Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 1 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
(Name and location or address):
Skechers Distribution Center
29800 Eucalyptus Avenue
Rancho Belago, California 92555
(Name and address):
14225 Corporate Way
Moreno Valley, California 92553
(Name and address):
18831 Bardeen Avenue, Suite 100
Irvine, California 92612
14725 Alton Parkway
Irvine, Ca 92618
(949) 855-5716
16361 Scientific Way
Irvine, CA 92618
(949) 224-0044
1 | GENERAL PROVISIONS | 11 | |
2 | OWNER | 13 | |
3 | CONTRACTOR | 15 | |
4 | ADMINISTRATION OF THE CONTRACT | 22 | |
5 | SUBCONTRACTORS | 27 | |
6 | CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS | 29 | |
7 | CHANGES IN THE WORK | 30 | |
8 | TIME | 32 | |
9 | PAYMENTS AND COMPLETION | 33 | |
10 | PROTECTION OF PERSONS AND PROPERTY | 41 | |
11 | INSURANCE AND BONDS | 43 | |
12 | UNCOVERING AND CORRECTION OF WORK | 44 | |
13 | MISCELLANEOUS PROVISIONS | 45 | |
14 | TERMINATION OR SUSPENSION OF THE CONTRACT | 47 |
Page 2 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
(Numbers and Topics in Bold are Section Headings)
9.6.6, 9.9.3,12.3
Acceptance of Work
9.6.6, 9.8.2, 9.9.3, 9.10.1, 9.10.3, 12.3
Access to Work
3.16, 6.2.1, 12.1
Accident Prevention
4.2.3, 10
Acts and Omissions
3.2, 3.3.2, 3.12.8, 3.18, 4.2.3, 4.3.8, 4.4.1, 8.3.1, 9.5.1, 10.2.5, 13.4.2, 13.7, 14.1
Addenda
1.1.1, 3.11
Additional Costs, Claims for
4.3.4, 4.3.5, 4.3.6, 6.1.1, 10.3
Additional Inspections and Testing
9.8.3, 12.2.1, 13.5
Additional Time, Claims for
4.3.4, 4.3.7, 8.3.2
ADMINISTRATION OF THE CONTRACT
3.1.3,4, 9.4, 9.5
Advertisement or Invitation to Bid
1.1.1
Aesthetic Effect
4.2.13, 4.5.1
Allowances
3.8
All-risk Insurance
11.4.1.1
Applications for Payment
4.2.5, 7.3.8, 9.2,9.3, 9.4, 9.5.1, 9.6.3, 9.7.1, 9.8.5, 9.10, 11.1.3, 14.2.4, 14.4.3
Approvals
2.4, 3.1.3, 3.5, 3.10.2, 3.12, 4.2.7, 9.3.2, 13.4.2, 13.5
Arbitration
4.3.3, 4.4, 4.5.1, 4.5.2,4.6, 8.3.1, 9.7.1, 11.4.9, 11.4.10
Architect
4.1
Architect, Definition of
4.1.1
Architect, Extent of Authority
2.4, 3.12.7, 4.2, 4.3.6, 4.4, 5.2, 6.3, 7.1.2, 7.3.6, 7.4, 9.2, 9.3.1, 9.4, 9.5, 9.8.3, 9.10.1, 9.10.3, 12.1, 12.2.1, 13.5.1, 13.5.2, 14.2.2, 14.2.4
Architect, Limitations of Authority and Responsibility
2.1.1, 3.3.3, 3.12.4, 3.12.8, 3.12.10, 4.1.2, 4.2.1, 4.2.2, 4.2.3, 4.2.6, 4.2.7, 4.2.10, 4.2.12, 4.2.13, 4.4, 5.2.1, 7.4, 9.4.2, 9.6.4, 9.6.6
Architect’s Additional Services and Expenses
2.4, 11.4.1.1, 12.2.1, 13.5.2, 13.5.3, 14.2.4
Architect’s Administration of the Contract
3.1.3,4.2, 4.3.4, 4.4, 9.4, 9.5
Architect’s Approvals
2.4, 3.1.3, 3.5.1, 3.10.2, 4.2.7
Architect’s Authority to Reject Work
3.5.1, 4.2.6, 12.1.2, 12.2.1
Architect’s Copyright
1.6
Architect’s Decisions
4.2.6, 4.2.7, 4.2.11, 4.2.12, 4.2.13, 4.3.4, 4.4.1, 4.4.5,
4.4.6, 4.5, 6.3, 7.3.6, 7.3.8, 8.1.3, 8.3.1, 9.2, 9.4, 9.5.1,
9.8.4, 9.9.1, 13.5.2, 14.2.2, 14.2.4
Architect’s Inspections
4.2.2, 4.2.9, 4.3.4, 9.4.2, 9.8.3, 9.9.2, 9.10.1, 13.5
Architect’s Instructions
3.2.3, 3.3.1, 4.2.6, 4.2.7, 4.2.8, 7.4.1, 12.1, 13.5.2
Architect’s Interpretations
4.2.11, 4.2.12, 4.3.6
Architect’s Project Representative
4.2.10
Architect’s Relationship with Contractor
1.1.2, 1.6, 3.1.3, 3.2.1, 3.2.2, 3.2.3, 3.3.1, 3.4.2, 3.5.1, 3.7, 3, 3.10, 3.11, 3.12, 3.16, 3.18, 4.1.2, 4.1.3, 4.2, 4.3.4, 4.4.1, 4.4.7, 5.2, 6.2.2, 7, 8.3.1, 9.2, 9.3, 9.4, 9.5, 9.7, 9.8, 9.9, 10.2.6, 10.3, 11.3, 11.4.7, 12, 13.4.2, 13.5
Architect’s Relationship with Subcontractors
1.1.2, 4.2.3, 4.2.4, 4.2.6, 9.6.3, 9.6.4, 11.4.7
Architect’s Representations
9.4.2, 9.5.1, 9.10.1
Architect’s Site Visits
4.2.2, 4.2.5, 4.2.9, 4.3.4, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.5
Asbestos
10.3.1
Attorneys’ Fees
3.18.1, 9.10.2, 10.3.3
Award of Separate Contracts
6.1.1, 6.1.2
Award of Subcontracts and Other Contracts for Portions of the Work
5.2
Basic Definitions
1.1
Bidding Requirements
1.1.1, 1.1.7, 5.2.1, 11.5.1
Boiler and Machinery Insurance
11.4.2
Bonds, Lien
9.10.2
Bonds, Performance, and Payment
7.3.6.4, 9.6.7, 9.10.3, 11.4.9, 11.5
Building Permit
3.7.1
Capitalization
1.3
Certificate of Substantial Completion
9.8.3, 9.8.4, 9.8.5
Certificates for Payment
Page 3 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Certificates of Inspection, Testing or Approval
13.5.4
Certificates of Insurance
9.10.2, 11.1.3
Change Orders
1.1.1, 2.4.1, 3.4.2, 3.8.2.3, 3.11.1, 3.12.8, 4.2.8, 4.3.4, 4.3.9, 5.2.3, 7.1,7.2, 7.3, 8.3.1, 9.3.1.1, 9.10.3, 11.4.1.2, 11.4.4, 11.4.9, 12.1.2
Change Orders, Definition of
7.2.1
CHANGES IN THE WORK
3.11, 4.2.8, 7, 8.3.1, 9.3.1.1, 11.4.9
Claim,Definitionof
4.3.1
Claims and Disputes
3.2.3,4.3,4.4, 4.5, 4.6, 6.1.1, 6.3, 7.3.8, 9.3.3, 9.10.4, 10.3.3
Claims and Timely Assertion of Claims
4.6.5
Claims for Additional Cost
3.2.3, 4.3.4,4.3.5,4.3.6, 6.1.1, 7.3.8, 10.3.2
Claims for Additional Time
3.2.3, 4.3.4,4.3.7,6.1.1, 8.3.2, 10.3.2
Claims for Concealed or Unknown Conditions
4.3.4
Claims for Damages
3.2.3, 3.18, 4.3.10, 6.1.1, 8.3.3, 9.5.1, 9.6.7, 10.3.3, 11.1.1, 11.4.5, 11.4.7, 14.1.3, 14.2.4
Claims Subject to Arbitration
4.4.1, 4.5.1, 4.6.1
Cleaning Up
3.15, 6.3
Commencement of Statutory Limitation Period
13.7
Commencement of the Work, Conditions Relating to
2.2.1, 3.2.1, 3.4.1, 3.7.1, 3.10.1, 3.12.6, 4.3.5, 5.2.1, 5.2.3, 6.2.2, 8.1.2, 8.2.2, 8.3.1, 11.1, 11.4.1, 11.4.6, 11.5.1
Commencement of the Work, Definition of
8.1.2
Communications Facilitating Contract Administration
3.9.1,4.2.4
Completion, Conditions Relating to
1.6.1, 3.4.1, 3.11, 3.15, 4.2.2, 4.2.9, 8.2, 9.4.2, 9.8, 9.9.1,
9.10, 12.2, 13.7, 14.1.2
COMPLETION, PAYMENTS AND
9
Completion, Substantial
4.2.9, 8.1.1, 8.1.3, 8.2.3, 9.4.2, 9.8, 9.9.1, 9.10.3, 9.10.4.2,
12.2, 13.7
Compliance with Laws
1.6.1, 3.2.2, 3.6, 3.7, 3.12.10, 3.13, 4.1.1, 4.4.8, 4.6.4, 4.6.6, 9.6.4, 10.2.2, 11.1, 11.4, 13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14.1.1, 14.2.1.3
Concealed or Unknown Conditions
4.3.4, 8.3.1, 10.3
Conditions of the Contract
1.1.1, 1.1.7, 6.1.1, 6.1.4
Consent, Written
1.6, 3.4.2, 3.12.8, 3.14.2, 4.1.2, 4.3.4, 4.6.4, 9.3.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3, 11.4.1, 13.2, 13.4.2
CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS
1.1.4,6
Construction Change Directive, Definition of
7.3.1
Construction Change Directives
1.1.1, 3.12.8, 4.2.8, 4.3.9, 7.1,7.3, 9.3.1.1
Construction Schedules, Contractor’s
1.4.1.2, 3.10, 3.12.1, 3.12.2, 4.3.7.2, 6.1.3
Contingent Assignment of Subcontracts
5.4, 14.2.2.2
Continuing Contract Performance
4.3.3
Contract, Definition of
1.1.2
CONTRACT, TERMINATION OR SUSPENSION OF THE
5.4.1.1, 11.4.9, 14
Contract Administration
3.1.3, 4, 9.4, 9.5
Contract Award and Execution, Conditions Relating to
3.7.1, 3.10, 5.2, 6.1, 11.1.3, 11.4.6, 11.5.1
Contract Documents, The
1.1, 1.2
Contract Documents, Copies Furnished and Use of
1.6, 2.2.5, 5.3
Contract Documents, Definition of
1.1.1
Contract Sum
3.8, 4.3.4, 4.3.5, 4.4.5, 5.2.3, 7.2, 7.3, 7.4,9.1,9.4.2, 9.5.1.4, 9.6.7, 9.7, 10.3.2, 11.4.1, 14.2.4, 14.3.2
Contract Sum, Definition of
9.1
Contract Time
4.3.4, 4.3.7, 4.4.5, 5.2.3, 7.2.1.3, 7.3, 7.4, 8.1.1, 8.2, 8.3.1,
9.5.1, 9.7, 10.3.2, 12.1.1, 14, 3.2
Contract Time, Definition of
8.1.1
CONTRACTOR
3
Contractor, Definition of
3.1, 6.1.2
Contractor’s Construction Schedules
1.4.1.2,3.10,3.12.1, 3.12.2, 4.3.7.2, 6.1.3
Contractor’s Employees
3.3.2, 3.4.3, 3.8.1, 3.9, 3.18.2, 4.2.3, 4.2.6, 10.2, 10.3, 11.1.1, 11.4.7, 14.1, 14.2.1.1,
Contractor’s Liability Insurance
Page 4 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Contractor’s Relationship with Separate Contractors and Owner’s Forces
3.12.5, 3.14.2, 4.2.4, 6, 11.4.7, 12, 1.2, 12.2.4
Contractor’s Relationship with Subcontractors
1.2.2, 3.3.2, 3.18.1, 3.18.2, 5, 9.6.2, 9.6.7, 9.10.2, 11.4.1.2, 11.4.7, 11.4.8
Contractor’s Relationship with the Architect
1.1.2, 1.6, 3.1.3, 3.2.1, 3.2.2, 3.2.3, 3.3.1, 3.4.2, 3.5.1, 3.7.3, 3.10, 3.11, 3.12, 3.16, 3.18, 4.1.2, 4.1.3, 4.2, 4.3.4, 4.4.1, 4.4.7, 5.2, 6.2.2, 7, 8.3.1, 9.2, 9.3, 9.4, 9.5, 9.7, 9.8, 9.9, 10.2.6, 10.3, 11.3, 11.4.7, 12, 13.4.2, 13.5
Contractor’s Representations
1.5.2, 3.5.1, 3.12.6, 6.2.2, 8.2.1, 9.3.3, 9.8.2
Contractor’s Responsibility for Those Performing the Work
3.3.2, 3.18, 4.2.3, 4.3.8, 5.3.1, 6.1.3, 6.2, 6.3, 9.5.1, 10
Contractor’s Review of Contract Documents
1.5.2, 3.2, 3.7.3
Contractor’s Right to Stop the Work
9.7
Contractor’s Right to Terminate the Contract
4.3.10, 14.1
Contractor’s Submittals
3.10, 3.11, 3.12, 4.2.7, 5.2.1, 5.2.3, 7.3.6, 9.2, 9.3, 9.8.2, 9.8.3, 9.9.1, 9.10.2, 9.10.3, 11.1.3, 11.5.2
Contractor’s Superintendent
3.9, 10.2.6
Contractor’s Supervision and Construction Procedures
1.2.2, 3.3, 3.4, 3.12.10, 4.2.2, 4.2.7, 4.3.3, 6.1.3, 6.2.4, 7.1.3, 7.3.4, 7.3.6, 8.2, 10, 12, 14
Contractual Liability Insurance
11.1.1.8, 11.2, 11.3
Coordination and Correlation
1.2, 1.5.2, 3.3.1, 3.10, 3.12.6, 6.1.3, 6.2.1
Copies Furnished of Drawings and Specifications
1.6, 2.2.5, 3.11
Copyrights
1.6, 3.17
Correction of Work
2.3, 2.4, 3.7.4, 4.2.1, 9.4.2, 9.8.2, 9.8.3, 9.9.1, 12.1.2, 12.2, 13.7.1.3
Correlation and Intent of the Contract Documents
1.2
Cost, Definition of
7.3.6
Costs
2.4, 3.2.3, 3.7.4, 3.8.2, 3.15.2, 4.3, 5.4.2, 6.1.1, 6.2.3, 7.3.3.3, 7.3.6, 7.3.7, 7.3.8, 9.10.2, 10.3.2, 10.5, 11.3, 11.4, 12.1, 12.2.1, 12.2.4, 13.5, 14
Cutting and Patching
6.2.5,3.14
Damage to Construction of Owner or Separate Contractors
3.14.2, 6.2.4, 9.2.1.5, 10.2.1.2, 10.2.5, 10.6, 11.1, 11.4, 12.2.4
Damage to the Work
3.14.2, 9.9.1, 10.2.1.2, 10.2.5, 10.6, 11.4, 12.2.4
Damages, Claims for
3.2.3, 3.18, 4.3.10, 6.1.1, 8.3.3, 9.5.1, 9.6.7, 10.3.3, 11.1.1, 11.4.5, 11.4.7, 14.1.3, 14.2.4
Damages for Delay
6.1.1, 8.3.3, 9.5.1.6, 9.7, 10.3.2
Date of Commencement of the Work, Definition of
8.1.2
Date of Substantial Completion, Definition of
8.1.3
Day, Definition of
8.1.4
Decisions of the Architect
4.2.6, 4.2.7, 4.2.11, 4.2.12, 4.2.13, 4.3.4, 4.4.1, 4.4.5, 4.4.6, 4.5, 6.3, 7.3.6, 7.3.8, 8.1.3, 8.3.1, 9.2, 9.4, 9.5.1, 9.8.4, 9.9.1, 13.5.2, 14.2.2, 14.2.4
Decisions to Withhold Certification
9.4.1, 9.5, 9.7, 14.1.1.3
Defective or Nonconforming Work, Acceptance, Rejection and Correction of
2.3, 2.4, 3.5.1, 4.2.6, 6.2.5, 9.5.1, 9.5.2, 9.6.6, 9.8.2, 9.9.3, 9.10.4, 12.2.1, 13.7.1.3
Defective Work, Definition of
3.5.1
Definitions
1.1, 2.1.1, 3.1, 3.5.1, 3.12.1, 3.12.2, 3.12.3, 4.1.1, 4.3.1, 5.1, 6.1.2, 7.2.1, 7.3.1, 7.3.6, 8.1, 9.1, 9.8.1
Delays and Extensions of Time
3.2.3, 4.3.1, 4.3.4, 4.3.7, 4.4.5, 5.2.3, 7.2.1, 7.3.1, 7.4.1,8.3,9.5.1, 9.7.1, 10.3.2, 10.6.1, 14.3.2
Disputes
4.1.4, 4.3, 4.4, 4.5, 4.6, 6.3, 7.3.8
Documents and Samples at the Site
3.11
Drawings, Definition of
1.1.5
Drawings and Specifications, Use and Ownership of
1.1.1, 1.3, 2.2.5, 3.11, 5.3
Effective Date of Insurance
8.2.2, 11.1.2
Emergencies
4.3.5,10.6,14.1.1.2
Employees, Contractor’s
3.3.2, 3.4.3, 3.8.1, 3.9, 3.18.2, 4.2.3, 4.2.6, 10.2, 10.3, 11.1.1, 11.4.7, 14.1, 14.2, 1.1
Equipment, Labor, Materials and
1.1.3, 1.1.6, 3.4, 3.5.1, 3.8.2, 3.8.3, 3.12, 3.13, 3.15.1, 4.2.6, 4 ..2.7, 5.2.1, 6.2.1, 7.3.6, 9.3, 2, 9.3.3, 9.5.1.3, 9.10.2, 10.2.1, 10.2.4, 14.2.1.2
Execution and Progress of the Work
Page 5 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Extensions of Time
3.2.3, 4.3.1, 4.3.4, 4.3.7, 4.4.5, 5.2.3, 7.2.1, 7.3, 7.4.1, 9.5.1, 9.7.1, 10.3.2, 10.6.1, 14.3.2
Failure of Payment
4.3.6, 9.5.1.3, 9.7, 9.10.2, 14.1.1.3, 14.2.1.2, 13.6
Faulty Work
(SeeDefective or Nonconforming Work)
Final Completion and Final Payment
4.2.1, 4.2.9, 4.3.2, 9.8.2,9.10, 11.1.2, 11.1.3, 11.4.1, 11.4.5, 12.3.1, 13.7, 14.2.4, 14.4.3
Financial Arrangements, Owner’s
2.2.1, 13.2.2, 14.1.1.5
Fire and Extended Coverage Insurance
11.4
GENERAL PROVISIONS
1
Governing Law
13.1
Guarantees(SeeWarranty)
Hazardous Materials
10.2.4,10.3,10.5
Identification of Contract Documents
1.5.1
Identification of Subcontractors and Suppliers
5.2.1
Indemnification
3.17,3.18, 9.10.2, 10.3.3, 10.5, 11.4.1.2, 11.4.7
Information and Services Required of the Owner
2.1.2,2.2,3.2.1, 3.12.4, 3.12.10, 4.2.7, 4.3.3, 6.1.3, 6.1.4, 6.2.5, 9.3.2, 9.6.1, 9.6.4, 9.9.2, 9.10.3, 10.3.3, 11.2, 11.4, 13.5.1, 13.5.2, 14.1.1.4, 14.1.4
Injury or Damage to Person or Property
4.3.8, 10.2, 10.6
Inspections
3.1.3, 3.3.3, 3.7.1, 4.2.2, 4.2.6, 4.2.9, 9.4, 2, 9.8.2, 9.8.3, 9.9.2, 9.10.1, 12.2.1, 13.5
Instructions to Bidders
1.1.1
Instructions to the Contractor
3.2.3, 3.3.1, 3.8.1, 4.2.8, 5.2.1, 7, 12, 8.2.2, 13.5.2
Insurance
3.18.1, 6.1.1, 7.3.6, 8.2.1, 9.3.2, 9.8.4, 9.9.1, 9.10.2, 9.10.5, 11
Insurance, Boiler and Machinery
11.4.2
Insurance, Contractor’s Liability
11.1
Insurance, Effective Date of
8.2.2, 11.1.2
Insurance, Loss of Use
11.4.3
Insurance, Owner’s Liability
Insurance, Project Management Protective Liability
11.3
Insurance, Property
10.2.5,11.4
Insurance, Stored Materials
9.3.2, 11.4.1.4
INSURANCE AND BONDS
11
Insurance Companies, Consent to Partial Occupancy
9.9.1, 11.4.1.5
Insurance Companies, Settlement with
11.4.10
Intent of the Contract Documents
1.2.1, 4.2.7, 4.2.12, 4.2.13, 7.4
Interest
13.6
Interpretation
1.2.3,1.4,4.1.1, 4.3.1, 5.1, 6.1.2, 8.1.4
Interpretations, Written
4.2.11, 4.2.12, 4.3.6
Joinder and Consolidation of Claims Required
4.6.4
Judgment on Final Award
4.6.6
Labor and Materials, Equipment
1.1.3, 1.1.6,3.4,3.5.1, 3.8.2, 3.8.3, 3.12, 3.13, 3.15.1, 42.6, 4.2.7, 5.2.1, 6.2.1, 7.3.6, 9.3.2, 9.3.3, 9.5.1.3, 9.10.2, 10.2.1, 10.2, 4, 14.2.1.2
Labor Disputes
8.3.1
Laws and Regulations
1.6, 3.2.2, 3.6, 3.7, 3.12.10, 3.13, 4.1.1, 4.4.8, 4.6, 9.6.4, 9.9.1, 10.2.2, 11.1, 11.4, 13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14
Liens
2.1.2, 4.4.8, 8.2.2, 9.3.3, 9.10
Limitation on Consolidation or Joinder
4.6.4
Limitations, Statutes of
4.6.3, 12.2.6, 13.7
Limitations of Liability
2.3, 3.2.1, 3.5.1, 3.7.3, 3.12.8, 3.12.10, 3.17, 3.18, 4.2.6, 4.2.7, 4.2.12, 6.2.2, 9.4.2, 9.6.4, 9.6.7, 9.10.4, 10.3.3, 10.2.5, 11.1.2, 11.2.1, 11.4.7, 12.2.5, 13.4.2
Limitations of Time
2.1.2, 2.2, 2.4, 3.2.1, 3.7.3, 3.10, 3.11, 3.12.5, 3.15.1, 4.2.7, 4.3, 4.4, 4.5, 4.6, 5.2, 5.3, 5.4, 6.2.4, 7.3, 7.4, 8.2, 9.2, 9.3.1, 9.3.3, 9.4.1, 9.5, 9.6, 9.7, 9.8, 9.9, 9.10, 11.1.3, 11.4.1.5, 11.4.6, 11.4.10, 12.2, 13.5, 13.7, 14
Loss of Use Insurance
11.4.3
Material Suppliers
1.6, 3.12.1, 4.2.4, 4.2.6, 5, 2.1, 9.3, 9.4.2, 9.6, 9.10.5
Materials, Hazardous
Page 6 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Materials, Labor, Equipment and
1.1.3, 1.1.6, 1.6.1, 3.4, 3.5.1, 3.8.2, 3.8.23, 3.12, 3.13, 3.15.1, 4.2.6, 4.2.7, 5.2.1, 6.2.1, 7.3.6, 9.3.2, 9.3.3, 9.5, 1.3, 9.10.2, 10.2.1, 10.2.4, 14.2.1.2
Means, Methods, Techniques, Sequences and Procedures of Construction
3.3.1, 3.12.10, 4.2.2, 4.2.7, 9.4.2
Mechanic’s Lien
4.4.8
Mediation
4.4.1,4.4.5,4.4.6, 4.4.8,4.5,4.6.1, 4.6.2, 8.3.1, 10.5
Minor Changes in the Work
1.1.1, 3.12.8, 4.2.8, 4.3.6, 7.1,7.4
MISCELLANEOUS PROVISIONS
13
Modifications, Definition of
1.1.1
Modifications to the Contract
1.1.1, 1.1.2, 3.7.3, 3.11, 4.1.2, 4.2.1, 5.2.3, 7, 8.3.1, 9.7, 10.3.2, 11.4.1
Mutual Responsibility
6.2
Nonconforming Work, Acceptance of
9.6.6, 9.9.3,12.3
Nonconforming Work, Rejection and Correction of
2.3, 2.4, 3.5.1, 4.2.6, 6.2.5, 9.5.1, 9.8.2, 9.9.3, 9.10.4, 12.2.1, 13.7.1.3
Notice
2.2.1, 2.3, 2.4, 3.2.3, 3.3.1, 3.7.2, 3.7.4, 3.12.9, 4.3, 4.4.8, 4.6.5, 5.2.1, 8.2.2, 9.7, 9.10, 10.2.2, 11.1.3, 11.4.6, 12.2.2, 12.2.4, 13.3, 13.5.1, 13.5.2, 14.1, 14.2
Notice, Written
2.3, 2.4, 3.3.1, 3.9, 3.12.9, 3.12.10, 4.3, 4.4.8, 4.6.5, 5.2.1, 8.2.2, 9.7, 9.10, 10.2.2, 30.3, 11.1.3, 11.4.6, 12.2.2, 12.2.4,13.3,14
Notice of Testing and Inspections
13.5.1, 13.5.2
Notice to Proceed
8.2.2
Notices, Permits, Fees and
2.2.2,3.7,3.13, 7.3.6.4, 10.2.2
Observations, Contractor’s
1.5.2, 3.2, 3.7.3, 4.3.4
Occupancy
2.2.2, 9.6.6, 9.8, 11.4.1.5
Orders, Written
1.1.1, 2.3, 3.9, 4.3.6, 7, 8.2.2, 11.4.9, 12.1, 12.2, 13.5.2, 14.3.1
OWNER
2
Owner, Definition of
2.1
Owner, Information and Services Required of the
2.1.2,2.2,3.2.1, 3.12.4, 3.12.10, 4.2.7, 4.3.3, 6.1.3, 6.1.4, 6.2.5, 9.3.2, 9.6.1, 9.6.4, 9.9.2, 9.10.3, 10.3.3, 11.2, 11.4, 13.5.1, 13.5.2, 14.1.1.4, 14.1.4
Owner’s Authority
1.6, 2.1.1, 2.3, 2.4, 3.4.2, 3.8.1, 3.12.10, 3.14.2, 4.1.2, 4.1.3, 4.2.4, 4.2.9, 4.3.6, 4.4.7, 5.2.1, 5.2.4, 5.4.1, 6.1, 6.3, 7.2.1, 7.3.1, 8.2.2, 8.3.1, 9.3.1, 9.3.2, 9.5.1, 9.9.1, 9.10.2, 10.3.2, 11.1.3, 11.3.1, 11.4.3, 11.4.10, 12.2.2, 12.3.1, 13.2.2, 14, 3, 14.4
Owner’s Financial Capability
2.2.1, 13.2.2, 14.1.1.5
Owner’s Liability Insurance
11.2
Owner’s Loss of Use Insurance
11.4.3
Owner’s Relationship with Subcontractors
1.1.2, 5.2, 5.3, 5.4, 9.6.4, 9.10.2, 14.2.2
Owner’s Right to Carry Out the Work
2.4, 12.2.4.14.2.2.2
Owner’s Right to Clean Up
6.3
Owner’s Right to Perform Construction and to Award
Separate Contracts
6.1
Owner’s Right to Stop the Work
2.3
Owner’s Right to Suspend the Work
14.3
Owner’s Right to Terminate the Contract
14.2
Ownership and Use of Drawings, Specifications and Other Instruments of Service
1.1.1,1.6,2.2.5, 3.2.1, 3.11.1, 3.17.1, 4.2.12, 5.3
Partial Occupancy or Use
9.6.6,9.9, 11.4.1.5
Patching, Cutting and
3.14, 6.2.5
Patents
3.17
Payment, Applications for
4.2.5, 7.3.8, 9.2,9.3,9.4, 9.5.1, 9.6.3, 9.7.1, 9.8.5, 9.10.1, 9.10.3, 9.10.5, 11.1.3, 14.2.4, 14.4.3
Payment, Certificates for
4.2.5, 4.2.9, 9.3.3,9.4,9.5, 9.6.1, 9.6.6, 9.7.1, 9.10.1, 9.10.3, 13.7, 14.1.1.3, 14.2.4
Payment, Failure of
4.3.6, 9.5.1.3, 9.7, 9.10.2, 14.1.1.3, 14.2.1.2, 13.6
Payment, Final
4.2.1, 4.2.9, 4.3.2, 9.8.2, 9.10, 11.1.2, 11.1.3, 11.4.1, 11.4.5, 12.3.1, 13.7, 14.2.4, 14.4.3
Payment Bond, Performance Bond and
7.3.6.4, 9.6.7, 9.10.3, 11.4.9,11.5
Payments, Progress
4.3.3, 9.3, 9.6, 9.8.5, 9.10.3, 13.6, 14.2.3
PAYMENTS AND COMPLETION
Page 7 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Payments to Subcontractors
5.4.2, 9.5.1.3, 9.6.2, 9.6.3, 9.6.4, 9.6.7, 11.4.8, 14.2.1.2
PCB
10.3.1
Performance Bond and Payment Bond
7.3.6.4, 9.6.7, 9.10.3, 11.4.9,11.5
Permits, Feesand Notices
2.2.2, 3.7, 3.13, 7.3.6.4, 10.2.2
PERSONS AND PROPERTY, PROTECTION OF
10
Polychlorinated Biphenyl
10.3.1
Product Data, Definition of
3.12.2
Product Data and Samples, Shop Drawings
3.11,3.12, 4.2.7
Progress and Completion
4.2.2, 4.3.3,8.2,9.8, 9.9.1, 14.1.4
Progress Payments
4.3.3, 9.3,9.6,9.8.5, 9.10.3, 13.6, 14.2.3
Project, Definition of the
1.1.4
Project Management Protective Liability Insurance
11.3
Project Manual, Definition of the
1.1.7
Project Manuals
2.2.5
Project Representatives
4.2.10
Property Insurance
10.2.5, 11.4
PROTECTION OF PERSONS AND PROPERTY
10
Regulations and Laws
1.6, 3.2.2, 3.6, 3.7, 3.12.10, 3.13, 4.1.1, 4.4.8, 4.6, 9.6.4, 9.9.1, 10.2.2, 11.1,11.4,13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14
Rejection of Work
3.5.1, 4.2.6, 12.2.1
Releases and Waivers of Liens
9.10.2
Representations
1.5.2, 3.5.1, 3.12.6, 6.2.2, 8.2.1, 9.3.3, 9.4.2, 9.5.1, 9.8.2, 9.10.1
Representatives
2.1.1, 3.1.1, 3.9, 4.1.1, 4.2.1, 4.2.10, 5.1.1, 5.1.2, 13.2.1
Resolution of Claims and Disputes
4.4, 4.5, 4.6
Responsibility for Those Performing the Work
3.3.2, 3.18, 4.2.3, 4.3.8, 5.3.1, 6.1.3, 6.2, 6.3, 9.5.1, 10
Retainage
9.3.1, 9.6.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3
Review of Contract Documents and Field Conditions by Contractor
1.5.2,3.2, 3.7.3, 3.12.7, 6.1.3
Review of Contractor’s Submittals by Owner and Architect
3.10.1, 3.10.2, 3.11, 3.12, 4.2, 5.2, 6.1.3, 9.2, 9.8.2
Review of Shop Drawings, Product Data and Samples by Contractor
3.12
Rights and Remedies
1.1.2, 2.3, 2.4, 3.5.1, 3.15.2, 4.2.6, 4.3.4, 4.5, 4.6, 5.3, 5.4, 6.1, 6.3, 7.3.1, 8.3, 9.5.1, 9.7, 10.2.5, 10.3, 12.2.2, 12.2.4,13.4,14
Royalties, Patents and Copyrights
3.17
Rules and Notices for Arbitration
4.6.2
Safety of Persons and Property
10.2, 10.6
Safety Precautions and Programs
3.3.1, 4.2.2, 4.2.7, 5.3.1,10.1,10.2, 10.6
Samples, Definition of
3.12.3
Samples, Shop Drawings, Product Data and
3.11, 3.12, 4.2.7
Samples at the Site, Documents and
3.11
Schedule of Values
9.2, 9.3.1
Schedules,
1.4.1.2, 3.10, 3. Construction 12.1, 3.12.2, 4.3.7.2, 6.1.3
Separate Contracts and Contractors
1.1.4, 3.12.5, 3.14.2, 4.2.4, 4.2.7, 4.6.4, 6, 8.3.1, 11.4.7, 12.1.2, 12.2.5
Shop Drawings, Definition of
3.12.1
Shop Drawings, Product Data and Samples
3.11,3.12, 4.2.7
Site, Use of
3.13, 6.1.1, 6.2.1
Site Inspections
1.2.2, 3.2.1, 3.3.3, 3.7.1, 4.2, 4.3.4, 9.4.2, 9.10.1, 13.5
Site Visits, Architect’s
4.2.2, 4.2.9, 4.3.4, 9.4.2, 9.5.1, 9.9.2, 9.10.1, 13.5
Special Inspections and Testing
4.2.6, 12.2.1, 13.5
Specifications, Definition of the
1.1.6
Specifications, The
1.1.1,1.1.6,1.1.7, 1.2.2, 1.6, 3.11, 3.12.10, 3.17
Statute of Limitations
4.6.3, 12.2.6, 13.7
Stopping the Work
2.3, 4.3.6, 9.7, 10.3, 14.1
Stored Materials
Page 8 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Subcontractor, Definition of
5.1.1
SUBCONTRACTORS
5
Subcontractors, Work by
1.2.2, 3.3.2, 3.12.1, 4.2.3, 5.2.3, 5.3, 5.4, 9.3.1.2, 9.6.7
Subcontractual Relations
5.3, 5.4, 9.3.1.2, 9.6, 9.10 10.2.1, 11.4.7, 11.4.8, 14.1, 14.2.1, 14.3.2
Submittals
1.6, 3.10, 3.11, 3.12, 4.2.7, 5.2.1, 5.2.3, 7.3.6, 9.2, 9.3, 9.8, 9.9.1, 9.10.2, 9.10.3, 11.1.3
Subrogation, Waivers of
6.1.1, 11.4.5,11.4.7
Substantial Completion
4.2.9, 8.1.1, 8.1.3, 8.2.3, 9.4.2,9.8,9.9.1, 9.10.3, 9.10.4.2, 12.2, 13.7
Substantial Completion, Definition of
9.8.1
Substitution of Subcontractors
5.2, 3, 5.2.4
Substitution of Architect
4.1.3
Substitutions of Materials
3.4.2, 3.5.1, 7.3.7
Sub-subcontractor, Definition of
5.1.2
Subsurface Conditions
4.3.4
Successors and Assigns
13.2
Superintendent
3.9, 10.2.6
Supervision and Construction Procedures
1.2.2,3.3,3.4, 3.12.10, 4.2.2, 4.2.7, 4, 3.3, 6.1.3, 6.2.4, 7.1.3, 7.3.6, 8.2, 8.3.1, 9.4.2, 10, 12, 14
Surety
4.4.7, 5.4.1.2, 9.8.5, 9.10.2, 9.10.3, 14.2.2
Surety, Consent of
9.10.2, 9.10.3
Surveys
2.2.3
Suspension by the Owner for Convenience
14.4
Suspension of the Work
5.4.2, 14.3
Suspension or Termination of the Contract
4.3.6, 5.4.1.1, 11.4.9, 14
Taxes
3.6, 3.8.2.1, 7.3.6.4
Termination by the Contractor
4.3.10,14.1
Termination by the Owner for Cause
4.3.10, 5.4.1.1,14.2
Termination of the Architect
4.1.3
Termination of the Contractor
14.2.2
TERMINATION OR SUSPENSION OF THE CONTRACT
14
Tests and Inspections
3.1.3, 3.3.3, 4.2.2, 4.2.6, 4.2.9, 9.4.2, 9.8.3, 9.9.2, 9.10.1, 10.3.2, 11.4.1.1, 12.2, 1,13.5
TIME
8
Time, Delays and Extensions of
3.2.3, 4.3.1, 4.3.4, 4.3.7, 4.4.5, 5.2.3, 7.2.1, 7.3.1, 7.4.1,8.3,9.5.1, 9.7.1, 10.3.2, 10.6.1, 14.3.2
Time Limits
2.1.2, 2.2, 2.4, 3.2.1, 3.7.3, 3.10, 3.11, 3.12.5, 3.15.1, 4.2, 4.3, 4.4, 4.5, 4.6, 5.2, 5.3, 5.4, 6.2.4, 7.3, 7.4, 8.2, 9.2, 9.3.1, 9.3.3, 9.4.1, 9.5, 9.6, 9.7, 9.8, 9.9, 9.10, 11.1.3, 11, 4.1.5, 11.4.6, 11.4.10, 12.2, 13.5, 13.7, 14
Time Limits on Claims
4.3.2, 4.3.4, 4.3.8, 4.4, 4.5, 4.6
Title to Work
9.3.2, 9.3.3
UNCOVERING AND CORRECTION OF WORK
12
Uncovering of Work
12.1
Unforeseen Conditions
4.3.4, 8.3.1, 10.3
Unit Prices
4.3.9, 7.3.3.2
Use of Documents
1.1.1, 1.6, 2.2.5, 3.12.6, 5.3
Use of Site
3.13, 6.1.1, 6.2.1
Values, Schedule of
9.2, 9.3.1
Waiver of Claims by the Architect
13.4.2
Waiver of Claims by the Contractor
4.3.10, 9.10.5, 11.4.7, 13.4.2
Waiver of Claims by the Owner
4.3.10, 9.9.3, 9.10.3, 9, 10.4, 11.4.3, 11.4.5, 11.4.7, 12.2.2.1, 13.4.2, 14.2.4
Waiver of Consequential Damages
4.3.10, 14.2.4
Waiver of Liens
9.10.2, 9.10.4
Waivers of Subrogation
6.1.1, 11.4.5, 11.4.7
Warranty
3.5, 4.2.9, 4.3.5.3, 9.3.3, 9.8.4, 9.9.1, 9.10.4, 12.2.2, 13.7.1.3
Weather Delays
Page 9 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Work, Definition of
1.1.3
Written Consent
1.6, 3.4.2, 3.12.8, 3.14.2, 4.1.2, 4.3.4, 4.6.4, 9.3.2, 9.8.5, 9.9.1, 9.10.2, 9.10.3, 11.4.1, 13.2, 13.4.2
Written Interpretations
4.2.11, 4.2.12, 4.3.6
Written Notice
2.3, 2.4, 3.3.1, 3.9, 3.12.9, 3.12.10, 4.3, 4.4.8, 4.6.5, 5.2.1, 8.2.2, 9.7, 9.10, 10.2.2, 10.3, 11.1.3, 11.4.6, 12.2.2, 12.2.4,13.3,14
Written Orders
1.1.1, 2.3, 3.9, 4.3.6, 7, 8.2.2, 11.4.9, 12.1, 12.2, 13.5.2, 14.3.1
Page 10 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 11 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 12 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 13 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 14 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 15 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 16 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 17 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and all required taxes, less applicable trade discounts; | ||
.2 | Contractor’s costs for unloading and handling at the site, labor, installation costs, overhead, profit and other expenses contemplated for stated allowance amounts shall be included in the Contract Sum but not in the allowances; | ||
.3 | whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect (1) the difference between actual costs and the allowances under Section 3.8.2.1 and (2) changes in Contractor’s costs under Section 3.8.2.2. In the event of a Change Order executed for the purpose of adjusting an allowance, the Contractor’s fee shall be 1.75%. |
Page 18 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 19 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 20 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 21 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 22 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 23 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 24 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 25 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons; and | ||
.2 | damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising directly from the Work. |
Page 26 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 27 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 28 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | assignment is effective only after termination of the Contract by the Owner with or without cause pursuant to Article 14 and only for those subcontract agreements which the Owner accepts by notifying the Subcontractor and Contractor in writing (Owner will be responsible for any payments due for Work performed after termination of the Contract under any subcontract agreements that are so accepted by Owner); and | ||
.2 | assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the Contract. |
Page 29 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | change in the Work; | ||
.2 | the amount of the adjustment, if any, in the Contract Sum; and | ||
.3 | the extent of the adjustment, if any, in the Contract Time. |
Page 30 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation; | ||
.2 | unit prices stated in the Contract Documents or subsequently agreed upon; | ||
.3 | cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or | ||
.4 | as provided in Section 7.3.6. |
.1 | costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers’ compensation insurance; |
Page 31 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.2 | costs of materials, supplies and equipment, including cost of transportation, whether incorporated or consumed; | ||
.3 | rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others; | ||
.4 | costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the Work; and | ||
.5 | additional costs of supervision and field office personnel directly attributable to the change. |
Page 32 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 33 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 34 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | Work not in accordance with the Contract Documents; | ||
.2 | third party claims filed or reasonable evidence indicating probable filing of such claims unless security acceptable to the Owner is provided by the Contractor; | ||
.3 | failure of the Contractor to make payments properly to Subcontractors or for labor, materials or equipment or to provide invoices, signed releases and lien waivers; | ||
.4 | reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; | ||
.5 | damage to the Owner or another contractor; | ||
.6 | reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; | ||
.7 | failure to carry out the Work in accordance with the Contract Documents; or | ||
.8 | Contractor has failed to perform any of its material obligations under the Contract Documents. | ||
.9 | Failure of the Contractor to submit with each application for payment evidence that all inspections necessary to issue Warranties required pursuant to the Contract Documents have been made. | ||
.10 | Failure of the Contractor to comply in any way with the requirements set forth herein for any Application for Payment. |
Page 35 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 36 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 37 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 38 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 39 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | liens, Claims, security interests or encumbrances arising out of the Contract and unsettled; | ||
.2 | failure of the Work to comply with the requirements of the Contract Documents, including latent defects; | ||
.3 | terms of warranties required by the Contract Documents; or | ||
.4 | all of Contractor’s indemnity and defense obligations and all other obligations that survive completion of the Work. |
Page 40 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | employees on the Work and other persons who may be affected thereby; | ||
.2 | the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody or control of the Contractor or the Contractor’s Subcontractors or Sub-subcontractors; and | ||
.3 | other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction. |
Page 41 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 42 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 43 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 44 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 45 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 46 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.1 | Before Substantial Completion. As to acts or failures to act occurring prior to the relevant date of Substantial Completion, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than such date of Substantial Completion; | ||
.2 | Between Substantial Completion and Final Certificate for Payment. As to acts or failures to act occurring subsequent to the relevant date of Substantial Completion and prior to issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of issuance of the final Certificate for Payment; and | ||
.3 | After Final Certificate for Payment. As to acts or failures to act occurring after the relevant date of issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of any act or failure to act by the Contractor pursuant to any Warranty provided under Section 3.5, the date of any correction of the Work or failure to correct the Work by the Contractor under Section 12.2, or the date of actual commission of any other act or failure to perform any duty or obligation by the Contractor or Owner, whichever occurs last. |
.1 | issuance of an order of a court or other public authority having jurisdiction which requires all Work to be stopped; |
Page 47 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.2 | an act of government, such as a declaration of national emergency which requires all Work to be stopped; or | ||
.3 | because the Owner has not made payment on a Certificate for Payment within the time stated in the Contract Documents; provided, however, if Owner is disputing the payment in good faith, Contractor shall not have the right to terminate the Contract for nonpayment. If such a dispute is resolved and Owner fails to make the payment in the manner agreed to by the parties in the resolution, Contractor shall have the right to terminate the Contract for nonpayment as set forth herein. | ||
.4 | the Owner has failed to furnish to the Contractor promptly, upon the Contractor’s request, reasonable evidence as required by Section 2.2.1. |
.1 | refuses or fails to supply enough properly skilled workers or proper materials except in cases where an extension of time is provided under the Contract Documents; | ||
.2 | fails to make payment to Subcontractors for materials or labor in accordance with the respective agreements between the Contractor and the Subcontractors; | ||
.3 | disregards any material laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction; | ||
.4 | otherwise fails to comply with a material provision of the Contract Documents; | ||
.5 | if Contractor should be adjudged bankrupt, file or suffer to be filed a petition for relief under the Bankruptcy Act, or make a general assignment for the benefit of creditors; or | ||
.6 | if a receiver should be appointed on account of Contractor’s insolvency. |
.1 | take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor; |
Page 48 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
.2 | accept assignment of subcontracts pursuant to Article 5 herein; and | ||
.3 | finish the Work by whatever reasonable method the Owner may deem expedient including requiring that Contractor’s surety within 30 days of the written notice described herein, immediately proceed with completion of the Work. Upon request of the Contractor, the Owner shall furnish to the Contractor a detailed accounting of the costs incurred by the Owner in finishing the Work. |
.1 | that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Contractor is responsible; or | ||
.2 | that an equitable adjustment is made or denied under another provision of the Contract. |
.1 | cease operations as directed by the Owner in the notice vacate the site and remove all of Contractor’s equipment and materials; | ||
.2 | take actions necessary, or that the Owner may direct, for the protection and preservation of the Work; and | ||
.3 | except for Work directed to be performed prior to the effective date of termination stated in the notice, and except for subcontracts to be assigned to Owner pursuant to Article 5 herein, terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders. |
Page 49 of 50
Project:HIGHLAND CORPORATE PARK
SKECHERS DISTRIBUTION CENTER
Trade:GENERAL CONTRACTOR
Page 50 of 50