Unapproved Change Orders, and Claims, Against Clients and Estimated Recoveries of Claims Against Suppliers and Subcontractors | Unapproved Change Orders, and Claims, Against Clients and Estimated Recoveries of Claims Against Suppliers and Subcontractors The amounts of unapproved change orders, and claims against clients and estimated recoveries of claims against suppliers and subcontractors included in determining the profit or loss on contracts are as follows: Dollars in millions 2019 2018 Amounts included in project estimates-at-completion at January 1, $ 973 $ 924 Increase, including foreign currency effect 11 10 Approved change orders, net of foreign currency effect (5 ) (1 ) Amounts included in project estimates-at-completion at June 30, $ 979 $ 933 Amounts recognized over time based on progress at June 30, $ 966 $ 887 As of June 30, 2019 , the predominant component of the change orders, customer claims and estimated recoveries of claims against suppliers and subcontractors above relates to our 30% proportionate share of unapproved change orders and claims associated with the Ichthys LNG Project discussed below. KBR intends to vigorously pursue approval and collection of amounts still due under all unapproved change orders and claims, against the clients and recoveries from subcontractors. Further, there are additional claims that KBR believes it is entitled to recover from its client and from subcontractors which have been excluded from estimated revenues and profits at completion as appropriate under U.S. GAAP. These commercial matters may not be resolved in the near term. Our current estimates for the above unapproved change orders, client claims and estimated recoveries of claims against suppliers and subcontractors may prove inaccurate and any material change could have a material adverse effect on our results of operations, financial position and cash flows. Ichthys LNG Project Project Status We have a 30% ownership interest in the JKC joint venture, which has contracted to perform the engineering, procurement, supply, construction and commissioning of onshore LNG facilities for a client in Darwin, Australia (the "Ichthys LNG Project"). The contract between JKC and its client is a hybrid contract containing both cost-reimbursable and fixed-price (including unit-rate) scopes. The construction and commissioning of the Ichthys LNG Project is substantially complete and the plant is producing LNG. All of the components of the plant, except for the combined cycle power plant ("Power Plant"), have been completed and handed over to the client. The Power Plant includes five gas turbine generators which are complete and handed over to the client, and three steam turbine generators (the "STGs") which are currently forecasted to be completed in 2019. We expect commissioning and hand-over of the STGs to be completed by mid-2019. Unapproved Change Orders and Claims Against Client Under the cost-reimbursable scope of the contract with the client, JKC has entered into commercial contracts with multiple suppliers and subcontractors to execute various scopes of work on the project. Certain of these suppliers and subcontractors have made contract claims against JKC for recovery of costs and extensions of time to progress the works under the scope of their respective contracts due to a variety of issues related to alleged changes to the scope of work, delays and lower than planned subcontractor productivity. In addition, JKC has incurred costs related to scope increases and other factors, and has made claims to its client for matters for which JKC believes it is entitled to reimbursement under the contract. JKC believes any amounts paid or payable to the suppliers and subcontractors in settlement of their contract claims related to the cost-reimbursable scope are an adjustment to the contract price, and accordingly JKC has made claims for contract price adjustments under the cost-reimbursable scope of the contract between JKC and its client. However, the client disputed some of these contract price adjustments and subsequently withheld certain payments. In order to facilitate the continuation of work under the contract while we worked to resolve this dispute, the client agreed to a contractual mechanism (“Funding Deed”) in 2016 providing funding in the form of an interim contract price adjustment to JKC and consented to settlement of subcontractor claims as of that date related to the cost-reimbursable scope. While the client has reserved its contractual rights under this funding mechanism, settlement funds (representing the interim contract price adjustment) have been paid by the client. JKC in turn settled these subcontractor claims which have been funded through the Funding Deed by the client. If JKC's claims against its client which were funded under the Funding Deed remain unresolved by December 31, 2020, JKC will be required to refund sums funded by the client under the terms of the Funding Deed. We, along with our joint venture partners, are jointly and severally liable to the client for any amounts required to be refunded. Our proportionate share of the total amount of the contract price adjustments under the Funding Deed included in the unapproved change orders and claims related to our unconsolidated affiliates discussed above was $159 million as of June 30, 2019 and December 31, 2018 . In September and October 2017, additional settlements pertaining to suppliers and subcontractors under the cost-reimbursable scope of the contract were presented to the client. The client consented to these settlements and paid for them but reserved its contractual rights. In reliance, JKC in turn settled these claims with the associated suppliers and subcontractors. The formal contract price adjustments for these settlements remained pending at June 30, 2019 . However, unlike amounts funded under the Funding Deed, there is no requirement to refund these amounts to the client by a certain date. In October 2018, JKC received a favorable ruling from an arbitration tribunal. The ruling determined a contract interpretation in JKC's favor, to the effect that delay and disruption costs payable to subcontractors under the cost-reimbursable scope of the EPC contract are for the client's account and are reimbursable to JKC. JKC contends this ruling resolves the reimbursability of the subcontractor settlement sums under the Funding Deed and additional settlements made in September and October 2017. Pursuant to this decision, JKC is undertaking steps for a formal contract adjustment to the cost-reimbursable scope of the contract for these settlement claims which are included in the recognized unapproved change orders as of June 30, 2019 . Our view is that the arbitration ruling resolves our obligations under the Funding Deeds and settlements with reimbursable subcontractors. However, the client does not agree with the impact of the arbitration award and, accordingly, we have initiated a new proceeding to obtain further determination from the arbitration tribunal. There has been deterioration of paint and insulation on certain exterior areas of the plant. The client previously requested and funded, paint remediation for a portion of the facilities. JKC’s profit estimate at completion includes a portion of revenues and costs for these remediation activities. Revenue for the client-funded amounts are included in the table above. In the first quarter of 2019, the client demanded repayment of the amounts previously funded to JKC. JKC is disputing the client's demand. The client has also requested a proposal to remediate any remaining non-conforming paint and insulation, but JKC and its client have not resolved the nature and extent of the non-conformances, the method and degree of remediation that was and is required, or who is responsible. We believe the remaining remediation costs could be material given the plant is now operating and there will be several operating constraints on any such works. In addition, JKC has started proceedings against the paint manufacturer and initiated claims against the subcontractors. JKC has also made demands on insurance policies in respect of these matters. Proceedings and claims against the paint manufacturer, certain subcontractors and insurance policies are ongoing. Combined Cycle Power Plant Pursuant to JKC's fixed-price scope of its contract with its client, JKC awarded a fixed-price EPC contract to a subcontractor for the design, construction and commissioning of the Power Plant. The subcontractor was a consortium consisting of General Electric and GE Electrical International Inc. and a joint venture between UGL Infrastructure Pty Limited and CH2M Hill (collectively, the "Consortium"). On January 25, 2017, JKC received a Notice of Termination from the Consortium, and the Consortium ceased work on the Power Plant and abandoned the construction site. JKC believes the Consortium materially breached its subcontract and repudiated its obligation to complete the Power Plant, plus undertook actions making it more difficult and more costly for the works to be completed by others after the Consortium abandoned the site. Subsequently, the Consortium filed a request for arbitration with the ICC asserting that JKC repudiated the contract. The Consortium also sought an order that the Consortium validly terminated the subcontract. JKC has responded to this request, denying JKC committed any breach of its subcontract with the Consortium and restated its claim that the Consortium breached and repudiated its subcontract with JKC and is furthermore liable to JKC for all costs to complete the Power Plant. In March 2017, JKC prevailed in a legal action against the Consortium requiring the return of materials, drawings and tools following their unauthorized removal from the site by the Consortium. After taking over the work, JKC discovered incomplete and defective engineering designs, defective workmanship on the site, missing, underreported and defective materials; and the improper termination of key vendors/suppliers. JKC's investigations also indicate that progress of the work claimed by the Consortium was over-reported. JKC has evaluated the cost to complete the Consortium's work, which significantly exceeds the awarded fixed-price subcontract value. JKC's cost to complete the Power Plant includes re-design efforts, additional materials and significant re-work. These costs represent estimated recoveries of claims against the Consortium and have been included in JKC's estimate to complete the Consortium's remaining obligations. JKC is pursuing recourse against the Consortium to recover all of the costs to complete the Power Plant, plus the additional interest, and/or general damages by all means inclusive of calling bank guarantees provided by the Consortium partners. In April 2018, JKC prevailed in a legal action to call bank guarantees (bonds) and received funds totaling $52 million . Each of the Consortium partners has joint and several liability with respect to all obligations under the subcontract. JKC intends to pursue recovery of all additional amounts due from the Consortium via various legal remedies available to JKC. Estimated costs to complete the Power Plant that have been determined to be probable of recovery from the Consortium under U.S. GAAP have been included as a reduction of cost in our estimate of profit at completion. The estimated recoveries exclude interest, liquidated damages and other related costs which JKC intends to pursue recovery from the Consortium. Amounts expected to be recovered from the Consortium are included in the table above. As of June 30, 2019 , JKC claims against the Consortium were approximately $1.9 billion for recovery of JKC's costs. An arbitration hearing against the Consortium is scheduled in the first half of 2020 (the "Arbitration"). JKC also initiated suit against the parent companies of the Consortium members to seek a declaration that the parents either had to perform and finish the work or pay for the completion of the power plant based on their payment and performance guarantees. In May 2019, the court ruled against the declaration and JKC's appeal is pending from the court. To the extent JKC is unsuccessful in prevailing in the Arbitration or the Consortium members are unable to satisfy their financial obligations in the event of a decision favorable to JKC, we would be responsible for our pro-rata portion of unrecovered costs from the Consortium. This could have a material adverse impact on the profit at completion of the overall contract and thus on our consolidated statements of operations, financial position and planned cash flows. Additionally, to the extent JKC does not resolve this matter with the Consortium in the near term, the joint venture partners have been and will continue to be required to fund JKC's completion of the Power Plant which could have a material adverse effect on our financial position and cash flows. Ichthys Project Funding As a result of the ongoing disputes with the client and pursuit of recoveries against the Consortium through the Arbitration, we have funded and continue to fund our proportionate share of the working capital requirements of JKC to complete the project. During the year ended December 31, 2018, we made investment contributions to JKC of approximately $344 million to fund the ongoing project execution activities. During the six months ended June 30, 2019 , we made additional investment contributions to JKC of approximately $126 million to fund the ongoing project execution activities. Our projection of total investment contributions to complete the project is approximately $500 million . If our estimates to complete the project increase, or if we experience unfavorable outcomes associated with the various legal and commercial disputes, our projection of total investment contributions could increase which could have a material adverse effect on our financial position and cash flows. Further, if our joint venture partner(s) in JKC do not fulfill their responsibilities under the JKC JV agreement or subcontract, we could be exposed to additional funding requirements as a result of the nature of the JKC JV agreement. As of June 30, 2019 , we had $164 million in letters of credit outstanding in support of performance and warranty guarantees provided to the client. The performance letter of credit expires upon provisional acceptance of the facility by the client and the warranty letter of credit expires upon the end of the warranty obligation. Other Matters JKC is entitled to an amount of profit and overhead (“TRC Fee”) which is a fixed percentage of the target reimbursable costs ("TRC") under the reimbursable component of the contract which was to be agreed by JKC and its client. At the time of the contract, JKC and its client agreed to postpone the fixing of the TRC until after a specific milestone in the project had been achieved. Although the milestone was achieved, JKC and its client have been unable to reach agreement on the TRC. This matter was taken to arbitration in 2017. A decision was issued in December 2017 concluding that the TRC should be determined based on project estimate information available at April 2014. JKC has included an estimate for the TRC Fee in its determination of profit at completion at June 30, 2019 , based on the contract provisions and the decision from the December 2017 arbitration. JKC has submitted the revised estimate of the TRC Fee to the client. The parties have not agreed to the revised estimate, and JKC has started an additional arbitration on this dispute. All of the Ichthys LNG project commercial matters are complex and involve multiple interests, including the client, suppliers and other third parties. Ultimate resolution may not occur in the near term. Our current estimates for resolving these matters may prove inaccurate and, if so, any material change could have a material adverse effect on our results of operations, financial position and cash flows. See Note 10 to our condensed consolidated financial statements for further discussion regarding our equity method investment in JKC. |