COMMITMENTS AND CONTINGENCIES | NOTE 11 — COMMITMENTS AND CONTINGENCIES Mt. Hope Project The Mt. Hope Project is owned/leased and will be operated by the LLC under the LLC Agreement. The LLC currently has a lease (“Mt. Hope Lease”) with Mount Hope Mines, Inc. (“MHMI”) for a period of 30 years from October 19, 2005 and for so long thereafter as operations are being conducted on the property. The lease may be terminated earlier at the election of the LLC, or upon a material breach of the agreement and failure to cure such breach. If the LLC terminates the lease, termination is effective 30 days after receipt by MHMI of written notice to terminate the Mt. Hope Lease and no further payments would be due to MHMI. If MHMI terminates the lease, termination is effective upon receipt of a notice of termination due to a material breach, representation, warranty, covenant or term contained in the Mt. Hope Lease and followed by failure to cure such breach within 90 days of receipt of a notice of default. MHMI may also elect to terminate the Mt. Hope Lease if the LLC has not cured the non-payment of obligations under the lease within 10 days of receipt of a notice of default. In order to maintain the Lease Agreement, the LLC must pay certain minimum advance royalties as discussed below. The Mt. Hope Lease requires a royalty advance (“Construction Royalty Advance”) of 3% of certain construction capital costs, as defined in the Mt. Hope Lease. The LLC is obligated to pay a portion of the Construction Royalty Advance each time capital is raised for the Mt. Hope Project based on 3% of the expected capital to be used for those certain construction capital costs defined in the Mt. Hope Lease. Through March 31, 2020, we have paid $26.1 million of the total royalty advance. Based on our Mt. Hope Project capital budget we estimate that a final reconciliation payment on the Capital Construction Cost Estimate (the “Estimate”) will be due following the commencement of commercial production, after as-built costs are definitively determined. The Company estimates, based on the revised capital estimate discussed above and the current timeline for the commencement of commercial production, that an additional $5.4 million will be due approximately 24 months after the commencement of construction. This amount has been accrued for all periods presented as accrued advance royalties. The capital estimates may be subject to escalation in the event the Company experiences continued delays in achieving full financing for the Mt. Hope Project. The LLC is also obligated to make a minimum annual advance royalty payment (“Annual Advance Royalty”) of $0.5 million each October 19 for any year wherein commercial production has not been achieved or the MHMI Production Royalty (as hereinafter defined) is less than $0.5 million. As commercial production is not anticipated to commence before early-2022, the Company has accrued $2.0 million in Annual Advance Royalty payments which will be due in four $0.5 million installments in October 2020, 2021, 2022, and 2023 respectively. The Estimate and the Annual Advance Royalty are collectively referred to as the “Advance Royalties.” All Advance Royalties are credited against the MHMI Production Royalties once the mine has achieved commercial production. After the mine begins production, the LLC estimates that the MHMI Production Royalties will be in excess of the Annual Advance Royalties for the life of the Mt. Hope Project. Until the advance royalties are fully credited, the LLC will pay one half of the calculated Production Royalty annually. Assuming a $12 molybdenum price, the Annual Advance Royalties will be consumed within the first five years of commercial production. On February 28, 2018, the LLC) and MHMI entered into a Second Amendment dated effective January 15, 2018 (the “Lease Amendment”), to the Mt. Hope Lease. The Lease Amendment provides that following commencement of commercial production of any non- molybdenum minerals at the Mt. Hope Project, the LLC will pay a production royalty to MHMI as follows: · For zinc, the production royalty shall be equal to (i) 4.0% of net returns when the average gross value for the calendar quarter is less than or equal to $2.00 per pound; (ii) 4.5% of net returns when the average gross value is between $2.01 and $2.49 per pound; and (iii) 5.0% of net returns when the average gross value is $2.50 per pound or greater; and · For all other non-molybdenum minerals, the production royalty shall be equal to 4.0% of net returns. If commercial production of non-molybdenum minerals commences before commercial production of molybdenum, the Lease Amendment provides that the LLC’s obligation to pay the annual advance royalty under the Mt. Hope Lease will continue until the LLC has paid MHMI an aggregate of $3 million in non-moly production royalties in a three-year period. After this threshold is met, then payment of the advance royalty may be deferred in whole or in part if the non-moly production royalty exceeds specified levels. After non-moly production royalties have exceeded $10,000,000, future payments may be credited against future production royalties under certain circumstances. Additionally, Exxon Corporation will receive a perpetual 1% royalty interest in and to all ores, metals, minerals and metallic substances mineable or recoverable from the Mt. Hope Project in kind at the mine or may elect to receive cash payment equal to 1% of the total amount of gross payments received from the purchaser of ores mined/removed/sold from property net of certain deductions. The Liberty Project Liberty Moly continues to work with the Nevada Division of Environmental Protection (“NDEP”) to address environmental concerns with some Liberty Project facilities acquired with the property. We have implemented remedial treatment of the Liberty pit lake and developed and implemented procedures to manage process solutions draining from the pre-existing leach pad, as required by NDEP. We may be required to treat the pit lake again, and/or revise our systems to manage heap leach solution. At this time we are working with NDEP to reasonably estimate the scope and costs of addressing these issues.. Deposits on project property, plant and equipment As discussed in Note 1, the LLC has active orders with varying stages of fabrication on milling process equipment comprised of two 230kV primary transformers and substation, a primary crusher, a semi-autogenous mill, two ball mills, and various motors for the mills with remaining cash commitments of $0.6 million due on these orders. Equipment and Supply Procurement Through March 31, 2020, the LLC has made deposits and/or final payments of $88.0 million on equipment orders and has spent approximately $208.9 million for the development of the Mt. Hope Project, for a total Mt. Hope Project inception-to-date spend of $298.9 million. In 2012, the LLC issued a firm purchase order for eighteen haul trucks. The order provides for delivery of those haul trucks required to perform initial mine development, which will begin several months prior to commercial production. Non-refundable down-payments of $1.2 million were made in 2012, with pricing subject to escalation as the trucks were not delivered prior to December 31, 2013. Since that time, the LLC has renegotiated the timelines for truck delivery and delayed deliveries into December 2020. The contract is cancellable with no further liability to the LLC. Also in 2012, the LLC issued a firm purchase order for four mine production drills with a non-refundable down-payment of $0.4 million, and pricing was subject to escalation if the drills were not delivered by the end of 2013. Since that time, the LLC accepted a change order which delayed delivery into December 2020. The contract remains cancellable with no further liability to the LLC. On June 30, 2012, the LLC’s contract to purchase two electric shovels expired. On July 11, 2012, we signed a letter of intent with the same vendor providing for the opportunity to purchase the electric shovels at prices consistent with the expired contract, less a special discount in the amount of $3.4 million to provide credit to the LLC for amounts paid as deposits under the expired contract. The letter of intent provides that equipment pricing will remain subject to inflation indexes and guarantees production slots to ensure that the equipment is available when required by the LLC. Since that time, the parties agreed to extend the letter of intent through December 31, 2020. Obligations under capital and operating leases We have contractual operating leases that will require a total of $0.1 million in payments over the next three years. Operating leases consist primarily of rents on office facilities and office equipment. Our expected payments are $0.1 million, nil, and nil for the years ended December 31, 2020, 2021, and 2022, respectively. Creation of Agricultural Sustainability Trust On August 19, 2010, the LLC entered into an agreement with the Eureka Producers’ Cooperative (“EPC”), which was amended on October 15, 2018, whereby the LLC will fund a $5.6 million Sustainability Trust (“Trust”) in exchange for the cooperation of the EPC with respect to the LLC’s water rights and permitting of the Mt. Hope Project. The Trust will be tasked with developing and implementing programs that will serve to enhance the sustainability and well-being of the agricultural economy in the Diamond Valley Hydrographic Basin through reduced water consumption. The LLC has contributed $0.1 million into the Trust as of March 31, 2020. The remaining contributions to the Trust may be funded by the LLC over several years based on the achievement of certain milestones, which are considered probable, and as such $5.5 million has been accrued in the Company’s financial statements and is included in mining properties, land, and water rights. Permitting Considerations In the ordinary course of business, mining companies are required to seek governmental permits for expansion of existing operations or for the commencement of new operations. The LLC is required to obtain approval, in the form of a Record of Decision (“ROD”), from the BLM to implement the Mt. Hope Project Plan of Operations (“PoO”). The LLC is also required to obtain various state and federal permits including, but not limited to, water protection, air quality, water rights and reclamation. In addition to requiring permits for the development of the Mt. Hope Project, we will need to obtain and modify various mining and environmental permits during the life of the Mt. Hope Project. Maintaining, modifying, and renewing the necessary governmental permits is a complex and time-consuming process involving numerous jurisdictions and often involving public hearings and substantial expenditures. The duration and success of the LLC’s efforts to obtain, modify or renew permits will be contingent upon many variables, some of which are not within the LLC’s control. Increased costs or delays could occur, depending on the nature of the activity to be permitted and the interpretation of applicable requirements implemented by the permitting authority. All necessary permits may not be obtained and, if obtained, may not be renewed, or the costs involved in each case may exceed those that we previously estimated. In addition, it is possible that compliance with such permits may result in additional costs and delays. History of Record of Decision (ROD) On November 16, 2012, the BLM issued its initial ROD authorizing development of the Mt. Hope Project. The ROD was subsequently vacated by the U.S. Court of Appeals for the Ninth Circuit in December 2016, discussed below. Also, on April 23, 2015, the BLM issued a Finding of No Significant Impact (“FONSI”) supporting their Decision to approve an amendment to the PoO. The initial ROD and FONSI/Decision approved the PoO and amended PoO, respectively, for construction and operation of the mining and processing facilities and also granted the Right-of-Way, and amended Right-of-Way, respectively, for a 230kV power transmission line, discussed below. Monitoring and mitigation measures identified in the initial ROD and FONSI, developed in collaboration with the regulatory agencies involved throughout the permitting process, will avoid, minimize, and mitigate environmental impacts, and reflect the Company’s commitment to be good stewards of the environment. Ongoing changes to permits and the PoO during the life of mining operations are typical as design evolves and operations are optimized. On February 15, 2013, Great Basin Resource Watch and the Western Shoshone Defense Project (“Plaintiffs”) filed a Complaint against the U.S. Department of the Interior and the BLM (“Defendants”) in the U.S. District Court, District of Nevada (“District Court”), seeking relief under the National Environmental Policy Act (“NEPA”) and other federal laws challenging the BLM’s issuance of the initial ROD for the Mt. Hope Project, and on February 20, 2013 filed a Motion for Preliminary Injunction. The District Court allowed the LLC to intervene in the matter. On August 22, 2013, the District Court denied, without prejudice, Plaintiffs’ Motion for Preliminary Injunction based on a Joint Stipulation to Continue Preliminary Injunction Oral Argument, which advised the District Court that as a result of economic conditions, including the Company’s ongoing financing efforts, all major ground disturbing activities had ceased at the Mt. Hope Project. On July 23, 2014, the District Court denied Plaintiffs’ motion for summary judgment in its entirety and on August 1, 2014 the Court entered judgment in favor of the Defendants and the LLC, and against Plaintiffs regarding all claims raised in the Complaint. Thereafter, on September 22, 2014, the Plaintiffs filed their notice of appeal to the U.S. Court of Appeals for the Ninth Circuit (“Ninth Circuit”) of the District Court’s dismissal. Oral argument of the parties before the Ninth Circuit was completed on October 18, 2016. O n December 28, 2016, the Ninth Circuit issued its Opinion rejecting many of the arguments raised by the Plaintiffs challenging the Environmental Impact Statement ("EIS") completed for the Mt. Hope Project, but issued a narrow reversal of the BLM's findings related to air quality analysis and information related to potential public water resources. Because of this technical deficiency, the Court vacated the initial ROD. Re-Issuance of Record of Decision Approving Supplemental Environmental Impact Statement (“SEIS”) On remand to the BLM, the agency conducted additional evaluation of air quality impacts and resulting cumulative impact analysis under NEPA in preparation of a Supplemental Environmental Impact Statement (“SEIS”). The SEIS disclosed additional information to the public related to the selection of appropriate background concentrations to use for dispersion modeling of air pollutants and information related to potential public water reserves. Because the SEIS must be prepared in accordance with NEPA guidelines, the SEIS process included three publications in the Federal Register: the first was the Notice of Intent (“NOI”) which was published on July 19, 2017; the second, the Notice of Availability (“NOA”) of the Draft SEIS (“DSEIS”) was published on March 6, 2019; and on September 27, 2019, the third, an NOA of the final SEIS was published announcing that the BLM had re-issued the ROD marking completion of the NEPA process and approval of the SEIS. On October 31, 2019, a Complaint was filed against the U.S. Department of Interior and the BLM in the U.S. District Court in Nevada, challenging the re-issuance of the ROD. On March 11, 2020, the LLC filed its unopposed Motion to Intervene in the U.S. District Court on behalf of the Mt. Hope Project. The District Court approved the LLC’s intervention on March 19, 2020 and the LLC’s Answer to the Complaint was filed on March 20, 2020. The LLC will work closely with the BLM and DOI to defend the claims filed by Great Basin Resource Watch and Western Shoshone Defense Project. Reclamation Considerations Environmental regulations related to reclamation require that the cost for a third party contractor to perform reclamation activities on the minesite be estimated. In October 2015, we submitted a request to the BLM to reduce our reclamation liability to current surface disturbance. Simultaneously, we submitted an application to NDEP-BMRR to modify the Reclamation Permit to reflect this reduced reclamation liability. On October 26, 2015, NDEP-BMRR approved the proposed permit modification, including the reduced reclamation liability amount. On December 21, 2015, BLM approved the updated reclamation liability estimate, reducing of the reclamation liability to approximately $2.8 million. In early 2019, the Company submitted, and BLM approved a required 3-year update to the reclamation liability estimate, resulting in an increased liability of approximately $3.1 million. We worked with the LLC’s reclamation surety underwriters to satisfy the $2.8 million financial guarantee requirements under the approved amended PoO for the Mt. Hope Project and funded the $0.3 million increase in cash directly with the BLM in April 2019. As of March 31, 2020, the surety bond program was funded with a cash collateral payment of $0.3 million. Water Rights Considerations History of Mt. Hope Water Permits In July 2011, the Nevada State Engineer (“State Engineer”) initially approved our applications for new appropriation of water for mining and milling use, and applications to change existing water from agricultural use to mining and milling use for the Mt. Hope Project. Subsequently, the State Engineer granted water permits associated with the approved applications and approved a Monitoring, Management and Mitigation Plan (“3M Plan”) for the Mt. Hope Project. Eureka County, Nevada and two other parties comprised of water rights holders in Diamond Valley and Kobeh Valley appealed the State Engineer’s decision approving the applications and granting the water permits to the Nevada State District Court (“District Court”) and then filed a further appeal to the Nevada Supreme Court challenging the District Court’s decision affirming the State Engineer’s decision to approve the applications and grant the water permits. In June 2013, the appeal was consolidated by the Nevada Supreme Court with an appeal of the State Engineer’s approval of the 3M Plan filed by two water rights holders. The District Court previously upheld the State Engineer’s approval of the 3M Plan and the two parties subsequently appealed the District Court’s decision to the Nevada Supreme Court. On September 18, 2015, the Nevada Supreme Court issued an Order that reversed and remanded the cases to the District Court for further proceedings consistent with the Order. On October 29, 2015, the Nevada Supreme Court issued the Order as a published Opinion. The Nevada Supreme Court ruled that the State Engineer did not have sufficient evidence in the record at the time he approved the applications and granted the water permits to demonstrate that successful mitigation may be undertaken so as to dispel the threat to existing water rights holders. On September 27, 2017, the Nevada Supreme Court affirmed a March 4, 2016 District Court Order vacating the 3M Plan, denying the water applications and vacating the permits issued by the State Engineer in July 2011 and June 2012. This decision of the Nevada Supreme Court was final, and not subject to further appeal. New Change Applications for Water Use at Mt. Hope Project After the Company received the September 2017 decision from the Nevada Supreme Court, it proceeded with new applications to change existing agricultural irrigation and mining/milling water rights owned by the Company to use at the Mt. Hope Project. These new change applications had been filed with the State Engineer in 2015 and 2016 while the above described appeals were pending before the Nevada Supreme Court. Originally, these applications and other new appropriation applications were to be addressed at a pre-hearing conference scheduled on August 25, 2016 before the State Engineer. These applications were the subject of a Writ of Prohibition or Mandamus (“Writ”) filed by Eureka County on August 23, 2016 to the Nevada Supreme Court seeking the Supreme Court’s intervention to stop further action by the State Engineer while the appeals discussed above were pending. On December 22, 2017 the Nevada Supreme Court denied Eureka County’s Writ Petition. As a result, the State Engineer allowed a pre-hearing conference held on January 24, 2018. At the pre-hearing conference the State Engineer and his hearing officer scheduled review of the new change applications for a September 11, 2018 hearing in Carson City, Nevada. On January 2, 2018, Eureka County, and later joined by the other two protestants representing a rancher in Kobeh Valley and a ranching group in Diamond Valley, filed a motion to dismiss with the State Engineer asserting that our applications were precluded from review and approval asserting that they were repetitive of the applications denied previously by the Nevada Supreme Court in its September 2017 decision. On March 26, 2018, the State Engineer issued a non-final order denying the motion to dismiss finding that the applications to be reviewed at the upcoming hearing were not identical issues and that further consideration of the motion could be taken at the hearing. On May 14, 2018, Eureka County, joined by the other protestants filed a Writ to the Nevada Supreme Court and later a Motion to Stay the September hearing date, asserting that the denial of the Motion to Dismiss was erroneous and that the Nevada Supreme Court should order that the applications be denied and/or the September 2018 hearing should be delayed until the Nevada Supreme Court can consider the Writ and underlying motion to dismiss. The Company filed its objection on June 27, 2018, and on August 30, 2018, the Nevada Supreme Court denied the Writ, permitting the September 2018 hearing before the Nevada State Engineer to proceed. On the second day of the September hearing, all protest issues raised by Eureka County and the Diamond Natural Resources Protections & Conservation Association (“DNR”) concerning the Mt. Hope water rights applications were resolved through a Stipulation, Settlement Agreement and Withdrawal of Protest (“Settlement”). After Eureka County and DNR were excused, the hearing continued with evidence addressing concerns raised by another protestant representing a Kobeh Valley ranching family and cattle company that refused to participate in the Settlement. At the public hearing, the Company presented expert testimony in support of its augmentation and monitoring plan to the Nevada State Engineer, which will protect senior water rights in the Kobeh Valley basin when the Company commences construction and operation of its proposed Mt. Hope molybdenum project near the town of Eureka, Nevada. The hearing concluded on September 21, 2018. Effective April 30, 2019, the Company, through its wholly owned subsidiary Kobeh Valley Ranch LLC (“KVR”) entered into a settlement agreement with a Kobeh Valley, Nevada ranching family (“Ranchers”), resolving the last set of protests pending before the Nevada State Engineer pertaining to the Mt. Hope Project’s water rights applications. On June 6, 2019, the Nevada State Engineer issued Ruling 6464 granting the Company’s water rights applications for mining purposes. The water right permits for the Mt. Hope Project were issued on July 24, 2019. With receipt of and in compliance with the terms of the water permits, the water is available for consumptive use at the Mt. Hope Project. Neither the issuance of Ruling 6464 nor the issuance of the water permits were challenged, and the deadline for filing any appeal has expired. Key Terms of Settlements Eureka County and the DNR Under the terms of the Settlement with Eureka County and the DNR, the Company and the LLC agreed to convey all related water rights for Mt. Hope Project at the future cessation of all mining activity to assist Eureka County and the DNR’s efforts to mitigate the pre-existing effects of agricultural groundwater pumping in Diamond Valley. Furthermore, upon construction of certain power infrastructure and grants of right of way by the LLC at the Mt. Hope Project, the Company and the LLC will work cooperatively with Eureka County to allow use of and access to such infrastructure to lessen the pre-existing effects of Diamond Valley groundwater pumping. Eureka County, and the Company and the LLC, also agreed to work cooperatively to seek opportunities to improve and implement groundwater monitoring efforts. In addition, the Company withdrew its protests to Eureka County’s pending applications with the Nevada State Engineer to appropriate water from the Kobeh Valley basin, and at the request of DNR, the Company also agreed to publicly support the proposed Diamond Valley Ground Water Management Plan currently pending before the Nevada State Engineer. With receipt of the water permits, the LLC increased its financial contributions to the existing Agricultural Sustainability Trust Agreement, discussed above, with the Eureka Producers’ Cooperative (“EPC”) in Diamond Valley with an additional $50,000 to EPC. Initially, upon execution of the Settlement, the LLC made a payment of $50,000. The LLC will make additional contributions of $750,000 each after the commencement of molybdenum production at the Mt. Hope Project and on the one-year anniversary of production, for a total contribution obligation to the Sustainability Trust of $5.6 million, an increase of $1.6 million related to the terms of the Settlement. The amount has been accrued under mining properties, land, and water rights in the Company’s financial statements in addition to the previously accrued $4.0 million resulting in a total accrual of $5.6 million. The LLC has contributed $0.1 million into the Trust as of December 31, 2019. The Sustainability Trust is tasked with developing and implementing programs that will serve to slow groundwater drawdown and thereby improve the sustainability of the agricultural economy in the Diamond Valley Hydrographic Basin. Kobeh Valley Ranching Family At the execution of the settlement agreement, the LLC funded an initial payment of $1 million into a trust account; distribution to the Ranchers occurred when the water permits were issued on July 24, 2019. Upon receipt of the initial $1,000,000 into the trust account, the Ranchers withdrew their protests and forfeited any judicial review of Ruling 6464 and the water applications and issuance of the water permits issued on July 24, 2019 by the Nevada State Engineer. When conditions exist for the LLC to secure project financing, additional consideration of $14,000,000 will be payable to the Ranchers. If the LLC has not secured Mt. Hope Project financing within 12 months of the executed settlement agreement or April 2020, the LLC will begin to make monthly payments of $10,000 to the Ranchers until financing is achieved and the remaining consideration will be paid to the Ranchers. Pursuant to an April 29, 2019 Consent Agreement, the members of the LLC agreed that funding for the $1 million was advanced to the LLC by the Company, to preserve the joint venture’s existing reserve account. General Moly sourced $500,000 from its available cash, and received the remaining $500,000 from closing a sale of Series A Convertible Preferred Shares in a private placement with Mount Hope Mines Inc. (“MHMI”), the Mt. Hope Project’s claim/land lessor, discussed in Items 1 and 2 above and later in Note 7 to the consolidated financial statements contained elsewhere in this report. In exchange for General Moly advancing the $1,000,000 initial settlement funding, the LLC members have agreed to repay the $1 million advance from the proceeds of ongoing sales of non-critical LLC assets and lands. On September 27, 2019, the Company and POS-Minerals entered into a further Consent Agreement for a reimbursement schedule concerning the approximately $700,000 owed to the Company by the LLC in return for the Company’s advance of funding to settle protests related to the water right applications for the Mt. Hope Project. Under the September Consent Agreement, $200,000 was reimbursed from the Reserve Account to the Company on September 30, 2019 and an additional $200,000 was reimbursed in early November. The remaining approximately $300,000 was reimbursed in March 2020 upon the sale by the LLC of more than $400,000 in non-critical Mt. Hope Project related equipment. The Company and POS-Minerals agreed in the Consent Agreement that all funds received from the future sale of other assets owned by the LLC are owed to the Reserve Account until the March 31, 2020 balance of $0.7 million is repaid. Environmental Considerations Our former mineral property holdings in Shoshone County, Idaho included lands contained in mining districts that have been designated as a “Superfund Site” pursuant to the Comprehensive Environmental Response, Compensation, and Liability Act. This “Superfund Site” was established to investigate and remediate primarily the Bunker Hill properties of Smelterville, Idaho, a small portion of Shoshone County where a large smelter was located. However, because of the extent of environmental impact caused by the historical mining in the mining district, the Superfund Site covers the majority of Shoshone County including our former Chicago-London and Little Pine Creek properties as well as many small towns located in Northern Idaho. We have conducted a property environmental investigation of these properties, which revealed no evidence of material adverse environmental effects at either property. We are unaware of any pending action or proceeding relating to any regulatory matters that would affect our financial position due to these inactive mining claims in Shoshone County. Our Chicago-London property was sold in January 2020 and Little Pine Creek in 2019. |