023. The increases were a result of increased work in all categories of business except for an $11.3 million decrease in Gas & Petroleum Transmission work for the three months ended June 30, 2024 as compared to the same period in 2023.

Gas & Water Distribution revenues totaled $22.5 million for the three months ended June 30, 2024, a $4.6 million increase from $17.9 million for the three months ended June 30, 2023.  Gas & Water Distribution revenues totaled $53.9 million for the nine months ended June 30, 2024, a $10.1 million increase from $43.8 million for the nine months ended June 30, 2023.  The revenue increases were primarily related to increased paving and gas and water distribution services performed during the three and nine months ended June 30, 2024, as compared to the same periods in 2023.

Gas & Petroleum Transmission revenues totaled $17.1 million for the three months ended June 30, 2024, an $11.4 million decrease from $28.5 million for the three months ended June 30, 2023. Gas & Petroleum Transmission revenues totaled $55.5 million for the nine months ended June 30, 2024, a $4.8 million increase from $50.7 million for the nine months ended June 30, 2023.  The revenue decrease for the three months ended June 30, 2024, as compared to the same period in 2023, was primarily due to transmission work starting later in 2024 as compared to 2023 and the Company having a large transmission project that started in the third fiscal year quarter of 2023 that was not replaced in the third quarter of fiscal year 2024.  The revenue increase for the nine months ended June 30, 2024, as compared to the same period in 2023, was primarily due to projects that started later in fiscal year 2023 and continued into fiscal year 2024.

Electrical, Mechanical, & General construction services revenues totaled $46.2 million for the three months ended June 30, 2024, a $7.1 million increase from $39.1 million for the three months ended June 30, 2023. Electrical, Mechanical, & General construction services revenues totaled $137.9 million for the nine months ended June 30, 2024, a $33.2 million increase from $104.7 million for the nine months ended June 30, 2023. The revenue increases were primarily related to an increase in general contracting and electrical services performed during the three and nine months ended June 30, 2024, as compared to the same period in the prior year.

23

Cost of Revenues. A table comparing the Company’s costs of revenues for the three and nine months ended June 30, 2024, compared to the three and nine months ended June 30, 2023, is below:

	Three Months Ended
	June 30, 2024		% of total		June 30, 2023		% of total		Change		% Change
Gas & Water Distribution	$	16,141,729	22.9	%	$	13,256,617	17.8	%	$	2,885,112	21.8	%
Gas & Petroleum Transmission		12,549,506	17.8	%		24,517,102	32.8	%		(11,967,596)	-48.8	%
Electrical, Mechanical, & General		40,219,956	57.0	%		36,627,738	49.1	%		3,592,218	9.8	%
Unallocated Shop Expense		1,704,745	2.4	%		249,440	0.3	%		1,455,305	583.4	%
Total	$	70,615,936	100.0	%	$	74,650,897	100.0	%	$	(4,034,961)	-5.4	%

	Nine Months Ended
	June 30, 2024		% of total		June 30, 2023		% of total		Change		% Change
Gas & Water Distribution	$	41,110,876	19.1	%	$	34,521,047	19.3	%	$	6,589,829	19.1	%
Gas & Petroleum Transmission		47,248,674	22.0	%		44,352,812	24.9	%		2,895,862	6.5	%
Electrical, Mechanical, & General		123,650,574	57.6	%		98,125,733	55.0	%		25,524,841	26.0	%
Unallocated Shop Expense		2,818,139	1.3	%		1,480,418	0.8	%		1,337,721	90.4	%
Total	$	214,828,263	100.0	%	$	178,480,010	100.0	%	$	36,348,253	20.4	%

Total cost of revenues decreased by $4.0 million to $70.6 million for the three months ended June 30, 2024, as compared to $74.7 million for the three months ended June 30, 2023.  Total cost of revenues increased by $36.3 million to $214.8 million for the nine months ended June 30, 2024, as compared to $178.5 million for the nine months ended June 30, 2023. The cost of revenues decreases for the three months ended June 30, 2024, as compared to the same period in 2023, as a result of Gas & Petroleum Transmission work starting later in 2024 as compared to 2023 and the Company having a large transmission project that started in the third fiscal year quarter of 2023 that was not replaced in the third quarter of fiscal year 2024. The cost of revenue increase for the nine months ended June 30, 2024, as compared to the nine months ended June 30, 2023, as a result of increased work in all categories of business.

Gas & Water Distribution cost of revenues totaled $16.1 million for the three months ended June 30, 2024, a $2.9 million increase from $13.3 million for the three months ended June 30, 2023.  Gas & Water Distribution cost of revenues totaled $41.1 million for the nine months ended June 30, 2024, a $6.6 million increase from $34.5 million for the nine months ended June 30, 2023. The cost of revenues increase was primarily related to increased paving and gas and water distribution services performed during the nine months ended June 30, 2024, as compared to the same periods in 2023.

Gas & Petroleum Transmission cost of revenues totaled $12.5 million for the three months ended June 30, 2024, a $12.0 million decrease from $24.5 million for the three months ended June 30, 2023.  Gas & Petroleum Transmission cost of revenues totaled $47.2 million for the nine months ended June 30, 2024, a $2.9 million increase from $44.4 million for the nine months ended June 30, 2023. The cost of revenues decreases for the three months ended June 30, 2024, as compared to the same period in 2023, were primarily due to Gas & Petroleum Transmission work starting later in 2024 as compared to 2023 and the Company having a large transmission project that started in the third fiscal year quarter of 2023 that was not replaced in the third quarter of fiscal year 2024. The cost of revenues increased for the nine months ended June 30, 2024, as compared to the same period in 2023, primarily due to projects that started later in fiscal year 2023 and continued into fiscal year 2024.

Electrical, Mechanical, & General construction services cost revenues totaled $40.2 million for the three months ended June 30, 2024, a $3.6 million increase from $36.6 million for the three months ended June 30, 2023. Electrical, Mechanical, & General construction services cost of revenues totaled $123.7 million for the nine months ended June 30, 2024, a $25.5 million increase from $98.1 million for the nine months ended June 30, 2023. The cost of revenues increase was primarily related to an increase in general contracting and electrical services performed during the three and nine months ended June 30, 2024, as compared to the same period in the prior year.

Unallocated shop expenses totaled $1.7 million for the three months ended June 30, 2024, a $1.5 increase from $249,000 for the three months ended June 30, 2023. Unallocated shop expenses totaled $2.8 million for the nine months ended June 30, 2024, a $1.3 million increase from $1.5 million for the nine months ended June 30, 2023. The changes in unallocated shop expenses were primarily due to changes in the amount of internal equipment charged to projects for the three and nine months ended June 30, 2024, as compared to the same period in the prior year.

24

Gross Profit (Loss). A table comparing the Company’s gross profit (loss) for the three and nine months ended June 30, 2024, compared to the three and nine months ended June 30, 2023, is below:

	Three Months Ended
	June 30, 2024		% of revenue		June 30, 2023		% of revenue		Change		Pct.
Gas & Water Distribution	$	6,394,637	28.37	%	$	4,649,388	25.97	%		1,745,249	37.5	%
Gas & Petroleum Transmission		4,589,300	26.78	%		3,971,227	13.94	%		618,073	15.6	%
Electrical, Mechanical, & General		6,028,632	13.04	%		2,507,820	6.41	%		3,520,812	140.4	%
Unallocated Shop Expense		(1,704,745)				(249,440)				(1,455,305)	583.4	%
Total	$	15,307,824	17.8	%	$	10,878,995	12.7	%		4,428,829	40.7	%

	Nine Months Ended
	June 30, 2024		% of revenue		June 30, 2023		% of revenue		Change		% Change
Gas & Water Distribution	$	12,782,076	23.72	%	$	9,304,910	21.23	%	$	3,477,166	37.4	%
Gas & Petroleum Transmission		8,216,453	14.81	%	$	6,365,192	12.55	%		1,851,261	29.1	%
Electrical, Mechanical, & General		14,205,949	10.30	%	$	6,576,226	6.28	%		7,629,723	116.0	%
Unallocated Shop Expense		(2,818,139)			$	(1,480,418)				(1,337,721)	90.4	%
Total	$	32,386,339	13.1	%	$	20,765,910	10.4	%	$	11,620,429	56.0	%

Total gross profit increased by $4.4 million to $15.3 million for the three months ended June 30, 2024, as compared to $10.9 million for the three months ended June 30, 2023.  Total gross profit increased by $11.6 million to $32.4 million for the nine months ended June 30, 2024, as compared to $20.8 million for the nine months ended June 30, 2023.

Gas & Water Distribution gross profit totaled $6.4 million for the three months ended June 30, 2024, a $1.7 million increase from $4.6 million for the three months ended June 30, 2023.  Gas & Water Distribution gross profit totaled $12.8 million for the nine months ended June 30, 2024, a $3.5 million increase from $9.3 million for the nine months ended June 30, 2023. The gross profit increase was primarily related to increased paving and gas and water distribution services performed during the three and nine months ended June 30, 2024, as compared to the same period in 2023.

Gas & Petroleum Transmission gross profit totaled $4.6 million for the three months ended June 30, 2024, a $618,000 increase from $4.0 million for the three months ended June 30, 2023.  Gas & Petroleum Transmission gross profit totaled $8.2 million for the nine months ended June 30, 2024, a $1.9 million increase from $6.4 million for the nine months ended June 30, 2023.  The gross profit increase for the three months ended June 30, 2024, as compared to the same period in 2023, was primarily related to the unexpected receipt of project changes orders for work performed earlier in fiscal year 2023.  The gross profit increase for the nine months ended June 30, 2024, as compared to the same period in 2023, was primarily related to projects that started later in fiscal year 2023 and continued into fiscal year 2024.

Electrical, Mechanical, & General construction services gross profit totaled $6.0 million for the three months ended June 30, 2024, a $3.5 million increase from $2.5 million for the three months ended June 30, 2023. Electrical, Mechanical, & General construction services gross profit totaled $14.2 million for the nine months ended June 30, 2024, a $7.6 million increase from $6.6 million for the nine months ended June 30, 2023. The gross profit increases were primarily related to an increase in general contracting and electrical services performed during the three and nine months ended June 30, 2024, as compared to the same periods in the prior year.  In addition, the Company completed several milestones on a significant project nearing completion during the third quarter of fiscal year 2024 with a higher than expected profits.

Gross loss attributable to unallocated shop expenses totaled ($1.7) million for the three months ended June 30, 2024, a $1.5 increase from ($249,000) for the three months ended June 30, 2023. Gross loss attributable to unallocated shop expenses totaled ($2.8) million for the nine months ended June 30, 2024, a $1.3 million increase from ($1.5) million for the nine months ended June 30, 2023. The changes in unallocated shop expenses were due to changes in the amount of internal equipment charged to projects for the three and nine months ended June 30, 2024, as compared to the same periods in the prior year.

Selling and administrative expenses. Total selling and administrative expenses increased by $1.5 million to $6.8 million for the three months ended June 30, 2024, as compared to $5.3 million for the same period in the prior year. Total selling and administrative expenses increased by $4.8 million to $21.3 million for the nine months ended June 30, 2024, as compared to $16.5 million for the same

25

period in the prior year.  The increase was primarily related to additional personnel hired to secure and manage work for expected growth.

Other nonoperating expense. Other nonoperating expenses totaled $27,000 for the three months ended June 30, 2024, as compared to $72,000 for the same period in the prior year.  Other nonoperating expenses totaled $34,000 for the nine months ended June 30, 2024, as compared to $164,000 for the same period in the prior year. The change for the nine months ended June 30, 2024, as compared to the same period in 2023, was primarily related to an immaterial legal settlement that recouped costs expended in a prior period.

Income from Lawsuit Judgement. As previously disclosed, in February 2018, the Company filed a lawsuit against a customer in the United States District Court for the Western District of Pennsylvania (the “District Court”). The lawsuit was related to a dispute over work performed on a pipeline construction project. On November 21, 2022, the District Court issued a judgment in favor of the Company. On April 17, 2024, the United States Court of Appeals for the Third Circuit (the “Appeals Court”) affirmed the decision of the District Court. In May 2024, the Appeals Court denied petitions for a rehearing. This upheld the award granted by the District Court in November 2022. The Company received an approximately $15.6 million payment related to the lawsuit in May 2024.

Interest expense. Interest expense totaled $547,000 for the three months ended June 30, 2024, a decrease of $93,000 from $640,000 for the same period in the prior year. The decrease was primarily due to the Company paying off its operating line of credit in late May 2024.  Interest expense totaled $1.8 million for the nine months ended June 30, 2024, an increase of $58,000 from $1.7 million for the same period in the prior year. The increase in interest expense was primarily due to interest paid for equipment financing added in late fiscal year 2023 and an increase in interest rates, partially offset by the Company paying off its operating line of credit in late May 2024.

Gain on sale of equipment. Gain on sale of equipment totaled $600 for the three months ended June 30, 2024, a decrease of $29,400 from $30,000 for the same period in the prior year. Gain on sale of equipment totaled $292,000 for the nine months ended June 30, 2024, an increase of $245,000 from $47,000 for the same period in the prior year. The Company sold certain underutilized or non-working pieces of equipment during the nine months ended June 30, 2024, with no comparable sale occurring during the nine months ended June 30, 2023.

Net income. Income before income taxes was $23.6 million for the three months ended June 30, 2024, as compared to $4.9 million for the same period in the prior year. Income before income taxes was $25.2 million for the nine months ended June 30, 2024, as compared to income before income taxes of $2.4 million for the same period in the prior year. The increases were primarily related to the items mentioned above.

Income tax expense for the three months ended June 30, 2024, was $6.0million compared to $1.5 million for the same period in the prior year.  Income tax expense for the nine months ended June 30, 2024, was $6.7 million compared to income tax expense of $768,000 for the same period in the prior year. The increases in income tax expenses were due to an increase in taxable income primarily related to $15.6 million recognized as income from the receipt of a lawsuit judgement during the three and nine months ended June 30, 2024.

Net income for the three months ended June 30, 2024, was $17.5 million, as compared to $3.4 million for the same period in the prior year.  Net income for the nine months ended June 30, 2024 was $18.4 million, as compared to a net loss of $1.7 million for the same period in 2023.

Comparison of Financial Condition at June 30, 2024, and September 30, 2023

The Company had total assets of $148.8 million at June 30, 2024, an increase of $6.3 million from the prior fiscal year end balance of $142.5 million.

Contract assets totaled $21.0 million at June 30, 2024, an increase of $5.1 million from the prior fiscal year end balance of $16.0 million.  The increase was due to a difference in the timing of project billings at June 30, 2024, compared to September 30, 2023.

Retainage receivable totaled $10.3 million at June 30, 2024, an increase of $2.7 million from the prior fiscal year end balance of $7.6 million.  The increase was primarily due to more current year projects that require retainages to be withheld.

26

The Company had net property, plant and equipment of $37.9 million at June 30, 2024, an increase of $1.4 million from the prior fiscal year end balance of $36.5 million. The increase was due to $8.4 million in asset additions, partially offset by $6.3 million in depreciation and net equipment disposals of $703,000.

Prepaid expenses and other totaled $4.2 million at June 30, 2024, an increase of $726,000 from the prior fiscal year end balance of $3.5 million. The increase was primarily due to an increase in prepaid insurance that will be expensed in the next twelve months.

Other receivables totaled $1.1 million at June 30, 2024, an increase of $605,000 from the prior fiscal year end balance of $517,000. The increase was primarily due to an advance made to the variable interest entity referenced in Related Party Transactions.

Cash and cash equivalents totaled $14.5 million at June 30, 2024, a decrease of $1.9 million from the prior fiscal year end balance of $16.4 million.  The decrease was primarily due to a net $5.7 million investment in equipment, and a net $15.7 million used in financing activities, partially offset by a net $19.5 million provided from operating activities.

Accounts receivable, net of allowance for doubtful accounts, totaled $50.1 million at June 30, 2024, a decrease of $1.1 million from the prior fiscal year end balance of $51.2 million.  The decrease was primarily due to the timing of cash collections and project invoicing since September 30, 2023.

Right-of-use assets totaled $2.5 million at June 30, 2024, a decrease of $829,000 from the prior fiscal year end balance of $3.3 million. The decrease was primarily due to the amortization of operating leases during the nine months ended June 30, 2024, partially offset by a net increase in leased vehicles.

Intangible assets, net totaled $3.1 million at June 30, 2024, a decrease of $324,000 from the prior fiscal year end balance of $3.4 million. The decrease was due to the amortization of intangible assets during the nine months ended June 30, 2024.

Goodwill totaled $4.1 million at June 30, 2024 and September 30, 2023.

The Company had total liabilities of $96.8 million at June 30, 2024, a decrease of $11.1 million from the prior fiscal year end balance of $107.9 million.

Lines of credit and short-term borrowings totaled $10.3 million at June 30, 2024, a decrease of $9.6 million from the prior fiscal year end balance of $19.8 million. The decrease was primarily due to repayment of the operating line of credit and financed insurance premiums.  The remaining balance relates to PPP loans. Refer to Note 3 “Accounting for PPP Loans” in the accompanying consolidated financial statements for additional details.

Long-term debt totaled $21.7 million at June 30, 2024, a decrease of $3.3 million from the prior fiscal year end balance of $25.0 million. The decrease in long-term debt was primarily due to $5.0 million in payments on long-term debt, partially offset by $1.7 million in new equipment financing.

Accounts payable totaled $19.4 million at June 30, 2024, a decrease of approximately $2.6 million from the prior fiscal year end balance of $22.0 million. The decrease was due to the timing of accounts payable payments as compared to September 30, 2023.

Accrued expenses and other current liabilities totaled $12.0 million at June 30, 2024, a decrease of $1.1 million from the prior fiscal year end balance of $13.1 million. The decrease was due to the timing of accrued expense payments, as compared to September 30, 2023.

Current and long-term operating lease liabilities totaled $2.5 million at June 30, 2024, a decrease of $864,000 from the prior fiscal year end balance of $3.6 million. The decrease was due to payments made during the nine months ended June 30, 2024.

Income tax payable totaled $5.7 million at June 30, 2024, an increase of $5.7 million from the prior fiscal year end. The increase was primarily related to the taxable income generated during the nine months ended June 30, 2024.

Deferred tax liabilities totaled $7.3 million at June 30, 2024, an increase of $412,000 from the prior fiscal year end balance of $6.9 million. The increase was primarily related to a $910,000 reduction of a tax asset related to a net operating loss carry forward during the nine months ended June 30, 2024, partially offset by a $460,000 decrease in deferred taxes related to property and equipment.

27

Contract liabilities totaled $17.9 million at June 30, 2024, an increase of $202,000 from the prior fiscal year end balance of $17.7 million. The increase was due to a difference in the timing of project billings at June 30, 2024, as compared to September 30, 2023.

Shareholders’ equity was $52.0 million at June 30, 2024, an increase of $17.4 million from the prior fiscal year end balance of $34.6 million.  The increase was primarily due to net income of $18.4 million for the nine months ended June 30, 2024, partially offset by an annual cash dividend payment of $994,000 on January 2, 2024.

Liquidity and Capital Resources

Operating Line of Credit

On January 19, 2023, the Company received an amendment to its $15.0 million operating line of credit which increased the line of credit to $30.0 million with a maturity date of June 28, 2023. The interest rate on the line of credit is the “Wall Street Journal” Prime Rate (the index) with a floor of 4.99%.  On June 1, 2023, the agreement was renewed through June 28, 2024. The Company is working with its lender and expects the operating line of credit to be extended in the Company’s fourth quarter of fiscal year 2024.

The line of credit is limited to a borrowing base calculation as summarized below:

	June 30, 2024			September 30, 2023
Eligible borrowing base	$	18,971,952		$	23,942,868
Borrowed on line of credit		—			8,712,915
Line of credit balance available	$	—		$	15,229,953
Interest rate		8.5	%		8.5	%

The modified financial covenants for the quarter ended June 30, 2023, and all subsequent quarters, are below:

● Minimum tangible net worth of $28.0 million,

● Minimum traditional debt service coverage of 1.50x on a rolling twelve- month basis,

● Minimum current ratio of 1.20x,

● Maximum debt to tangible net worth ratio (“TNW”) of 2.75x,

● Each ratio and covenant shall be determined, tested, and measured as of each calendar quarter beginning June 30, 2023,

● The Company shall maintain a ratio of Maximum Senior Funded Debt (“SFD”) to Earnings before Interest, Taxes, Depreciation and Amortization (“EBDITA”) equal to or less than 3.5:1. SFD shall mean any funded debt or lease of the Company, other than subordinated debt. The covenant shall be tested quarterly, at the end of each fiscal quarter, with EBITDA based on the preceding four quarters.

The Company’s lender has agreed to omit the effect of the PPP loan restatement from the Company’s covenant compliance calculations while a final decision on PPP loan forgiveness remains in question. Thus, the Company was in compliance with all covenants at June 30, 2024. The Company projects to meet all covenant requirements for the next twelve months.

Insurance Premiums Financed

The Company financed its captive insurance policy premiums on a short-term basis through a financing company for the calendar year ended December 31, 2023. These insurance policies include workers’ compensation, general liability, automobile, umbrella, and equipment policies. The Company made a down payment in January 2023 and financed the remaining premium amount over eleven monthly payments. At June 30, 2024 and September 30, 2023, the remaining balance of the insurance premiums was $0 and $950,000, respectively.

28

For the calendar year beginning January 1, 2024, the Company’s insurance company is accepting quarterly payments on certain insurance policies and the Company has prepaid the balance of the remaining policies as of June 30, 2024. The Company has no insurance premiums financed as of June 30, 2024.

Paycheck Protection Program Loans

Due to the economic uncertainties created by COVID-19 and limited operating funds available, the Company applied for loans under the PPP. On April 15, 2020, the Company and its subsidiaries, C.J. Hughes, Contractors Rental and Nitro, entered into separate PPP notes effective April 7, 2020, with its Lender in an aggregate principal amount of $13.1 million pursuant to the PPP Loans. In a special meeting held on April 27, 2020, the Board of Directors of the Company unanimously voted to return $3.3 million of the PPP Loans after discussing the financing needs of the Company and subsidiaries. That left the Company and subsidiaries with $9.8 million in PPP Loans to fund operations. During fiscal year 2021, the Company received notice that the SBA had granted forgiveness of the $9.8 million of PPP Loans and the SBA repaid the Lender in full. The forgiveness was recorded as other income for the fiscal year ended September 30, 2021.

During April 2023, management received notification from the SBA that one of the Company’s forgiveness applications related to the PPP Loans was under review. As part of the review, the SBA requested additional payroll information. Additionally, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender. The Company recognizes that there is a possibility that the SBA could reverse its previous determination on the forgiveness of the PPP Loans. As a result of this uncertainty, the Company restated the previously audited financial statements of the Company for the fiscal years 2022 and 2021. The Company has recorded a short-term borrowing due to the SBA inquiry for the full $9.8 million, plus accrued interest.

During July 2023, management received notification from the SBA that two additional forgiveness applications related to the PPP Loans were under review. As part of the review, the SBA requested information regarding the ability of the Company’s affiliates to meet SBA size standards and/or PPP corporate maximum limits. The requested information was subsequently provided to the SBA through the Lender.

Borrowers must retain PPP documentation for at least six years after the date the loan is forgiven or paid in full, and the SBA and SBA Inspector General must be granted these files upon request. The SBA could revisit its forgiveness decision and determine that the Company does not qualify in whole or in part for loan forgiveness and demand repayment of the loans. In addition, it is unknown what type of penalties could be assessed against the Company if the SBA disagrees with the Company’s certification. Any penalties in addition to the potential repayment of the PPP Loans could negatively impact the Company’s business, financial condition and results of operations and prospects.

Long-Term Debt

On December 16, 2014, the Company’s Nitro subsidiary entered into a 20-year $1.2 million loan agreement with a bank to purchase the office building and property it had previously been leasing. The interest rate on this loan agreement is 4.82% with monthly payments of $7,800. The interest rate on this note is subject to change from time to time based on changes in the U.S. Treasury yield, adjusted to a constant maturity of three years as published by the Federal Reserve weekly. As of June 30, 2024, the Company had made principal payments of $425,000. The loan is collateralized by the building purchased under this agreement. The note is currently held by Peoples Bank, Inc., formerly First Bank of Charleston, Inc. (West Virginia).

On November 13, 2015, the Company entered into a 10-year $1.1 million loan agreement with United Bank to purchase the fabrication shop and property Nitro had previously been leasing. The variable interest rate on the loan agreement is 9.5% at June 30, 2024. As of June 30, 2024, the Company had made principal payments of $900,000. The loan is collateralized by the building and property purchased under this agreement.

On December 31, 2020, West Virginia Pipeline Acquisition Company, later renamed West Virginia Pipeline, Inc., entered into a $3.0 million sellers’ note agreement with David and Daniel Bolton for the remaining purchase price of West Virginia Pipeline, Inc. For the purchase price allocation, the $3.0 million note had a fair value of $2.85 million. As part of the $6.35 million acquisition price, the Company paid $3.5 million in cash in addition to the note. The unsecured five-year term note requires annual payments of at least $500,000 with a fixed interest rate of 3.25% on the $3.0 million sellers’ note, which equates to 5.35% on the carrying value of the note. As of June 30, 2024, the Company had made annual installment payments of $2.1 million.

29

On January 4, 2021, the Company entered into a $3.0 million Non-Revolving Note agreement with United Bank. This five-year agreement gave the Company access to a $3.0 million line of credit (“Equipment Line of Credit 2021”), specifically for the purchase of equipment, for a period of twelve months with a variable interest rate initially established at 4.25% as based on the Prime Rate as published by The Wall Street Journal. After twelve months, all borrowings against the Equipment Line of Credit 2021 were converted to a four-year term note agreement with a variable interest rate initially established at 4.25%. The loan is collateralized by the equipment purchased under this agreement. As of June 30, 2024, the Company borrowed $3.0 million against this line of credit with monthly payments of $68,150 that started in February 2022. The interest rate at June 30, 2023 was 9.5%. The Company has made principal payments of $1.6 million on this note as of June 30, 2024.

On April 2, 2021, the Company entered into a $3.5 million Non-Revolving Note agreement with United Bank. This five-year agreement repaid the outstanding $3.5 million line of credit that was used for the down payment on the West Virginia Pipeline acquisition. This loan has monthly installment payments of $64,853 and has a fixed interest rate of 4.25%. The loan is collateralized by the Company’s equipment and receivables. As of June 30, 2024, the Company had made principal payments of $2.2 million.

On April 29, 2022, the Company entered into a $7.5 million Non-Revolving Note agreement with United Bank. This five-year agreement was used to finance the purchase of Tri-State Paving and has monthly payments of $129,910 with a fixed interest rate of 4.25%. The Company has made principal payments of $2.8 million on this note as of June 30, 2024.

On October 10, 2022, the Company entered into a $3.1 million promissory note agreement with United Bank. This five-year agreement financed the previous cash value of equipment purchased in the Ryan Construction acquisition. This loan has monthly installment payments of $59,932 and has a fixed interest rate of 6.0%. The loan is collateralized by the Company’s equipment and receivables. As of June 30, 2024, the Company had made principal payments of $928,000.

On April 29, 2022, the Company entered into a $1.0 million promissory note agreement with Corns Enterprises, a related party, as partial consideration for the purchase of Tri-State Paving. David E. Corns remained as president of Tri-State Paving. This four-year agreement requires $250,000 principal installment payments on or before the end of each twelve (12) full calendar month period beginning April 29, 2022. Interest payments due shall be calculated on the principal balance remaining and shall be at the stated rate of 3.5% per year. The Company has made principal payments of $750,000 on this note as of June 30, 2024.

On June 1, 2023, the Company entered into a $9.3 million Non-Revolving Note agreement with United Bank. This five-year agreement gave the Company access to a $9.3 million line of credit (“Equipment Line of Credit 2023”), specifically for the purchase of equipment, for a period of six months with a fixed interest rate of 7.25%. After six months, all borrowings against the Equipment Line of Credit 2023 will convert to a fifty-four-month term note agreement with a fixed interest rate of 7.25%. The loan is collateralized by the equipment purchased under this agreement. As of June 30, 2024, the Company had borrowed $9.3 million against this line of credit and made $1.0 million in principal payments.

Operating Leases

The Company leases office space for SQP for $1,500 per month. The lease, which was originally signed on March 25, 2021, is for a period of two years with five one-year renewals available immediately following the end of the base term. The Company has only committed to a one-year renewal and is evaluating the intent to renew for additional periods.

The Company had two lease agreements for construction equipment with a combined amount of $160,000 that were paid in full as of June 30, 2024. The leases had a term of twenty-two months with a stated interest rate of 0%, combined monthly installment payments of $6,645 and were cancellable at any time without penalty. The Company exercised the right to purchase the equipment at the expiration of the leases by applying the two-month deposit paid. The related assets and finance lease obligations associated with these lease agreements had been included in the consolidated balance sheets within property, plant and equipment and long-term debt.

The Company has two right-of-use operating leases acquired on April 29, 2022, as part of the Tri-State Paving, LLC transaction. The first operating lease, for the Hurricane, West Virginia facility, had a net present value of $236,000 at inception, and a carrying value of $69,000 at June 30, 2024. The second operating lease, for the Chattanooga, Tennessee facility, had a net present value of $144,000 at inception, and a carrying value of $6,000 at June 30, 2024. The 4.5% interest rate on the operating leases is based on the Company’s incremental borrowing rate at inception.

30

The Company has a right-of-use operating lease with Enterprise Fleet Management, Inc. (Enterprise) acquired on August 11, 2022, as part of the Ryan Environmental acquisition. This lease agreement was initially for thirty-one vehicles with a net present value of $1.2 million. The Company had seventy-one vehicles on lease at June 30, 2024. The right-of-use operating lease has a carrying value of $2.2 million at June 30, 2024. Each vehicle leased under the master lease program has its own implicit rate ranging from 12.8% to 15.6%.

The Company has a right-of-use operating lease with RICA Developers, LLC acquired on August 12, 2022 and renewed for one year effective October 1, 2023. This lease, for the Bridgeport, West Virginia facility, had a net present value of $125,000 at inception and a carrying value of $21,000 at June 30, 2024. The 8.5% interest rate on the operating lease was based on the Company’s incremental borrowing rate at renewal.

The Company has a right-of-use operating lease acquired on March 28, 2023. This lease, for the Winchester, Kentucky facility, had a net present value of $290,000 at inception and a carrying value of $169,000 at June 30, 2024. The 7.75% interest rate on the operating lease is based on the Company’s incremental borrowing rate at inception.

Off-Balance Sheet Arrangements

Due to the nature of our industry, we often enter into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected in our balance sheets. Though for the most part not material in nature, some of these are:

Rental Agreements

The Company rents equipment for use on construction projects with rental agreements being week to week or month to month. Rental expense can vary by reporting period due to equipment requirements on construction projects and the availability of Company owned equipment. Rental expense, which is included in cost of goods sold on the consolidated statements of income, was $3.3 million and $2.5 million, respectively, for the three months ended June 30, 2024 and 2023. Rental expenses were $12.0 million and $6.8 million, respectively, for the nine months ended June 30, 2024 and 2023.

Letters of Credit

Certain customers or vendors may require letters of credit to secure payments that the vendors are making on our behalf or to secure payments to subcontractors and vendors on various customer projects. At June 30, 2024, the Company did not have any letters of credit outstanding.

Performance Bonds

Some customers, particularly new ones or governmental agencies require the Company to post bid bonds, performance bonds and payment bonds (collectively, performance bonds). These performance bonds are obtained through insurance carriers and guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If the Company fails to perform under a contract or to pay subcontractors and vendors, the customer may demand that the insurer make payments or provide services under the bond. The Company must reimburse the insurer for any expenses or outlays it is required to make.

Currently, the Company has an agreement with a surety company to provide bonding which will suit the Company’s immediate needs. The ability to obtain bonding for future contracts is an important factor in the contracting industry with respect to the type and value of contracts that can be bid. Depending upon the size and conditions of a particular contract, the Company may be required to post letters of credit or other collateral in favor of the insurer. Posting these letters or other collateral will reduce our borrowing capabilities. The Company does not anticipate any claims in the foreseeable future. At June 30, 2024, the Company had $94.5 million in performance bonds outstanding.

Concentration of Credit Risk

In the ordinary course of business, the Company grants credit under normal payment terms, generally without collateral, to our customers, which include natural gas and oil companies, general contractors, and various commercial and industrial customers located within the United States. Consequently, the Company is subject to potential credit risk related to business and economic factors that

31

would affect these companies. However, the Company generally has certain statutory lien rights with respect to services provided. Under certain circumstances such as foreclosure, the Company may take title to the underlying assets in lieu of cash in settlement of receivables.

Please see the tables below for customers that represent 10.0% or more of the Company’s revenue or accounts receivable, net of retention for the three and nine months ended June 30, 2024 and 2023:

	Three Months Ended		Three Months Ended		Nine Months Ended		Nine Months Ended
	June 30,		June 30,		June 30,		June 30,
Revenue	2024		2023		2024		2023
TransCanada Corporation	11.6	%	15.1	%	14.3	%	11.1	%
NiSource and subsidiaries		*	15.5	%		*	10.7	%
All other	88.4	%	69.4	%	85.7	%	78.2	%
Total	100.0	%	100.0	%	100.0	%	100.0	%

*Less than 10.0% and included in “All other” if applicable

Accounts receivable, net of retention	at June 30, 2024		at September 30, 2023
Walbridge Aldinger	11.1	%		*
All other	88.9	%	100.0	%
Total	100.0	%	100.0	%

*Less than 10.0% and included in “All other” if applicable

Litigation

As previously disclosed, in February 2018, the Company filed a lawsuit against a customer in the United States District Court for the Western District of Pennsylvania (the “District Court”). The lawsuit was related to a dispute over work performed on a pipeline construction project. On November 21, 2022, the District Court issued a judgment in favor of the Company. On April 17, 2024, the United States Court of Appeals for the Third Circuit (the “Appeals Court”) affirmed the decision of the District Court. In May 2024, the Appeals Court denied petitions for a rehearing. This upheld the award granted by the District Court in November 2022. The Company received an approximately $15.6 million payment related to the lawsuit in May 2024.

On November 12, 2021, the Company received a withdrawal liability claim from a pension plan to which the Company made pension contributions for union construction employees performing covered work in a particular jurisdiction. The Company has not performed covered work in their jurisdiction since 2011; however, the Company disagrees with the withdrawal claim and believes it is covered by an exemption under federal law. The demand called for thirty-four quarterly installment payments of $41,000 starting December 15, 2021. The Company must comply with the demand under federal pension law; however, the Company firmly believes no withdrawal liability exists. The Company is in negotiations with the pension fund to resolve the matter and all future payments have been suspended as part of the negotiation. The Company has expensed all $164,000 in payments made through September 30, 2022 and does not expect any future liabilities related to this claim. The Company did not make any payments during the three and nine months ended June 30, 2024.

Other than described above, at June 30, 2024, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties, or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At June 30, 2024, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

Related Party Transactions

On April 29, 2022, the Company entered into a $1.0 million promissory note agreement with Corns Enterprises as partial consideration for the purchase of Tri-State Paving. This four-year agreement requires $250,000 principal installment payments on or before the end of each twelve (12) full calendar month period beginning April 29, 2022. Interest payments due shall be calculated on

32

the principal balance remaining and shall be at the stated rate of 3.5% per year. The Company has made $750,000 in principal payments on this note as of June 30, 2024.

Subsequent to the April 29, 2022 acquisition of Tri-State Paving, the Company entered into an operating lease for facilities in Hurricane, West Virginia with Corns Enterprises. This thirty-six-month lease is treated as a right to use asset and has payments of $7,000 per month. The total net present value at inception was $236,000 with a carrying value of $69,000 at June 30, 2024.

SQP made an equity investment of $156,000 in 1030 Quarrier Development, LLC (“Development”) in August 2022. Development is a variable interest entity (“VIE”) that is 75% owned by 1030 Quarrier Ventures, LLC (“Ventures”) and 25% owned by SQP. SQP is not the primary beneficiary of the VIE and therefore will not consolidate Development into its consolidated financial statements. Instead, SQP will apply the equity method of accounting for its investment in Development. Development, a 1% owner, and United Bank, a 99% owner, formed 1030 Quarrier Landlord, LLC (“Landlord”). Landlord decided to pursue the following development project (the “Project”): a historical building at 1030 Quarrier Street, Charleston, West Virginia as well as associated land (the “Property”) was purchased to be developed/rehabilitated into a commercial project including apartments and commercial space. Upon the completion of development, the Property will be used to generate rental income. SQP has been awarded the construction contract for the Project. United Bank provided $5.0 million in loans to fund the Project. SQP and Ventures have jointly provided an unconditional guarantee for the $5.0 million of obligations associated with the Project.

Other than mentioned above, there were no new material related party transactions entered into during the three and nine months ended June 30, 2024.

Certain Energy Services subsidiaries routinely engage in transactions in the normal course of business with each other, including sharing employee benefit plan coverage, payment for insurance and other expenses on behalf of other affiliates, and other services incidental to business of each of the affiliates. All revenue and related expense transactions, as well as the related accounts payable and accounts receivable have been eliminated in consolidation.

Inflation

Most significant project materials, such as pipe or electrical wire, are provided by the Company’s customers. When possible, the Company attempts to lock in pricing with vendors and include qualifications regarding material costs increases in bids. Where allowed by contract, the Company will address fuel cost increases with customers. Significant inflation or supply chain issues could cause customers to delay or cancel planned projects; however, inflation did not have a significant effect on our results for the three and nine months ended June 30, 2024 and 2023.

Critical Accounting Estimates

The discussion and analysis of the Company’s financial condition and results of operations are based on our consolidated financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosures of contingent assets and liabilities known to exist at the date of the consolidated financial statements and reported amounts of revenues and expenses during the reporting period. We evaluate our estimates on an ongoing basis, based on historical experience and on various other assumptions that are believed to be reasonable under the circumstances. There can be no assurance that actual results will not differ from those estimates. Management believes the following accounting policies affect our more significant judgments and estimates used in the preparation of our consolidated financial statements.

Revenues

The Company recognizes revenue as performance obligations are satisfied and control of the promised goods and service is transferred to the customer. For Lump Sum and Unit Price contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward complete satisfaction of the performance obligation(s) using an input (i.e., “cost to cost”) method. For Cost Plus and Time and Material (“T&M”) contracts, revenue is ordinarily recognized over time as control is transferred to the customers by measuring the progress toward satisfaction of the performance obligation(s) using an output method. The Company also does certain T&M service work that is generally completed in a short duration and is recognized at a point in time.

33

The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our estimates of the cost to complete each project. We believe our experience allows us to create materially reliable estimates. There are a number of factors that can contribute to changes in estimates of contract cost and profitability. The most significant of these include:

● the completeness and accuracy of the original bid;

● costs associated with scope changes;

● changes in costs of labor and/or materials;

● extended overhead and other costs due to owner, weather and other delays;

● subcontractor performance issues;

● changes in productivity expectations;

● site conditions that differ from those assumed in the original bid;

● changes from original design on design-build projects;

● the availability and skill level of workers in the geographic location of the project;

● a change in the availability and proximity of equipment and materials;

● our ability to fully and promptly recover on affirmative claims and back charges for additional contract costs; and

● the customer’s ability to properly administer the contract.

The foregoing factors, as well as the stage of completion of contracts in process and the mix of contracts at different margins may cause fluctuations in gross profit from period to period. Significant changes in cost estimates, particularly in our larger, more complex projects could have a significant effect on our profitability.

Our contract assets include cost and estimated earnings in excess of billings that represent amounts earned and reimbursable under contracts, including claim recovery estimates, but have a conditional right for billing and payment such as achievement of milestones or completion of the project. With the exception of customer affirmative claims, generally, such unbilled amounts will become billable according to the contract terms and generally will be billed and collected over the next three months. Settlement with the customer of outstanding affirmative claims is dependent on the claims resolution process and could extend beyond one year. Based on our historical experience, we generally consider the collection risk related to billable amounts to be low. When events or conditions indicate that it is probable that the amounts outstanding become unbillable, the transaction price and associated contract asset is reduced.

Our contract liabilities consist of provisions for losses and billings in excess of costs and estimated earnings. Provisions for losses are recognized in the consolidated statements of income at the uncompleted performance obligation level for the amount of total estimated losses in the period that evidence indicates that the estimated total cost of a performance obligation exceeds its estimated total revenue. Billings in excess of costs and estimated earnings are billings to customers on contracts in advance of work performed, including advance payments negotiated as a contract condition. Generally, unearned project-related costs will be earned over the next twelve months.

The following table presents our costs and estimated earnings in excess of billings and billings in excess of costs and estimated earnings at June 30, 2024 and September 30, 2023:

	June 30, 2024		September 30, 2023
Costs incurred on contracts in progress	$	347,023,673	$	287,347,650
Estimated earnings, net of estimated losses		55,753,948		38,976,895
		402,777,621		326,324,545
Less billings to date		399,676,125		328,112,326
	$	3,101,496	$	(1,787,781)
Costs and estimated earnings in excess of billed on uncompleted contracts	$	21,046,114	$	15,955,220
Less billings in excess of costs and estimated earnings on uncompleted contracts		17,944,618		17,743,001
	$	3,101,496	$	(1,787,781)

34

Allowance for doubtful accounts

The Company provides an allowance for doubtful accounts when collection of an account is considered doubtful. Inherent in the assessment of the allowance for doubtful accounts are certain judgments and estimates relating to, among others, our customers’ access to capital, our customers’ willingness or ability to pay, general economic conditions and the ongoing relationship with the customers. While most of our customers are large well capitalized companies, should they experience material changes in their revenues and cash flows or incur other difficulties and not be able to pay the amounts owed, this could cause reduced cash flows and losses in excess of our current reserves.

Materially incorrect estimates of bad debt reserves could result in an unexpected loss in profitability for the Company. Additionally, frequently changing reserves could be an indication of risky or unreliable customers. At June 30, 2024, the management review deemed that the allowance for doubtful accounts was adequate.

Please see the allowance for doubtful accounts table below as of and for the nine months ended June 30, 2024 and as of and for the twelve months ended September 30, 2023:

	June 30, 2024		September 30, 2023
Balance at beginning of period	$	51,063	$	70,310
Charged to expense		—		—
Deductions for uncollectible receivables written off, net of recoveries		—		(19,247)
Balance at end of period	$	51,063	$	51,063

Impairment of goodwill and intangible assets

The Company follows the guidance of Accounting Standards Codification (“ASC”) 350-20-35-3 “Intangibles-Goodwill and Other (Topic 350)” which requires a company to record an impairment charge based on the excess of a reporting unit’s carrying amount of goodwill over its fair value. Under the current guidance, companies can first choose to assess any impairment based on qualitative factors (Step 0). If a company fails this test or decides to bypass this step, it must proceed with a quantitative assessment of goodwill impairment. The Company did not have a goodwill impairment at June 30, 2024.

Materially incorrect estimates could cause an impairment of goodwill or intangible assets and result in a loss in profitability for the Company.

A table of the Company’s intangible assets subject to amortization is below:

				Accumulated		Accumulated		Amortization		Amortization		Amortization		Amortization
	Remaining Life			Amortization		Amortization		and Impairment		and Impairment		and Impairment		and Impairment
	(in months) at			and Impairment		and Impairment		Three Months		Nine Months		Three Months		Nine Months		Net Book Value		Net Book Value
	June 30,			at June 30,		at September 30,		Ended June 30,		Ended June 30,		Ended June 30,		Ended June 30,		at June 30,		at September 30,
Intangible assets:	2024	Original Cost		2024		2023		2024		2024		2023		2023		2024		2023
West Virginia Pipeline:
Customer Relationships	78	$	2,209,724		773,387	$	607,661		55,242		165,726		65,643		186,532	$	1,436,337	$	1,602,063
Tradename	78		263,584		92,273		72,500		6,591		19,773		6,591		19,773		171,311		191,084
Non-competes	—		83,203		83,203		83,203		—		—		—		10,397		—		—
Revolt Energy:
Employment agreement/non-compete	—		100,000		100,000		100,000		—		—		13,887		22,221		—		—
Tri-State Paving:
Customer Relationships	94		1,649,159		357,318		233,631		41,229		123,687		41,229		123,687		1,291,841		1,415,528
Tradename	94		203,213		44,029		28,789		5,080		15,240		5,080		15,241		159,184		174,424
Non-competes	—		39,960		39,960		39,960		-		-		3,390		23,370		—		—
Total intangible assets		$	4,548,843	$	1,490,170	$	1,165,744	$	108,142	$	324,426	$	135,820	$	401,221	$	3,058,673	$	3,383,099

Depreciation and Amortization

The purpose of depreciation and amortization is to represent an accurate value of assets on the books. Every year, as assets are used, their values are reduced on the balance sheet and expensed on the income statement. As depreciation and amortization are a noncash expense, the amount must be estimated. Each year a certain amount of depreciation and amortization is written off and the book value of the asset is reduced.

35

Property and equipment are recorded at cost. Costs which extend the useful lives or increase the productivity of the assets are capitalized, while normal repairs and maintenance that do not extend the useful life or increase productivity of the asset are expensed as incurred. Property and equipment are depreciated principally on the straight-line method over the estimated useful lives of the assets: buildings 39 years; operating equipment and vehicles 5-7 years; and office equipment, furniture and fixtures 5-7 years.

Acquired intangible assets subject to amortization are amortized on a straight-line basis, which approximates the pattern in which the economic benefit of the respective intangible assets is realized, over their respective estimated useful lives. The definite-lived identifiable intangible assets recognized as part of the Company’s business combinations are initially recorded at their estimated fair value.

The Company’s depreciation expenses for the three months ended June 30, 2024 and 2023 were $2.2 million and $1.7 million, respectively. The Company’s depreciation expenses for the nine months ended June 30, 2024 and 2023 were $6.3 million and $5.4 million, respectively. In general, depreciation is included in “cost of revenues” on the Company’s consolidated statements of income.

The Company’s amortization expenses for the three months ended June 30, 2024 and 2023 were $108,142 and $135,820, respectively. The Company’s amortization expenses for the nine months ended June 30, 2024 and 2023 were $324,426 and $401,221, respectively. In general, amortization is included in “cost of revenues” on the Company’s consolidated statements of income.

Materially incorrect estimates of depreciation and amortization and/or the useful lives of assets could significantly impact the value of long-lived assets on the Company’s consolidated financial statements. A material overvaluation could result in impairment charges and reduced profitability for the Company.

Income Taxes

The Company’s income tax expenses and deferred tax assets and liabilities reflect management’s best estimate of current and future taxes to be paid. Significant judgments and estimates are required in the determination of the consolidated income tax expense. The Company’s provision for income taxes is computed by applying a federal rate of 21.0% and a state rate of 6.0% to taxable income or loss after consideration of non-taxable and non-deductible items.

The income tax expense for the three months ended June 30, 2024 was $6.0 million as compared to $1.5 million for the three months ended June 30, 2023. The income tax expense for the nine months ended June 30, 2024 was $6.7 million as compared to 768,000 for the nine months ended June 30, 2023. The changes were due to an increase in taxable income for the three and nine months ended June 30, 2024, as compared to the same period in 2023.

The effective income tax rate for the three and nine months ended June 30, 2024, was 25.6% and 30.5%,  respectively, as compared to 26.7% and 31.4%, respectively, for the same periods in 2023. Effective income tax rates are estimates and may vary from period to period due to changes in the amount of taxable income and non-deductible expenses.

Accounting for PPP Loans

The Company’s accounting for PPP loans reflects management’s best estimate of current and future amounts to be paid. The Company applies significant judgment regarding the determination of PPP loan forgiveness based on the rules established, and subsequently clarified by the SBA, including rules related to the Company’s affiliations and meeting SBA size standards.

Refer to Note 3 “Accounting for PPP Loans” in the accompanying consolidated financial statements for additional details.

New Accounting Pronouncements

On October 28, 2021, the Financial Accounting Standards Board (“FASB”) released Accounting Standards Update (“ASU”) 2021-08, Business Combinations (Topic 805): Accounting for Contract Assets and Contract Liabilities from Contracts with Customers. The amendments of this ASU require entities to apply Topic 606 to recognize and measure contract assets and contract liabilities in a business combination. The amendments improve comparability after the business combination by providing consistent recognition and measurement guidance for revenue contracts with customers acquired in a business combination and revenue contracts with customers not acquired in a business combination. The amendments are effective for public business entities for the fiscal years, including interim periods within those the fiscal years, beginning after December 15, 2022. For all other entities they are effective for the fiscal years,

36

including interim periods within those the fiscal years, beginning after December 15, 2023. Entities should apply the amendments prospectively to business combinations that occur after the effective date. Early adoption is permitted, including in any interim period, for public business entities for periods for which financial statements have not yet been issued, and for all other entities for periods for which financial statements have not yet been made available for issuance. The Company is currently assessing the effect that ASU 2021-08 will have on its results of operations, financial position and cash flows; however, the Company does not expect a significant impact.

Subsequent Events

On July 11, 2024, the Company’s Nitro subsidiary completed the acquisition of substantially all the physical assets of Heritage Painting, LLC, a West Virginia corporation located in Poca, West Virginia for $300,000 cash.

Management has evaluated all subsequent events for accounting and disclosure. There have been no other material events during the period, other than noted above, that would either impact the results reflected in the report or the Company’s results going forward.

Outlook

The following statements are based on current expectations. These statements are forward-looking, and actual results may differ materially.

The Company is seeing a significant increase in bid opportunities for natural gas transmission and distribution projects along with electrical, mechanical, and general construction projects.  The Company’s unaudited backlog at June 30, 2024, was $250.9 million, as compared to $185.9 million and $229.8 million at June 30, 2023, and September 30, 2023, respectively.  While adding additional projects appears likely, no assurances can be given that the Company will be successful in bidding on projects that become available.  Moreover, even if the Company obtains contracts, there can be no guarantee that the projects will go forward.

ITEM 3. Quantitative and Quantitative Disclosures About Market Risk

Not required for a smaller reporting company.

ITEM 4. Controls and Procedures

Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, we evaluated the effectiveness of the design and operation of our disclosure controls and procedures (as defined in Rule 13a-15(e) under the Securities Exchange Act of 1934) as of the end of the period covered by this report. Based upon that evaluation, the Chief Executive Officer and Chief Financial Officer concluded that, as of the end of the period covered by this report, our disclosure controls and procedures were effective to ensure that information required to be disclosed in the reports that Energy Services of America Corporation files or submits under the Securities Exchange Act of 1934, is (1) recorded, processed, summarized and reported, within the time periods specified in the SEC’s rules and forms, and (2) accumulated and communicated to our management, including our Chief Executive Officer and Chief Financial Officer, as appropriate to allow timely decisions regarding required disclosure.

There has been no change in Energy Services of America Corporation’s internal control over financial reporting during Energy Services of America Corporation’s third quarter of fiscal year 2024 that has materially affected, or is reasonably likely to materially affect, Energy Services of America Corporation’s internal control over financial reporting.

37

PART II

OTHER INFORMATION

ITEM 1. Legal Proceedings

As previously disclosed, in February 2018, the Company filed a lawsuit against a customer in the United States District Court for the Western District of Pennsylvania (the “District Court”). The lawsuit was related to a dispute over work performed on a pipeline construction project. On November 21, 2022, the District Court issued a judgment in favor of the Company. On April 17, 2024, the United States Court of Appeals for the Third Circuit (the “Appeals Court”) affirmed the decision of the District Court. In May 2024, the Appeals Court denied petitions for a rehearing. This upheld the award granted by the District Court in November 2022. The Company received an approximately $15.6 million payment related to the lawsuit in May 2024.

On November 12, 2021, the Company received a withdrawal liability claim from a pension plan to which the Company made pension contributions for union construction employees performing covered work in a particular jurisdiction. The Company has not performed covered work in their jurisdiction since 2011; however, the Company disagrees with the withdrawal claim and believes it is covered by an exemption under federal law. The demand called for thirty-four quarterly installment payments of $41,000 starting December 15, 2021. The Company must comply with the demand under federal pension law; however, the Company firmly believes no withdrawal liability exists. The Company is in negotiations with the pension fund to resolve the matter and all future payments have been suspended as part of the negotiation. The Company has expensed all $164,000 in payments made through September 30, 2022 and does not expect any future liabilities related to this claim. The Company did not make any payments during the three and nine months ended June 30, 2024.

Other than described above, at June 30, 2024, the Company was not involved in any legal proceedings other than in the ordinary course of business. The Company is a party from time to time to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties, or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims, and proceedings, we record reserves when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. At June 30, 2024, the Company does not believe that any of these proceedings, separately or in aggregate, would be expected to have a material adverse effect on our financial position, results of operations or cash flows.

ITEM 1A. Risk Factors

Please see the information disclosed in the “Risk Factors” section of our Annual Report on Form 10-K as filed with the Securities and Exchange Commission on January 16, 2024. There have been no material changes to the risk factors since the filing of the Annual Report on Form 10-K.

38

ITEM 2. Unregistered Sales of Equity Securities, Use of Proceeds and Issuer Purchases of Equity Securities

(a) There have been no unregistered sales of equity securities during the period covered by the report.

(b) None.

(c) A table showing repurchases of Energy Services of America Corporation’s shares of its common stock during the three months ended June 30, 2024 is below:

				Value of Shares		Maximum Number of
				Purchased as Part of		Shares That May Yet Be
	Total Number of Shares	Average Price		Publicly Announced		Purchased Under the
Period	Purchased	Paid Per Share		Plans or Programs (1)		Plans or Programs
April 2024	—		—		—	934,478
May 2024	6,901	$	6.00	$	41,379	893,099
June 2024	—		—		—	893,099
Total	6,901	$	6.00	$	41,379	893,099

(1) On July 6, 2022 the Company announced that the Board of Directors authorized a stock repurchase program under which the Company would repurchase up to 1,000,000 shares, or approximately 6%, of the Company’s issued and outstanding stock. The repurchase program started on August 16, 2022 and has no expiration date.

ITEM 5. Other Information

During the third fiscal quarter of 2024, none of our directors or officers adopted or terminated any contract, instruction or written plan for the purchase or sale of Company securities that was intended to satisfy the affirmative defense conditions of Rule 10b5-1(c) or any “non-Rule 10b5-1 trading arrangement,” as that term is used in SEC regulations.

39

ITEM 6. Exhibits

31.1	Certification of Chief Executive Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
31.2	Certification of Chief Financial Officer pursuant to Rule 13a-14(a) of the Securities Exchange Act of 1934, as amended, as adopted pursuant to Section 302 of the Sarbanes-Oxley Act of 2002
32	Certification of Chief Executive Officer and Chief Financial Officer pursuant to 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002
101.INS	XBRL Instance Document
101.SCH	XBRL Taxonomy Extension Schema Document
101.CAL	XBRL Taxonomy Extension Calculation Linkbase Document
101.DEF	XBRL Taxonomy Extension Definition Linkbase Document
101.LAB	XBRL Taxonomy Extension Label Linkbase Document
101.PRE	XBRL Taxonomy Extension Presentation Linkbase Document

40

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the Company has duly caused this report to be signed on its behalf by the undersigned, thereunto duly authorized.

ENERGY SERVICES OF AMERICA CORPORATION

Date: August 12, 2024	By:	/s/ Douglas V. Reynolds
		Douglas V. Reynolds
		Chief Executive Officer
Date: August 12, 2024	By:	/s/ Charles P. Crimmel
		Charles P. Crimmel
		Chief Financial Officer

41