TerraForm Global 10-Q 31 Jan 17 2016 Q2 Quarterly report Financial data

Document and Entity Information

Document and Entity Information - shares	6 Months Ended
	Jun. 30, 2016	Dec. 31, 2016
Document Information [Line Items]
Entity Registrant Name	TerraForm Global, Inc.
Entity Central Index Key	1,620,702
Current Fiscal Year End Date	--12-31
Entity Filer Category	Accelerated Filer
Document Type	10-Q
Document Period End Date	Jun. 30, 2016
Document Fiscal Year Focus	2,016
Document Fiscal Period Focus	Q2
Amendment Flag	false
Common Class A
Document Information [Line Items]
Entity Common Stock, Shares Outstanding		113,228,527
Common Class B
Document Information [Line Items]
Entity Common Stock, Shares Outstanding		61,343,054
Common Class B1
Document Information [Line Items]
Entity Common Stock, Shares Outstanding		0

Unaudited Condensed Consolidate

Unaudited Condensed Consolidated Statements of Operations - USD ($) shares in Thousands, $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015
Income Statement [Abstract]
Operating revenues, net	$ 56,430	$ 25,681	$ 104,116	$ 43,487
Operating costs and expenses:
Cost of operations	7,114	2,751	12,316	3,109
Cost of operations - affiliate	4,683	1,369	9,713	2,333
General and administrative	(1,740)	2,931	1,207	7,417
General and administrative - affiliate	15,965	3,852	23,202	6,819
Acquisition, formation and related costs	83	13,683	10,088	13,683
Depreciation, accretion and amortization	13,025	3,336	27,597	6,071
Total operating costs and expenses	39,130	27,922	84,123	39,432
Operating income (loss)	17,300	(2,241)	19,993	4,055
Other expense (income):
Loss (gain) on the extinguishment of debt	526	1,219	(5,735)	1,219
Interest expense, net	28,975	28,186	62,638	45,007
Gain on previously held equity investment	0	(1,426)	0	(1,426)
Gain on foreign currency exchange	(13,882)	(6,686)	(26,231)	(6,974)
Other income, net	(6,061)	(187)	(13,031)	(317)
Total other expenses, net	9,558	21,106	17,641	37,509
Income (loss) before income tax expense	7,742	(23,347)	2,352	(33,454)
Income tax expense (benefit)	2,061	(668)	2,919	450
Net income (loss)	5,681	$ (22,679)	(567)	$ (33,904)
Less: gain attributable to non-controlling interests	4,584		2,968
Net income (loss) attributable to TerraForm Global, Inc. Class A common stockholders	$ 1,097		$ (3,535)
Weighted average number of shares:
Class A common stock - Basic and diluted (in shares)	106,856		106,856
Earnings (loss) per share:
Class A common stock - Basic and diluted (in usd per share)	$ 0.01		$ (0.03)

Unaudited Condensed Consolidat3

Unaudited Condensed Consolidated Statements of Comprehensive Loss - USD ($) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015
Statement of Comprehensive Income [Abstract]
Net loss	$ 5,681	$ (22,679)	$ (567)	$ (33,904)
Other comprehensive income (loss):
Net foreign currency translation adjustments	34,225	(2,338)	38,782	2,139
Net unrealized gain (loss) on hedging instruments	2,139	(4,147)	(12,324)	(4,250)
Other comprehensive income (loss), net of tax	36,364	(6,485)	26,458	(2,111)
Total comprehensive income (loss)	42,045	(29,164)	25,891	(36,015)
Less: Predecessor comprehensive loss prior to initial public offering on August 5, 2015	0	(29,164)	0	(36,015)
Comprehensive income subsequent to initial public offering	42,045	$ 0	25,891	$ 0
Less: Comprehensive income attributed to non-controlling interest:
Net income	4,584		2,968
Net foreign currency translation adjustments	13,453		15,285
Net unrealized gain (loss) on hedging instruments	1,433		(8,249)
Comprehensive income attributed to non-controlling interest	19,470		10,004
Comprehensive income attributed to Class A common stockholders	$ 22,575		$ 15,887

Unaudited Condensed Consolidat4

Unaudited Condensed Consolidated Balance Sheets - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Current assets:
Cash and cash equivalents	$ 870,494	$ 922,318
Current portion of restricted cash, including consolidated variable interest entities of $61,590 in June 30, 2016 and $46,321 in December 31, 2015	72,264	119,151
Accounts receivable, net	41,931	30,287
Prepaid expenses and other current assets, including consolidated variable interest entities of $100,411 in June 30, 2016 and $123,876 in December 31, 2015	117,841	139,335
Total current assets	1,102,530	1,211,091
Power plants, net, including consolidated variable interest entities of $461,067 in June 30, 2016 and $460,042 in December 31, 2015	1,375,254	1,206,604
Restricted cash	18,003	22,682
Intangible assets, net, including consolidated variable interest entities of $51,362 in June 30, 2016 and $51,159 in December 31, 2015	70,054	70,630
Equity method investment	0	73,249
Deposit for acquisitions, net	49,733	51,101
Other assets	40,211	51,809
Total assets	2,655,785	2,687,166
Current liabilities:
Current portion of long-term debt, including consolidated variable interest entities of $333,144 in June 30, 2016 and $326,535 in December 31, 2015	324,225	319,498
Accounts payable	23,555	8,491
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015	111,305	129,437
Due to Sun Edison, net	29,326	44,254
Total current liabilities	488,411	501,680
Long-term debt, less current portion	888,082	952,653
Asset retirement obligations	10,855	8,629
Other long-term liabilities	8,044	1,455
Deferred tax liabilities, including consolidated variable interest entities of $38,615 in June 30, 2016 and $37,295 in December 31, 2015	43,494	39,482
Total liabilities	1,438,886	1,503,899
Stockholders’ Equity:
Preferred stock, par value $0.01 per share, 50,000,000 shares authorized, no shares issued and outstanding at June 30, 2016 or December 31, 2015	0	0
Treasury stock	(28)	(28)
Additional paid-in capital	935,492	923,740
Accumulated deficit	(215,664)	(212,129)
Accumulated other comprehensive loss	8,241	(11,181)
Total TerraForm Global, Inc. stockholders’ equity	729,785	702,161
Non-controlling interests	487,114	481,106
Total stockholders’ equity	1,216,899	1,183,267
Total liabilities and stockholders’ equity	2,655,785	2,687,166
Common Class A
Stockholders’ Equity:
Common stock	1,131	1,146
Common Class B
Stockholders’ Equity:
Common stock	613	613
Common Class B1
Stockholders’ Equity:
Common stock	$ 0	$ 0

Unaudited Condensed Consolidat5

Unaudited Condensed Consolidated Balance Sheets (Parenthetical) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Preferred stock, par value (usd per share)	$ 0.01	$ 0.01
Preferred stock, shares authorized	50,000,000	50,000,000
Preferred stock, shares issued	0	0
Preferred stock, shares outstanding	0	0
Cash and cash equivalents	$ 870,494	$ 922,318
Current portion of restricted cash, including consolidated variable interest entities of $61,590 in June 30, 2016 and $46,321 in December 31, 2015	72,264	119,151
Prepaid expenses and other current assets, including consolidated variable interest entities of $100,411 in June 30, 2016 and $123,876 in December 31, 2015	117,841	139,335
Power plants, net, including consolidated variable interest entities of $461,067 in June 30, 2016 and $460,042 in December 31, 2015	1,375,254	1,206,604
Intangible assets, net, including consolidated variable interest entities of $51,362 in June 30, 2016 and $51,159 in December 31, 2015	70,054	70,630
Other assets	40,211	51,809
Current portion of long-term debt, including consolidated variable interest entities of $333,144 in June 30, 2016 and $326,535 in December 31, 2015	324,225	319,498
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015	111,305	129,437
Other long-term liabilities	$ 8,044	$ 1,455
Common Class A
Common stock, par value (usd per share)	$ 0.01	$ 0.01
Common stock, shares authorized	2,750,000,000	2,750,000,000
Common stock, shares issued	113,101,162	114,630,318
Common stock, shares outstanding	113,101,162	114,630,318
Common Class B
Common stock, par value (usd per share)	$ 0.01	$ 0.01
Common stock, shares authorized	200,000,000	200,000,000
Common stock, shares issued	61,343,054	61,343,054
Common stock, shares outstanding	61,343,054	61,343,054
Common Class B1
Common stock, par value (usd per share)	$ 0.01	$ 0.01
Common stock, shares authorized	550,000,000	550,000,000
Common stock, shares issued	0	0
Common stock, shares outstanding	0	0
Variable interest entities
Cash and cash equivalents
Current portion of restricted cash, including consolidated variable interest entities of $61,590 in June 30, 2016 and $46,321 in December 31, 2015	61,590	46,321
Prepaid expenses and other current assets, including consolidated variable interest entities of $100,411 in June 30, 2016 and $123,876 in December 31, 2015	100,411	123,876
Power plants, net, including consolidated variable interest entities of $461,067 in June 30, 2016 and $460,042 in December 31, 2015	461,067	460,042
Intangible assets, net, including consolidated variable interest entities of $51,362 in June 30, 2016 and $51,159 in December 31, 2015	51,362	51,159
Current portion of long-term debt, including consolidated variable interest entities of $333,144 in June 30, 2016 and $326,535 in December 31, 2015	333,144	326,535
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015	46,773	15,496
Other long-term liabilities
Deferred tax liabilities, including consolidated variable interest entities of $26,714 in June 30, 2016 and $37,295 in December 31, 2015	$ 38,615	$ 37,295

Unaudited Condensed Consolidat6

Unaudited Condensed Consolidated Statement of Equity - USD ($) $ in Thousands	Total	Common Class A	Common Class B	Common Class B1	Controlling Interest	Common StockCommon Class A	Common StockCommon Class B	Common StockCommon Class B1	Treasury Stock	Treasury StockCommon Class A	Additional Paid-in-Capital	Accumulated Deficit	Accumulated Other Comprehensive Income (Loss)	Non-controlling Interest	Non-controlling Interest, Capital	Non-controlling Interest, Accumulated Deficit	Non-controlling Interest, Accumulated Other Comprehensive Income (Loss)
Increase (Decrease) in Stockholders' Equity [Roll Forward]
Investments in NPS and WXA | Recast Adjustments	$ 858				$ 420						$ (184)	$ 532	$ 72	$ 438	$ (191)	$ 554	$ 75
Balance at January 1, 2016 (As Reported) at Dec. 31, 2015	1,182,409				701,741	$ 1,146	$ 613	$ 0	$ (28)		923,924	(212,661)	(11,253)	480,668	609,416	(118,995)	(9,753)
Balance at January 1, 2016 at Dec. 31, 2015	1,183,267				702,161	$ 1,146	$ 613		$ (28)		923,740	(212,129)	(11,181)	481,106	609,225	(118,441)	(9,678)
Balance at January 1, 2016 (shares) (As Reported) at Dec. 31, 2015						114,630,318,000	61,343,054,000	0	5,244,000
Balance at January 1, 2016 (shares) at Dec. 31, 2015		114,630,318	61,343,054	0		114,630,318,000	61,343,054,000	0	5,244
Increase (Decrease) in Stockholders' Equity [Roll Forward]
Class A shares forfeited on termination of employment	0					$ (15)					15
Class A shares forfeited on termination of employment (shares)						(1,529,156,000)
Stock-based compensation	1,972				1,972						1,972
Net income (loss)	(567)				(3,535)							(3,535)		2,968		2,968
Net SunEdison Investment	36,443													36,443	36,443
Other comprehensive loss	26,458				19,422						0		19,422	7,036	0		7,036
Dividends paid	(30,674)				(30,674)						(30,674)
Transfer of equity interest from non-controlling to controlling	0				14,869						14,869			(14,869)	(14,869)
Equity reallocation	0				25,570						25,570			(25,570)	(25,570)
Balance at June 30, 2016 at Jun. 30, 2016	$ 1,216,899				$ 729,785	$ 1,131	$ 613		$ (28)		$ 935,492	$ (215,664)	$ 8,241	$ 487,114	$ 605,229	$ (115,473)	$ (2,642)
Balance at December 31, 2016 (shares) at Jun. 30, 2016		113,101,162	61,343,054	0		113,101,162,000	61,343,054,000	0		5,244

Unaudited Condensed Consolidat7

Unaudited Condensed Consolidated Statements of Cash Flows - USD ($) $ in Thousands	6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015
Cash flows from operating activities:
Net loss	$ (567)	$ (33,904)
Adjustments to reconcile net loss to net cash provided by (used in) operating activities:
Amortization of deferred financing costs	1,768	13,929
Depreciation, amortization and accretion	27,597	6,071
Stock-based compensation expense	1,972	0
Change in fair value of interest rate swaps	4,638	(470)
Gain on previously held equity investment	0	(1,426)
Loss (gain) on the extinguishment of debt	(5,735)	1,219
Unrealized gains on foreign currency, net	21,239	0
Deferred tax (benefit) expense	(511)	450
Changes in assets and liabilities:
Accounts receivable	3,366	(5,927)
Prepaid expenses and other current assets	7,915	(9,934)
Accounts payable, accrued expenses, and other current liabilities	(9,584)	13,711
Due to/from SunEdison, net	(3,192)	23,120
Other noncurrent assets and liabilities	(2,838)	9,519
Net cash provided by operating activities	3,590	16,358
Cash flows from investing activities:
Capital expenditures	(47,105)	(94,475)
Change in cash committed for construction	0	20,493
Change in restricted cash	57,103	(55,854)
Cash paid for acquisitions, net of cash acquired	(32,128)	(113,851)
Deposits on investments	0	(860)
Cash acquired upon FERSA consolidation	8,022	0
Returns from BioTherm escrow and deposits	3,775	0
Net cash used in investing activities	(10,333)	(244,547)
Cash flows from financing activities:
Proceeds from Bridge Facility	0	400,000
Repayments on Bridge Facility	0	(91,469)
Repayments of the 2022 Senior Notes	(35,441)	0
Proceeds from system debt financing	0	48,800
Repayments of system debt financing	(29,477)	(98,041)
Net SunEdison investment	48,983	7,245
Dividends paid	(30,674)	0
Proceeds from private placement, net of fee	0	485,933
Proceeds from loans from parent and affiliates	0	5,111
Payment of deferred financing costs	0	(11,779)
Net cash (used in) provided by financing activities	(46,609)	745,800
Net (decrease) increase in cash and cash equivalents	(53,352)	517,611
Effect of exchange rate changes on cash and cash equivalents	1,528	(19)
Cash and cash equivalents at beginning of period	922,318	150,146
Cash and cash equivalents at end of period	$ 870,494	$ 667,738

Nature of Operations

Nature of Operations	6 Months Ended
	Jun. 30, 2016
Organization, Consolidation and Presentation of Financial Statements [Abstract]
Nature of Operations	NATURE OF OPERATIONS Nature of Operations TerraForm Global, Inc. and its subsidiaries (the “Company”) is a controlled affiliate of SunEdison, Inc. (together with its consolidated subsidiaries excluding the Company, "SunEdison"). TerraForm Global, Inc. is a holding company and its sole asset is an equity interest in TerraForm Global, LLC (“Global LLC”), a globally diversified renewable energy company that owns, through its subsidiaries, wind and solar power plants and long-term contractual arrangements to sell the electricity generated by such power plants to third parties. TerraForm Global, Inc. is the managing member of Global LLC and operates, controls and consolidates the business affairs of Global LLC. Going Concern The accompanying unaudited condensed consolidated financial statements have been prepared on a going concern basis, which contemplates the realization of assets and the satisfaction of liabilities in the normal course of business. The unaudited condensed consolidated financial statements do not include any adjustments that might be necessary should the Company be unable to continue as a going concern. Our sponsor, SunEdison, Inc., and certain of its domestic and international subsidiaries voluntarily filed for protection under Chapter 11 of the U.S. Bankruptcy Code on April 21, 2016 (the “SunEdison Bankruptcy”). We believe that we have observed formalities and operating procedures to maintain our separate existence, that our assets and liabilities can be readily identified as distinct from those of SunEdison and that we do not rely substantially on SunEdison for funding or liquidity and will have sufficient liquidity to support our ongoing operations. Our contingency planning with respect to the SunEdison Bankruptcy has included and will include, among other things, establishing stand-alone information technology, accounting and other critical systems and infrastructure, establishing separate human resources systems and employee retention efforts, retaining replacement operation and maintenance and asset management services for our power plants from other providers and the pursuit of strategic alternatives. However, there is a risk that an interested party in the SunEdison Bankruptcy could request that the assets and liabilities of the Company be substantively consolidated with SunEdison and that the Company and/or its assets and liabilities be included in the SunEdison Bankruptcy. While it has not been requested to date and we believe there is no basis for substantive consolidation in our circumstances, we cannot assure you that substantive consolidation will not be requested in the future or that the bankruptcy court would not consider it. Substantive consolidation is an equitable remedy in bankruptcy that results in the pooling of assets and liabilities of the debtor and one or more of its affiliates solely for purposes of the bankruptcy case, including for purposes of distributions to creditors and voting on and treatment under a reorganization plan. Bankruptcy courts have broad equitable powers, and as a result, outcomes in bankruptcy proceedings are inherently difficult to predict. To the extent the bankruptcy court were to determine that substantive consolidation was appropriate under the Company's facts and circumstances, the assets and liabilities of the Company could be made available to help satisfy the debt or contractual obligations of SunEdison. There have also been covenant defaults under certain of our project level financing arrangements, mainly because of delays in the delivery of project level audited financial statements and the delay in the filing of the Company’s audited annual financial statements for the year ended December 31, 2015, which was filed on Form 10-K on December 21, 2016. In addition, in a number of cases, the SunEdison Bankruptcy resulted in defaults because SunEdison, Inc. and certain of its affiliates have been serving as operation and maintenance and asset management services providers or as guarantors under relevant contracts. We have been working diligently with our lenders to cure or waive instances of default, including through the completion of project level audits and the retention of replacement service providers. However, there can be no assurance that all remaining defaults will be cured or waived. All of our project level financing arrangements are on a non-recourse basis, and therefore these defaults do not directly affect the financial position of the Company. However, if the remaining defaults are not cured or waived, this would continue to restrict the ability of the relevant project companies to make distributions to us, which may affect our ability to meet certain covenants under the Company’s revolving credit facility (the "Revolver"), or entitle certain project level lenders to demand repayment or enforce their security interests. Additionally, covenant defaults may occur in the future under the Revolver and the indenture governing our 9.75% senior notes due 2022 (the “Senior Notes”) in the event of further delays in the filing of our periodic reports with the SEC and potential violation of financial covenants. There can be no assurance that we will be able to file our periodic reports (including our Form 10-Q for the quarter ended September 30, 2016, our Form 10-K for the year ended December 31, 2016 and our Form 10-Q for the quarter ended March 31, 2017 or any quarters thereafter) with the SEC within the periods currently required under our Revolver and the indenture governing our Senior Notes. The Revolver also contains financial covenants that the Company is required to meet on a quarterly basis, and management projections indicate that the Company could violate the Revolver’s debt service coverage covenant during 2017 which, if the Revolver is not amended or terminated, could cause a default under the Revolver and, depending on the outstanding amount under the Revolver at the time of such default, a cross-default on the Senior Notes. There can be no assurance that our lenders will agree to further extensions of financial statement filing dates or amendments to relevant covenants on acceptable terms or at all. As of January 30, 2017, the Revolver is undrawn, and in the event we are not able to cure or secure a waiver for a default under the Revolver, the Company’s available liquidity is sufficient to allow for the Revolver to be terminated, which would also avoid a cross-default on the Senior Notes. However, a default on the Senior Notes would permit the trustee or the holders of at least 25% in aggregate principal amount of notes outstanding to accelerate the Senior Notes. The Company would likely not have sufficient liquidity to meet this obligation, which could have a material adverse effect on our business, results of operations, financial condition and ability to pay dividends. A default under the indenture governing our Senior Notes would also result in a cross-default under the Revolver that would permit the lenders holding more than 50% of the aggregate exposure under the Revolver to accelerate any outstanding principal amount of loans, terminate any outstanding letter of credit and terminate the outstanding commitments under our Revolver. The risk of substantive consolidation of the Company with SunEdison and inclusion in the SunEdison Bankruptcy, as well as the risk of future covenant defaults under the Revolver and the indenture governing our Senior Notes, raise substantial doubt about the Company’s ability to continue as a going concern. Basis of Presentation The accompanying unaudited condensed consolidated financial statements have been prepared in accordance with SEC regulations for interim financial information. Accordingly, they do not include all of the information and notes required by accounting principles generally accepted in the United States of America ("U.S. GAAP") for complete financial statements. The financial statements should be read in conjunction with the accounting policies and other disclosures as set forth in the notes to the Company’s annual financial statements for the year ended December 31, 2015, filed with the SEC on Form 10-K on December 21, 2016. Certain solar power plants in the Company’s current portfolio have been contributed from SunEdison (also referred to as “dropdown”) and are reflected in the accompanying unaudited condensed consolidated balance sheets at SunEdison’s historical cost. When power plants are contributed or acquired from SunEdison, the Company is required to recast its historical financial statements to reflect the assets and liabilities of the acquired power plants for the period such power plants were owned by SunEdison in accordance with rules applicable to transactions between entities under common control. For all periods prior to our initial public offering (“IPO”) on August 5, 2015, the accompanying unaudited condensed consolidated financial statements reflect the operations of SunEdison Emerging Markets Co. (the "Predecessor"), which consisted of the assets that the Company acquired from SunEdison and third parties prior to and concurrently with the closing of the IPO, and were prepared using SunEdison’s historical basis in these assets and liabilities. For all periods subsequent to the IPO, the accompanying unaudited condensed consolidated financial statements represent the results of TerraForm Global, Inc., which consolidates Global LLC through its controlling interest. The historical financial statements of the Predecessor include allocations of certain SunEdison corporate expenses and income tax expense. Management believes the assumptions and methodology underlying the allocation of general corporate overhead expenses are reasonable. Subsequent to the IPO, corporate expenses represent those costs allocated to the Company under the Management Service Agreement ("MSA"), as more fully described in Note 17 -Related Parties . In the opinion of management, the accompanying unaudited condensed consolidated financial statements contain all material adjustments consisting of normal and recurring adjustments necessary to present fairly the Company’s unaudited condensed consolidated financial position as of June 30, 2016, and the results of operations, comprehensive income and cash flows for the six months ended June 30, 2016 and 2015. Use of Estimates In preparing the unaudited condensed consolidated financial statements in conformity with U.S. GAAP, the Company used estimates and assumptions that affect the reported amounts of assets and liabilities as of the date of the financial statements. Such estimates also affect the reported amounts of revenues, expenses and cash flows during the reporting period. To the extent there are material differences between the estimates and actual results, the Company's future results of operations would be affected. Restricted Cash Restricted cash consists of cash on deposit in financial institutions that is restricted to satisfy the requirements of certain debt and acquisition agreements and funds held within the Company's project companies that are restricted for current debt service payments and other purposes in accordance with the applicable debt agreements. These restrictions include: (i) cash on deposit in collateral accounts, debt service reserve accounts, and maintenance reserve accounts; and (ii) cash on deposit in operating accounts but subject to distribution restrictions due to debt defaults, as of the balance sheet dates. New Accounting Standards In May 2014, the Financial Accounting Standards Board (“FASB”) issued Accounting Standards Update (“ASU”) 2014-09, Revenue from Contracts with Customers , which requires an entity to recognize the amount of revenue to which it expects to be entitled for the transfer of promised goods or services to customers. ASU 2014-09 will replace most existing revenue recognition guidance in U.S. GAAP when it becomes effective. ASU 2014-09 is effective for the Company on January 1, 2018. Early adoption is permitted but not before January 1, 2017. ASU 2014-09 permits the use of either a retrospective or cumulative effect transition method. The Company has not determined which transition method it will adopt, and it is currently evaluating the impact that ASU 2014-09 will have on its consolidated financial statements and related disclosures upon adoption. We do not plan to adopt this standard prior to January 1, 2018. In August 2014, the FASB issued ASU 2014-15, Disclosure of Uncertainties about an Entity’s Ability to Continue as a Going Concern , which describes how an entity should assess its ability to meet obligations and sets rules for how this information should be disclosed in the financial statements. ASU 2014-15 provides accounting guidance that will be used along with existing auditing standards. ASU 2014-15 applies to all entities for the first annual period ending after December 15, 2016, and interim periods thereafter. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In January 2015, the FASB issued ASU 2015-01, Income Statement-Extraordinary and Unusual Items (Subtopic 225-20): Simplifying Income Statement Presentation by Eliminating the Concept of Extraordinary Items . ASU 2015-01 eliminates from U.S. GAAP the concept of extraordinary items. An entity will no longer be required to (1) segregate an extraordinary item from the results of ordinary operations; (2) separately present an extraordinary item on its income statement, net of tax, after income from continuing operations; and (3) disclose income taxes and earnings-per-share data applicable to an extraordinary item. ASU 2015-01 will be effective for fiscal years beginning after December 15, 2015. An entity may apply ASU 2015-01 prospectively or retrospectively to all prior periods presented in the financial statements. Early adoption is permitted provided that the guidance is applied from the beginning of the fiscal year of adoption. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In February 2015, the FASB issued ASU 2015-02, Consolidation (Topic 810) Amendments to the Consolidation Analysis, which affects the following areas of the consolidation analysis: limited partnerships and similar entities, evaluation of fees paid to a decision maker or service provider as a variable interest and in determination of the primary beneficiary, effect of related parties on the primary beneficiary determination and for certain investment funds. ASU 2015-02 is effective on a retrospective basis for the Company for the fiscal year ending December 31, 2016 and interim periods therein. The Company adopted ASU 2015-02 as of January 1, 2016, which resulted in certain of our consolidated subsidiaries to be considered variable interest entities. One previously unconsolidated investment was consolidated as a result of implementing this standard (see Acquisition of FERSA in Note 3 - Acquisitions ). No consolidated subsidiaries were deconsolidated as a result of implementing this standard. In April 2015, the FASB issued ASU 2015-03, Interest - Imputation of Interest (Subtopic 835-30): Simplifying the Presentation of Debt Issuance Costs. ASU 2015-03 requires that debt issuance costs related to a recognized debt liability be presented in the balance sheets as a direct deduction from the carrying amount of that debt liability. In August 2015, the FASB issued ASU 2015-15, Interest - Imputation of Interest (Subtopic 835-30): Presentation and Subsequent Measurement of Debt Issuance Costs Associated with Line-of Credit Arrangements. ASU 2015-15 indicates that an entity may defer and present debt issuing costs associated with line-of-credit arrangements as an asset and subsequently amortize the deferred debt issuance costs ratably over the term of the line-of-credit arrangement, regardless of whether there are any outstanding borrowings on the line-of-credit arrangement. ASU 2015-03 and ASU 2015-15 are effective on a retrospective basis for annual and interim periods beginning on or after December 15, 2015. The Company adopted ASU 2015-03 and ASU 2015-15 as of January 1, 2016, which resulted in a reclassification of $21.4 million and $23.6 million from deferred financing costs, net to long-term debt and financing lease obligations, including current portion, as of June 30, 2016 and December 31, 2015, respectively. In April 2015, the FASB issued ASU 2015-06 Earnings Per Share (Topic 260) , which provides guidance on the presentation of historical earnings per unit under the two-class method for transfers of net assets between entities under common control. ASU 2015-06 is effective for the Company for the fiscal year ending December 31, 2016 and interim periods therein. In September 2015, the FASB issued ASU 2015-16, Business Combinations (Topic 805): Simplifying the Accounting for Measurement-Period Adjustments , which eliminates the requirement for an acquirer in a business combination to account for measurement-period adjustments retrospectively. Instead, acquirers must recognize measurement-period adjustments during the period in which they determine the amounts, including the effect on earnings of any amounts they would have recorded in previous periods if the accounting had been completed at the acquisition date. ASU 2015-16 is effective for the Company on a prospective basis on January 1, 2016. Early adoption is permitted for any interim and annual financial statements that have not yet been made available for issuance. The Company early adopted ASU 2015-16 and all measurement-period adjustments for business combinations completed in 2015 were recorded in our consolidated financial statements for the year ended December 31, 2015, with the exception of FERSA which was accounted for using the equity method. In November 2015, the FASB issued ASU 2015-17, Income Taxes (Topic 740): Balance Sheet Classification of Deferred Taxes instructing reporting entities to classify deferred income taxes as non-current on the unaudited condensed consolidated balance sheets. Deferred income taxes were previously required to be classified as current or non-current on the unaudited condensed consolidated balance sheets. The provisions of ASU 2015-17 are effective for fiscal years, and interim periods within those fiscal years, beginning after December 15, 2016. Early adoption is permitted for any interim and annual financial statements that have not yet been made available for issuance. A reporting entity has the option to apply ASU 2015-17 prospectively or retrospectively. We have early adopted ASU 2015-17 effective December 31, 2015 using the prospective method allowed under the standard and prior periods were not retrospectively adjusted. In February 2016, the FASB issued ASU 2016-02, Leases (Topic 842) , which primarily changes the lessee’s accounting for operating leases by requiring recognition of lease right-of-use assets and lease liabilities. This standard is effective for annual reporting periods beginning after December 15, 2018, with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In March 2016, the FASB issued ASU 2016-05, Derivatives and Hedging (Topic 815), which clarifies that a change in one of the parties to a derivative contract (through novation) that is part of a hedge accounting relationship does not, by itself, require designation of that relationship, as long as all other hedge accounting criteria continue to be met. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In March 2016, the FASB issued ASU 2016-06, Derivatives and Hedging (Topic 815) , which clarifies that determining whether the economic characteristics of a put or call are clearly and closely related to its debt host requires only an assessment of the four-step decision sequence outlined in FASB ASC paragraph 815-15-25-24. Additionally, entities are not required to separately assess whether the contingency itself is clearly and closely related. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2018, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In March 2016, the FASB issued ASU 2016-07, Investments - Equity Method and Joint Ventures (Topic 323) which eliminates the requirement for an investor to retroactively apply the equity method when its increase in ownership interest (or degree of influence) in an investee triggers equity method accounting. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. On March 30, 2016, the FASB issued ASU 2016-09, Compensation - Stock Compensation (Topic 718) , which is intended to improve the accounting for share-based payment transactions as part of the FASB’s simplification initiative. ASU 2016-09 changes seven aspects of the accounting for share-based payment award transactions, including but not limited to: (1) accounting for income taxes; (2) classification of excess tax benefits on the statement of cash flows; (3) forfeitures; (4) minimum statutory tax withholding requirements; and (5) classification of employee taxes paid on the statement of cash flows when an employer withholds shares for tax-withholding purposes. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In August 2016, the FASB issued ASU 2016-15, Statement of Cash Flows (Topic 230), Classification of Certain Cash Receipts and Cash Payments. The amendments of ASU 2016-15 were issued to address eight specific cash flow issues for which stakeholders have indicated to the FASB that a diversity in practice existed in how entities were presenting and classifying these items in the statement of cash flows. The issues addressed by ASU 2016-15 include but are not limited to the classification of debt prepayment and debt extinguishment costs, payments made for contingent consideration for a business combination, proceeds from the settlement of insurance proceeds, distributions received from equity method investees and separately identifiable cash flows and the application of the predominance principle. The amendments of ASU 2016-15 are effective for public entities for fiscal years beginning after December 15, 2017 and interim periods in those fiscal years. Early adoption is permitted, including adoption in an interim fiscal period with all amendments adopted in the same period. The adoption of ASU 2016-15 is required to be applied retrospectively. The Company is evaluating the impact of the standard on its consolidated statements of cash flows. In October 2016, the FASB issued ASU 2016-16, Income Taxes (Topic 740): Intra-Entity Transfer of Assets Other Than Inventory , which eliminates the recognition of current and deferred income taxes for an intra-entity asset transfer until the asset has been sold to an outside party exception for an intra-entity transfer of an asset other than inventory. ASU 2016-16 is effective for annual periods beginning after December 15, 2017, and for annual periods and interim periods thereafter with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In October 2016, the FASB issued ASU 2016-17, Consolidation (Topic 810): Interests Held through Related Parties That Are under Common Control . ASU 2016-17 updates ASU 2015-02. Under the amendments, a single decision maker is not required to consider indirect interests held through related parties that are under common control with the single decision maker to be the equivalent of direct interests in their entirety. Instead, a single decision maker is required to include those interests on a proportionate basis consistent with indirect interests held through other related parties. ASU 2016-17 is effective for annual periods beginning after December 15, 2017, and for annual periods and interim periods thereafter with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In November 2016, the FASB issued ASU 2016-18, Statement of Cashflows (Topic 320): Restricted Cash a Consensus of the FASB Emerging Issues Task Force. The amendments require that a statement of cash flows to explain the change during the period in the total of cash, cash equivalents, and amounts generally described as restricted cash or restricted cash equivalents. Therefore, amounts generally described as restricted cash and restricted cash equivalents should be included with cash and cash equivalents when reconciling the beginning-of-period and end-of-period total amounts shown on the statement of cash flows. The amendments in this update do not provide a definition of restricted cash or restricted cash equivalents. ASU 2016-18 is effective for fiscal years beginning after December 15, 2017 and interim periods within those fiscal years. The Company is evaluating the effect of this standard on its consolidated financial statements. In December 2016, the FASB issued ASU 2016-19, Technical Corrections and Improvements. The amendments cover a wide range of topics in the Accounting Standards Codification, including differences between original guidance and the Accounting Standards Codification, guidance clarification and reference corrections, simplification and minor improvements. The adoption of ASU 2016-19 is effective for annual periods, including interim periods, within those annual periods, beginning after December 15, 2016. The Company is evaluating the effect of this standard on its consolidated financial statements. In December 2016, the FASB issued ASU 2016-20, Technical Corrections and Improvements to Topic 606, Revenue from Contracts with Customers. The amendments in this update are of a similar nature to the items typically addressed in the ASU 2016-19, Technical Corrections and Improvements. However, the FASB decided to issue a separate update for technical corrections and improvements to Topic 606 and other Topics amended by ASU 2014-09 to increase stakeholders’ awareness of the proposals and to expedite improvements to ASU 2014-09. The adoption of ASU 2016-20 is effective from the periods beginning after December 15, 2017, including interim reporting periods within that reporting period. Early adoption is permitted only as of annual reporting periods beginning after December 15, 2016, including interim reporting periods within that reporting period. The Company is evaluating the effect of this standard on its consolidated financial statements. In January 2017, the FASB issued ASU 2017-01, Business Combinations (Topic 805): Clarifying the Definition of a Business. The amendment seeks to clarify the definition of a business with the objective of adding guidance to assist entities with evaluating whether transactions should be accounted for as acquisitions (or disposals) of assets or businesses. The definition of a business affects many areas of accounting including acquisitions, disposals, goodwill and consolidation. The adoption of ASU 2017-01 is effective for annual periods beginning after December 15, 2017, including interim periods within those periods. The amendments should be applied prospectively on or after the effective dates. The Company is evaluating the effect of this standard on its consolidated financial statements.

Transactions Between Entities U

Transactions Between Entities Under Common Control	6 Months Ended
	Jun. 30, 2016
Accounting Policies [Abstract]
Transactions Between Entities Under Common Control	TRANSACTIONS BETWEEN ENTITIES UNDER COMMON CONTROL Recast of Historical Financial Statements On February 24, 2016, the Company acquired two solar power plants in Thailand from SunEdison, NPS Star and WXA, with an aggregate net capacity of 35.6 MW, which resulted in a recast of the consolidated balance sheet as of December 31, 2015 . The previously reported consolidated statement of cash flows and consolidated statements of operations of the Predecessor for the six months ended June 30, 2015 include WXA and NPS Star, thus no recast of these statements is required. Both of these power plants began operations at the end of December 2015. The following table presents changes to the Company's consolidated balance sheet as of December 31, 2015 : (In thousands) Balance Sheet Caption Unadjusted Recast Adjustments As Recasted Cash and cash equivalents $ 921,946 $ 372 $ 922,318 Prepaid expenses and other current assets 144,743 (5,408 ) 139,335 Power plants, net 1,148,350 58,254 1,206,604 Restricted cash 22,582 100 22,682 Due from SunEdison, net 10,110 (10,110 ) — Other assets 66,901 (15,092 ) 51,809 Change in total assets $ 28,116 Accounts payable $ 8,034 $ 457 $ 8,491 Accrued expenses and other current liabilities 123,280 6,157 129,437 Due to SunEdison, net — 44,254 44,254 Current portion of long-term debt 327,714 (8,216 ) 319,498 Long-term debt, less current portion 968,047 (15,394 ) 952,653 Change in total liabilities $ 27,258 Additional paid-in capital $ 923,924 $ (184 ) $ 923,740 Accumulated deficit (212,661 ) 532 (212,129 ) Accumulated other comprehensive loss (11,253 ) 72 (11,181 ) Non-controlling interests 480,668 438 481,106 Change in total stockholders' equity $ 858 The recast adjustments also include the impact of the Adoption of ASU 2015-03 on presentation of debt issuance costs, which reclassed $23.6 million from other current assets to long-term debt, less current portion.

Acquisitions

Acquisitions	6 Months Ended
	Jun. 30, 2016
Business Combinations [Abstract]
Acquisitions	ACQUISITIONS First and Second Quarter 2016 Acquisitions Acquisition of NPS Star and WXA On February 24, 2016, SunEdison transferred to the Company a 49.0% equity interest, constituting a controlling interest and substantially all of the economic interest, in each of NPS Star and WXA, each of which consists of three solar power plants located in Thailand. These solar power plants, which achieved commercial operation in December 2015 and represent 35.6 MW of aggregate net capacity, were required to be contributed to the Company, without further payment, pursuant to the Project Investment Agreement between SunEdison and the Company. Acquisition of Alto Cielo On April 8, 2016, the Company completed the acquisition of a 100.0% ownership interest in the Alto Cielo solar power plant located in Uruguay with an aggregate net capacity of 26.4 MW from Solarpack Corporación Tecnológica, S.L. The power plant reached commercial operation in March 2016. The aggregate cash consideration paid for the Alto Cielo power plant was $32.3 million , of which $1.8 million was being held in escrow accounts as of June 30, 2016 until certain conditions are met. Transfer of Balance of Equity in Certain Projects in India In April 2016, SunEdison transferred to the Company the balance of 51.0% of the equity shares of the NSM Suryalabh, NSM Sitara and NSM L’Volta solar power plants in India following the expiration of the equity lock-up period in the applicable Power Purchase Agreements (“PPAs”). Consideration for the transfer of the balance 51.0% of the equity shares of these power plants was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there was no further payment made by the Company to SunEdison at the time of the transfer. 2015 Acquisitions Acquisition of Honiton On May 14, 2015, the Company completed the acquisition of 100.0% of the outstanding shares of Honiton Energy XIL Holdings Limited (“Honiton XIL”) and Honiton Energy BAV Holdings Limited (“Honiton BAV,” and together with Honiton XIL, “Honiton”) from Honiton Energy Caymans Limited. Honiton operates three wind power plants located in China with an aggregate net capacity of 148.5 MW. The aggregate consideration paid for this acquisition was $109.1 million in cash. Acquisition of NSM 24 On June 9, 2015, the Company completed the acquisition of a 51.0% equity interest in SEI Solar Power Private Limited (“NSM 24”) from Astronergy Solar Korea Co. Limited. NSM 24 owns a solar power plant located in India with an aggregate net capacity of 24.0 MW. The aggregate consideration paid for the acquisition of this interest was $9.1 million in cash. Concurrently, SunEdison contributed its 49.0% equity interest in NSM 24 to the Company, which was remeasured from SunEdison’s historical cost basis to fair value of $8.7 million at the time of the acquisition. Accordingly, the NSM 24 acquisition was accounted for as a step acquisition, and the Company recognized a gain of $1.4 million for the year ended December 31, 2015 related to the remeasurement of the equity interest in NSM 24 to fair value. Acquisition of Witkop/Soutpan On August 6, 2015, SunEdison completed the acquisition of an additional 41.3% equity interest in the solar power plants Witkop and Soutpan located in South Africa with an aggregate net capacity of 32.6 MW from a subsidiary of Chint Solar (Zhejiang) Co., Ltd. Prior to this purchase, SunEdison held a 9.7% interest in each of these solar power plants, which were accounted for as equity method investments in its consolidated financial statements. Concurrent with its acquisition of additional equity interest in Witkop and Soutpan, SunEdison transferred its aggregate interest in each of these solar power plants and an intermediary holding entity to the Company. The aggregate consideration paid by the Company for the acquisition of these interests was $38.7 million in cash. The combined fair value of the Company’s aggregate interest was $47.8 million on the date of the acquisition. The fair value of the non-controlling interest was determined using the combined fair value of the Company's aggregate interest, pro-rata at the fair value rate of the percentage acquired multiplied against the non-controlling interest. Acquisition of Renova - Bahia/Salvador In July 2015, the Company entered into agreements with Renova Energia S.A. (“Renova”) to acquire two wind power plants and one hydro-electric power plant in Brazil that have an aggregate net capacity of approximately 336.2 MW (the “Renova Transaction”). On September 18, 2015, the Company completed the acquisition of Salvador and Bahia, two wind power plants that represent 306.7 MW of aggregate net capacity. At the time, the consideration paid for the Salvador and Bahia wind power plants was $321.3 million , comprised of $117.3 million in cash, 20,327,499 shares of the Company’s Class A common stock valued at $ 183.6 million based on the value on September 18, 2015 of $9.03 per share and a put/call arrangement contributed by SunEdison with a fair value of $20.4 million . In the first quarter of 2016, the Company agreed with Renova on the final purchase price adjustments for wind power plants. The adjustments are factored into the allocation of assets and liabilities as of the acquisition date. Pending settlement, the revised consideration for the Salvador and Bahia wind power plants is $320.7 million . This is comprised of $117.7 million in cash, 20,223,581 shares of the Company’s Class A common stock valued at $182.6 million based on the value on September 18, 2015 share price of $9.03 per share and a put/call arrangement contributed by SunEdison with a fair value of $20.4 million . In connection with the closing of the Salvador and Bahia acquisitions on September 18, 2015, the Company entered into an omnibus closing agreement (the “Omnibus Agreement”) with Global LLC, SunEdison, certain of the Company’s foreign subsidiaries, and Renova, pursuant to which, among other things, the Company accepted certain financing liens on certain bank accounts related to the Bahia and Salvador power plants (the “Renova Liens”). In exchange for its acceptance of the Renova Liens, Renova granted to Global LLC a security interest in certain shares of the Company’s Class A common stock received by Renova in connection with the Renova Transaction and an agreement to place $5.0 million of the purchase price for the Bahia wind power plant and certain future dividends payable to Renova into an escrow account as security for Renova’s performance of its obligations to release the Renova Liens. On January 27, 2016, Renova released the liens related to the Bahia and Salvador wind power plants. Therefore, in March 2016 and pursuant to the terms of the Omnibus Agreement, the cash held in escrow was released to Renova, and Global LLC terminated its security interest in the 19,221,671 shares of the Company’s Class A common stock owned by Renova. After the closing of the Bahia and Salvador acquisitions, the various project companies repaid their outstanding project level indebtedness in full on September 30, 2015. Although the repayment of this indebtedness resulted in the termination of all guarantees and restrictions arising under the financing agreements, as of December 31, 2015, the project lender had not provided a release letter to the escrow agent under the financing agreements, and as a result approximately $49.2 million in funds of the Bahia and Salvador project companies continued to be held in restricted cash on the Company's consolidated balance sheet as of December 31, 2015. On March 31, 2016, the project lender provided the release letter to the escrow agent, thereby lifting any and all restrictions on usage of funds in the previously restricted accounts. As a result of the Renova Transaction, Renova is entitled to appoint one director to the Company’s board of directors (the "Board"), and such right will continue so long as Renova holds at least 28.0% of the 20,327,499 shares of the Company’s Class A common stock that Renova received in connection with the Renova Transaction. As of June 30, 2016 , Renova held 20,327,499 , or 100.0% of those shares. Renova has not exercised its right to appoint a director to the Board. As further described in Note 16 - Commitments and Contingencies , Renova has filed a request for arbitration to bring certain claims against the Company related to the Renova Transaction including, but not limited to, claims that the Company was liable to satisfy SunEdison’s obligations under a put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction, and claims for common law fraud and securities fraud in connection with the Salvador and Bahia transactions. Acquisition of FERSA On October 7, 2015, the Company completed the acquisition of three Indian wind power plants, Bhakrani, Gadag and Hanumanhatti (the “FERSA Projects”), which represent 101.6 MW of aggregate net capacity, from Fersa Energias Renovables, S.A. (“FERSA”), a Spanish wind developer. The aggregate consideration paid for the FERSA Projects was approximately $72.4 million , which includes the repayment of project level indebtedness of $39.0 million . At the time of acquisition, the Company recorded this acquisition as ‘Equity method investment’. On January 1, 2016, as part of the adoption of ASU 2015-02, the Company consolidated the assets and liabilities of the FERSA Projects. The net sales and net loss related to the foregoing acquisitions are reflected in the accompanying unaudited condensed consolidated statements of operations for the six months ended June 30, 2016 as shown below. Six Months Ended June 30, 2016 (In thousands) FERSA Alto Cielo Net sales 4,103 679 Net (loss) income (582 ) 266 Unaudited Pro Forma Supplementary Data The unaudited pro forma supplementary data presented in the table below gives effect to the acquisitions as if the transactions occurred on January 1, 2015. The pro forma supplementary data is provided for informational purposes only and should not be construed to be indicative of the Company’s results of operations had the acquisitions been consummated on the date assumed or of its results of operations for any future date. Six Months Ended June 30, (In thousands) 2016 2015 ProForma Net sales $ 104,527 $ 48,435 Net loss (373 ) (34,131 ) Acquisition Accounting The acquisition date allocation of assets and liabilities for the above acquisitions as of June 30, 2016 is as follows: 2016 (In thousands) FERSA Final Alto Cielo Preliminary Cash and cash equivalents $ 8,022 $ 190 Restricted cash — 1,923 Accounts receivable 4,220 311 Power plants 55,312 35,530 Intangible assets 8,400 — Other assets 1,182 2,738 Total assets acquired 77,136 40,692 Accrued expenses and other current liabilities 4,479 3,670 Deferred tax liabilities 1,518 673 Long-term debt, including current portion 38,746 4,031 Total liabilities assumed 44,743 8,374 Fair value of net assets acquired $ 32,393 $ 32,318 The initial accounting for the Alto Cielo business combination is not complete because the evaluation necessary to assess the fair values of certain assets acquired and liabilities assumed is in process. The initial accounting for Alto Cielo is preliminary, as such all assets and liabilities are presented at historical book value with the exception of power plants, which includes a preliminary fair value estimate. The preliminary amounts are subject to revision until the evaluations are completed to the extent that any additional information is obtained about the facts and circumstances that existed as of the acquisition date. Subsequent Events Transfer of Balance of Equity in Certain Projects in India In October 2016, SunEdison transferred to the Company 11.0% of the equity interests in the Millenium solar power plant in India for cash consideration of approximately $1.0 million . In addition, SunEdison transferred to the Company the balance of 51.0% of the equity interests in the Focal solar power plant in India following the expiration of the equity lock-up period in the applicable PPAs, at which time the Company was required to make a cash payment of $0.5 million to the original project developer, a third party. Consideration for the transfer of the balance of 51.0% of the equity interests in the Focal power plant was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there was no further payment made by the Company to SunEdison at the time of the transfer. In October 2016, the Company also entered into arrangements with SunEdison for the transfer of the balance of the equity interests in the Millenium, Azure, ESP Urja and SE-25 solar power plants in India, in each case following the expiration of the equity lock-up period in the applicable PPAs (ranging from November 2016 to March 2017) and without further action by SunEdison. Consideration for the transfer of the balance of the equity interests in these power plants was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there is no further payment to be made by the Company to SunEdison at the time of these planned transfers. In accordance with these arrangements, in November and December 2016, the balance of 26.0% of the equity interests in Azure and ESP Urja, respectively, was transferred to the Company, and in January 2017 the balance of 26% of Millenium was transferred to the Company. Pending Acquisition Acquisition of BioTherm In April 2015, the Company entered into purchase and sale agreements to acquire a controlling interest in three operating power plants located in South Africa with an aggregate net capacity of 32.6 MW from BTSA Netherlands Cooperatie U.A. (“BioTherm”). The aggregate consideration payable for the controlling interests in these three power plants is approximately $74.5 million in cash, comprised of approximately $67.6 million , and ZAR 100.4 million (approximately $6.7 million as of June 30, 2016), plus 544,055 shares of the Company’s Class A common stock, which is fixed in accordance with the purchase and sale agreements. The aggregate consideration includes amounts for certain additional rights and services. The completion of the BioTherm transaction remains subject to obtaining consents from project lenders and is expected to occur in the first quarter of 2017. In August 2015, the Company paid $65.6 million in cash for the interests in the solar power plants Aries and Konkoonsies, and the wind power plant Klipheuwel, as well as certain additional rights. In addition to the cash consideration, the Company provided 544,055 shares of its Class A common stock as consideration for the interests in the three power plants. Approximately $20.3 million of the cash payment and all of the 544,055 shares of the Company’s Class A common stock were deposited into an escrow account. The remaining cash portion of this escrow deposit is reported as non-current restricted cash on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016 . The remaining paid consideration of $43.9 million in cash and the August 2015 fair value of the 544,055 shares are reported as a deposit for acquisitions on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016. As of June 30, 2016, the remaining balance due was approximately $8.9 million , comprised of $2.0 million and ZAR 11.6 million (approximately $0.8 million ) due to BioTherm and ZAR 88.9 million (approximately $5.9 million ) due to minority interest shareholders. Prior to the completion of the BioTherm transaction, BioTherm is required to direct the payment of all distributions from the Klipheuwel power plant to the Company, and the Company and BioTherm are required to jointly direct the release of amounts equal to the cash distributions from the Aries and Konkoonsies solar power plants from the escrow to the Company. Pending receipt of the consents from the project lenders, the Company may at its discretion direct a sale of the power plants to a third party. In respect of the Aries and Konkoonsies solar power plants, due to the fact that the closing did not occur by November 30, 2016, the parties have engaged in discussion to agree upon an alternative structure that would permit release of the escrowed funds as required pursuant to the applicable purchase and sale agreements. Failure to complete the transaction with respect to the Aries and Konkoonsies solar power plants, or to reach agreement upon an alternative structure that would permit release of the escrowed funds, by February 14, 2017 would entitle BioTherm to sell the Aries and Konkoonsies solar power plants to a third party. Upon closing of a sale to a third party, all sale proceeds are required to be paid to the Company, any amounts remaining in the escrow account are required to be released to BioTherm and the Company is required to pay the remainder of the purchase price . Incomplete IPO Project Transfers and Dropdowns Del Litoral, El Naranjal and Bora Bora Poly Immediately prior to the completion of the IPO on August 5, 2015, and pursuant to the Project Investment Agreement between SunEdison and the Company, SunEdison agreed to contribute to the Company certain projects, without further payment, once each project reached commercial operation. These projects include the 17.4 MW Del Litoral and 57.4 MW El Naranjal solar power projects in Uruguay (the “Uruguay Projects”), the 24.1 MW Bora Bora Poly wind power project located in India, and the 17.8 MW NPS Star and 17.8 MW WXA solar power projects in Thailand. The NPS Star and WXA solar power plants reached commercial operation in December 2015 and were transferred by SunEdison to the Company in the first quarter of 2016. On March 23, 2016, SunEdison and the Company entered into an amendment to the Project Investment Agreement, which extended the contribution deadline for SunEdison to contribute the remaining projects pursuant to the Project Investment Agreement to July 31, 2016. As part of the SunEdison Bankruptcy, the construction on the projects was materially delayed and/or abandoned due to the lack of funding by SunEdison. There were material amounts of project costs and equity contributions for the Uruguay Projects that remained to be contributed by SunEdison in order to complete construction of these projects and disbursement of the project finance debt facilities. Additionally, SunEdison experienced delays in completing construction of the Bora Bora Poly wind power project in India, and the transfer of the project required project lender consent, which was not obtained. In light of the SunEdison Bankruptcy, we will not obtain these projects under the Project Investment Agreement and we will not obtain any substitute projects from SunEdison. 425 MW India Projects See Note 5 - Deposits for Acquisitions for information regarding the 425 MW India Projects. In September 2016, the Company reached an agreement with certain subsidiaries of SunEdison pursuant to which the Company consented to the sale of certain of SunEdison’s subsidiaries’ assets to a third party buyer (the “Third Party Sale Transaction”). The Third Party Sale Transaction is being conducted in connection with SunEdison’s bankruptcy process and includes the Uruguay Projects, the Bora Bora Poly wind power project in India and the 425 MW India Projects. The Company has agreed not to pursue claims against a third party buyer of these projects, however the Company has retained all of its claims against SunEdison and its affiliated persons. As a condition to the Company’s consent to the Third Party Sale Transaction, the Company and certain subsidiaries of SunEdison that directly or indirectly own the assets that are subject to the Third Party Sale Transaction have entered into a proceeds sharing arrangement pursuant to which the Company is entitled to receive a portion of the cash proceeds received by the SunEdison parties in the Third Party Sale Transaction. In September 2016, the Company received $6.7 million in cash proceeds from this arrangement, which will be classified as other income in the period received. The Company has not received, and does not expect to receive, any additional cash proceeds from this arrangement going forward. Terminated Acquisitions LAP In May 2015, SunEdison entered into a share purchase agreement with the stockholders of Latin America Power Holding, B.V. (“LAP”), to acquire certain hydro-electric and wind power plants located in Peru with a combined nameplate capacity of 72.5 MW (the “Peru Facilities”). SunEdison intended to transfer the Peru Facilities to the Company after the closing of the acquisition. The share purchase agreement was subsequently terminated by the parties thereto and, as a result of such termination, the Company will not acquire the Peru Facilities from SunEdison. All outstanding claims pending before arbitration tribunals and courts among the parties to the share purchase agreement were resolved pursuant to a settlement agreement entered into among the parties to the share purchase agreement on March 3, 2016 and a subsequent settlement agreement entered into among the parties to the share purchase agreement on April 20, 2016. The Company, which had no contractual obligation in connection with the LAP transaction, was not named as a party in any such arbitration or court proceeding and has no liability arising out of the settlement agreement. GME In June 2015, the Company entered into a stock purchase agreement (the "GME Agreement") with the stockholders of Globeleq Mesoamérica Energy (Wind) Limited (“GME”) to acquire four wind power plants and a solar power plant in Honduras, Costa Rica and Nicaragua representing an aggregate capacity of 326.0 MW, as well as GME’s wind and solar development platform. The aggregate consideration payable by the Company to GME would have been comprised of $337.9 million in cash and 701,754 shares of the Company’s Class A common stock, plus interest of 15.0% per annum on the purchase price accruing from October 1, 2015. Immediately following the acquisition of GME by the Company, the Company expected to sell GME’s development platform to SunEdison. In addition, shortly following the completion of the GME acquisition, the Company expected to pay $46.9 million to SunEdison for the Choluteca solar power plant upon the closing of a separate purchase agreement between SunEdison and GME, subject to a potential downward adjustment based on the actual tariff rates awarded to the power plant. The consummation of the GME transaction was subject to various conditions, including the receipt of consents from the project lenders, which consents were not received by the long-stop date of March 12, 2016 under the GME Agreement. Under the GME Agreement, in the event that the transaction did not close by March 12, 2016, either the Company or the sellers could terminate the transaction. As a result, on March 14, 2016, the Company terminated the GME Agreement. In December 2016, the Company and the stockholders of GME entered into a mutual release agreement pursuant to which each party agreed to release all potential claims against the other party in connection with the GME transaction. Pursuant to the release agreement, the Company paid $0.4 million to the stockholders of GME as a reimbursement for certain expenses incurred in connection with the GME transaction. Renova - ESPRA On March 29, 2016, the Company entered into a Termination Agreement (the “Termination Agreement”) with Renova with respect to the Securities Purchase Agreement dated July 15, 2015 among the Company, SunEdison and Renova relating to the ESPRA hydro-electric power plant (the “ESPRA SPA”). The Termination Agreement provides that, subject to the satisfaction of certain conditions, the ESPRA SPA will be terminated by mutual agreement of the Company and Renova. These conditions were satisfied on March 31, 2016 and the ESPRA SPA has been terminated. The Termination Agreement required the Company to pay Renova $10.0 million in connection with the termination of the ESPRA SPA. The Company made this payment on April 1, 2016, and recorded it as Acquisition, formation and related costs in the accompanying unaudited condensed consolidated statement of operations for the three and six months ended June 30, 2016 . Pursuant to the Termination Agreement, the Company and Renova have granted each other full releases of any further obligations under the ESPRA SPA. As further described in Note 16 - Commitments and Contingencies , on July 14, 2016, Renova filed a request for arbitration against the Company and certain subsidiaries related to the Renova Transaction including, but not limited to, claims that the Company was liable to satisfy SunEdison’s obligations under a put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction, and claims for common law fraud and securities fraud in connection with the Salvador and Bahia transactions. DEPOSITS FOR ACQUISITIONS Deposits for acquisitions consist of: As of June 30, As of December 31, (In thousands) 2016 2015 India PSA payment to SunEdison $ 231,000 $ 231,000 BioTherm payment 51,101 51,101 Total deposits for acquisitions 282,101 282,101 Less: provision for contingent loss (231,000 ) (231,000 ) Less: BioTherm distribution (1,368 ) — Total deposits for acquisitions, net $ 49,733 $ 51,101 425 MW India Projects On November 20, 2015, the Company and SunEdison Holdings Corporation entered into an Equity Interest Purchase and Sale Agreement pursuant to which the Company agreed to acquire from SunEdison Holdings Corporation a portfolio of 17 solar energy projects in India with an aggregate nameplate capacity of 425 MW (the “425 MW India Projects”). This agreement was subsequently amended and restated on December 1, 2015. Pursuant to the Amended and Restated Equity Interest Purchase and Sale Agreement (the “India PSA”), in the fourth quarter of 2015 the Company paid $231.0 million in cash to SunEdison Holdings Corporation in exchange for the 425 MW India Projects, which projects would be transferred to the Company upon satisfaction of certain conditions precedent. During 2016, and beginning prior to the SunEdison Bankruptcy, the Company became aware that there was substantial risk that the 425 MW India Projects would not be completed and transferred to the Company in accordance with the India PSA. In April 2016, the Company filed a verified complaint against SunEdison, SunEdison Holdings Corporation, Ahmad Chatila, Martin Truong and Brian Wuebbels in the Court of Chancery in the State of Delaware (see Note 16 - Commitments and Contingencies ). The complaint asserts claims for breach of fiduciary duty, breach of contract and unjust enrichment relating to the failure by SunEdison to transfer the equity interests in the 425 MW India Projects, for which the Company paid $231.0 million in the fourth quarter of 2015. The complaint seeks various forms of relief, including a constructive trust upon the equity interests of SunEdison in the 425 MW India Projects, money damages from the defendants, restoration of the $231.0 million to the Company and such other relief as the court may deem just and proper. The claims against SunEdison have been stayed as a result of the SunEdison Bankruptcy. The individual defendants filed an answer to the complaint on June 30, 2016. The $231.0 million paid by the Company in accordance with the India PSA was reported as a deposit for acquisitions on the Company’s consolidated balance sheets as of June 30, 2016 and December 31, 2015 . However, the Company determined that the deposit for acquisitions of the 425 MW India Projects was not realizable as of December 31, 2015 and recorded a provision for contingent loss of the full $231.0 million in the consolidated balance sheets as of December 31, 2015 and June 30, 2016 . As previously described in Note 3 - Acquisitions , the Third Party Sale Transaction is being conducted in connection with SunEdison’s bankruptcy process and includes the 425 MW India Projects. BioTherm In August 2015, the Company paid $65.6 million in cash for the interests in the solar power plants Aries and Konkoonsies and the wind power plant Klipheuwel, as well as certain additional rights. In addition to the cash consideration, the Company provided 544,055 shares of its Class A common stock, for total consideration of $71.4 million . In accordance with the funding arrangements, during the first quarter of 2016 the Company received $2.3 million from the escrow account holding the purchase consideration for the solar power plants Aries and Konkoonsies, which reduced the outstanding balance of the escrow account from $20.3 million to $18.0 million as of June 30, 2016. Cash paid to the escrow account was reported as non-current restricted cash in the Company’s unaudited condensed consolidated balance sheet. Also, in the first quarter of 2016 the Company received a $1.4 million distribution from BioTherm with respect to the Klipheuwel wind power plant. There were no payments received from BioTherm during the second quarter of 2016. The remaining paid consideration of $43.9 million in cash and the August 2015 fair value of the 544,055 shares were reported as a deposit for acquisitions on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016. The completion of the BioTherm transaction remains subject to obtaining consents from the project lenders and is expected to occur in the first quarter of 2017. See Note 3 - Acquisitions for additional details related to this acquisition. In accordance with the funding arrangements, during the third and fourth quarters of 2016 the Company received an additional $1.7 million from the escrow account with respect to the Aries and Konkoonsies solar power plants, and $1.1 million from BioTherm with respect to the Klipheuwel wind power plant.

Power Plants

Power Plants	6 Months Ended
	Jun. 30, 2016
Property, Plant and Equipment [Abstract]
Power Plants	POWER PLANTS Power plants, net consists of the following: (In thousands) June 30, 2016 December 31, 2015 Land $ 11,225 $ 9,749 Wind power plants 773,869 562,086 Solar power plants 658,412 674,856 Total power plants in service, at cost 1,443,506 1,246,691 Less: accumulated depreciation (69,180 ) (40,600 ) Total power plants in service, net 1,374,326 1,206,091 Construction in progress - solar projects 928 513 Total power plants, net $ 1,375,254 $ 1,206,604 The Company recorded depreciation expense, including foreign currency translation adjustments, related to power plants of $12.1 million and $25.8 million for the three and six months ended June 30, 2016 , respectively, as compared to $3.0 million and $5.7 million , respectively, for the same period in the prior year. Construction in progress represents costs incurred to complete the construction of the power plants in the Company’s current portfolio that were either contributed to the Company by SunEdison or acquired from SunEdison. When plants are contributed or sold to the Company after completion by SunEdison, the Company retroactively recasts its historical financial statements to present the construction activity as if it consolidated the power plants at inception of the construction. All construction in progress costs are stated at SunEdison’s historical cost. Certain of our solar power plants in India are entitled to receive viability gap funding support in an amount determined through a competitive bidding process. Such payment is made to the solar power plant over a five-year period from the date such solar plant commences operations and is funded by India’s National Clean Energy Fund. The Company recorded the awarded viability gap funding as a reduction to the cost of power plants in service, with a $ 1.8 million and $ 10.7 million receivable included in current other assets as of June 30, 2016 and December 31, 2015 , respectively, and $ 7.0 million and $ 7.1 million in other assets in the unaudited condensed consolidated balance sheet as of June 30, 2016 and December 31, 2015 , respectively. The current portion of the viability gap funding includes the initial 50% receivable following the solar power plant's commercial operation date and the 10% receivable in the first year thereafter. As of June 30, 2016 , the Company received $8.9 million of the initial 50% receivable, $ 1.8 million remained within other current assets and $ 7.0 million remained within other assets in the unaudited condensed consolidated balance sheet as of June 30, 2016. The remaining annual 10% receivable was due before December 31, 2016 and is presented within prepaid expenses and current other assets as of June 30, 2016 . This amount is expected to be received in the first quarter of 2017.

Deposits for Acquisitions

Deposits for Acquisitions	6 Months Ended
	Jun. 30, 2016
Deferred Costs, Capitalized, Prepaid, and Other Assets Disclosure [Abstract]
Deposits for Acquisitions	ACQUISITIONS First and Second Quarter 2016 Acquisitions Acquisition of NPS Star and WXA On February 24, 2016, SunEdison transferred to the Company a 49.0% equity interest, constituting a controlling interest and substantially all of the economic interest, in each of NPS Star and WXA, each of which consists of three solar power plants located in Thailand. These solar power plants, which achieved commercial operation in December 2015 and represent 35.6 MW of aggregate net capacity, were required to be contributed to the Company, without further payment, pursuant to the Project Investment Agreement between SunEdison and the Company. Acquisition of Alto Cielo On April 8, 2016, the Company completed the acquisition of a 100.0% ownership interest in the Alto Cielo solar power plant located in Uruguay with an aggregate net capacity of 26.4 MW from Solarpack Corporación Tecnológica, S.L. The power plant reached commercial operation in March 2016. The aggregate cash consideration paid for the Alto Cielo power plant was $32.3 million , of which $1.8 million was being held in escrow accounts as of June 30, 2016 until certain conditions are met. Transfer of Balance of Equity in Certain Projects in India In April 2016, SunEdison transferred to the Company the balance of 51.0% of the equity shares of the NSM Suryalabh, NSM Sitara and NSM L’Volta solar power plants in India following the expiration of the equity lock-up period in the applicable Power Purchase Agreements (“PPAs”). Consideration for the transfer of the balance 51.0% of the equity shares of these power plants was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there was no further payment made by the Company to SunEdison at the time of the transfer. 2015 Acquisitions Acquisition of Honiton On May 14, 2015, the Company completed the acquisition of 100.0% of the outstanding shares of Honiton Energy XIL Holdings Limited (“Honiton XIL”) and Honiton Energy BAV Holdings Limited (“Honiton BAV,” and together with Honiton XIL, “Honiton”) from Honiton Energy Caymans Limited. Honiton operates three wind power plants located in China with an aggregate net capacity of 148.5 MW. The aggregate consideration paid for this acquisition was $109.1 million in cash. Acquisition of NSM 24 On June 9, 2015, the Company completed the acquisition of a 51.0% equity interest in SEI Solar Power Private Limited (“NSM 24”) from Astronergy Solar Korea Co. Limited. NSM 24 owns a solar power plant located in India with an aggregate net capacity of 24.0 MW. The aggregate consideration paid for the acquisition of this interest was $9.1 million in cash. Concurrently, SunEdison contributed its 49.0% equity interest in NSM 24 to the Company, which was remeasured from SunEdison’s historical cost basis to fair value of $8.7 million at the time of the acquisition. Accordingly, the NSM 24 acquisition was accounted for as a step acquisition, and the Company recognized a gain of $1.4 million for the year ended December 31, 2015 related to the remeasurement of the equity interest in NSM 24 to fair value. Acquisition of Witkop/Soutpan On August 6, 2015, SunEdison completed the acquisition of an additional 41.3% equity interest in the solar power plants Witkop and Soutpan located in South Africa with an aggregate net capacity of 32.6 MW from a subsidiary of Chint Solar (Zhejiang) Co., Ltd. Prior to this purchase, SunEdison held a 9.7% interest in each of these solar power plants, which were accounted for as equity method investments in its consolidated financial statements. Concurrent with its acquisition of additional equity interest in Witkop and Soutpan, SunEdison transferred its aggregate interest in each of these solar power plants and an intermediary holding entity to the Company. The aggregate consideration paid by the Company for the acquisition of these interests was $38.7 million in cash. The combined fair value of the Company’s aggregate interest was $47.8 million on the date of the acquisition. The fair value of the non-controlling interest was determined using the combined fair value of the Company's aggregate interest, pro-rata at the fair value rate of the percentage acquired multiplied against the non-controlling interest. Acquisition of Renova - Bahia/Salvador In July 2015, the Company entered into agreements with Renova Energia S.A. (“Renova”) to acquire two wind power plants and one hydro-electric power plant in Brazil that have an aggregate net capacity of approximately 336.2 MW (the “Renova Transaction”). On September 18, 2015, the Company completed the acquisition of Salvador and Bahia, two wind power plants that represent 306.7 MW of aggregate net capacity. At the time, the consideration paid for the Salvador and Bahia wind power plants was $321.3 million , comprised of $117.3 million in cash, 20,327,499 shares of the Company’s Class A common stock valued at $ 183.6 million based on the value on September 18, 2015 of $9.03 per share and a put/call arrangement contributed by SunEdison with a fair value of $20.4 million . In the first quarter of 2016, the Company agreed with Renova on the final purchase price adjustments for wind power plants. The adjustments are factored into the allocation of assets and liabilities as of the acquisition date. Pending settlement, the revised consideration for the Salvador and Bahia wind power plants is $320.7 million . This is comprised of $117.7 million in cash, 20,223,581 shares of the Company’s Class A common stock valued at $182.6 million based on the value on September 18, 2015 share price of $9.03 per share and a put/call arrangement contributed by SunEdison with a fair value of $20.4 million . In connection with the closing of the Salvador and Bahia acquisitions on September 18, 2015, the Company entered into an omnibus closing agreement (the “Omnibus Agreement”) with Global LLC, SunEdison, certain of the Company’s foreign subsidiaries, and Renova, pursuant to which, among other things, the Company accepted certain financing liens on certain bank accounts related to the Bahia and Salvador power plants (the “Renova Liens”). In exchange for its acceptance of the Renova Liens, Renova granted to Global LLC a security interest in certain shares of the Company’s Class A common stock received by Renova in connection with the Renova Transaction and an agreement to place $5.0 million of the purchase price for the Bahia wind power plant and certain future dividends payable to Renova into an escrow account as security for Renova’s performance of its obligations to release the Renova Liens. On January 27, 2016, Renova released the liens related to the Bahia and Salvador wind power plants. Therefore, in March 2016 and pursuant to the terms of the Omnibus Agreement, the cash held in escrow was released to Renova, and Global LLC terminated its security interest in the 19,221,671 shares of the Company’s Class A common stock owned by Renova. After the closing of the Bahia and Salvador acquisitions, the various project companies repaid their outstanding project level indebtedness in full on September 30, 2015. Although the repayment of this indebtedness resulted in the termination of all guarantees and restrictions arising under the financing agreements, as of December 31, 2015, the project lender had not provided a release letter to the escrow agent under the financing agreements, and as a result approximately $49.2 million in funds of the Bahia and Salvador project companies continued to be held in restricted cash on the Company's consolidated balance sheet as of December 31, 2015. On March 31, 2016, the project lender provided the release letter to the escrow agent, thereby lifting any and all restrictions on usage of funds in the previously restricted accounts. As a result of the Renova Transaction, Renova is entitled to appoint one director to the Company’s board of directors (the "Board"), and such right will continue so long as Renova holds at least 28.0% of the 20,327,499 shares of the Company’s Class A common stock that Renova received in connection with the Renova Transaction. As of June 30, 2016 , Renova held 20,327,499 , or 100.0% of those shares. Renova has not exercised its right to appoint a director to the Board. As further described in Note 16 - Commitments and Contingencies , Renova has filed a request for arbitration to bring certain claims against the Company related to the Renova Transaction including, but not limited to, claims that the Company was liable to satisfy SunEdison’s obligations under a put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction, and claims for common law fraud and securities fraud in connection with the Salvador and Bahia transactions. Acquisition of FERSA On October 7, 2015, the Company completed the acquisition of three Indian wind power plants, Bhakrani, Gadag and Hanumanhatti (the “FERSA Projects”), which represent 101.6 MW of aggregate net capacity, from Fersa Energias Renovables, S.A. (“FERSA”), a Spanish wind developer. The aggregate consideration paid for the FERSA Projects was approximately $72.4 million , which includes the repayment of project level indebtedness of $39.0 million . At the time of acquisition, the Company recorded this acquisition as ‘Equity method investment’. On January 1, 2016, as part of the adoption of ASU 2015-02, the Company consolidated the assets and liabilities of the FERSA Projects. The net sales and net loss related to the foregoing acquisitions are reflected in the accompanying unaudited condensed consolidated statements of operations for the six months ended June 30, 2016 as shown below. Six Months Ended June 30, 2016 (In thousands) FERSA Alto Cielo Net sales 4,103 679 Net (loss) income (582 ) 266 Unaudited Pro Forma Supplementary Data The unaudited pro forma supplementary data presented in the table below gives effect to the acquisitions as if the transactions occurred on January 1, 2015. The pro forma supplementary data is provided for informational purposes only and should not be construed to be indicative of the Company’s results of operations had the acquisitions been consummated on the date assumed or of its results of operations for any future date. Six Months Ended June 30, (In thousands) 2016 2015 ProForma Net sales $ 104,527 $ 48,435 Net loss (373 ) (34,131 ) Acquisition Accounting The acquisition date allocation of assets and liabilities for the above acquisitions as of June 30, 2016 is as follows: 2016 (In thousands) FERSA Final Alto Cielo Preliminary Cash and cash equivalents $ 8,022 $ 190 Restricted cash — 1,923 Accounts receivable 4,220 311 Power plants 55,312 35,530 Intangible assets 8,400 — Other assets 1,182 2,738 Total assets acquired 77,136 40,692 Accrued expenses and other current liabilities 4,479 3,670 Deferred tax liabilities 1,518 673 Long-term debt, including current portion 38,746 4,031 Total liabilities assumed 44,743 8,374 Fair value of net assets acquired $ 32,393 $ 32,318 The initial accounting for the Alto Cielo business combination is not complete because the evaluation necessary to assess the fair values of certain assets acquired and liabilities assumed is in process. The initial accounting for Alto Cielo is preliminary, as such all assets and liabilities are presented at historical book value with the exception of power plants, which includes a preliminary fair value estimate. The preliminary amounts are subject to revision until the evaluations are completed to the extent that any additional information is obtained about the facts and circumstances that existed as of the acquisition date. Subsequent Events Transfer of Balance of Equity in Certain Projects in India In October 2016, SunEdison transferred to the Company 11.0% of the equity interests in the Millenium solar power plant in India for cash consideration of approximately $1.0 million . In addition, SunEdison transferred to the Company the balance of 51.0% of the equity interests in the Focal solar power plant in India following the expiration of the equity lock-up period in the applicable PPAs, at which time the Company was required to make a cash payment of $0.5 million to the original project developer, a third party. Consideration for the transfer of the balance of 51.0% of the equity interests in the Focal power plant was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there was no further payment made by the Company to SunEdison at the time of the transfer. In October 2016, the Company also entered into arrangements with SunEdison for the transfer of the balance of the equity interests in the Millenium, Azure, ESP Urja and SE-25 solar power plants in India, in each case following the expiration of the equity lock-up period in the applicable PPAs (ranging from November 2016 to March 2017) and without further action by SunEdison. Consideration for the transfer of the balance of the equity interests in these power plants was received by SunEdison in the form of shares of the Company’s Class B common stock that were issued to SunEdison at the time of our IPO, and there is no further payment to be made by the Company to SunEdison at the time of these planned transfers. In accordance with these arrangements, in November and December 2016, the balance of 26.0% of the equity interests in Azure and ESP Urja, respectively, was transferred to the Company, and in January 2017 the balance of 26% of Millenium was transferred to the Company. Pending Acquisition Acquisition of BioTherm In April 2015, the Company entered into purchase and sale agreements to acquire a controlling interest in three operating power plants located in South Africa with an aggregate net capacity of 32.6 MW from BTSA Netherlands Cooperatie U.A. (“BioTherm”). The aggregate consideration payable for the controlling interests in these three power plants is approximately $74.5 million in cash, comprised of approximately $67.6 million , and ZAR 100.4 million (approximately $6.7 million as of June 30, 2016), plus 544,055 shares of the Company’s Class A common stock, which is fixed in accordance with the purchase and sale agreements. The aggregate consideration includes amounts for certain additional rights and services. The completion of the BioTherm transaction remains subject to obtaining consents from project lenders and is expected to occur in the first quarter of 2017. In August 2015, the Company paid $65.6 million in cash for the interests in the solar power plants Aries and Konkoonsies, and the wind power plant Klipheuwel, as well as certain additional rights. In addition to the cash consideration, the Company provided 544,055 shares of its Class A common stock as consideration for the interests in the three power plants. Approximately $20.3 million of the cash payment and all of the 544,055 shares of the Company’s Class A common stock were deposited into an escrow account. The remaining cash portion of this escrow deposit is reported as non-current restricted cash on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016 . The remaining paid consideration of $43.9 million in cash and the August 2015 fair value of the 544,055 shares are reported as a deposit for acquisitions on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016. As of June 30, 2016, the remaining balance due was approximately $8.9 million , comprised of $2.0 million and ZAR 11.6 million (approximately $0.8 million ) due to BioTherm and ZAR 88.9 million (approximately $5.9 million ) due to minority interest shareholders. Prior to the completion of the BioTherm transaction, BioTherm is required to direct the payment of all distributions from the Klipheuwel power plant to the Company, and the Company and BioTherm are required to jointly direct the release of amounts equal to the cash distributions from the Aries and Konkoonsies solar power plants from the escrow to the Company. Pending receipt of the consents from the project lenders, the Company may at its discretion direct a sale of the power plants to a third party. In respect of the Aries and Konkoonsies solar power plants, due to the fact that the closing did not occur by November 30, 2016, the parties have engaged in discussion to agree upon an alternative structure that would permit release of the escrowed funds as required pursuant to the applicable purchase and sale agreements. Failure to complete the transaction with respect to the Aries and Konkoonsies solar power plants, or to reach agreement upon an alternative structure that would permit release of the escrowed funds, by February 14, 2017 would entitle BioTherm to sell the Aries and Konkoonsies solar power plants to a third party. Upon closing of a sale to a third party, all sale proceeds are required to be paid to the Company, any amounts remaining in the escrow account are required to be released to BioTherm and the Company is required to pay the remainder of the purchase price . Incomplete IPO Project Transfers and Dropdowns Del Litoral, El Naranjal and Bora Bora Poly Immediately prior to the completion of the IPO on August 5, 2015, and pursuant to the Project Investment Agreement between SunEdison and the Company, SunEdison agreed to contribute to the Company certain projects, without further payment, once each project reached commercial operation. These projects include the 17.4 MW Del Litoral and 57.4 MW El Naranjal solar power projects in Uruguay (the “Uruguay Projects”), the 24.1 MW Bora Bora Poly wind power project located in India, and the 17.8 MW NPS Star and 17.8 MW WXA solar power projects in Thailand. The NPS Star and WXA solar power plants reached commercial operation in December 2015 and were transferred by SunEdison to the Company in the first quarter of 2016. On March 23, 2016, SunEdison and the Company entered into an amendment to the Project Investment Agreement, which extended the contribution deadline for SunEdison to contribute the remaining projects pursuant to the Project Investment Agreement to July 31, 2016. As part of the SunEdison Bankruptcy, the construction on the projects was materially delayed and/or abandoned due to the lack of funding by SunEdison. There were material amounts of project costs and equity contributions for the Uruguay Projects that remained to be contributed by SunEdison in order to complete construction of these projects and disbursement of the project finance debt facilities. Additionally, SunEdison experienced delays in completing construction of the Bora Bora Poly wind power project in India, and the transfer of the project required project lender consent, which was not obtained. In light of the SunEdison Bankruptcy, we will not obtain these projects under the Project Investment Agreement and we will not obtain any substitute projects from SunEdison. 425 MW India Projects See Note 5 - Deposits for Acquisitions for information regarding the 425 MW India Projects. In September 2016, the Company reached an agreement with certain subsidiaries of SunEdison pursuant to which the Company consented to the sale of certain of SunEdison’s subsidiaries’ assets to a third party buyer (the “Third Party Sale Transaction”). The Third Party Sale Transaction is being conducted in connection with SunEdison’s bankruptcy process and includes the Uruguay Projects, the Bora Bora Poly wind power project in India and the 425 MW India Projects. The Company has agreed not to pursue claims against a third party buyer of these projects, however the Company has retained all of its claims against SunEdison and its affiliated persons. As a condition to the Company’s consent to the Third Party Sale Transaction, the Company and certain subsidiaries of SunEdison that directly or indirectly own the assets that are subject to the Third Party Sale Transaction have entered into a proceeds sharing arrangement pursuant to which the Company is entitled to receive a portion of the cash proceeds received by the SunEdison parties in the Third Party Sale Transaction. In September 2016, the Company received $6.7 million in cash proceeds from this arrangement, which will be classified as other income in the period received. The Company has not received, and does not expect to receive, any additional cash proceeds from this arrangement going forward. Terminated Acquisitions LAP In May 2015, SunEdison entered into a share purchase agreement with the stockholders of Latin America Power Holding, B.V. (“LAP”), to acquire certain hydro-electric and wind power plants located in Peru with a combined nameplate capacity of 72.5 MW (the “Peru Facilities”). SunEdison intended to transfer the Peru Facilities to the Company after the closing of the acquisition. The share purchase agreement was subsequently terminated by the parties thereto and, as a result of such termination, the Company will not acquire the Peru Facilities from SunEdison. All outstanding claims pending before arbitration tribunals and courts among the parties to the share purchase agreement were resolved pursuant to a settlement agreement entered into among the parties to the share purchase agreement on March 3, 2016 and a subsequent settlement agreement entered into among the parties to the share purchase agreement on April 20, 2016. The Company, which had no contractual obligation in connection with the LAP transaction, was not named as a party in any such arbitration or court proceeding and has no liability arising out of the settlement agreement. GME In June 2015, the Company entered into a stock purchase agreement (the "GME Agreement") with the stockholders of Globeleq Mesoamérica Energy (Wind) Limited (“GME”) to acquire four wind power plants and a solar power plant in Honduras, Costa Rica and Nicaragua representing an aggregate capacity of 326.0 MW, as well as GME’s wind and solar development platform. The aggregate consideration payable by the Company to GME would have been comprised of $337.9 million in cash and 701,754 shares of the Company’s Class A common stock, plus interest of 15.0% per annum on the purchase price accruing from October 1, 2015. Immediately following the acquisition of GME by the Company, the Company expected to sell GME’s development platform to SunEdison. In addition, shortly following the completion of the GME acquisition, the Company expected to pay $46.9 million to SunEdison for the Choluteca solar power plant upon the closing of a separate purchase agreement between SunEdison and GME, subject to a potential downward adjustment based on the actual tariff rates awarded to the power plant. The consummation of the GME transaction was subject to various conditions, including the receipt of consents from the project lenders, which consents were not received by the long-stop date of March 12, 2016 under the GME Agreement. Under the GME Agreement, in the event that the transaction did not close by March 12, 2016, either the Company or the sellers could terminate the transaction. As a result, on March 14, 2016, the Company terminated the GME Agreement. In December 2016, the Company and the stockholders of GME entered into a mutual release agreement pursuant to which each party agreed to release all potential claims against the other party in connection with the GME transaction. Pursuant to the release agreement, the Company paid $0.4 million to the stockholders of GME as a reimbursement for certain expenses incurred in connection with the GME transaction. Renova - ESPRA On March 29, 2016, the Company entered into a Termination Agreement (the “Termination Agreement”) with Renova with respect to the Securities Purchase Agreement dated July 15, 2015 among the Company, SunEdison and Renova relating to the ESPRA hydro-electric power plant (the “ESPRA SPA”). The Termination Agreement provides that, subject to the satisfaction of certain conditions, the ESPRA SPA will be terminated by mutual agreement of the Company and Renova. These conditions were satisfied on March 31, 2016 and the ESPRA SPA has been terminated. The Termination Agreement required the Company to pay Renova $10.0 million in connection with the termination of the ESPRA SPA. The Company made this payment on April 1, 2016, and recorded it as Acquisition, formation and related costs in the accompanying unaudited condensed consolidated statement of operations for the three and six months ended June 30, 2016 . Pursuant to the Termination Agreement, the Company and Renova have granted each other full releases of any further obligations under the ESPRA SPA. As further described in Note 16 - Commitments and Contingencies , on July 14, 2016, Renova filed a request for arbitration against the Company and certain subsidiaries related to the Renova Transaction including, but not limited to, claims that the Company was liable to satisfy SunEdison’s obligations under a put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction, and claims for common law fraud and securities fraud in connection with the Salvador and Bahia transactions. DEPOSITS FOR ACQUISITIONS Deposits for acquisitions consist of: As of June 30, As of December 31, (In thousands) 2016 2015 India PSA payment to SunEdison $ 231,000 $ 231,000 BioTherm payment 51,101 51,101 Total deposits for acquisitions 282,101 282,101 Less: provision for contingent loss (231,000 ) (231,000 ) Less: BioTherm distribution (1,368 ) — Total deposits for acquisitions, net $ 49,733 $ 51,101 425 MW India Projects On November 20, 2015, the Company and SunEdison Holdings Corporation entered into an Equity Interest Purchase and Sale Agreement pursuant to which the Company agreed to acquire from SunEdison Holdings Corporation a portfolio of 17 solar energy projects in India with an aggregate nameplate capacity of 425 MW (the “425 MW India Projects”). This agreement was subsequently amended and restated on December 1, 2015. Pursuant to the Amended and Restated Equity Interest Purchase and Sale Agreement (the “India PSA”), in the fourth quarter of 2015 the Company paid $231.0 million in cash to SunEdison Holdings Corporation in exchange for the 425 MW India Projects, which projects would be transferred to the Company upon satisfaction of certain conditions precedent. During 2016, and beginning prior to the SunEdison Bankruptcy, the Company became aware that there was substantial risk that the 425 MW India Projects would not be completed and transferred to the Company in accordance with the India PSA. In April 2016, the Company filed a verified complaint against SunEdison, SunEdison Holdings Corporation, Ahmad Chatila, Martin Truong and Brian Wuebbels in the Court of Chancery in the State of Delaware (see Note 16 - Commitments and Contingencies ). The complaint asserts claims for breach of fiduciary duty, breach of contract and unjust enrichment relating to the failure by SunEdison to transfer the equity interests in the 425 MW India Projects, for which the Company paid $231.0 million in the fourth quarter of 2015. The complaint seeks various forms of relief, including a constructive trust upon the equity interests of SunEdison in the 425 MW India Projects, money damages from the defendants, restoration of the $231.0 million to the Company and such other relief as the court may deem just and proper. The claims against SunEdison have been stayed as a result of the SunEdison Bankruptcy. The individual defendants filed an answer to the complaint on June 30, 2016. The $231.0 million paid by the Company in accordance with the India PSA was reported as a deposit for acquisitions on the Company’s consolidated balance sheets as of June 30, 2016 and December 31, 2015 . However, the Company determined that the deposit for acquisitions of the 425 MW India Projects was not realizable as of December 31, 2015 and recorded a provision for contingent loss of the full $231.0 million in the consolidated balance sheets as of December 31, 2015 and June 30, 2016 . As previously described in Note 3 - Acquisitions , the Third Party Sale Transaction is being conducted in connection with SunEdison’s bankruptcy process and includes the 425 MW India Projects. BioTherm In August 2015, the Company paid $65.6 million in cash for the interests in the solar power plants Aries and Konkoonsies and the wind power plant Klipheuwel, as well as certain additional rights. In addition to the cash consideration, the Company provided 544,055 shares of its Class A common stock, for total consideration of $71.4 million . In accordance with the funding arrangements, during the first quarter of 2016 the Company received $2.3 million from the escrow account holding the purchase consideration for the solar power plants Aries and Konkoonsies, which reduced the outstanding balance of the escrow account from $20.3 million to $18.0 million as of June 30, 2016. Cash paid to the escrow account was reported as non-current restricted cash in the Company’s unaudited condensed consolidated balance sheet. Also, in the first quarter of 2016 the Company received a $1.4 million distribution from BioTherm with respect to the Klipheuwel wind power plant. There were no payments received from BioTherm during the second quarter of 2016. The remaining paid consideration of $43.9 million in cash and the August 2015 fair value of the 544,055 shares were reported as a deposit for acquisitions on the Company’s unaudited condensed consolidated balance sheet as of June 30, 2016. The completion of the BioTherm transaction remains subject to obtaining consents from the project lenders and is expected to occur in the first quarter of 2017. See Note 3 - Acquisitions for additional details related to this acquisition. In accordance with the funding arrangements, during the third and fourth quarters of 2016 the Company received an additional $1.7 million from the escrow account with respect to the Aries and Konkoonsies solar power plants, and $1.1 million from BioTherm with respect to the Klipheuwel wind power plant.

Intangible Assets

Intangible Assets	6 Months Ended
	Jun. 30, 2016
Finite-Lived Intangible Assets, Net [Abstract]
Intangible Assets	INTANGIBLE ASSETS The following table presents the gross carrying amount and accumulated amortization of intangible assets as of June 30, 2016 : (In thousands, except weighted average amortization period) Remaining Weighted Average Amortization Period (Years) Gross Carrying Amount Accumulated Amortization Accumulated Currency Translation Adjustment Net Book Value In-place value of market rate revenue contracts 19 $ 84,643 $ (3,537 ) $ (11,052 ) $ 70,054 The following table presents the gross carrying amount and accumulated amortization of intangibles as of December 31, 2015: (In thousands, except weighted average amortization period) Remaining Weighted Average Amortization Period (Years) Gross Carrying Amount Accumulated Amortization Accumulated Currency Translation Adjustment Net Book Value In-place value of market rate revenue contracts 20 $ 84,643 $ (1,632 ) $ (12,381 ) $ 70,630 As of June 30, 2016 , the Company had PPAs that were obtained through acquisitions (see Note 3 - Acquisitions ). Revenue contracts are amortized on a straight line basis over the useful life of the agreements, which range from 20 to 25 years as of June 30, 2016 . Amortization expense related to the revenue contracts is recognized in the unaudited condensed consolidated statements of operations as either a reduction or increase of revenue when the contract rate is above or below market rates (favorable or unfavorable) or within depreciation, accretion and amortization expense when the contract rate is equal to market rates (in-place). The amortization expense for the three and six months ended June 30, 2016 was $ 1.0 million and $ 1.9 million , respectively. For the three and six month periods ended June 30, 2016 , $ 0.2 million and $ 0.4 million , respectively, was recorded as a reduction of revenue and $ 0.8 million and $ 1.5 million , respectively, was recorded within the depreciation, accretion, and amortization line item in the consolidated statement of operations.

Variable Interest Entities

Variable Interest Entities	6 Months Ended
	Jun. 30, 2016
Organization, Consolidation and Presentation of Financial Statements [Abstract]
Variable Interest Entities	VARIABLE INTEREST ENTITIES The Company consolidates any variable interest entities (“VIEs”) in power plants in which it is the primary beneficiary. The Company is the primary beneficiary of 13 VIEs in power plants that were consolidated as of June 30, 2016 , 11 of which existed and were consolidated as of December 31, 2015 . The VIEs own and operate power plants in order to generate contracted cash flows. As disclosed in Note 3 - Acquisitions , the Company acquired the equity interest in the FERSA Projects in October 2015, and as of December 31, 2015 , the Company was not the primary beneficiary and thus did not consolidate the acquired power plants, but recorded this investment as an equity method investment. Based on the adoption of ASU 2015-02 in 2016, the Company has consolidated the assets and liabilities of the FERSA Projects as of January 1, 2016. As disclosed in Note 3 - Acquisitions , SunEdison transferred to the Company a 49.0% equity interest, constituting a controlling interest and substantially all of the economic interest, in each of NPS Star and WXA, each of which consists of three solar power plants located in Thailand. These solar power plants represent 35.6 MW of aggregate net capacity. The carrying amounts and classification of the consolidated VIEs’ assets and liabilities included in the Company’s unaudited condensed consolidated balance sheets are as follows: (In thousands) As of June 30, 2016 As of December 31, 2015 Current assets $ 194,980 $ 212,295 Non-current assets 528,624 560,228 Total assets $ 723,604 $ 772,523 Current liabilities $ 397,705 $ 351,554 Non-current liabilities 61,444 80,158 Total liabilities $ 459,149 $ 431,712 The amounts shown in the table above exclude intercompany balances which are eliminated upon consolidation. All of the assets in the table above are restricted for settlement of the VIE obligations, and all of the liabilities in the table above can only be settled by using VIE resources.

Long-Term Debt

Long-Term Debt	6 Months Ended
	Jun. 30, 2016
Debt Disclosure [Abstract]
Long-Term Debt	LONG-TERM DEBT Long-term debt as of June 30, 2016 and December 31, 2015 consists of the following: As of June 30, As of December 31, (In thousands, except rates) 2016 2015 Interest Type Current Interest Rate (%) (1) Financing Type Corporate level long-term debt: Revolving Credit Facility $ 135,000 $ 135,000 Variable 3.9% Revolving line of credit Senior Notes due 2022 752,445 791,826 Fixed 9.8% Term debt Project level long-term debt: Permanent financing 346,281 368,935 Blended 12.1% (2) Term debt Total long-term debt 1,233,726 1,295,761 Less: deferred financing costs, net (3) 21,419 23,610 Less: current portion of long-term debt (4) 324,225 319,498 Consolidated long-term debt, less current portion $ 888,082 $ 952,653 (1) The weighted average effective interest rate as of June 30, 2016 . (2) As of June 30, 2016 , 11.3% of this balance had fixed interest rate debt and the remaining 88.7% had variable interest rate debt, of which a portion is hedged with interest rate swaps. (3) Total net debt reflects the reclassification of deferred financing costs to reduce long-term debt as further described in Note 1 - Nature of Operations and Basis of Presentation. (4) Approximately $319.9 million and $319.0 million have been classified as current due to non-compliance with certain debt covenants as of June 30, 2016 and December 31, 2015 , respectively. Corporate Level Long-term Debt Revolving Credit Facility The Company had drawn $135.0 million on its revolving credit facility (the "Revolver") as of June 30, 2016 and December 31, 2015 . Additionally, as of December 31, 2015 the Company had issued a letter of credit for $0.5 million under the terms of the Revolver in support of the Alto Cielo acquisition; no additional letters of credit were issued for the six months ended June 30, 2016 . On March 30, 2016, Global Operating LLC entered into a first amendment to the Revolver to amend certain financial covenants to extend the date on which the Company must deliver to the administrative agent and the other lenders party to the Revolver its financial statements and accompanying audit report with respect to the year ended December 31, 2015 (the “2015 Financials”) to April 30, 2016 and to provide for the engagement of a financial consultant to serve as advisor to the Revolver lenders. On April 29, 2016, Global Operating LLC entered into a second amendment to the Revolver, which further extended the due date for the delivery of the 2015 Financials to May 7, 2016. On May 6, 2016, Global Operating LLC entered into a third amendment (the “Third Amendment”) to the Revolver. The Third Amendment reduced the aggregate amount of the revolving commitments to $350.0 million . Additionally, the Third Amendment extended the date by which the Company must deliver to the Administrative Agent and the other lenders party to the Revolver the 2015 Financials to the earlier of (a) the tenth business day prior to the date on which the failure to deliver the 2015 Financials would constitute an event of default under the indenture governing the Senior Notes and (b) March 30, 2017. The Third Amendment also extended the date by which the Company must deliver its unaudited quarterly financial statements with respect to the quarter ended March 31, 2016 to June 30, 2016 and with respect to the quarters ended June 30, 2016 and September 30, 2016 to the date that is 75 days after the end of each fiscal quarter. The Third Amendment also required the Company to undertake certain additional obligations, including (1) to provide the lenders with preliminary financial information for the quarter ended March 31, 2016, (2) to comply with Nasdaq requirements for submitting compliance plans for the Company’s delayed filings and (3) to request a waiver or amendment under the indenture governing the Senior Notes with respect to Global Operating LLC’s obligation to make available audited financial statements for the year ended December 31, 2015 . The Company has complied with all three requirements. On September 8, 2016, the Company repaid the $135.0 million balance on the Revolver in connection with the consent solicitation of its Senior Notes and entered into the Second Supplemental Indenture as described below. Pursuant to the terms of the Second Supplemental Indenture, we may not borrow under the Revolver until the earlier of March 8, 2017 or such time as SunEdison has disposed of all or substantially all of its equity interests in the Company and an offer has been made to repurchase the Senior Notes at a purchase price in cash at least equal to 101% of the applicable principal amount, plus accrued and unpaid interest and additional interest, if any, to the repurchase date (or a binding agreement to make such an offer has been entered into). On September 13, 2016, Global Operating LLC entered into a fourth amendment (the “Fourth Amendment”) to the Revolver pursuant to the requirements of the Third Amendment to increase the applicable margin used to determine the interest rate on loans under the Revolver under certain circumstances relating to a waiver or amendment under the Senior Notes. Senior Notes Due 2022 The aggregate amount of the Senior Notes outstanding at June 30, 2016 was $752.4 million (or a notional amount of $760.4 million ). On May 11, 2016, Global Operating LLC received a letter on behalf of certain beneficial holders of the Senior Notes, which purported to constitute a notice of default with respect to the failure of Global Operating LLC to comply with its obligations under the indenture governing the Senior Notes to timely furnish the Company’s annual report for the year ended December 31, 2015 . On May 13, 2016, Global Operating LLC sent a response to this letter, stating that the purported notice of default was untimely, and therefore ineffective, under the indenture. On May 31, 2016, Global Operating LLC received a notice of default from the trustee under the indenture governing the Senior Notes with respect to the failure of Global Operating LLC to comply with its obligations under the indenture governing the Senior Notes to timely furnish the Company’s annual report for the year ended December 31, 2015 . The notice of default from the trustee complied with the 60 -day grace period under the indenture. Under the indenture, Global Operating LLC has 90 days from the date such notice of default is deemed to be duly given under the indenture to cure the default by filing or making publicly available the Company’s annual report for the year ended December 31, 2015 . If Global Operating LLC does not cure the default under the indenture, the trustee under the indenture or the holders of at least 25% of the Senior Notes may accelerate the Senior Notes, and the unpaid principal and accrued interest on the Senior Notes then outstanding would become immediately due and payable. The notice of default does not result in an acceleration of the Senior Notes prior to the expiration of such cure period, nor does it result in a cross-default under the Revolver. Global Operating LLC received a notice of default, dated July 15, 2016, from the trustee under the indenture governing the Senior Notes with respect to the failure of Global Operating LLC to comply with its obligations under the indenture governing the Senior Notes to timely furnish the Company's Form 10-Q for the first quarter of 2016 . On September 2, 2016, the Company announced the successful completion of a consent solicitation to obtain waivers relating to certain reporting covenants under the indenture governing the Senior Notes and to effectuate certain amendments to the indenture governing the Senior Notes. Global Operating LLC received validly delivered and unrevoked consents from the holders of a majority in aggregate principal amount of the Senior Notes outstanding as of the record date. Global Operating LLC paid to each consenting holder a consent fee of $5.00 for each $1,000 principal amount of the Senior Notes held by such holder as to which Global Operating LLC received and accepted consents. Under the terms of the waivers, the deadline to comply with the reporting covenants in the indenture governing the Senior Notes relating to the filing of the Company’s Form 10-K for 2015 and Form 10-Q for the first quarter of 2016 was extended to December 6, 2016. Compliance with the reporting covenants in the indenture governing the Senior Notes relating to the filing of the Company’s Form 10-Q for the second quarter of 2016 was also waived until December 6, 2016. Additionally, on September 2, 2016, Global Operating LLC entered into a second supplemental indenture (the “Second Supplemental Indenture”) to the indenture governing the Senior Notes. The Second Supplemental Indenture, among other things, (i) provides for additional special interest on the Senior Notes beginning on September 6, 2016 through December 6, 2016 at a rate equal to 4.0% per annum; (ii) required Global Operating LLC to repay the borrowing then outstanding (other than the outstanding letters of credit) under the Revolver, and restricted the ability of Global Operating LLC and its restricted subsidiaries to further borrow or issue any additional letters of credit under the Revolver until the earlier of March 8, 2017 or such time as SunEdison has disposed of all or substantially all of its equity interests in the Company and Global Operating LLC has offered to repurchase the Senior Notes at 101% of the applicable principal amount, plus accrued and unpaid interest and additional interest, if any, to the repurchase date (or a binding agreement to make such an offer has been entered into); (iii) imposed additional restrictions and conditions (including, in some cases, that require the existence of a board of directors of the Company that is independent from SunEdison) on the ability of Global LLC and its restricted subsidiaries to make restricted payments and permitted investments or to incur indebtedness or permitted liens; (iv) imposed restrictions and conditions on the ability of Global LLC and its restricted subsidiaries to settle, or pay settlement amounts in respect of, litigation claims involving excess settlement amounts; and (v) required Global LLC to provide legal and financial advisors to certain ad hoc holders of the Senior Notes with certain information, including certain information delivered to the lenders under the Revolver. On December 2, 2016, Global Operating LLC received a letter from the trustee under the indenture governing the Senior Notes, which purported to constitute a notice of default with respect to the failure of Global Operating LLC to comply with its obligations under the indenture governing the Senior Notes to timely furnish the Company’s Form 10-Q for the second quarter of 2016. Global Operating LLC sent a response to this letter, stating that the purported notice of default was untimely, and therefore ineffective, under the indenture. On December 6, 2016, the Company announced the successful completion of another consent solicitation to obtain additional waivers relating to certain reporting covenants under the indenture governing the Senior Notes. Global Operating LLC received validly delivered and unrevoked consents from the holders of a majority in aggregate principal amount of the Senior Notes outstanding as of the record date. Global Operating LLC paid to each consenting holder an initial consent fee of $3.50 for each $1,000 principal amount of the Senior Notes held by such holder as to which Global Operating LLC received and accepted consents. Under the terms of the additional waivers, the deadline to comply with the reporting covenants in the indenture governing the Senior Notes relating to the filing of the Company’s annual and quarterly reports required to be filed (including the Form 10-K for 2015 and the Form 10-Q for the first quarter of 2016) was extended to December 26, 2016, with Global Operating LLC having the option to further extend the deadline to January 6, 2017, to the extent necessary, by paying an extension fee. Global Operating LLC agreed with the holders of the Senior Notes in connection with its most recent consent solicitation that written notice shall be deemed to have been validly given, for purposes of the related event of default under the indenture governing the Senior Notes, on December 6, 2016 with respect to the Company’s Form 10-Q for the second quarter of 2016. Global Operating LLC received a notice of default, dated January 17, 2016, from the trustee under the indenture governing the Senior Notes with respect to the failure of Global Operating LLC to comply with its obligations under the indenture governing the Senior Notes to timely furnish the Company's Form 10-Q for the third quarter of 2016. However, no event of default under the indenture governing the Senior Notes is expected to occur with respect to the Company's Form 10-Q for the third quarter of 2016 unless such Form 10-Q is not filed by April 18, 2017. Covenant defaults may occur in the future under the Company’s Revolver and the indenture governing our Senior Notes in the event of further delays in the filing of our periodic reports with the SEC and potential violation of financial covenants. There can be no assurance that we will be able to file our periodic reports (including our Form 10-Q for the quarter ended September 30, 2016, our Form 10-K for the year ended December 31, 2016 and our Form 10-Q for the quarter ended March 31, 2017 or any quarters thereafter) with the SEC within the periods currently required under our Revolver and the indenture governing our Senior Notes. The Revolver also contains financial covenants that the Company is required to meet on a quarterly basis, and management projections indicate that the Company could violate the Revolver’s debt service coverage covenant during 2017 which, if the Revolver is not amended or terminated, could cause a default under the Revolver and, depending on the outstanding amount under the Revolver at the time of such default, a cross-default on the Senior Notes. There can be no assurance that our lenders will agree to further extensions of financial statement filing dates or amendments to relevant covenants on acceptable terms or at all. As of January 30, 2017, the Revolver is undrawn, and in the event we are not able to cure or secure a waiver for a default under the Revolver, the Company’s available liquidity is sufficient to allow for the Revolver to be terminated, which would also avoid a cross-default on the Senior Notes. However, in the event of a default on the Senior Notes, the Company would likely not have sufficient liquidity to meet this obligation, which could have a material adverse effect on our business, results of operations, financial condition and ability to pay dividends. A default under the indenture governing our Senior Notes would also result in a cross-default under the Revolver that would permit the lenders holding more than 50% of the aggregate exposure under the Revolver to accelerate any outstanding principal amount of loans, terminate any outstanding letter of credit and terminate the outstanding commitments under our Revolver. Project Level Long-term Debt The Company typically finances power plants through entity specific debt secured by the power plant’s assets and equity interests with no recourse to the Company. These financing agreements typically provide for a credit facility used for construction, which upon completion is converted into term debt. As of June 30, 2016 , the Company had $ 346.3 million of project level debt that is secured by the assets of the applicable project companies and certain intermediary holding companies. Term debt for power plants in South Africa consists of variable rate loans, totaling $307.3 million , with interest rates tied to the three -month LIBOR and the three -month Johannesburg Interbank Agreed Rate, as well as fixed rate loans totaling $10.5 million . The interest rates on the South Africa term debt as of June 30, 2016 range from 12.3% to 13.0% and the debt matures in 2031 . Principal and interest are due and payable in arrears at the end of each fiscal quarter or semi-annually and on the maturity date of the credit facilities. As of June 30, 2016 , the Witkop and Soutpan power plants, which have term debt financed with a South African Rand (ZAR)-denominated term loan from The Standard Bank of South Africa Limited ("Standard Bank"), had an outstanding principal amount totaling $125.6 million . This term debt matures in 2031 . As of June 30, 2016 and December 31, 2015, the Witkop and Soutpan project companies were not in compliance with certain covenants due to the SunEdison Bankruptcy, as well as the failure by the Witkop and Soutpan project companies to file auditors' certificates for certain financial ratios, audited financial statements and semi-annual operating reports. Thus, the debt balances are classified as current as of June 30, 2016 and December 31, 2015. These defaults also prevent the Soutpan and Witkop project companies from making distributions and provide the lenders with the right to accelerate the debt maturity. The Company has obtained waivers and/or forbearance agreements from Standard Bank for varying periods as the Company works to cure such defaults, however there is no assurance that all such defaults will be cured prior to the expiration of the applicable waivers. As of June 30, 2016 , the Boshof power plant, which has term debt financed with a U.S. dollar-denominated term debt from the Overseas Private Investment Corporation (“OPIC”), had an outstanding principal amount of approximately $181.6 million . The term debt matures in September 2031. As of June 30, 2016 and December 31, 2015 , the project company was not in compliance with certain covenants due to the SunEdison Bankruptcy, a delay by the contractor, a SunEdison subsidiary, in achieving final completion under the engineering, procurement and construction contract, failure to satisfy certain required economic development obligations and failure to file audited financial statements. Thus the debt balances are classified as current as of June 30, 2016 and December 31, 2015 . These defaults also prevent the Boshof project company from making distributions and provide OPIC with the right to accelerate the debt maturity. The Company is currently working with OPIC to cure such defaults. Term debt for power plants in India consists of fixed and variable rate loans with interest rates tied to one of the following indexes: (i) the six -month LIBOR; (ii) the two -year Infrastructure Development Finance Company (“IDFC”) benchmark rate; (iii) the PFS reference rate; or (iv) the L&T prime lending rate. India term debt with fixed rates totaled $20.5 million as of June 30, 2016 , with an annual interest rate between 4.5% and 12.0% . All loans mature between 2026 and 2029 . Principal and interest are due and payable in arrears monthly or quarterly and on the maturity dates of the credit facilities. During the second quarter of 2016, the Company repaid $23.6 million of Indian term debt with variable rates. As of June 30, 2016 , the Azure and ESP Urja power plants, which have term debt financed with a U.S. dollar-denominated term debt from OPIC, had a combined outstanding principal amount of approximately $18.4 million . The term debt matures in September and December of 2026 and bears fixed interest at a rate of 4.5% and 4.7% per annum, respectively. Interest and principal amortization payments are made on a quarterly basis. As of June 30, 2016 and December 31, 2015 , the Azure and ESP Urja project companies were not in compliance with certain covenants due to the SunEdison Bankruptcy, failure to file audited financial statements, and a delay by local authorities to complete the classification of a portion of the project sites as non-agricultural use. In addition, the Azure project company was not in compliance with certain financial ratio covenants due to changes in foreign currency valuations. Thus the debt balances are classified as current as of June 30, 2016 and December 31, 2015 . These defaults also prevent the Azure and ESP Urja project companies from making distributions and provide OPIC with the right to accelerate the debt maturity. The Company is currently working with OPIC to cure such defaults. As of June 30, 2016 , the Corporate Season power plant in Malaysia has term debt from Standard Chartered Bank with an outstanding principal amount of $6.1 million . The term debt matures in 2028 , and bears a variable interest rate tied to the Kuala Lumpur Interbank Offered Rate. The interest rate as of June 30, 2016 was 4.0% . Principal and interest are due and payable in arrears at the end of each fiscal quarter or on the maturity date of the credit facility. As of June 30, 2016 , the Corporate Season project company was not in compliance with certain covenants due to the failure by the Corporate Season project company to file its 2015 audited financial statements. Thus, the debt balances are classified as current as of June 30, 2016 . However, in July 2016 the Corporate Season project company successfully filed its 2015 audited financial statements, bringing the debt back into compliance with the applicable covenants and curing the default. The Silverstar Pavilion and Fortune 11 power plants in Malaysia have outstanding loans with a holder of a non-controlling interest in such power plants in the aggregate amount of $1.2 million as of June 30, 2016 and with a fixed 4.0% interest rate. Each of the project level financing agreements contains customary representations, covenants and warranties of the respective borrower including limitations on business activities, guarantees, environmental issues, power plant maintenance standards and a minimum debt service coverage ratio requirement. In particular, these agreements contain financial and other restrictive covenants that limit the project companies' ability to make distributions or otherwise engage in activities that may be in its long-term best interests. The project level financing agreements generally prohibit distributions from the project companies unless certain specific conditions are met, including the satisfaction of certain financial ratios. Debt Extinguishments In December 2015, the Company’s Board approved a $40.0 million open market repurchase program for the Company’s Senior Notes. The repurchase program began in December 2015 and continued through January 2016. As of December 31, 2015, $8.6 million of the Senior Notes were repurchased for $6.8 million , and the Company paid $0.4 million of accrued interest and prepayment fees. As of December 31, 2015, $0.4 million was included in accounts payable on the consolidated balance sheet representing principal and interest due to an investment bank for repurchases completed in December 2015 but settled in January 2016. In January 2016, the Company repurchased $41.0 million of the Senior Notes for $33.2 million and paid $1.9 million of interest and prepayment fees. In total, the Company repurchased $49.6 million of the Senior Notes for $40.0 million plus prepayment fees and interest of $2.3 million . A gain on extinguishment of debt of $6.3 million was recognized in the first quarter of 2016 related to these repurchases. During the second quarter of 2016, the Company repaid $23.6 million of Indian term debt with variable rates, resulting in a $0.4 million loss on extinguishment of debt. Interest Income Interest expense in the unaudited condensed consolidated statements of operations is presented net of interest income. During the three -month and six-month periods ended June 30, 2016 the Company received interest income of $0.9 million and $3.2 million, respectively, from its cash and cash equivalents balances, short-term investments and restricted deposit accounts. The Company received no interest income during the three -month and six- month periods ended June 30, 2015 . Maturities The aggregate amounts of contractual payments of long-term debt due after June 30, 2016 , excluding amortization of debt discounts and premiums, as stated in the financing agreements, are as follows: Maturities (1) (In thousands) Within 1 Year Year 1 through Year 2 Year 2 through Year 3 Year 3 through Year 4 Year 4 through Year 5 Thereafter Total Corporate $ — $ — $ — $ 135,000 $ — $ 752,445 $ 887,445 Project level $ 12,617 $ 8,145 $ 10,176 $ 14,613 $ 17,221 $ 283,509 $ 346,281 Total debt $ 12,617 $ 8,145 $ 10,176 $ 149,613 $ 17,221 $ 1,035,954 $ 1,233,726 (1) Represents the contractual principal payment due dates for our long-term debt and does not reflect the reclassification of $319.9 million of long-term debt to current as a result of debt defaults under a portion of our non-recourse financing agreements or deferred financing costs that are included with the net long-term balance of the unaudited condensed consolidated balance sheet. Events of Default On April 21, 2016, SunEdison and certain of its domestic and international subsidiaries voluntarily filed for protection under Chapter 11 of the U.S. Bankruptcy Code (the “SunEdison Bankruptcy”). Our Revolver and indenture governing our Senior Notes do not include an event of default provision triggered by the SunEdison Bankruptcy. However, the project level financing agreements for our two remaining levered power plants in India and our three power plants in South Africa contain provisions that provide the lenders with the right to accelerate debt maturity due to the SunEdison Bankruptcy as a result of SunEdison being an original sponsor of the project and/or party to certain material project agreements, such as operation and maintenance ("O&M") and engineering, procurement and construction related contracts. In addition, certain audited financial statements at the project level have been delayed, which has created defaults at the project level for our levered power plants. If not cured or waived, these defaults restrict the ability of the project companies to make distributions or may provide the lenders with the right to accelerate debt maturity. As of June 30, 2016 and December 31, 2015 , the outstanding debt balances of these power plants are classified as current. We have obtained waivers and/or forbearance agreements with respect to certain of these defaults, and we are currently working with the applicable project lenders to cure the defaults. On June 16, 2016, Global Operating LLC received a breach of agreement notice from one of its foreign currency hedging counterparties under the International Swap Dealers Association, Inc. ("ISDA") Master Agreement dated August 6, 2015 (the “ISDA Agreement”). The notice stated that because the applicable foreign currency hedging counterparty did not receive the audited financial statements of the Company within 120 days following the end of the fiscal year, as required under the ISDA Agreement, there would be an event of default under the ISDA Agreement if this deficiency is not remedied within 30 days after the date of the notice. On July 19, 2016, Global Operating LLC and the applicable foreign currency hedging counterparty entered into an amendment to the ISDA Agreement (the “Amendment”). The Amendment extended the date by which the Company must deliver to the applicable foreign currency hedging counterparty the audited financial statements of the Company for the year ended December 31, 2015 to the date such statements were to be delivered under the Revolver. See above in this Note 8 - Long-Term Debt for additional information on the date such statements were to be delivered under the Revolver. The Company complied with this obligation.

Income Taxes

Income Taxes	6 Months Ended
	Jun. 30, 2016
Income Tax Disclosure [Abstract]
Income Taxes	INCOME TAXES The income tax provision consisted of the following: Three Months Ended June 30, Six Months Ended June 30, (In thousands, except effective tax rate) 2016 2015 2016 2015 Income (loss) before income tax expense $ 7,742 $ (23,347 ) $ 2,352 $ (33,454 ) Income tax expense (benefit) 2,061 (668 ) 2,919 450 Effective tax rate 26.6 % 2.9 % 124.1 % (1.3 )% The Company records income tax expense each quarter using its best estimate of the full year’s effective tax rate. The Company regularly reviews its deferred tax assets for realizability, taking into consideration all available evidence, both positive and negative, including cumulative losses, projected future pre-tax and taxable income (losses), the expected timing of the reversals of existing temporary differences and the expected impact of tax planning strategies. As of June 30, 2016 , TerraForm Global, Inc. owned 64.8% of Global LLC and consolidates the results of Global LLC through its controlling interest. The Company records SunEdison's 35.2% ownership of Global LLC as a non-controlling interest in the financial statements. Global LLC is treated as a partnership for income tax purposes. For the six months ended June 30, 2016, the overall effective tax rate was different than the statutory rate of 35.0% primarily due to valuation allowances, tax holiday benefits, projected minimum taxes in foreign jurisdictions, and gross receipt taxes in Brazil. As of June 30, 2016 , most jurisdictions were in a net deferred tax asset position. A valuation allowance is recorded against some of the projects with deferred tax assets, primarily because of the historical losses in those jurisdictions.

Derivatives

Derivatives	6 Months Ended
	Jun. 30, 2016
Derivative Instruments and Hedging Activities Disclosure [Abstract]
Derivatives	DERIVATIVES As part of the Company’s risk management strategy, the Company has entered into derivative instruments which include interest rate swaps, foreign currency contracts and cross currency swaps to mitigate interest rate and foreign currency exposure. If the Company elects to do so and if the instrument meets the criteria specified in ASC 815, Derivatives and Hedging , the Company designates its derivative instruments as cash flow hedges. The Company enters into interest rate swap agreements in order to hedge the variability of expected future cash interest payments. Cross currency swaps are used to reduce risks arising from the change in fair value of certain foreign currency denominated assets and liabilities in order to minimize the impact of foreign currency fluctuations on operating results. The Company does not use derivative instruments for speculative purposes. Activities related to derivative instruments were reported in the line items as of and for the periods indicated, as follows: (In thousands) Fair Value As of Type of Instrument Balance Sheet Classification June 30, 2016 December 31, 2015 Derivatives designated as hedging: Interest rate swaps Other assets (liabilities) $ (2,329 ) $ 6,210 Accumulated other comprehensive loss (income) 2,329 (6,210 ) Cross currency swaps Other assets 50,566 64,083 Accumulated other comprehensive loss 9,779 1,202 Derivatives not designated as hedging: Interest rate swaps Other assets $ 412 $ 5,194 Foreign currency forward contracts Other (liabilities) assets (9,549 ) 21,383 (In thousands) Three Months Ended June 30, Six Months Ended June 30, Type of Instrument Statement of Operations Classification 2016 2015 2016 2015 Derivatives not designated as hedging: Interest rate swaps Interest income $ (1,813 ) $ (1,064 ) $ (4,782 ) $ (470 ) Currency forward contract Other expenses, net 14,021 — 32,184 — The foreign currency contracts were set up in August of 2015, as such there was no income or expense as of June 30, 2015 . Certain derivative contracts contain provisions providing the counterparties a lien on specific assets as collateral. There was no cash collateral received or pledged as of June 30, 2016 and December 31, 2015 related to the Company's derivative transactions. Derivatives Designated as Hedges Interest Rate Swaps The Company has entered into interest rate swap agreements to hedge variable rate project level debt. These interest rate swaps qualify for hedge accounting and are designated as cash flow hedges. Under the interest rate swap agreements, the power plant pays a fixed rate and the counterparty to the agreement pays a variable interest rate. No amounts deferred in other comprehensive income were reclassified into earnings during the three and six months ended June 30, 2016 and 2015 . Cross Currency Swaps The Company has entered into cross currency swap agreements to hedge its exposure to foreign currency fluctuations on debt denominated in U.S. dollars. These cross currency rate swaps qualify for hedge accounting and were designated as cash flow hedges. The amounts deferred in other comprehensive income and reclassified into earnings during the period related to these cross currency swaps was $5.9 million . There was no ineffectiveness recorded for the periods presented. Derivatives Not Designated as Hedges Interest Rate Swaps The Company has entered into interest rate swap agreements that economically hedge the cash flows for project level debt. These interest rate swaps pay a fixed rate and the counterparties to the agreements pay a variable interest rate. The changes in fair value are recorded in interest expense, net in the consolidated statements of operations as these hedges are not accounted for under hedge accounting. Foreign Currency Contracts The Company transacts business in various foreign currencies and has established a program that primarily utilizes foreign currency contracts to offset the risks associated with the effects of certain foreign currency exposures. The Company does not use these foreign currency contracts for trading purposes nor does it designate these forward contracts as hedging instruments pursuant to ASC 815. As of June 30, 2016 , the notional amounts of the foreign currency contracts the Company held to purchase U.S. dollars in exchange for other major international currencies were $293.1 million . Included in the Company’s non-operating income was $14.0 million and $32.2 million of net losses related to these foreign currency contracts for the three and six months ended June 30, 2016 , respectively, that hedge the purchase of foreign currencies for investments in acquisitions and debt extinguishments was a result of devaluation as compared to the U.S. dollar in the Brazilian real (BRL), Chinese yuan renminbi (CNY), Indian rupee (INR), Malaysian ringgit (MYR), South African rand (ZAR) and Thai baht (THB). The fair value of the Company’s outstanding foreign currency forward contracts was a net liability of $ 9.0 million as of June 30, 2016 . The cash flow related to foreign currency contracts that remain outstanding are classified as operating activities. The cash flows associated with foreign currency contract settlements are classified as investing activities. The net loss relating to investments is partially offset by the lower cost associated with the cash flows related to the acquisitions and debt extinguishments that were hedged. Notional Amounts (In thousands) Notional Amounts as of June 30, 2016 Derivatives designated as hedges: Interest rate swaps (USD) 121,213 Cross currency swaps (USD) 121,213 Derivatives not designated as hedges: Interest rate swaps (USD) 113,612 Currency forward contracts (BRL) 87,333 Currency forward contracts (CNY) 34,192 Currency forward contracts (INR) 85,904 Currency forward contracts (MYR) 7,940 Currency forward contracts (THB) 11,408 Currency forward contracts (ZAR) 38,691 Currency forward contracts (USD) 27,651

Fair Value of Financial Instrum

Fair Value of Financial Instruments	6 Months Ended
	Jun. 30, 2016
Fair Value Disclosures [Abstract]
Fair Value of Financial Instruments	FAIR VALUE OF FINANCIAL INSTRUMENTS The fair value of assets and liabilities are determined using either unadjusted quoted prices in active markets (Level 1) or pricing inputs that are observable (Level 2) whenever that information is available and using unobservable inputs (Level 3) to estimate fair value only when relevant observable inputs are not available. The Company uses valuation techniques that maximize the use of observable inputs. Assets and liabilities are classified in their entirety based on the lowest priority level of input that is significant to the fair value measurement. Where observable inputs are available for substantially the full term of the asset or liability, the instrument is categorized in Level 2. If the inputs into the valuation are not corroborated by market data, in such instances, the valuation for these contracts is established using techniques including extrapolation from or interpolation between actively traded contracts as well as the calculation of implied volatilities. When such inputs have a significant impact on the measurement of fair value, the instrument is categorized as Level 3. The Company regularly evaluates and validates the inputs used to determine fair value by using pricing services to support the underlying market price of interest rates and foreign currency exchange rates. Fair Value of Debt The following table presents the carrying amount and estimated fair value of our outstanding short-term and long-term debt obligations as of June 30, 2016 and December 31, 2015 , respectively: As of June 30, 2016 As of December 31, 2015 (In thousands) Carrying Amount Fair Value Carrying Amount Fair Value Long-term debt, including current portion $ 1,233,726 $ 1,148,307 $ 1,295,761 $ 1,125,124 The fair value of the Company’s long-term debt was determined using inputs classified as Level 2 and a discounted cash flow approach using market rates for similar debt instruments. Recurring Fair Value Measurements The following table summarizes the financial instruments measured at fair value on a recurring basis classified in the fair value hierarchy (Level 1, 2 or 3) based on the inputs used for valuation in the accompanying unaudited condensed consolidated balance sheets as of June 30, 2016 and in the audited condensed consolidated balance sheets as of December 31, 2015 : As of June 30, 2016 As of December 31, 2015 Assets (liabilities) in thousands Level 1 Level 2 Level 3 Total Level 1 Level 2 Level 3 Total Interest rate swaps $ — $ (1,917 ) $ — $ (1,917 ) $ — $ 11,404 $ — $ 11,404 Foreign currency forward contracts (9,549 ) — — (9,549 ) 21,383 — — 21,383 Cross currency swaps — 50,566 — 50,566 — 64,083 — 64,083 Total $ (9,549 ) $ 48,649 $ — $ 39,100 $ 21,383 $ 75,487 $ — $ 96,870 The Company uses a discounted valuation technique to fair value its derivative assets and liabilities. The primary inputs into the valuation of interest rate swaps and foreign currency contracts are forward interest rates, foreign currency exchange rates, and to a lesser degree, credit spreads. The Company’s interest rate swaps and cross currency swaps are considered Level 2, since all significant inputs are corroborated by market observable data. There were no transfers into or out of Level 1, Level 2 and Level 3 during the periods ended June 30, 2016 and December 31, 2015 .

Stockholders' Equity

Stockholders' Equity	6 Months Ended
	Jun. 30, 2016
Equity [Abstract]
Stockholders' Equity	STOCKHOLDERS’ EQUITY Outstanding Equity Securities As of June 30, 2016 , the following shares of the Company were outstanding: Class: Number Outstanding Holders Class A common stock 113,101,162 * Class B common stock 61,343,054 SunEdison Class B1 common stock — Not Applicable Preferred stock — Not Applicable Total shares outstanding 174,444,216 *Class A common stockholders are comprised of: public stockholders, Renova Energia SA, BTSA Netherlands Cooperatie UA, executive officers, management and employees. Treasury Stock As of June 30, 2016 , the Company owned 5,244 treasury shares of Class A common stock. All of these treasury shares were acquired in exchange for the settlement of future tax obligations related to stock-based compensation arrangements. Dividends On February 29, 2016, the Company declared a quarterly dividend for the fourth quarter of 2015 on the Company’s Class A common stock of $0.275 per share, or $1.10 per share on an annualized basis. The dividend was paid on March 17, 2016 to stockholders of record as of March 10, 2016. The Company has not declared or paid a dividend for the first, second, third or fourth quarter of 2016. As a result of the SunEdison Bankruptcy, the limitations on our ability to access the capital markets for our corporate debt and equity securities, and other risks that we face as detailed in within unaudited quarterly report, we believe it is prudent to defer any decisions on paying dividends to our stockholders for the time being.

Stock-Based Compensation

Stock-Based Compensation	6 Months Ended
	Jun. 30, 2016
Disclosure of Compensation Related Costs, Share-based Payments [Abstract]
Stock Based Compensation	STOCK-BASED COMPENSATION The TerraForm Global, Inc. 2014 Long-Term Incentive Plan (the “Incentive Plan”) provides for the award of incentive and non-qualified stock options, stock appreciation rights, restricted stock awards (“RSAs”) and restricted stock units (“RSUs”) to employees and non-employee directors, including employees and non-employee directors of SunEdison. The maximum contractual term of an award is 10 years from the date of grant. Shares issued under the plan may be authorized and unissued shares or treasury shares. As of June 30, 2016 , the Company had authorized 17,884,910 shares for awards under the Incentive Plan and 9,331,045 shares remained available for future grant under this plan. Stock-based compensation expense is recorded as a component of general and administrative expenses in the Company’s unaudited condensed consolidated statements of operations and totaled $0.9 million and $2.0 million for the three and six month periods ended June 30, 2016 , respectively. No stock-based compensation expense was recognized in the three and six month periods ended June 30, 2015 . Employee benefit related costs, including stock-based compensation costs related to equity awards in the stock of SunEdison, Inc. and its consolidated subsidiaries, of SunEdison employees who provide services to the Company are allocated to the Company based on the relative percentage of their time that the employee spends providing service to the Company. The amount of stock-based compensation expense related to equity awards in the stock of SunEdison and its consolidated subsidiaries which has been allocated to the Company was $0.7 million and $1.6 million for the three and six month periods ended June 30, 2016 and is reflected in the unaudited condensed consolidated statements of operations within general and administrative costs and has been treated as an equity contribution from SunEdison on the unaudited condensed consolidated statements of stockholders' equity. Similarly, stock-based compensation costs related to equity awards to SunEdison employees in the Company’s stock are allocated to SunEdison based on the relative percentage of their time that the employee spends providing service to SunEdison. The amount of stock-based compensation expense related to equity awards in our stock which has been allocated to SunEdison was $0.7 million and $2.0 million for the three and six month periods ended June 30, 2016 , respectively, and was recognized as a distribution to SunEdison on the unaudited condensed consolidated statements of stockholders' equity with no impact to the Company’s unaudited condensed consolidated statements of operations. Restricted Stock Awards RSAs provide the holder with immediate voting rights, but are restricted in all other respects until vested. Upon a termination of employment for any reason, any unvested shares of Class A common stock held by the terminated participant will be forfeited. All unvested RSAs are paid dividends and distributions. The following table presents information regarding outstanding RSAs as of June 30, 2016 and changes during the six -month period then ended, after giving effect to the conversion of restricted Class C common stock to restricted Class A common stock on a 178.8491 -for- one basis: Number of RSAs Outstanding Weighted Average Grant Date Fair Value Per Share Aggregate Intrinsic Value Outstanding at January 1, 2016 7,774,554 $ 0.18 Forfeited (1,749,137 ) 0.18 Outstanding at June 30, 2016 6,025,417 $ 0.17 $ 19.6 As of June 30, 2016 , $1.5 million of total unrecognized compensation cost related to RSAs is expected to be recognized over a weighted average period of approximately 3.2 years. The weighted-average fair value of RSAs per share on the date of grant was $0.17 for the six -month period ended June 30, 2016 . No RSAs were granted for the six -month period ended June 30, 2016 . On September 26, 2014 and March 31, 2015, the Company granted 31,350 and 35,245 shares of restricted Class C common stock, respectively (or 5,606,918 and 6,303,519 shares, respectively, of restricted Class A common stock after giving effect to conversion of restricted Class C common stock to restricted Class A common stock on a 178.8491 -for-one basis immediately prior to the completion of the IPO). Subject to accelerated vesting upon certain events, 25.0% of the restricted Class A common stock will vest on the first through fourth anniversary of the date of the IPO. The fair value of each grant was determined by using the percentage of shares granted multiplied by the overall fair value of SunEdison’s equity in the Company. In estimating the fair value of the RSAs, the primary valuation considerations were an enterprise value determined from a discounted cash flow of income-based approach, using a present value of after-tax probability weighted equity cash flow of those power plants expected to be included in the IPO, in a projection period extending through December 2024 and a lack of marketability discount of 10.0% and 5.0% for the September 26, 2014 and March 31, 2015 grants, respectively. The discount model used the following assumptions: a time to liquidity event of seven months and three months; a discount rate of 13.0% and 12.0% ; and volatility of 40.0% over the time to a liquidity event for the September 26, 2014 and March 31, 2015 grants, respectively. Estimates of the volatility of the Company’s Class A common stock were based on available information on the volatility of SunEdison and the common stock of comparable publicly traded companies. Restricted Stock Units RSUs will not entitle the holders to voting rights and holders of the RSUs will not have any right to receive dividends or distributions. The following table presents information regarding outstanding RSUs as of June 30, 2016 and changes during the six -month period then ended, after giving effect to the conversion of restricted Class C common stock to restricted Class A common stock on a 178.8491 -for- one basis: Number of RSUs Outstanding Aggregate Intrinsic Value (in millions) Weighted Average Remaining Balance at January 1, 2016 2,846,049 Granted 403,737 Forfeited (733,839 ) Balance at June 30, 2016 2,515,947 $ 8.2 1.6 As of June 30, 2016 , $17.6 million of total unrecognized compensation cost related to RSUs is expected to be recognized over a weighted average period of approximately 2.3 years. As of January 30, 2017, the Company has 2,382,487 RSUs outstanding. On December 22 and 23, 2015, the Company granted 2,024,800 Class A RSUs to certain employees and executive officers. These are time-based awards which will vest on the following schedule: 25% after one year, 25% after two years, and 50% after three years. The grant date fair value of these awards was $11.0 million which will be recognized as compensation cost on a straight line basis over the three -year service period. On September 26, 2014 and March 31, 2015, the Company granted 1,550 and 2,750 Class C RSUs, respectively (or 277,216 and 491,835 Class A RSUs, respectively, after giving effect to conversion of Class C RSUs to Class A RSUs on a 178.8491 -for-one basis immediately prior to the completion of the IPO). Subject to accelerated vesting upon certain events, 25% of the Class A RSUs will vest on the first through fourth anniversary of the date of the IPO.

Earnings (Loss) Per Share

Earnings (Loss) Per Share	6 Months Ended
	Jun. 30, 2016
Earnings Per Share [Abstract]
Earnings (Loss) Per Share	LOSS) PER SHARE Earnings (loss) per share (“EPS”) is calculated utilizing the weighted average shares outstanding. Under the two-class method, unvested RSAs that contain non-forfeitable rights to dividends are treated as participating securities and are included in the EPS computation to the extent that there are undistributed earnings available. These securities do not participate in losses. Class A Common Stock Basic and diluted earnings (loss) per share for the three and six months ended June 30, 2016 was calculated as follows: Three Months Ended June 30, 2016 Six Months Ended June 30, 2016 (In thousands, except per share amounts) Basic and diluted earnings (loss) per share (1) : Net income (loss) attributable to Class A common stockholders $ 1,097 $ (3,535 ) Less: dividends paid on Class A common stock and participating RSAs — 30,674 Undistributed loss attributable to Class A stockholders $ 1,097 $ (34,209 ) Weighted-average shares outstanding 106,856 106,856 Distributed earnings per share $ — $ 0.29 Undistributed earnings (loss) per share 0.01 (0.32 ) Basic and diluted earnings (loss) per share $ 0.01 $ (0.03 ) (1) The computation for diluted loss per share for the six months ended June 30, 2016 excludes 61,343,054 shares of Class B common stock, 6,245,398 unvested RSAs, and 2,515,947 unvested RSUs because the effect would have been anti-dilutive.

Non-Controlling Interests

Non-Controlling Interests	6 Months Ended
	Jun. 30, 2016
Noncontrolling Interest [Abstract]
Non-Controlling Interests	NON-CONTROLLING INTERESTS Non-controlling interests represent the portion of net assets in consolidated entities that are not owned by the Company. The following table presents the non-controlling interest balances by entity, reported in stockholders’ equity in the unaudited condensed consolidated balance sheets as of June 30, 2016 and December 31, 2015 : (in thousands) As of June 30, 2016 As of December 31, 2015 SunEdison's non-controlling interests in Global LLC $ 395,732 $ 375,540 Non-controlling interests in power plants 91,382 105,566 Total non-controlling interests $ 487,114 $ 481,106 As of June 30, 2016 , TerraForm Global, Inc. owned 64.8% of Global LLC and consolidated the results of Global LLC through its controlling interest, with SunEdison's 35.2% interest shown as a non-controlling interest.

Commitments and Contingencies

Commitments and Contingencies	6 Months Ended
	Jun. 30, 2016
Commitments and Contingencies Disclosure [Abstract]
Commitments and Contingencies	COMMITMENTS AND CONTINGENCIES Commitments to Acquire Power Plants In April 2015, the Company entered into purchase and sale agreements to acquire controlling interests in three operating power plants located in South Africa with an aggregate net capacity of 32.6 MW from BioTherm. The aggregate consideration payable for these three power plants is approximately $74.5 million . See Note 3 - Acquisitions for additional discussion of these commitments. Legal Proceedings Initiated Against the Company Project Litigation GUVNL Litigation The Company is subject to litigation with Gujarat Urja Vikas Nigam Limited (“GUVNL”), the offtake counterparty for certain power plants in India, which is seeking a reduction of the tariff set forth in the applicable PPAs. In separate litigation, GUVNL also claims that there has been a violation of the terms of certain PPAs between GUVNL and the applicable project companies on account of a change in stockholders since execution of such PPAs, and as such GUVNL is entitled to terminate such PPAs. The Company successfully defended each case at the first court level and an appeal of each case was dismissed by the appellate level, but GUVNL has appealed to the Supreme Court of India on each matter. The cases are currently pending with the Supreme Court of India. The Company believes that the likelihood of an unfavorable outcome is remote. Honiton Litigation The Company was subject to pending litigation proceedings with Suzlon Energy (Tianjin) Limited (“SETL”) with respect to alleged breaches of a turbine supply contract relating to the Honiton wind power plants in China. The operation and maintenance service contracts claim pending before an arbitral tribunal was resolved on December 3, 2015, pursuant to which the Company was required to pay an award of approximately $0.5 million , which was paid in January 2016. On June 3, 2016, SETL and the Company reached a settlement resolving all remaining disputes relating to the turbine contracts. The terms of this final settlement resulted in SETL assigning all rights as a creditor it held against the Company to Beijing Aliyun Investment and Consulting Co. Ltd. (“Aliyun”). In addition, the Company agreed to pay Aliyun $7.1 million (RMB 47.0 million ), of which RMB 45.0 million was paid during the second quarter of 2016, and the remaining RMB 2.0 million is due no later than July 2018, subject to various conditions set forth in the settlement agreement. In accordance with the settlement agreement, SETL withdrew its pending claims against the Company. As of June 30, 2016 a liability was recognized related to the proceedings in the amount of $0.3 million (RMB 2.0 million ). Bankruptcy Court Action Motion to Stay and Motion to Compel Mediation On November 2, 2016, the unsecured creditors’ committee in the SunEdison Bankruptcy filed an adversary complaint against the Company and others with the U.S. Bankruptcy Court for the Southern District of New York. The complaint and contemporaneous motion to stay seek to stay pending litigation against current and former directors and officers of SunEdison, including TerraForm Global, Inc. v. SunEdison, Inc., et al., the Company’s action against SunEdison described below. The unsecured creditors’ committee intends to file a derivative action on behalf of the SunEdison bankruptcy estate against current and former SunEdison officers and directors. It has requested the stay in order to preserve the proceeds of SunEdison’s directors’ and officers’ liability insurance policies. On November 4, 2016, the unsecured creditors’ committee filed a motion in the SunEdison Bankruptcy case for derivative standing to sue various current and former SunEdison officers and directors. The unsecured creditors’ committee filed an amended adversary complaint on November 9, 2016. As described in a motion to compel mediation filed by SunEdison on November 23, 2016, SunEdison and the unsecured creditors’ committee have agreed to hold the motion to stay and any proposed claims by the unsecured creditors’ committee against various current and former SunEdison officers and directors in abeyance pending a global mediation relating to insurance issues. The Company’s objection to the motion to stay and the motion to compel mediation was filed on December 1, 2016. Given the preliminary nature of the claims, the Company is unable to provide any assurances as to the ultimate outcome of these motions or that an adverse resolution of legal proceedings would not have a material adverse effect on the Company’s consolidated financial position and results of operations. Avoidance Actions On November 7, 2016, the unsecured creditors’ committee in the SunEdison Bankruptcy filed a motion with the bankruptcy court seeking standing to assert against the Company, on behalf of SunEdison, avoidance claims arising from intercompany transactions between the Company and SunEdison. The Company’s objection to the standing motion was filed on November 29, 2016. The Company expects to vigorously contest this standing motion and, if standing is granted, the underlying avoidance claims. Furthermore, the Company is currently engaged in settlement discussions with SunEdison and certain of SunEdison’s stakeholders to resolve, among other issues, intercompany claims and defenses between the Company and SunEdison. While these settlement discussions remain ongoing and there can be no guaranty that a settlement will be reached, the Company believes that a successful settlement could facilitate the Company’s exploration of strategic alternatives. Any settlement would be subject to the approval of the bankruptcy court in the SunEdison Bankruptcy. Given the preliminary nature of the claims, the Company is unable to provide any assurances as to the ultimate outcome of these claims or that an adverse resolution of a legal proceeding, if commenced, would not have a material adverse effect on the Company’s consolidated financial position and results of operations. Renova Arbitration On July 14, 2016, Renova Energia, S.A. (“Renova”) filed a request for arbitration against TerraForm Global, Inc., TerraForm Global, LLC, TerraForm Global Brazil Holding B.V. and TERP GLBL Brasil I Participacoes S.A. in the Center for Arbitration and Mediation of the Chamber of Commerce Brazil-Canada. Renova alleges, among other things, that TerraForm Global, Inc. and certain of its subsidiaries listed above: (i) fraudulently induced Renova to enter into the acquisition agreements related to the Salvador and Bahia wind power projects, the omnibus closing agreement with respect to such acquisitions, and the put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction based on misleading and false representations about their and SunEdison’s financial condition and prospects; (ii) aided and abetted SunEdison’s fraud; (iii) negligently misrepresented their and SunEdison’s financial conditions and prospects; (iv) committed related violations of federal and state securities laws; (v) breached express warranties under the applicable acquisition agreements; (vi) wrongfully refused to repurchase from Renova seven million shares of TerraForm Global Class A common stock pursuant to Renova’s put exercise notice of March 31, 2016, in breach of the put/call arrangement entered into between SunEdison and Renova in connection with the Renova Transaction; and (vii) unjustly enriched themselves. Renova seeks, among other relief, rescission of the Salvador and Bahia transactions, and/or damages in an amount to be determined in the arbitration of not less than $250 million , representing the drop in value of the approximately 20 million shares of TerraForm Global Class A common stock Renova received in the Salvador transaction, from its $15 /share IPO price to its trading level of approximately $3.38 /share at the time the request for arbitration was filed, as well as other related losses. Given the preliminary nature of the arbitration, the Company is unable to provide any assurances as to the ultimate outcome of these proceedings or that an adverse resolution of the arbitration would not have a material adverse effect on the Company’s consolidated financial position and results of operations. Securities Litigation Multidistrict Litigation On July 27, 2016, lead plaintiff Municipal Employees’ Retirement System of Michigan in the Horowitz et. al v. SunEdison, Inc. et al. action (E.D. Mo.) moved to transfer various actions pending in federal district courts to the U.S. District Court for the Southern District of New York (the "SDNY") for consolidated or coordinated pretrial proceedings before the Multidistrict Litigation Panel. On October 4, 2016, the Multidistrict Litigation Panel issued an order transferring the following cases to the SDNY for consolidated or coordinated pretrial proceedings: • Fraser v. Wuebbels et al. • Iron Workers Mid-South Pension Fund v. TerraForm Global, Inc. et al. • Badri v. TerraForm Global, Inc. et al. • Patel v. TerraForm Global, Inc. et al. • Pyramid Holdings, Inc. v. TerraForm Global, Inc. et al. • Beltran v. TerraForm Global, Inc. et al. • Oklahoma Firefighters Pension & Retirement System v. SunEdison, Inc. et al. • Glenview Capital Partners, L.P. et al. v. SunEdison, Inc. et al. • Omega Capital Investors et al. v. SunEdison, Inc. et al. Four of these actions, Fraser v. Wuebbels et al., Iron Workers Mid-South Pension Fund v. TerraForm Global, Inc. et al., Badri v. TerraForm Global, Inc. et al., and Patel v. TerraForm Global, Inc. et al., were initially filed in the Superior Court of the State of California for the County of San Mateo on October 23, 2015, December 3, 2015, December 9, 2015 and January 4, 2016, respectively. These four separate purported class actions were filed against the Company, certain of its officers and directors, each of the underwriters of the Company’s IPO, and SunEdison. A separate class action, Agrawal v. TerraForm Global, Inc. et al., was filed in the Superior Court of the State of California for the County of San Mateo on October 30, 2015. This action was voluntarily dismissed without prejudice in February 2016. Additionally, two separate purported class action lawsuits, Beltran v. TerraForm Global, Inc. et al. and Pyramid Holdings, Inc. v. TerraForm Global, Inc. et al., were filed on October 29, 2015 and November 5, 2015, respectively, in the U.S. District Court for the Northern District of California against the same defendants. The class action plaintiffs assert claims under Sections 11, 12(a)(2), and 15 of the Securities Act of 1933, as amended (the “Securities Act”). The class action complaints allege, among other things, that the defendants made false and materially misleading statements and failed to disclose material information in the Company's registration statement for the IPO regarding SunEdison and its recent operating results and business strategy. Among other relief, the class action complaints seek class certification, unspecified compensatory damages, rescission, attorneys’ fees, costs, and such other relief as the court should deem just and proper. On April 26, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the remaining state actions to the U.S. District Court for the Northern District of California. On May 27, 2016, the plaintiffs in the cases removed from state court filed motions to remand. On June 1, 2016, the defendants filed motions to transfer the cases to the SDNY, the jurisdiction in which SunEdison’s bankruptcy is pending. The previous briefing schedule has been vacated as a result of the October 4, 2016 transfer order issued by the Multidistrict Litigation Panel. On November 3, 2016, Plaintiff in Patel v. TerraForm Global, Inc. et al. voluntarily dismissed the case. On December 22, 2016, the court consolidated Pyramid Holdings, Inc. v. TerraForm Global, Inc. et al., Badri v. TerraForm Global, Inc. et al., Iron Workers Mid-South Pension Fund v. TerraForm Global, Inc. et al., and Fraser v. Wuebbels et al. as In re TerraForm Global, Inc. and ordered the plaintiffs to file a consolidated complaint. On January 16, 2017, the plaintiffs filed the Consolidated Class Action Complaint. On December 20, 2016, Plaintiff in Beltran v. TerraForm Global, Inc. et al. voluntarily dismissed the case. The Company is in the preliminary stages of reviewing the allegations made in the remaining complaints and, as a result, is unable to provide any assurances as to the ultimate outcome of these lawsuits or that an adverse resolution of these lawsuits would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On March 29, 2016, plaintiff filed Oklahoma Firefighters Pension & Retirement System v. SunEdison, Inc. et al., in the Superior Court of the State of California for the County of San Mateo against the Company, SunEdison, certain officers and directors of the Company and SunEdison, and the underwriters of the Company’s IPO. The plaintiff asserts claims under Sections 11, 12(a)(2), and 15 of the Securities Act. The complaint alleges, among other things, that the defendants made false and materially misleading statements and failed to disclose material information in the Company's registration statement for the IPO regarding SunEdison and its recent operating results and business strategy. The complaint seeks compensatory damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On April 26, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. On May 27, 2016, the plaintiffs moved to remand. On June 1, 2016, the defendants moved to transfer the case to the SDNY, the jurisdiction in which SunEdison’s bankruptcy is pending. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On March 29, 2016, plaintiffs filed Glenview Capital Partners, L.P. et al. v. SunEdison, Inc. et al., in the Superior Court of the State of California for the County of San Mateo against the Company, SunEdison, certain officers and directors of the Company and SunEdison, and the underwriters of the Company’s August 5, 2015 bond offering and SunEdison’s August 18, 2015 preferred stock offering. The plaintiffs assert claims under Sections 11, 12(a)(2), and 15 of the Securities Act, as well as the Maryland Securities Act. The plaintiffs allege, among other things, that they purchased securities pursuant to offering documents that contained untrue statements of material fact and omitted other material facts necessary to make the statements in the offering documents not misleading. The complaint further alleges that these false and misleading statements led to the forced conversion of the plaintiffs’ Class D securities into restricted common stock, that the Company breached the June 9, 2015 Class D Purchase Agreement between the Company and the plaintiffs, and that the defendants made negligent misrepresentations in connection with the Company’s Class D registration statement. The complaint seeks unspecified damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On April 26, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. On May 26, 2016, the plaintiffs filed a motion to remand. On May 27, 2016, the defendants moved to transfer the case to the SDNY, the jurisdiction in which SunEdison’s bankruptcy is pending. The Court held a hearing on the motion to remand and the motion to transfer on August 18, 2016. On August 26, 2016, the Court issued an order denying the plaintiffs’ motion to remand and granting the defendants’ motion to transfer. The Court also certified a legal issue for interlocutory review, and on September 2, 2016, the plaintiffs filed a petition for permission to appeal with the U.S. Court of Appeals for the Ninth Circuit. On November 17, 2016, the Ninth Circuit issued an order requiring all parties to file statements addressing the effect of the Multidistrict Litigation Panel’s transfer order on the motion for permission to appeal. On December 8, 2016, the parties filed their responses. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On March 30, 2016, plaintiffs filed Omega Capital Investors et al. v. SunEdison, Inc. et al., in the Superior Court of the State of California for the County of San Mateo against the Company, SunEdison, certain officers and directors of the Company and SunEdison, and the underwriters of SunEdison’s preferred stock offering. The plaintiffs assert claims under Sections 11, 12(a)(2), and 15 of the Securities Act, as well as the Maryland Securities Act. The plaintiffs allege, among other things, that the defendants made false and misleading statements in connection with the Company’s IPO, and that these false and misleading statements led to the forced conversion of their Class D securities into restricted common stock. The complaint further alleges that the Company breached the June 9, 2015 Class D Purchase Agreement between the Company and the plaintiffs and made negligent misrepresentations in connection with the Company’s Class D registration statement. The complaint seeks unspecified damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On April 26, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. On May 26, 2016, the plaintiffs filed a motion to remand. On June 1, 2016, the defendants moved to transfer the case to the SDNY, the jurisdiction in which SunEdison’s bankruptcy is pending. The Court held a hearing on the motion to remand and the motion to transfer on August 18, 2016. On August 26, 2016, the Court issued an order denying the plaintiffs’ motion to remand and granting the defendants’ motion to transfer. The Court also certified a legal issue for interlocutory review, and on September 2, 2016, the plaintiffs filed a petition for permission to appeal with the U.S. Court of Appeals for the Ninth Circuit. On November 17, 2016, the Ninth Circuit issued an order requiring all parties to file statements addressing the effect of the Multidistrict Litigation Panel’s transfer order on the motion for permission to appeal. On December 8, 2016, the parties filed their responses. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. Conditional Transfer Cases On October 5, 2016, the Multidistrict Litigation Panel issued conditional transfer orders in three cases, Kingdon Associates et al. v. TerraForm Global, Inc. et al., VMT II LLC v. TerraForm Global, Inc. et al., and Canyon Capital Advisors LLC et al. v. TerraForm Global, Inc. et al. On July 14, 2016, plaintiffs filed Kingdon Associates et al. v. TerraForm Global, Inc. et al. in the Superior Court of the State of California for the County of San Mateo against the Company, TerraForm Global, LLC, certain officers and directors of the Company and SunEdison, and the underwriters of the Company’s IPO. The plaintiffs assert claims under Sections 11, 12(a)(2), and 15 of the Securities Act, as well as state law claims for breach of contract, negligent misrepresentation, and violation of Maryland securities laws. The plaintiffs allege, among other things, that the defendants made false and materially misleading statements and failed to disclose material information in the Company's registration statement for the IPO regarding SunEdison and its recent operating results and business strategy and that these false and misleading statements led to the forced conversion of their Class D securities into restricted common stock. The complaint further alleges that the Company breached the June 9, 2015 Class D Purchase Agreement between the Company and the plaintiffs and made negligent misrepresentations in connection with the Company’s Class D registration statement. The complaint seeks compensatory damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On September 26, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. Plaintiffs did not oppose the Multidistrict Litigation Panel's conditional transfer order. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On August 8, 2016, plaintiffs filed Canyon Capital Advisors LLC et al. v. TerraForm Global, Inc. et al. in the Superior Court of the State of California for the County of San Mateo against the Company, certain officers and directors of the Company and SunEdison, and the underwriters of the Company’s IPO and SunEdison’s August 18, 2015 preferred stock offering. The plaintiffs assert claims under Sections 11, 12(a)(2), and 15 of the Securities Act, as well as the California Corporate Securities Law. The plaintiffs allege, among other things, that they purchased securities pursuant to offering documents that contained untrue statements of material fact and omitted other material facts necessary to make the statements in the offering documents not misleading. The complaint seeks unspecified damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On September 8, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. On September 26, 2016, plaintiffs filed a motion to remand. On October 6, 2016, plaintiffs filed an amended motion to remand. On October 20, 2016, defendants filed their opposition to that motion, and on November 2, 2016, plaintiffs filed their reply. On October 19, 2016, defendants filed a motion to stay the case until a final transfer determination is made by the Multidistrict Litigation Panel. On November 2, 2016, plaintiffs filed an opposition to the motion to stay. The Court held a hearing on the motion to remand and the motion to stay on November 10, 2016. On October 26, 2016, plaintiffs filed a motion to vacate the conditional transfer order. On November 16, 2016, defendants filed an opposition to the motion to vacate. On November 17, 2016, the parties filed a stipulation withdrawing the motions to stay and vacate, which the court entered. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On September 16, 2016, plaintiff filed VMT II LLC v. TerraForm Global, Inc. et al. in the Superior Court of the State of California for the County of San Mateo against the Company, certain officers and directors of the Company and SunEdison, and the underwriters of SunEdison’s preferred stock offering. The plaintiff asserts claims under Sections 11, 12(a)(2), and 15 of the Securities Act, as well as the Maryland Securities Act. The plaintiff alleges, among other things, that the defendants made false and misleading statements in connection with the Company’s IPO, and that these false and misleading statements led to the forced conversion of their Class D securities into restricted common stock. The complaint further alleges that the Company breached the June 9, 2015 Class D Purchase Agreement between the Company and the plaintiffs and made negligent misrepresentations in connection with the Company’s Class D registration statement. The complaint seeks unspecified damages, rescission, and such other relief (including equitable or injunctive relief) as the court may deem just and proper. On September 28, 2016, in light of SunEdison’s voluntary petition for bankruptcy on April 21, 2016, the Company and the other defendants removed the action to the U.S. District Court for the Northern District of California. Plaintiffs did not oppose the Multidistrict Litigation Panel's conditional transfer order. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. On December 19, 2016, an initial case management conference was held in the multidistrict litigation proceedings in the SDNY. The Court entered an order requiring all parties to the multidistrict litigation, including the parties to the conditional transfer cases, to mediate and entered a partial stay of all proceedings through March 31, 2017. Derivative Claim Aldridge v. Blackmore et al. On April 12, 2016, a verified stockholder derivative complaint on behalf of the Company was filed against four directors of the Company in the Court of Chancery of the State of Delaware. The lawsuit alleges that the directors breached their fiduciary duties by authorizing the Company’s $231.0 million payment to SunEdison for the 425 MW India Projects. The complaint seeks unspecified compensatory damages and such other relief that the court may deem just and equitable. The Company filed its answer to the complaint on June 30, 2016. On July 6, 2016, the Company served its responses to the plaintiff’s discovery requests. On December 28, 2016, the parties agreed to stay the litigation and participate in the mediation for the securities litigation cases pending before the Multidistrict Litigation Panel. The Company is in the preliminary stages of reviewing the allegations made in the complaint and, as a result, is unable to provide any assurances as to the ultimate outcome of this lawsuit or that an adverse resolution of this lawsuit would not have a material adverse effect on the Company’s consolidated financial position and results of operations. Retaliation Claims Francisco Perez Gundin Claim On May 18, 2016, the Company’s former director, Francisco Perez Gundin, filed a complaint against the Company, TerraForm Power, Inc., and certain individuals, with the United States Department of Labor. The complaint alleges that the defendants engaged in a retaliatory termination of Mr. Gundin’s employment after he allegedly voiced concerns to SunEdison’s board of directors about public representations made by SunEdison officers regarding SunEdison’s liquidity position, and after he allegedly voiced his opposition to transactions that he alleges were self-interested and which he alleges SunEdison forced on the Company. He alleges that the Company participated in SunEdison’s retaliatory termination by constructively terminating his position as a member of the board of directors of the Company in connection with SunEdison’s constructive termination of his employment. He seeks lost wages, bonuses, benefits, and other money that he alleges that he would have received if he had not been subjected to the allegedly retaliatory termination. The matter will now be adjudicated in an administrative proceeding before the Occupational Safety and Health Administration agency of the United States Department of Labor. On October 17, 2016, the Company filed its Position Statement, which seeks dismissal of the matter in full, in response to the Complaint. Mr. Gundin has not yet filed a response. The Company is in the preliminary stages of reviewing the allegations made in the complaint. As a result, the Company is unable to predict with certainty the ultimate resolution of this proceeding. Carlos Domenech Zornoza Claim On May 10, 2016, the Company’s former director and Chief Executive Officer, Carlos Domenech Zornoza, filed a complaint against the Company, TerraForm Power, Inc., and certain individuals, with the United States Department of Labor. The complaint alleges that the defendants engaged in a retaliatory termination of Mr. Domenech Zornoza’s employment on November 20, 2015 after he allegedly voiced concerns to SunEdison’s board of directors about public representations made by SunEdison officers regarding SunEdison’s liquidity position, and after he allegedly voiced his opposition to transactions that he alleges were self-interested and which he alleges SunEdison forced on the Company. He alleges that the Company participated in SunEdison’s retaliatory termination by terminating his position as Chief Executive Officer of the Company in connection with SunEdison’s termination of his employment. He seeks lost wages, bonuses, benefits, and other money that he alleges that he would have received if he had not been subjected to the allegedly retaliatory termination. The matter will now be adjudicated in an administrative proceeding before the Occupational Safety and Health Administration agency of the United States Department of Labor. On October 17, 2016, the Company filed its Position Statement, which seeks dismissal of the matter in full, in response to the Complaint. Mr. Domenech Zornoza has not yet filed a response. The Company is in the preliminary stages of reviewing the allegations made in the complaint. As a result, the Company is unable to predict with certainty the ultimate resolution of this proceeding. United States Securities and Exchange Commission Investigation On April 21, 2016, the Company received a subpoena for documents and information in connection with an investigation by the Enforcement Division of the staff of the SEC captioned “In the Matter of SunEdison, Inc. (HO-12908).” The Company is cooperating with the investigation, and the outcome or resolution of this matter cannot be predicted at this time. Legal Proceeding Initiated by the Company TerraForm Global, Inc. v. SunEdison, Inc., et al. On April 3, 2016, the Company filed a verified complaint against SunEdison, SunEdison Holdings Corporation (collectively with SunEdison, the “SunEdison Defendants”), Ahmad Chatila, Martin Truong and Brian Wuebbels in the Court of Chancery of the State of Delaware. The complaint asserts claims for breach of fiduciary duty, breach of contract and unjust enrichment relating to the failure by the SunEdison Defendants to transfer the equity interests in the 425 MW India Projects for which the Company paid $231.0 million in the fourth quarter of 2015. The complaint seeks various forms of relief, including a constructive trust upon the equity interests of SunEdison in the 425 MW India Projects, money damages from the defendants, restoration of the $231.0 million to the Company and such other relief as the court may deem just and proper. The claims against the SunEdison Defendants have been stayed as a result of the SunEdison Bankruptcy. The individual defendants filed an answer to the complaint on June 30, 2016. As previously described, the Third Party Sale Transaction is being conducted in connection with SunEdison’s bankruptcy pr

Related Parties

Related Parties	6 Months Ended
	Jun. 30, 2016
Related Party Transactions [Abstract]
Related Parties	RELATED PARTIES SunEdison Bankruptcy On April 21, 2016, SunEdison and certain of its domestic and international subsidiaries voluntarily filed for protection under Chapter 11 of the U.S. Bankruptcy Code (the “SunEdison Bankruptcy”). The Company is not a part of the SunEdison Bankruptcy and does not rely substantially on SunEdison for funding or liquidity. The Company continues to participate actively in the SunEdison Bankruptcy proceedings, and the SunEdison Bankruptcy will continue to have a negative impact on the Company given our complex relationship with SunEdison. During the SunEdison Bankruptcy, SunEdison has not performed substantially as obligated under its agreements with us, including under the Sponsorship Arrangement and certain O&M and asset management arrangements. The Company believes that the Sponsorship Arrangement comprises a single integrated transaction. The agreements comprising the Sponsorship Arrangement are set forth in separate documents and discussed individually in this unaudited quarterly report. However, the elements of the Sponsorship Arrangement are closely related and a default under one element may be a defense to, or excuse performance under, another element. SunEdison and its various stakeholders have expressed disagreement with this view of the Sponsorship Arrangements and can be expected to contest any such assertion in connection with the SunEdison Bankruptcy. The Company is currently engaged in settlement discussions with SunEdison to resolve, among other issues, intercompany claims and defenses. While these settlement discussions remain ongoing and there can be no guaranty that a settlement will be reached, the Company believes that a successful settlement could facilitate the Company’s exploration of strategic alternatives. Any settlement would be subject to the approval of the bankruptcy court in the SunEdison Bankruptcy. Our relationship with SunEdison, the ongoing SunEdison Bankruptcy, the delay of our Forms 10-Q for the quarters ended June 30 and September 30, 2016 and the conditions in the capital markets for our corporate level debt and equity securities have increased uncertainty and heightened some of the risks we face. Other aspects of the markets relevant to our business have remained relatively stable, including the expected performance of our power plants, long-term offtake agreements, and the credit quality of our offtakers. We have adjusted our plans and priorities in light of these developments according to our comprehensive contingency plan. While we remain focused on executing our near term objectives, we will continue to monitor market developments and consider further adjustments to our plans and priorities if required. On September 25, 2016, the Company filed its initial proof of claim in the SunEdison Bankruptcy case, and filed an amended proof of claim on October 7, 2016. Refer to Note 16 - Commitments and Contingencies for discussion regarding this initial proof of claim and settlement discussions between the Company and SunEdison. Management Services Agreement Immediately prior to the completion of the IPO on August 5, 2015, the Company entered into a Management Services Agreement (the “MSA") with SunEdison. Prior to the IPO and MSA execution, amounts were allocated from SunEdison for general corporate overhead costs attributable to the operations of the Company. The general corporate overhead expenses incurred by SunEdison include costs from certain corporate and shared services functions provided by SunEdison and are reflected in the Company’s unaudited condensed consolidated statements of operations as general and administrative expense - affiliate. The amounts reflected include (i) charges that were incurred by SunEdison that were specifically identified as being attributable to the Company and (ii) an allocation of applicable remaining general corporate overhead costs based on the proportional level of effort attributable to the operation of the Company’s power plants. These costs include legal, accounting, tax, treasury, information technology, insurance, employee benefit costs, communications, human resources, and procurement. Corporate costs that were specifically identifiable to a particular operation of SunEdison have been allocated to that operation, including the Company. Where specific identification of charges to a particular operation of SunEdison was not practicable, an allocation was applied to all remaining general corporate overhead costs. The allocation methodology for all remaining corporate overhead costs is based on management’s estimate of the proportional level of effort devoted by corporate resources that is attributable to each of the Company’s operations. The cost allocations have been determined on a basis considered to be a reasonable reflection of all costs of doing business by the Company. The amounts that would have been or will be incurred on a stand-alone basis could differ from the amounts allocated due to economies of scale, management judgment, or other factors. General and administrative expenses - affiliate represent costs incurred by SunEdison for services provided to the Company pursuant to the MSA. As noted above, the agreements comprising the Sponsorship Arrangement, including the MSA, are discussed individually in this report. Subsequent to the IPO and pursuant to the MSA, SunEdison agreed to provide or arrange for other service providers to provide management and administrative services including legal, accounting, tax, treasury, project finance, information technology, insurance, employee benefit costs, communications, human resources, and procurement to the Company. As consideration for the services provided, the Company agreed to pay SunEdison a base management fee as follows: (i) no fee for 2015 , (ii) 2.5% of the Company’s cash available for distribution in 2016, 2017 and 2018, and (iii) an amount equal to SunEdison’s or other service provider’s actual cost in 2019 and thereafter. All costs under the MSA are reflected in the Company’s unaudited condensed consolidated statements of operations as general and administrative expense - affiliate, and the difference between actual costs and the fee paid pursuant to the MSA will be treated as an equity contribution from SunEdison. No fees were paid to SunEdison under the MSA for the three and six months ended June 30, 2016 . As part of the SunEdison Bankruptcy, SunEdison could seek to reject the MSA or may be limited in its ability to perform under this agreement by the bankruptcy court or by the terms of the SunEdison bankruptcy financing. If SunEdison rejects, or seeks to substantially renegotiate the MSA due to the SunEdison Bankruptcy, the Company may bear these actual costs in future periods. Included in general and administrative expense - affiliate are costs incurred under the MSA and corporate allocations of $16.0 million and $3.9 million for the three months ended June 30, 2016 and 2015, and $23.2 million and $6.8 million for the six months ended June 30, 2016 and 2015 , respectively. General and administrative expense - affiliate represents costs incurred for services provided to the Company pursuant to the MSA subsequent to the IPO and allocated to the Company in corporate allocations prior to the IPO. Project Investment Agreement Immediately prior to the completion of the IPO on August 5, 2015, the Company entered into a Project Investment Agreement with SunEdison (the “Project Investment Agreement”). Pursuant to the Project Investment Agreement, SunEdison agreed to contribute to the Company certain projects, without further payment, once each project reached commercial operation. These projects include the 17.4 MW Del Litoral and 57.4 MW El Naranjal solar power projects in Uruguay (the “Uruguay Projects”), the 24.1 MW Bora Bora Poly wind power project located in India and the 17.8 MW NPS Star and 17.8 MW WXA solar power projects in Thailand. The NPS Star and WXA solar power plants reached commercial operation in December 2015 and were transferred by SunEdison to the Company in the first quarter of 2016. On March 23, 2016, SunEdison and the Company entered into an amendment to the Project Investment Agreement which extended the contribution deadline for SunEdison to contribute the remaining projects pursuant to the Project Investment Agreement to July 31, 2016. As part of the SunEdison Bankruptcy, the construction on the projects was materially delayed and/or abandoned due to the lack of funding by SunEdison. There were material amounts of project costs and equity contributions for the Uruguay Projects that remained to be contributed by SunEdison in order to complete construction of these projects and disbursement of the project finance debt facilities. Additionally, SunEdison experienced delays in completing construction of the Bora Bora Poly wind power project in India, and the transfer of the project required project lender consent, which was not obtained. In light of the SunEdison Bankruptcy, we will not obtain these projects under the Project Investment Agreement and we will not obtain any substitute projects from SunEdison. As discussed in Note 16 - Commitments and Contingencies , on September 25, 2016, the Company filed its initial proof of claim in the SunEdison Bankruptcy case, which was amended on October 7, 2016. This proof of claim asserted claims based on, among other things, SunEdison's breach of the Sponsorship Arrangement between the Company and SunEdison which included the Project Investment Agreement. Interest Payment Agreement Immediately prior to the completion of the IPO on August 5, 2015, Global LLC and Global Operating LLC entered into an interest payment agreement (the “Interest Payment Agreement”) with SunEdison, pursuant to which SunEdison agreed to pay an aggregate amount equal to all of the scheduled interest of up to $81.2 million on the Senior Notes through December 31, 2016 and up to an aggregate amount of $40.0 million in 2017, $30.0 million in 2018, $20.0 million in 2019 and $10.0 million in 2020, plus any interest due on any payment not remitted when due. SunEdison’s interest support payments due to the Company have been reduced by $2.9 million as a result of the $49.6 million of the Senior Notes that were extinguished under the open market repurchase program that began in December 2015 and continued through January 2016. SunEdison will not be obligated to pay any amounts due under the Senior Notes in connection with an acceleration of the payment of the principal amount of such indebtedness. Upon expiration of the distribution forbearance period applicable to the Class B common stock that were issued to SunEdison at the time of our IPO, Global LLC will be entitled to set off any amounts owing by SunEdison pursuant to the Interest Payment Agreement against any and all amounts owed by Global LLC to SunEdison under the distribution provisions of the Global LLC Operating Agreement, and Global LLC may pay such amounts to Global Operating LLC. For the six months ended June 30, 2016, SunEdison paid Global LLC $41.2 million related to interest payments on the Senior Notes. SunEdison was not required to contribute capital to fund interest on the Senior Notes or credit facility payments during the year ended December 31, 2015. The Interest Payment Agreement terminates upon payment by SunEdison of all amounts owing thereunder. It may, however, be terminated prior to that by mutual written agreement of SunEdison and Global Operating LLC and will automatically terminate upon the repayment in full of the outstanding principal amount of the Senior Notes or a change of control of the Company, Global LLC or Global Operating LLC. The agreement may also be terminated at the election of SunEdison, Global LLC or Global Operating LLC if any of them experiences bankruptcy or insolvency. Any decision by Global LLC or Global Operating LLC to terminate the Interest Payment Agreement must have the prior approval of the Company’s Corporate Governance and Conflicts Committee. On July 29, 2016, the Company received a notice from SunEdison purporting to terminate the Interest Payment Agreement. The notice alleges that SunEdison's bankruptcy permits termination as of right without following the bankruptcy procedures for rejection of executory contracts. Although we do not expect SunEdison to perform under the Interest Payment Agreement going forward, the Company is contesting the purported termination of the Interest Payment Agreement, believes that the termination notice is invalid, and is asserting a claim in the SunEdison Bankruptcy for the full amount of damages resulting from SunEdison’s breach of the Interest Payment Agreement. Commitments to Acquire Power Plants from SunEdison See Note 16 - Commitments and Contingencies -Commitments to Acquire Power Plants for information regarding Commitments to Acquire Power Plants from SunEdison. Equity Interest Purchase and Sale Agreement for 425 MW India Projects See Note 5 - Deposits for Acquisitions for information regarding the 425 MW India Projects. Operation and Maintenance (“O&M”) and Asset Management Services Operations and maintenance services, as well as asset management services, are provided to the Company by affiliates of SunEdison pursuant to contractual agreements. Costs incurred for these services were $4.7 million and $9.7 million and $1.4 million and $2.3 million for the three and six months ended June 30, 2016 and 2015 , respectively, and are reported as cost of operations-affiliates in the unaudited condensed consolidated statements of operations. Engineering, Procurement and Construction Contracts and Module Warranties SunEdison served as the prime construction contractor for most of our power plants acquired from SunEdison pursuant to engineering, procurement and construction contracts with our project companies. These contracts are generally fixed price, turn-key construction contracts that include workmanship and other warranties with respect to the design and construction of the power plants that survive for a period of time after the completion of construction. These contracts and related contracts (including O&M agreements) also often include production or availability guarantees with respect to the output or availability of the power plant that survive completion of construction. Moreover, we also generally obtained solar module warranties from SunEdison, including workmanship warranties and output guarantees, for those solar power plants that we acquired from SunEdison that utilized SunEdison modules. The SunEdison Bankruptcy will likely reduce or eliminate our potential recoveries on claims under these agreements and warranties. Due to/from SunEdison, net Certain of the Company’s expenses and capital expenditures related to construction in process are paid by affiliates of SunEdison and are reimbursed by the Company to the same or other affiliates of SunEdison. As of June 30, 2016 and December 31, 2015 , the Company owed SunEdison and affiliates $29.3 million and $44.3 million , net, respectively. The due to balance as of December 31, 2015, presents changes to the Company's previously reported amounts due to the recasting performed. These amounts are reported as Due to SunEdison, net in the consolidated balance sheets. Depending on the nature of the activity, amounts are either reflected in operating activities or as a non-cash addition to power plants included in Due to SunEdison, net. Additionally, SunEdison provided contributions to the Company in the form of stockholder loans. Related amounts have been recognized as additional paid-in capital as there is no expectation for the Company to repay SunEdison for the contributions related to stockholder loans. These contributions totaled $38.4 million and $67.9 million for the six months ended June 30, 2016 and 2015 , respectively. Compulsorily Convertible Debentures During the three months ended June 30, 2016 , SunEdison transferred to the Company all, or INR 650.0 million (approximately $9.6 million ), of the unsecured compulsorily convertible debentures ("CCDs") held by SunEdison, which the Company previously issued to SunEdison in connection with its non-controlling interest in three power plants in India. As of June 30, 2016 , third parties held INR 112.1 million (approximately $1.7 million ) of CCDs issued by certain project companies in India. The CCDs held by third parties were subsequently transferred to the Company in the fourth quarter of 2016. Support Agreement Immediately prior to the completion of the IPO on August 5, 2015, Global LLC entered into a project support agreement with SunEdison (the “Support Agreement”). Pursuant to the Support Agreement, SunEdison granted the Company call rights with respect to projects identified therein by SunEdison (“Call Right Projects”) that had an aggregate net nameplate capacity of 1.6 GW (or reasonably equivalent projects), and SunEdison was contractually required to offer Global LLC additional qualifying projects through the fifth anniversary of the completion of the IPO that are projected to generate an aggregate of at least $1.4 billion of cash available for distribution during their respective first twelve months of commercial operation. At the time of the IPO, SunEdison had pending agreements with third-party developers to acquire clean energy projects that had an aggregate capacity of 4.2 GW, which were expected to be added to the call rights list under the Support Agreement. In addition, the Support Agreement granted Global LLC a right of first offer with respect to any clean energy projects (other than Call Right Projects) (“ROFO Projects”) that SunEdison elected to sell or otherwise transfer during the six -year period following the completion of the IPO and that were located in the Company’s initial target markets and other emerging markets that the parties mutually agreed upon. Following the SunEdison Bankruptcy, SunEdison breached the Support Agreement and the Company will not acquire any of the Call Right Projects or ROFO Projects. On September 25, 2016, the Company announced that as a result of SunEdison’s breach under the Support Agreement and other agreements constituting the Sponsorship Arrangement, the Company filed claims against SunEdison in excess of $2 billion . The claims include, without limitation, claims for damages relating to breach of SunEdison's obligations under the Sponsorship Arrangement and other agreements; contribution and indemnification claims arising from litigation; claims relating to SunEdison’s breach of fiduciary, agency and other duties; and claims for interference with and the disruption of the business of the Company, including the loss of business opportunities, loss of business records, failure to provide timely audited financials, and the increased cost of financing and commercial arrangements. Many of these claims are contingent or unliquidated; estimated amounts may change substantially as circumstances develop and damages are determined. Although SunEdison has not formally rejected the Sponsorship Arrangement, it has breached its obligations thereunder and the Company has additional claims for rejection damages.

Segment Reporting

Segment Reporting	6 Months Ended
	Jun. 30, 2016
Segment Reporting [Abstract]
Segment Reporting	SEGMENT REPORTING The Company has two reportable segments: Solar Energy and Wind Energy. These segments include the Company’s entire portfolio of power plants and are determined based on the “management” approach. This approach designates the internal reporting used by management for making decisions and assessing performance as the source of the reportable segments. Corporate expenses include general and administrative expenses, acquisition costs, formation and offering related fees and expenses, interest expense on corporate level indebtedness and stock-based compensation. The following table reflects summarized financial information concerning the Company’s reportable segments for the three and six months ended June 30, 2016 and 2015 : Three Months Ended June 30, 2016 Three Months Ended June 30, 2015 (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Operating revenues, net $ 28,878 $ 27,552 $ — $ 56,430 22,017 3,664 — 25,681 Depreciation, accretion and amortization 6,509 6,516 — 13,025 3,738 (402 ) — 3,336 Other operating costs and expenses 4,703 5,899 15,503 26,105 7,990 4,085 12,510 24,586 Interest expense, net 10,372 (281 ) 18,884 28,975 12,863 725 14,598 28,186 Other non-operating (income) expenses 14,304 1,053 (34,774 ) (19,417 ) (6,640 ) (440 ) — (7,080 ) Income tax expense (benefit) — — 2,061 2,061 — — (668 ) (668 ) Net income (loss) (7,010 ) 14,365 (1,674 ) 5,681 4,066 (304 ) (26,440 ) (22,679 ) Six Months Ended June 30, 2016 Six Months Ended June 30, 2015 (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Operating revenues, net 57,617 46,499 — 104,116 39,823 3,664 — 43,487 Depreciation, accretion and amortization 12,381 15,216 — 27,597 6,473 (402 ) — 6,071 Other operating costs and expenses 11,273 13,328 31,925 56,526 9,312 4,085 19,963 33,361 Interest expense (income), net 22,634 (2,049 ) 42,053 62,638 23,247 725 21,036 45,007 Other non-operating (income) expenses 18,549 3,042 (66,588 ) (44,997 ) (7,058 ) (440 ) — (7,498 ) Income tax expense — — 2,919 2,919 — — 450 450 Net income (loss) (7,220 ) 16,962 (10,309 ) (567 ) 7,849 (304 ) (41,449 ) (33,904 ) The following table reflects reportable segment assets as of June 30, 2016 , and December 31, 2015 : Balance Sheet As of June 30, 2016 As of December 31, 2015 (3) (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Total assets $ 671,131 $ 431,578 $ 1,553,076 $ 2,655,785 $ 764,475 $ 375,683 $ 1,547,008 $ 2,687,166 (1) Income tax benefit is not allocated to the Company’s Solar and Wind segments. (2) Corporate assets include cash and cash equivalents, intercompany accounts receivable, other current assets and other assets. (3) When power plants are sold to the Company after completion by SunEdison, the Company retroactively recasts its historical financial statements to present the construction activity as if it consolidated the facility at inception of the construction (see Note 2 - Transactions Between Entities Under Common Control ). Recasted values are included in the December 31, 2015 asset balances disclosed above.

Other Comprehensive Income (Los

Other Comprehensive Income (Loss)	6 Months Ended
	Jun. 30, 2016
Equity [Abstract]
Other Comprehensive Income (Loss)	OTHER COMPREHENSIVE INCOME (LOSS) Comprehensive income (loss) represents a measure of all changes in equity that result from recognized transactions and other economic events other than transactions with owners in their capacity as owners. Other comprehensive income (loss) includes foreign currency translations and gains (losses) on hedging instruments. The following table presents the changes in each component of accumulated other comprehensive loss: (In thousands) Foreign Currency Translation Adjustments Hedging Activities Accumulated Other Comprehensive Income (loss) Balance as of December 31, 2015 $ (12,819 ) $ 1,638 $ (11,181 ) Other comprehensive income (loss) 38,511 (17,116 ) 21,395 Less: other comprehensive income (loss) attributable to non-controlling interests 15,189 (11,456 ) 3,733 Balance as of June 30, 2016 10,503 (4,022 ) 6,481 The following tables present the changes in each component of accumulated other comprehensive loss and the related tax effects for the three and six months ended June 30, 2016 : Three Months Ended June 30, 2016 (In thousands) Before Tax Tax Effect Net of Tax Foreign currency translation adjustments $ 33,954 $ 271 $ 34,225 Unrealized (loss) gain on hedging instruments (2,653 ) 4,792 2,139 Net other comprehensive income (loss) $ 31,301 $ 5,063 $ 36,364 Less: Other comprehensive income attributable to non-controlling interests, net of tax 14,886 Other comprehensive income (loss) attributable to Class A stockholders $ 21,478 Six Months Ended June 30, 2016 (In thousands) Before Tax Tax Effect Net of Tax Foreign currency translation adjustments $ 38,511 $ 271 $ 38,782 Unrealized (loss) gain on hedging instruments (17,116 ) 4,792 (12,324 ) Net other comprehensive income (loss) $ 21,395 $ 5,063 $ 26,458 Less: Other comprehensive income attributable to non-controlling interests, net of tax 7,036 Other comprehensive income (loss) attributable to Class A stockholders $ 19,422 The following tables present the changes in each component of accumulated other comprehensive loss, net of tax for the three and six months ended June 30, 2015: 2015 (In thousands) Three Months Ended June 30, Six Months Ended June 30, Foreign currency translation adjustments (2,338 ) 2,139 Unrealized (loss) gain on hedging instruments (4.147 ) (4,250 ) Net other comprehensive income (loss) (6.485 ) (2,111 ) Less: Other comprehensive income attributable to non-controlling interests, net of tax — — Other comprehensive income (loss) attributable to Class A stockholders (6.485 ) (2,111 )

Subsequent Events

Subsequent Events	6 Months Ended
	Jun. 30, 2016
Subsequent Events [Abstract]
Subsequent Events	SUBSEQUENT EVENTS Nasdaq Compliance Periodic Reports On March 31, 2016, we received a notification letter from a Director of Nasdaq Listing Qualifications. The notification letter stated that because the Company had not yet filed its Form 10-K for the year ended December 31, 2015, the Company was no longer in compliance with Nasdaq Listing Rule 5250(c)(1), which requires timely filing of periodic reports with the SEC. On May 17, 2016, we received an additional notification letter from a Director of Nasdaq Listing Qualifications. The notification letter stated that because the Company had not yet filed its Form 10-Q for the quarter ended March 31, 2016, and because it remained delinquent in filing its Form 10-K for the year ended December 31, 2015 the Company was not in compliance with Nasdaq Listing Rule 5250(c)(1). On May 27, 2016, in compliance with the deadline specified in the notification letters, the Company submitted a plan to Nasdaq as to how it planned to regain compliance with Nasdaq’s continued listing requirements. On June 10, 2016, the Company received a letter from a Director of Nasdaq Listing Qualifications granting the Company an exception of 180 calendar days from the due date of the Form 10-K for the year ended December 31, 2015, or until September 26, 2016, to regain compliance with Nasdaq’s continued listing requirements. On August 16, 2016, we received an additional notification letter from a Director of Nasdaq Listing Qualifications. The notification letter stated that because the Company had not yet filed its Form 10-Q for the quarter ended June 30, 2016, the Company was not in compliance with Nasdaq Listing Rule 5250(c)(1). On September 9, 2016, the Company received a letter from Nasdaq stating that due to the Company’s ongoing non-compliance with Nasdaq’s listing requirements, the Company would be delisted from the Nasdaq Global Select Market at the opening of business on September 20, 2016 unless the Company requested a hearing on the determination by September 16, 2016. On September 9, 2016, the Company requested a hearing and also requested a stay of the delisting, pending the hearing. On September 15, 2016, we received a letter from Nasdaq granting our request to extend the stay of delisting until the hearings panel made a decision after the hearing scheduled for November 3, 2016. At the hearing on November 3, 2016, the Company requested from Nasdaq an extension until March 27, 2017 to regain compliance with Nasdaq’s continued listing requirements with respect to its delayed Form 10-K for the year ended December 31, 2015 and its delayed Forms 10-Q for the periods ended March 31 and June 30, 2016. On November 15, 2016, the Company received a notification letter from a Hearings Advisor from the Nasdaq Office of General Counsel informing the Company that the hearings panel granted the Company’s request for an extension until March 27, 2017 with respect to its delayed Form 10-K for the year ended December 31, 2015 and its delayed Forms 10-Q for first , second and third quarters of 2016. The hearings panel granted the Company the maximum possible extension until the expiration of the hearings panel’s discretion to allow continued listing while the Company remains out of compliance with Nasdaq’s continued listing requirements. The hearings panel reserved the right to reconsider the terms of the extension and the Nasdaq Listing and Hearing Review Council may determine to review the decision should an event occur that calls into question the Company’s ability to regain compliance by March 27, 2017. In addition, on November 15, 2016, the Company received an additional notification letter from a Director of Nasdaq Listing Qualifications. The notification letter stated that because the Company has not yet filed its Form 10-Q for the quarter ended September 30, 2016, and because it remained delinquent in filing its Form 10-K for the year ended December 31, 2015 and its Forms 10-Q for the quarters ended March 31 and June 30, 2016 the Company was not in compliance with Nasdaq Listing Rule 5250(c)(1). Based on discussions with the hearings panel’s staff, the extension until March 27, 2017 granted by the hearings panel also covers the non-compliance by the Company with Nasdaq Listing Rule 5250(c)(1) caused by the failure of the Company to timely file its Form 10-Q for the quarter ended September 30, 2016. 2016 Annual Meeting Nasdaq Listing Rule 5620(a) (the "Annual Meeting Rule") requires the Company to hold an annual meeting of shareholders within twelve months of the end for the Company's fiscal year. Because the Company did not hold an annual meeting during 2016, the Company is not in compliance with the Annual Meeting Rule. On January 4, 2017, the Company received a notification letter from a Senior Director of Nasdaq Listing Qualification, which stated that the Company's failure to hold its annual meeting by December 31, 2016 serves as an additional basis for delisting the Company's securities and that the hearings panel will consider this matter in their decision regarding the Company's continued listing on the Nasdaq Global Select Market. On January 11, 2017, the Company submitted a response requesting an extension to hold an annual meeting and regain compliance with the Annual Meeting Rule. There is no assurance that the hearings panel will grant an extension or of the length of time of any extension granted. Delayed Filing of Forms 10-Q We have not yet filed our Form 10-Q for the quarter ended September 30, 2016. On May 17, August 10 and November 10, 2016, we filed a Form 12b-25, Notification of Late Filing, with the SEC regarding our delayed Forms 10-Q for the quarters ended March 31, June 30 and September 30, 2016, respectively, in each case principally due to the need to complete all steps and tasks necessary to finalize our financial statements and other disclosures required to be in the filing. Delayed Filing of 2016 10-K and First Quarter 2017 Form 10-Q The Company is continuing its efforts to regain compliance with Nasdaq’s continued listing requirements with respect to its delayed SEC periodic reports, with significant progress made by filing its Form 10-K for the year ended December 31, 2015 and its Form 10-Q for the first quarter of 2016 in December 2016, and by filing its Form 10-Q for the second quarter of 2016 in January 2017. However, due to the time and resources required to complete its delayed SEC periodic reports, including its Form 10-K for the year ended December 31, 2015 and its Forms 10-Q for the first, second and third quarters of 2016, the Company has experienced delays in its ongoing efforts to complete all steps and tasks necessary to finalize financial statements and other disclosures required to be in its Form 10-K for the year ended December 31, 2016 (the “2016 10-K”) and subsequent quarterly reports. The Company currently does not expect to be able to file the 2016 10-K by the SEC filing deadline in March 2017 or its Form 10-Q for the first quarter of 2017 by the SEC filing deadline in May 2017. The Company continues to work to complete, as soon as practicable, all steps and tasks necessary to finalize the Company’s financial statements and other disclosures required to be included in its periodic filings with the SEC. There can be no assurance that the Company’s future periodic reports will not be delayed for similar reasons. Continued delays in the filing of the Company’s periodic reports with the SEC could have a material adverse effect on the Company. Acquisitions See Note 3 - Acquisitions for a description of subsequent events regarding the transfer of the balance of equity in certain projects in India, incomplete dropdowns (425MW India Projects), and the pending BioTherm acquisition. Long-Term Debt See Note 8 - Long-Term Debt for a description of the Event of Default of SunEdison as it relates to Long-Term Debt. Also in that section is a description of the Extinguishment of Debt during the third quarter of 2016 and a description of the amendment made to ISDA Agreement in July 2016. Related Parties See Note 17 - Related Parties for a description of the SunEdison bankruptcy and a description of its potential impact on the Company. Transition to Stand-alone Operations The Company is transitioning away from its historical reliance on SunEdison for management, corporate and accounting services, employees, critical systems and information technology infrastructure, and the operation, maintenance and asset management of our power plants. As part of this transition, as of January 1, 2017, substantially all employees at both the corporate and project levels who were previously employed by SunEdison were hired directly by the Company. As such, the Company no longer relies upon SunEdison for personnel to manage and operate our business or our power plants. The Company continues to execute on the other aspects of its plan to implement a stand-alone organization. Corporate Governance Changes Designation of David J. Mack On January 4, 2017, SunEdison Holdings Corporation, a wholly-owned subsidiary of SunEdison, Inc., exercised its right to designate Mr. David J. Mack to the Board effective immediately. The Company believes that Mr. Mack qualifies as an independent director under applicable stock exchange rules. Election of Alan Miller On January 25, 2017, the Board voted to elect Mr. Alan B. Miller to be a member of the Board effective immediately. The Company believes that Mr. Miller qualifies as an independent director under applicable stock exchange rules. In connection with the election of Mr. Miller to the Board, the Board consulted with various parties, including SunEdison, Inc., the Company's controlling shareholder. Resignation of David Springer On January 25, 2017, Mr. David Springer resigned from his position as a director of the Board. The resignation was contingent upon, and effective immediately prior to, the election of Mr. Alan B. Miller as a director of the Board. Mr. Springer’s resignation was not the result, in whole or in part, of any disagreement with the Company. Reconstitution of the Corporate Governance and Conflicts Committee On December 1, 2016, the Board appointed Mr. Mark Lerdal and Mr. Fred Boyle to the Corporate Governance and Conflicts Committee of the Board (the “Conflicts Committee”), effective immediately. Additionally, on December 1, 2016, the members of the Conflicts Committee of Global LLC (the “LLC Conflicts Committee”) appointed Mr. Boyle and Mr. Lerdal as additional members of the LLC Conflicts Committee. On January 13, 2017, the Board appointed Mr. Mack to the Conflicts Committee, effective immediately upon the resignation of Messrs. Christopher Compton, Hanif “Wally” Dahya and John F. Stark from the Conflicts Committee. Messrs. Compton, Dahya and Stark resigned from the Conflicts Committee on January 13, 2017. As a result of these changes, the Conflicts Committee consists of three members, Messrs. Lerdal, Boyle and Mack. Mr. Boyle serves as the Chairperson of the Conflicts Committee. Additionally, on January 13, 2017, the members of the LLC Conflicts Committee appointed Mr. Mack to the LLC Conflicts Committee, effective immediately upon the resignation of Messrs. Compton, Dahya and Stark from the LLC Conflicts Committee. Messrs. Compton, Dahya and Stark resigned from the LLC Conflicts Committee on January 13, 2017. As a result of these changes, the LLC Conflicts Committee consists of three members, Messrs. Lerdal, Boyle and Mack. Appointment of Mr. Fred Boyle to the Audit Committee On January 10, 2017, the Board appointed Fred Boyle to serve as a member of the Audit Committee of the Board. Following Mr. Boyle’s appointment, the Audit Committee consists of four members, Messrs. Dahya, Compton, Stark and Boyle. Creation of Compensation Committee For purposes of the applicable stock exchange rules, the Company is a “controlled company.” As a controlled company, the Company relies upon certain exceptions, including with respect to establishing a compensation committee or nominating committee. While the Company remains able to reply upon such exceptions, on January 10, 2017, the Board created a Compensation Committee of the Board (the “Compensation Committee”). The Compensation Committee is responsible for, among other matters: (i) reviewing and approving corporate goals and objectives relevant to the compensation of the Company’s Chief Executive Officer, (ii) determining, or recommending to the Board for determination, the Chief Executive Officer’s compensation level based on this evaluation, (iii) determining, or recommending to the Board for determination, the compensation of directors and all other executive officers, (iv) discharging the responsibility of the Board with respect to the Company’s incentive compensation plans and equity-based plans, (v) overseeing compliance with respect to compensation matters, (vi) reviewing and approving severance or similar termination payments to any current or former executive officer of the Company, and (vii) preparing an annual Compensation Committee Report, if required by applicable SEC rules. The Compensation Committee consists of three members, Messrs. Lerdal, Mack and Stark. Mr. Lerdal has been designated as the chairperson of the Compensation Committee. The Board has adopted a written charter for the Compensation Committee which is available on the Company’s corporate website, http://www.terraformglobal.com. Update on Settlement Discussions with SunEdison As previously disclosed, TerraForm Global, Inc. (“TerraForm Global”) has been engaged in settlement discussions with SunEdison to resolve, among other matters, intercompany claims in connection with the SunEdison Bankruptcy. On January 20, 2017, TerraForm Global and Global LLC entered into a memorandum of understanding (the “MOU”) with SunEdison, TerraForm Power, Inc. (“TerraForm Power” and, together with TerraForm Global, the “Yieldcos”) and TerraForm Power, LLC (“Terra LLC”), a subsidiary of TerraForm Power. The MOU outlines potential settlements of claims (i) between SunEdison and its affiliated debtors and non-debtors (excluding GLBL and TERP, as defined below) and their respective employees, officers, directors, agents and representatives in their capacities as such (the “SunEdison Parties”), on the one hand, and TerraForm Global (for itself and on behalf of Global LLC and Global Operating LLC) (collectively, “GLBL”), and GLBL’s employees, officers, directors, agents and representatives in their capacities as such, on the other hand (the “GLBL Intercompany Claims”); and (ii) between the SunEdison Parties, on the one hand, and TerraForm Power (for itself and on behalf of Terra LLC and TerraForm Power Operating, LLC) (collectively, “TERP”) and TERP’s employees, officers, directors, agents and representatives in their capacities as such, on the other hand (the “TERP Intercompany Claims”), in each case in connection with the SunEdison Bankruptcy and including, in each case, any avoidance actions and preference claims the SunEdison Parties may have. The MOU has been approved by the respective boards of directors of TerraForm Global, SunEdison and TerraForm Power. TerraForm Global’s board of directors approved the MOU upon the recommendation of its independent members who do not also serve on the board of directors of TerraForm Power. The settlement of the GLBL Intercompany Claims and the TERP Intercompany Claims is subject to the approval of the bankruptcy court in the SunEdison Bankruptcy (the “Bankruptcy Court”). On January 27, 2017 and January 29, 2017, the Yieldcos, Global LLC, Terra LLC and SunEdison modified the MOU to extend, from January 27, 2017 to February 2, 2017, the deadline under the MOU for agreeing to the terms of definitive settlement agreements. Under the MOU, as modified, the Yieldcos, Global LLC, Terra LLC and SunEdison will work in good faith toward agreeing to the terms of two separate settlement agreements, one for each Yieldco, as promptly as practicable on or before February 2, 2017. The Company expects that SunEdison will condition its motion for Bankruptcy Court approval of each settlement agreement upon Bankruptcy Court approval of the other settlement agreement. In addition, GLBL and SunEdison will work to document a transaction for the sale of all or part of GLBL in parallel with a separate effort by TERP and SunEdison to document a transaction for the sale of all or part of TERP (each an “M&A Transaction”), with each M&A Transaction requiring the approval by the applicable Yieldco and SunEdison; provided such obligation to work toward the M&A Transaction terminates if the Yieldcos and SunEdison have not executed and delivered settlement agreements on or before February 2, 2017. The MOU contains certain non-binding proposed settlement terms (the “Proposed Settlement Terms”) to resolve the complex legal relationship between the applicable Yieldco and SunEdison arising out of SunEdison’s sponsorship of such Yieldco, including, among other things, an allocation of the total consideration paid in connection with an M&A Transaction and, with certain exceptions, the full mutual release of all GLBL Intercompany Claims. At the closing of the GLBL M&A Transaction, in exchange for its Class B common stock of TerraForm Global, Class B units of Global LLC, incentive distribution rights and all other interests in GLBL, SunEdison would receive consideration equal to 25.0% of the total consideration paid to all stockholders of TerraForm Global, reflecting the settlement of GLBL Intercompany Claims, incentive distribution rights and other factors considered by the board of directors of TerraForm Global. The remaining consideration would be distributed to holders of shares of the Class A common stock of TerraForm Global (including SunEdison, solely in its capacity as a holder of Class A common stock of TerraForm Global immediately prior to the closing of such M&A Transaction). At the closing of the TERP M&A Transaction, in exchange for its Class B common stock of TerraForm Power, Class B units of Terra LLC, incentive distribution rights and all other interests in TERP, SunEdison would receive consideration equal to 36.9% of the total consideration paid to all TerraForm Power stockholders, reflecting the settlement of TERP Intercompany Claims, incentive distribution rights and other factors considered by the board of directors of TerraForm Power. The remaining consideration would be distributed to holders of shares of the Class A common stock of TerraForm Power. The Proposed Settlement Terms are not legally binding on any party to the MOU and are subject to a number of conditions and contingencies, including each of the Yieldcos and SunEdison entering into final settlement agreements before February 2, 2017, each of the Yieldcos entering into an M&A Transaction (and all documents with respect thereto) jointly approved by the applicable Yieldco and SunEdison by April 1, 2017 and approval of each settlement agreement by the Bankruptcy Court by April 1, 2017, which date may be extended until April 15, 2017 if approval of the settlement agreements is a contested matter that SunEdison is prosecuting in good faith. The settlement agreements will automatically terminate if approval of the Bankruptcy Court is not obtained and will be terminable if the applicable jointly approved M&A Transaction terminates prior to closing or if other customary milestones are not met or termination rights are triggered. There is no assurance that the Yieldcos and SunEdison will enter into binding settlement agreements, and there is no assurance as to the final terms or timing of any such settlement agreements. Exclusivity with Brookfield Asset Management Inc. The Company has been exploring and evaluating potential strategic alternatives to maximize stockholder value, including a merger or sale of its entire business or other business combinations or sponsorship arrangements. On January 20, 2017, TerraForm Global and Global LLC entered into an exclusivity agreement (the “Exclusivity Agreement”) with Brookfield Asset Management Inc. (“Brookfield”), which is subject to customary terms and conditions. Under the Exclusivity Agreement, subject to early termination under certain circumstances, the Company has agreed to negotiate exclusively with Brookfield in connection with a possible negotiated business combination transaction between the Company and Brookfield until the earlier of the execution of a definitive agreement for such transaction and 11:59 p.m. New York City time on March 6, 2017. Prior to entering into the Exclusivity Agreement, the Company received a bid letter from Brookfield, which was subsequently revised (as revised, the “Bid Letter”). In the Bid Letter, Brookfield proposed four possible transactions: 1. Brookfield would purchase 100% of the Company for cash (the “Whole Company Transaction”); 2. Brookfield would purchase 100% of the Company for cash and either (i) 100% of TerraForm Power, Inc. or (ii) at least a 50.1% interest in TerraForm Power, Inc. in a sponsorship transaction (the “Whole GLBL with TERP Transaction”); 3. Brookfield would replace SunEdison as sponsor and controlling stockholder of the Company (the “Sponsorship Transaction”); or 4. Brookfield would replace SunEdison as sponsor and controlling stockholder of the Company and TerraForm Power, Inc. (the “Double Sponsorship Transaction”). The Bid Letter included certain dollar amounts for each of the four proposals, which are described below. The amounts included in the Bid Letter and described below are presented on a fully diluted and converted per-share basis. However, any aggregate amounts payable to SunEdison, on the one hand, and the holders of TerraForm Global's Class A common stock, on the other hand, will reflect the terms of final settlement agreement, if any, between the Company and SunEdison. The terms of any such final settlement agreement may cause any amounts payable in a transaction for all or part of the Company to differ materially from those described below. None of the four proposals is subject to any financing condition. In the Whole Company Transaction, Brookfield would acquire all outstanding shares of TerraForm Global for $4.15 per share in cash, subject to adjustment in respect of certain specified contingencies. All shares of the Class B common stock of TerraForm Global and Class B units of Global LLC held by SunEdison would be exchanged for shares of Class A common stock of TerraForm Global immediately prior to consummation of the transaction and, as so exchanged, would receive the same consideration per share as all other holders of Class A common stock, subject to the final settlement agreement to be entered into between SunEdison and the Company. For the Whole GLBL with TERP Transaction, Brookfield indicated it would be willing to offer additional incremental consideration of $0.20 per share in cash, payable on the closing of a transaction for either (i) 100% of TerraForm Power, Inc. or (ii) at least 50.1% of TerraForm Power, Inc. in a sponsorship transaction, such that the total consideration to be paid to stockholders of TerraForm Global would be $4.35 per share in cash. Payment of the initial $4.15 per share in cash for all outstanding shares of TerraForm Global would not be conditioned upon the closing of a transaction for either (i) 100% of TerraForm Power, Inc. or (ii) at least 50.1% of TerraForm Power, Inc. in a sponsorship transaction. In the Sponsorship Transaction, Brookfield would replace SunEdison as the Company’s sponsor and controlling stockholder, and would invest cash in the Company in exchange for a number of newly issued shares of Class A common stock that, after taking into account the issuance of new Class A common stock and the exchange of SunEdison’s interests into Class A common stock, would equal 50.1% of the total number of shares outstanding in TerraForm Global following consummation of the transaction. However, Brookfield indicated that in the event it is advantageous to the Company, Brookfield would be prepared to consider acquiring more Class A common stock in a Sponsorship Transaction. All shares of Class B common stock and Class B units of Global LLC held by SunEdison would be exchanged for shares of Class A common stock immediately prior to consummation of the transaction. The cash consideration would be based on a pre-transaction equity value of the Company, which would represent a pre-transaction value per share of $4.15 and would be subject to adjustment in respect of the same specified contingencies as the Whole Company Transaction. The cash consideration would then be distributed to all stockholders of TerraForm Global (other than Brookfield) on a pro rata basis, subject to the final settlement agreement to be entered into between SunEdison and the Company. In a Double Sponsorship Transaction, Brookfield would be willing to offer incremental aggregate consideration based on a pre-transaction equity value of the Company, which would represent a pre-transaction value per share of $4.25 . Brookfield’s proposals are subject to certain conditions, including the satisfactory completion of confirmatory due diligence and the negotiation of mutually acceptable definitive transaction documentation which addresses, among other things, the treatment of potential liabilities previously disclosed by the Company, a voting and support agreement with SunEdison, and the negotiation of a comprehensive settlement agreement between the Company and SunEdison that releases the Company from claims by SunEdison and is acceptable to Brookfield. Consummation of any of the above transactions would be subject to customary closing conditions, including approval of the settlement agreement and SunEdison’s action to support the transaction by the bankruptcy court in the SunEdison Bankruptcy. There is no assurance that the Company and Brookfield will enter into a definitive agreement for a potential transaction and there is no assurance as to the form, terms or timing of any transaction even if an agreement is reached between the parties. The final form and terms of any such transaction, including any consideration ultimately received by TerraForm Global's stockholders in such transaction, and any conditions to closing, may be materially different from the terms under Brookfield’s proposals described above.

Nature of Operations (Policies)

Nature of Operations (Policies)	6 Months Ended
	Jun. 30, 2016
Organization, Consolidation and Presentation of Financial Statements [Abstract]
Basis of Presentation, Policy	Basis of Presentation The accompanying unaudited condensed consolidated financial statements have been prepared in accordance with SEC regulations for interim financial information. Accordingly, they do not include all of the information and notes required by accounting principles generally accepted in the United States of America ("U.S. GAAP") for complete financial statements. The financial statements should be read in conjunction with the accounting policies and other disclosures as set forth in the notes to the Company’s annual financial statements for the year ended December 31, 2015, filed with the SEC on Form 10-K on December 21, 2016. Certain solar power plants in the Company’s current portfolio have been contributed from SunEdison (also referred to as “dropdown”) and are reflected in the accompanying unaudited condensed consolidated balance sheets at SunEdison’s historical cost. When power plants are contributed or acquired from SunEdison, the Company is required to recast its historical financial statements to reflect the assets and liabilities of the acquired power plants for the period such power plants were owned by SunEdison in accordance with rules applicable to transactions between entities under common control. For all periods prior to our initial public offering (“IPO”) on August 5, 2015, the accompanying unaudited condensed consolidated financial statements reflect the operations of SunEdison Emerging Markets Co. (the "Predecessor"), which consisted of the assets that the Company acquired from SunEdison and third parties prior to and concurrently with the closing of the IPO, and were prepared using SunEdison’s historical basis in these assets and liabilities. For all periods subsequent to the IPO, the accompanying unaudited condensed consolidated financial statements represent the results of TerraForm Global, Inc., which consolidates Global LLC through its controlling interest. The historical financial statements of the Predecessor include allocations of certain SunEdison corporate expenses and income tax expense. Management believes the assumptions and methodology underlying the allocation of general corporate overhead expenses are reasonable. Subsequent to the IPO, corporate expenses represent those costs allocated to the Company under the Management Service Agreement ("MSA"), as more fully described in Note 17 -Related Parties . In the opinion of management, the accompanying unaudited condensed consolidated financial statements contain all material adjustments consisting of normal and recurring adjustments necessary to present fairly the Company’s unaudited condensed consolidated financial position as of June 30, 2016, and the results of operations, comprehensive income and cash flows for the six months ended June 30, 2016 and 2015.
Use of Estimates, Policy	Use of Estimates In preparing the unaudited condensed consolidated financial statements in conformity with U.S. GAAP, the Company used estimates and assumptions that affect the reported amounts of assets and liabilities as of the date of the financial statements. Such estimates also affect the reported amounts of revenues, expenses and cash flows during the reporting period. To the extent there are material differences between the estimates and actual results, the Company's future results of operations would be affected.
Restricted Cash, Policy	Restricted Cash Restricted cash consists of cash on deposit in financial institutions that is restricted to satisfy the requirements of certain debt and acquisition agreements and funds held within the Company's project companies that are restricted for current debt service payments and other purposes in accordance with the applicable debt agreements. These restrictions include: (i) cash on deposit in collateral accounts, debt service reserve accounts, and maintenance reserve accounts; and (ii) cash on deposit in operating accounts but subject to distribution restrictions due to debt defaults, as of the balance sheet dates.
New Accounting Standards, Policy	New Accounting Standards In May 2014, the Financial Accounting Standards Board (“FASB”) issued Accounting Standards Update (“ASU”) 2014-09, Revenue from Contracts with Customers , which requires an entity to recognize the amount of revenue to which it expects to be entitled for the transfer of promised goods or services to customers. ASU 2014-09 will replace most existing revenue recognition guidance in U.S. GAAP when it becomes effective. ASU 2014-09 is effective for the Company on January 1, 2018. Early adoption is permitted but not before January 1, 2017. ASU 2014-09 permits the use of either a retrospective or cumulative effect transition method. The Company has not determined which transition method it will adopt, and it is currently evaluating the impact that ASU 2014-09 will have on its consolidated financial statements and related disclosures upon adoption. We do not plan to adopt this standard prior to January 1, 2018. In August 2014, the FASB issued ASU 2014-15, Disclosure of Uncertainties about an Entity’s Ability to Continue as a Going Concern , which describes how an entity should assess its ability to meet obligations and sets rules for how this information should be disclosed in the financial statements. ASU 2014-15 provides accounting guidance that will be used along with existing auditing standards. ASU 2014-15 applies to all entities for the first annual period ending after December 15, 2016, and interim periods thereafter. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In January 2015, the FASB issued ASU 2015-01, Income Statement-Extraordinary and Unusual Items (Subtopic 225-20): Simplifying Income Statement Presentation by Eliminating the Concept of Extraordinary Items . ASU 2015-01 eliminates from U.S. GAAP the concept of extraordinary items. An entity will no longer be required to (1) segregate an extraordinary item from the results of ordinary operations; (2) separately present an extraordinary item on its income statement, net of tax, after income from continuing operations; and (3) disclose income taxes and earnings-per-share data applicable to an extraordinary item. ASU 2015-01 will be effective for fiscal years beginning after December 15, 2015. An entity may apply ASU 2015-01 prospectively or retrospectively to all prior periods presented in the financial statements. Early adoption is permitted provided that the guidance is applied from the beginning of the fiscal year of adoption. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In February 2015, the FASB issued ASU 2015-02, Consolidation (Topic 810) Amendments to the Consolidation Analysis, which affects the following areas of the consolidation analysis: limited partnerships and similar entities, evaluation of fees paid to a decision maker or service provider as a variable interest and in determination of the primary beneficiary, effect of related parties on the primary beneficiary determination and for certain investment funds. ASU 2015-02 is effective on a retrospective basis for the Company for the fiscal year ending December 31, 2016 and interim periods therein. The Company adopted ASU 2015-02 as of January 1, 2016, which resulted in certain of our consolidated subsidiaries to be considered variable interest entities. One previously unconsolidated investment was consolidated as a result of implementing this standard (see Acquisition of FERSA in Note 3 - Acquisitions ). No consolidated subsidiaries were deconsolidated as a result of implementing this standard. In April 2015, the FASB issued ASU 2015-03, Interest - Imputation of Interest (Subtopic 835-30): Simplifying the Presentation of Debt Issuance Costs. ASU 2015-03 requires that debt issuance costs related to a recognized debt liability be presented in the balance sheets as a direct deduction from the carrying amount of that debt liability. In August 2015, the FASB issued ASU 2015-15, Interest - Imputation of Interest (Subtopic 835-30): Presentation and Subsequent Measurement of Debt Issuance Costs Associated with Line-of Credit Arrangements. ASU 2015-15 indicates that an entity may defer and present debt issuing costs associated with line-of-credit arrangements as an asset and subsequently amortize the deferred debt issuance costs ratably over the term of the line-of-credit arrangement, regardless of whether there are any outstanding borrowings on the line-of-credit arrangement. ASU 2015-03 and ASU 2015-15 are effective on a retrospective basis for annual and interim periods beginning on or after December 15, 2015. The Company adopted ASU 2015-03 and ASU 2015-15 as of January 1, 2016, which resulted in a reclassification of $21.4 million and $23.6 million from deferred financing costs, net to long-term debt and financing lease obligations, including current portion, as of June 30, 2016 and December 31, 2015, respectively. In April 2015, the FASB issued ASU 2015-06 Earnings Per Share (Topic 260) , which provides guidance on the presentation of historical earnings per unit under the two-class method for transfers of net assets between entities under common control. ASU 2015-06 is effective for the Company for the fiscal year ending December 31, 2016 and interim periods therein. In September 2015, the FASB issued ASU 2015-16, Business Combinations (Topic 805): Simplifying the Accounting for Measurement-Period Adjustments , which eliminates the requirement for an acquirer in a business combination to account for measurement-period adjustments retrospectively. Instead, acquirers must recognize measurement-period adjustments during the period in which they determine the amounts, including the effect on earnings of any amounts they would have recorded in previous periods if the accounting had been completed at the acquisition date. ASU 2015-16 is effective for the Company on a prospective basis on January 1, 2016. Early adoption is permitted for any interim and annual financial statements that have not yet been made available for issuance. The Company early adopted ASU 2015-16 and all measurement-period adjustments for business combinations completed in 2015 were recorded in our consolidated financial statements for the year ended December 31, 2015, with the exception of FERSA which was accounted for using the equity method. In November 2015, the FASB issued ASU 2015-17, Income Taxes (Topic 740): Balance Sheet Classification of Deferred Taxes instructing reporting entities to classify deferred income taxes as non-current on the unaudited condensed consolidated balance sheets. Deferred income taxes were previously required to be classified as current or non-current on the unaudited condensed consolidated balance sheets. The provisions of ASU 2015-17 are effective for fiscal years, and interim periods within those fiscal years, beginning after December 15, 2016. Early adoption is permitted for any interim and annual financial statements that have not yet been made available for issuance. A reporting entity has the option to apply ASU 2015-17 prospectively or retrospectively. We have early adopted ASU 2015-17 effective December 31, 2015 using the prospective method allowed under the standard and prior periods were not retrospectively adjusted. In February 2016, the FASB issued ASU 2016-02, Leases (Topic 842) , which primarily changes the lessee’s accounting for operating leases by requiring recognition of lease right-of-use assets and lease liabilities. This standard is effective for annual reporting periods beginning after December 15, 2018, with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In March 2016, the FASB issued ASU 2016-05, Derivatives and Hedging (Topic 815), which clarifies that a change in one of the parties to a derivative contract (through novation) that is part of a hedge accounting relationship does not, by itself, require designation of that relationship, as long as all other hedge accounting criteria continue to be met. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In March 2016, the FASB issued ASU 2016-06, Derivatives and Hedging (Topic 815) , which clarifies that determining whether the economic characteristics of a put or call are clearly and closely related to its debt host requires only an assessment of the four-step decision sequence outlined in FASB ASC paragraph 815-15-25-24. Additionally, entities are not required to separately assess whether the contingency itself is clearly and closely related. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2018, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. In March 2016, the FASB issued ASU 2016-07, Investments - Equity Method and Joint Ventures (Topic 323) which eliminates the requirement for an investor to retroactively apply the equity method when its increase in ownership interest (or degree of influence) in an investee triggers equity method accounting. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company does not expect this standard will have a material effect on the Company’s consolidated financial statements. On March 30, 2016, the FASB issued ASU 2016-09, Compensation - Stock Compensation (Topic 718) , which is intended to improve the accounting for share-based payment transactions as part of the FASB’s simplification initiative. ASU 2016-09 changes seven aspects of the accounting for share-based payment award transactions, including but not limited to: (1) accounting for income taxes; (2) classification of excess tax benefits on the statement of cash flows; (3) forfeitures; (4) minimum statutory tax withholding requirements; and (5) classification of employee taxes paid on the statement of cash flows when an employer withholds shares for tax-withholding purposes. This standard is effective for annual and interim periods in fiscal years beginning after December 15, 2016, with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In August 2016, the FASB issued ASU 2016-15, Statement of Cash Flows (Topic 230), Classification of Certain Cash Receipts and Cash Payments. The amendments of ASU 2016-15 were issued to address eight specific cash flow issues for which stakeholders have indicated to the FASB that a diversity in practice existed in how entities were presenting and classifying these items in the statement of cash flows. The issues addressed by ASU 2016-15 include but are not limited to the classification of debt prepayment and debt extinguishment costs, payments made for contingent consideration for a business combination, proceeds from the settlement of insurance proceeds, distributions received from equity method investees and separately identifiable cash flows and the application of the predominance principle. The amendments of ASU 2016-15 are effective for public entities for fiscal years beginning after December 15, 2017 and interim periods in those fiscal years. Early adoption is permitted, including adoption in an interim fiscal period with all amendments adopted in the same period. The adoption of ASU 2016-15 is required to be applied retrospectively. The Company is evaluating the impact of the standard on its consolidated statements of cash flows. In October 2016, the FASB issued ASU 2016-16, Income Taxes (Topic 740): Intra-Entity Transfer of Assets Other Than Inventory , which eliminates the recognition of current and deferred income taxes for an intra-entity asset transfer until the asset has been sold to an outside party exception for an intra-entity transfer of an asset other than inventory. ASU 2016-16 is effective for annual periods beginning after December 15, 2017, and for annual periods and interim periods thereafter with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In October 2016, the FASB issued ASU 2016-17, Consolidation (Topic 810): Interests Held through Related Parties That Are under Common Control . ASU 2016-17 updates ASU 2015-02. Under the amendments, a single decision maker is not required to consider indirect interests held through related parties that are under common control with the single decision maker to be the equivalent of direct interests in their entirety. Instead, a single decision maker is required to include those interests on a proportionate basis consistent with indirect interests held through other related parties. ASU 2016-17 is effective for annual periods beginning after December 15, 2017, and for annual periods and interim periods thereafter with early adoption permitted. The Company is evaluating the effect of the standard on its consolidated financial statements. In November 2016, the FASB issued ASU 2016-18, Statement of Cashflows (Topic 320): Restricted Cash a Consensus of the FASB Emerging Issues Task Force. The amendments require that a statement of cash flows to explain the change during the period in the total of cash, cash equivalents, and amounts generally described as restricted cash or restricted cash equivalents. Therefore, amounts generally described as restricted cash and restricted cash equivalents should be included with cash and cash equivalents when reconciling the beginning-of-period and end-of-period total amounts shown on the statement of cash flows. The amendments in this update do not provide a definition of restricted cash or restricted cash equivalents. ASU 2016-18 is effective for fiscal years beginning after December 15, 2017 and interim periods within those fiscal years. The Company is evaluating the effect of this standard on its consolidated financial statements. In December 2016, the FASB issued ASU 2016-19, Technical Corrections and Improvements. The amendments cover a wide range of topics in the Accounting Standards Codification, including differences between original guidance and the Accounting Standards Codification, guidance clarification and reference corrections, simplification and minor improvements. The adoption of ASU 2016-19 is effective for annual periods, including interim periods, within those annual periods, beginning after December 15, 2016. The Company is evaluating the effect of this standard on its consolidated financial statements. In December 2016, the FASB issued ASU 2016-20, Technical Corrections and Improvements to Topic 606, Revenue from Contracts with Customers. The amendments in this update are of a similar nature to the items typically addressed in the ASU 2016-19, Technical Corrections and Improvements. However, the FASB decided to issue a separate update for technical corrections and improvements to Topic 606 and other Topics amended by ASU 2014-09 to increase stakeholders’ awareness of the proposals and to expedite improvements to ASU 2014-09. The adoption of ASU 2016-20 is effective from the periods beginning after December 15, 2017, including interim reporting periods within that reporting period. Early adoption is permitted only as of annual reporting periods beginning after December 15, 2016, including interim reporting periods within that reporting period. The Company is evaluating the effect of this standard on its consolidated financial statements. In January 2017, the FASB issued ASU 2017-01, Business Combinations (Topic 805): Clarifying the Definition of a Business. The amendment seeks to clarify the definition of a business with the objective of adding guidance to assist entities with evaluating whether transactions should be accounted for as acquisitions (or disposals) of assets or businesses. The definition of a business affects many areas of accounting including acquisitions, disposals, goodwill and consolidation. The adoption of ASU 2017-01 is effective for annual periods beginning after December 15, 2017, including interim periods within those periods. The amendments should be applied prospectively on or after the effective dates. The Company is evaluating the effect of this standard on its consolidated financial statements.

Transactions Between Entities29

Transactions Between Entities Under Common Control (Tables)	6 Months Ended
	Jun. 30, 2016
Accounting Policies [Abstract]
Schedule of Changes to Previously Reported Balance Sheets	The following table presents changes to the Company's consolidated balance sheet as of December 31, 2015 : (In thousands) Balance Sheet Caption Unadjusted Recast Adjustments As Recasted Cash and cash equivalents $ 921,946 $ 372 $ 922,318 Prepaid expenses and other current assets 144,743 (5,408 ) 139,335 Power plants, net 1,148,350 58,254 1,206,604 Restricted cash 22,582 100 22,682 Due from SunEdison, net 10,110 (10,110 ) — Other assets 66,901 (15,092 ) 51,809 Change in total assets $ 28,116 Accounts payable $ 8,034 $ 457 $ 8,491 Accrued expenses and other current liabilities 123,280 6,157 129,437 Due to SunEdison, net — 44,254 44,254 Current portion of long-term debt 327,714 (8,216 ) 319,498 Long-term debt, less current portion 968,047 (15,394 ) 952,653 Change in total liabilities $ 27,258 Additional paid-in capital $ 923,924 $ (184 ) $ 923,740 Accumulated deficit (212,661 ) 532 (212,129 ) Accumulated other comprehensive loss (11,253 ) 72 (11,181 ) Non-controlling interests 480,668 438 481,106 Change in total stockholders' equity $ 858

Acquisitions (Tables)

Acquisitions (Tables)	6 Months Ended
	Jun. 30, 2016
Business Combinations [Abstract]
Pro Forma for Acquisitions	The net sales and net loss related to the foregoing acquisitions are reflected in the accompanying unaudited condensed consolidated statements of operations for the six months ended June 30, 2016 as shown below. Six Months Ended June 30, 2016 (In thousands) FERSA Alto Cielo Net sales 4,103 679 Net (loss) income (582 ) 266 Unaudited Pro Forma Supplementary Data The unaudited pro forma supplementary data presented in the table below gives effect to the acquisitions as if the transactions occurred on January 1, 2015. The pro forma supplementary data is provided for informational purposes only and should not be construed to be indicative of the Company’s results of operations had the acquisitions been consummated on the date assumed or of its results of operations for any future date. Six Months Ended June 30, (In thousands) 2016 2015 ProForma Net sales $ 104,527 $ 48,435 Net loss (373 ) (34,131 )
Schedule of Recognized Assets and Liabilities	The acquisition date allocation of assets and liabilities for the above acquisitions as of June 30, 2016 is as follows: 2016 (In thousands) FERSA Final Alto Cielo Preliminary Cash and cash equivalents $ 8,022 $ 190 Restricted cash — 1,923 Accounts receivable 4,220 311 Power plants 55,312 35,530 Intangible assets 8,400 — Other assets 1,182 2,738 Total assets acquired 77,136 40,692 Accrued expenses and other current liabilities 4,479 3,670 Deferred tax liabilities 1,518 673 Long-term debt, including current portion 38,746 4,031 Total liabilities assumed 44,743 8,374 Fair value of net assets acquired $ 32,393 $ 32,318

Power Plants (Tables)

Power Plants (Tables)	6 Months Ended
	Jun. 30, 2016
Property, Plant and Equipment [Abstract]
Schedule of Power Plants, Net	Power plants, net consists of the following: (In thousands) June 30, 2016 December 31, 2015 Land $ 11,225 $ 9,749 Wind power plants 773,869 562,086 Solar power plants 658,412 674,856 Total power plants in service, at cost 1,443,506 1,246,691 Less: accumulated depreciation (69,180 ) (40,600 ) Total power plants in service, net 1,374,326 1,206,091 Construction in progress - solar projects 928 513 Total power plants, net $ 1,375,254 $ 1,206,604

Deposits for Acquisitions (Tabl

Deposits for Acquisitions (Tables)	6 Months Ended
	Jun. 30, 2016
Deferred Costs, Capitalized, Prepaid, and Other Assets Disclosure [Abstract]
Deposits for Acquisitions	Deposits for acquisitions consist of: As of June 30, As of December 31, (In thousands) 2016 2015 India PSA payment to SunEdison $ 231,000 $ 231,000 BioTherm payment 51,101 51,101 Total deposits for acquisitions 282,101 282,101 Less: provision for contingent loss (231,000 ) (231,000 ) Less: BioTherm distribution (1,368 ) — Total deposits for acquisitions, net $ 49,733 $ 51,101

Intangible Assets (Tables)

Intangible Assets (Tables)	6 Months Ended
	Jun. 30, 2016
Finite-Lived Intangible Assets, Net [Abstract]
Schedule of Gross Carrying Amount and Accumulated Amortization of Other Intangible Assets	The following table presents the gross carrying amount and accumulated amortization of intangible assets as of June 30, 2016 : (In thousands, except weighted average amortization period) Remaining Weighted Average Amortization Period (Years) Gross Carrying Amount Accumulated Amortization Accumulated Currency Translation Adjustment Net Book Value In-place value of market rate revenue contracts 19 $ 84,643 $ (3,537 ) $ (11,052 ) $ 70,054 The following table presents the gross carrying amount and accumulated amortization of intangibles as of December 31, 2015: (In thousands, except weighted average amortization period) Remaining Weighted Average Amortization Period (Years) Gross Carrying Amount Accumulated Amortization Accumulated Currency Translation Adjustment Net Book Value In-place value of market rate revenue contracts 20 $ 84,643 $ (1,632 ) $ (12,381 ) $ 70,630

Variable Interest Entities (Tab

Variable Interest Entities (Tables)	6 Months Ended
	Jun. 30, 2016
Organization, Consolidation and Presentation of Financial Statements [Abstract]
Schedule of Variable Interest Entities	The carrying amounts and classification of the consolidated VIEs’ assets and liabilities included in the Company’s unaudited condensed consolidated balance sheets are as follows: (In thousands) As of June 30, 2016 As of December 31, 2015 Current assets $ 194,980 $ 212,295 Non-current assets 528,624 560,228 Total assets $ 723,604 $ 772,523 Current liabilities $ 397,705 $ 351,554 Non-current liabilities 61,444 80,158 Total liabilities $ 459,149 $ 431,712

Long-Term Debt (Tables)

Long-Term Debt (Tables)	6 Months Ended
	Jun. 30, 2016
Debt Disclosure [Abstract]
Schedule of Long-term Debt	Long-term debt as of June 30, 2016 and December 31, 2015 consists of the following: As of June 30, As of December 31, (In thousands, except rates) 2016 2015 Interest Type Current Interest Rate (%) (1) Financing Type Corporate level long-term debt: Revolving Credit Facility $ 135,000 $ 135,000 Variable 3.9% Revolving line of credit Senior Notes due 2022 752,445 791,826 Fixed 9.8% Term debt Project level long-term debt: Permanent financing 346,281 368,935 Blended 12.1% (2) Term debt Total long-term debt 1,233,726 1,295,761 Less: deferred financing costs, net (3) 21,419 23,610 Less: current portion of long-term debt (4) 324,225 319,498 Consolidated long-term debt, less current portion $ 888,082 $ 952,653 (1) The weighted average effective interest rate as of June 30, 2016 . (2) As of June 30, 2016 , 11.3% of this balance had fixed interest rate debt and the remaining 88.7% had variable interest rate debt, of which a portion is hedged with interest rate swaps. (3) Total net debt reflects the reclassification of deferred financing costs to reduce long-term debt as further described in Note 1 - Nature of Operations and Basis of Presentation. (4) Approximately $319.9 million and $319.0 million have been classified as current due to non-compliance with certain debt covenants as of June 30, 2016 and December 31, 2015 , respectively.
Schedule of Maturities of Long-term Debt	The aggregate amounts of contractual payments of long-term debt due after June 30, 2016 , excluding amortization of debt discounts and premiums, as stated in the financing agreements, are as follows: Maturities (1) (In thousands) Within 1 Year Year 1 through Year 2 Year 2 through Year 3 Year 3 through Year 4 Year 4 through Year 5 Thereafter Total Corporate $ — $ — $ — $ 135,000 $ — $ 752,445 $ 887,445 Project level $ 12,617 $ 8,145 $ 10,176 $ 14,613 $ 17,221 $ 283,509 $ 346,281 Total debt $ 12,617 $ 8,145 $ 10,176 $ 149,613 $ 17,221 $ 1,035,954 $ 1,233,726

Income Taxes (Tables)

Income Taxes (Tables)	6 Months Ended
	Jun. 30, 2016
Income Tax Disclosure [Abstract]
Components of Income Tax Provision	The income tax provision consisted of the following: Three Months Ended June 30, Six Months Ended June 30, (In thousands, except effective tax rate) 2016 2015 2016 2015 Income (loss) before income tax expense $ 7,742 $ (23,347 ) $ 2,352 $ (33,454 ) Income tax expense (benefit) 2,061 (668 ) 2,919 450 Effective tax rate 26.6 % 2.9 % 124.1 % (1.3 )%

Derivatives (Tables)

Derivatives (Tables)	6 Months Ended
	Jun. 30, 2016
Derivative Instruments and Hedging Activities Disclosure [Abstract]
Schedule of Derivative Instruments in Statement of Financial Position, Fair Value	Activities related to derivative instruments were reported in the line items as of and for the periods indicated, as follows: (In thousands) Fair Value As of Type of Instrument Balance Sheet Classification June 30, 2016 December 31, 2015 Derivatives designated as hedging: Interest rate swaps Other assets (liabilities) $ (2,329 ) $ 6,210 Accumulated other comprehensive loss (income) 2,329 (6,210 ) Cross currency swaps Other assets 50,566 64,083 Accumulated other comprehensive loss 9,779 1,202 Derivatives not designated as hedging: Interest rate swaps Other assets $ 412 $ 5,194 Foreign currency forward contracts Other (liabilities) assets (9,549 ) 21,383 (In thousands) Three Months Ended June 30, Six Months Ended June 30, Type of Instrument Statement of Operations Classification 2016 2015 2016 2015 Derivatives not designated as hedging: Interest rate swaps Interest income $ (1,813 ) $ (1,064 ) $ (4,782 ) $ (470 ) Currency forward contract Other expenses, net 14,021 — 32,184 —
Gain (Loss) of Derivative Instruments	(In thousands) Three Months Ended June 30, Six Months Ended June 30, Type of Instrument Statement of Operations Classification 2016 2015 2016 2015 Derivatives not designated as hedging: Interest rate swaps Interest income $ (1,813 ) $ (1,064 ) $ (4,782 ) $ (470 ) Currency forward contract Other expenses, net 14,021 — 32,184 —
Schedule of Notional Amounts	(In thousands) Notional Amounts as of June 30, 2016 Derivatives designated as hedges: Interest rate swaps (USD) 121,213 Cross currency swaps (USD) 121,213 Derivatives not designated as hedges: Interest rate swaps (USD) 113,612 Currency forward contracts (BRL) 87,333 Currency forward contracts (CNY) 34,192 Currency forward contracts (INR) 85,904 Currency forward contracts (MYR) 7,940 Currency forward contracts (THB) 11,408 Currency forward contracts (ZAR) 38,691 Currency forward contracts (USD) 27,651

Fair Value of Financial Instr38

Fair Value of Financial Instruments (Tables)	6 Months Ended
	Jun. 30, 2016
Fair Value Disclosures [Abstract]
Schedule of Carrying Values and Estimated Fair Values of Debt	The following table presents the carrying amount and estimated fair value of our outstanding short-term and long-term debt obligations as of June 30, 2016 and December 31, 2015 , respectively: As of June 30, 2016 As of December 31, 2015 (In thousands) Carrying Amount Fair Value Carrying Amount Fair Value Long-term debt, including current portion $ 1,233,726 $ 1,148,307 $ 1,295,761 $ 1,125,124
Fair Value, Assets and Liabilities Measured on Recurring Basis	The following table summarizes the financial instruments measured at fair value on a recurring basis classified in the fair value hierarchy (Level 1, 2 or 3) based on the inputs used for valuation in the accompanying unaudited condensed consolidated balance sheets as of June 30, 2016 and in the audited condensed consolidated balance sheets as of December 31, 2015 : As of June 30, 2016 As of December 31, 2015 Assets (liabilities) in thousands Level 1 Level 2 Level 3 Total Level 1 Level 2 Level 3 Total Interest rate swaps $ — $ (1,917 ) $ — $ (1,917 ) $ — $ 11,404 $ — $ 11,404 Foreign currency forward contracts (9,549 ) — — (9,549 ) 21,383 — — 21,383 Cross currency swaps — 50,566 — 50,566 — 64,083 — 64,083 Total $ (9,549 ) $ 48,649 $ — $ 39,100 $ 21,383 $ 75,487 $ — $ 96,870

Stockholders' Equity (Tables)

Stockholders' Equity (Tables)	6 Months Ended
	Jun. 30, 2016
Equity [Abstract]
Schedule of Outstanding Equity Securities	As of June 30, 2016 , the following shares of the Company were outstanding: Class: Number Outstanding Holders Class A common stock 113,101,162 * Class B common stock 61,343,054 SunEdison Class B1 common stock — Not Applicable Preferred stock — Not Applicable Total shares outstanding 174,444,216 *Class A common stockholders are comprised of: public stockholders, Renova Energia SA, BTSA Netherlands Cooperatie UA, executive officers, management and employees.

Stock-Based Compensation (Table

Stock-Based Compensation (Tables)	6 Months Ended
	Jun. 30, 2016
Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted Stock and Restricted Stock Units Activity	The following table presents information regarding outstanding RSAs as of June 30, 2016 and changes during the six -month period then ended, after giving effect to the conversion of restricted Class C common stock to restricted Class A common stock on a 178.8491 -for- one basis: Number of RSAs Outstanding Weighted Average Grant Date Fair Value Per Share Aggregate Intrinsic Value Outstanding at January 1, 2016 7,774,554 $ 0.18 Forfeited (1,749,137 ) 0.18 Outstanding at June 30, 2016 6,025,417 $ 0.17 $ 19.6
Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted Stock and Restricted Stock Units Activity	The following table presents information regarding outstanding RSUs as of June 30, 2016 and changes during the six -month period then ended, after giving effect to the conversion of restricted Class C common stock to restricted Class A common stock on a 178.8491 -for- one basis: Number of RSUs Outstanding Aggregate Intrinsic Value (in millions) Weighted Average Remaining Balance at January 1, 2016 2,846,049 Granted 403,737 Forfeited (733,839 ) Balance at June 30, 2016 2,515,947 $ 8.2 1.6

Earnings (Loss) Per Share (Tabl

Earnings (Loss) Per Share (Tables)	6 Months Ended
	Jun. 30, 2016
Earnings Per Share [Abstract]
Schedule of Basic and DIluted Loss Per Share	Basic and diluted earnings (loss) per share for the three and six months ended June 30, 2016 was calculated as follows: Three Months Ended June 30, 2016 Six Months Ended June 30, 2016 (In thousands, except per share amounts) Basic and diluted earnings (loss) per share (1) : Net income (loss) attributable to Class A common stockholders $ 1,097 $ (3,535 ) Less: dividends paid on Class A common stock and participating RSAs — 30,674 Undistributed loss attributable to Class A stockholders $ 1,097 $ (34,209 ) Weighted-average shares outstanding 106,856 106,856 Distributed earnings per share $ — $ 0.29 Undistributed earnings (loss) per share 0.01 (0.32 ) Basic and diluted earnings (loss) per share $ 0.01 $ (0.03 )

Non-Controlling Interests (Tabl

Non-Controlling Interests (Tables)	6 Months Ended
	Jun. 30, 2016
Noncontrolling Interest [Abstract]
Schedule of Non-controlling Interests	The following table presents the non-controlling interest balances by entity, reported in stockholders’ equity in the unaudited condensed consolidated balance sheets as of June 30, 2016 and December 31, 2015 : (in thousands) As of June 30, 2016 As of December 31, 2015 SunEdison's non-controlling interests in Global LLC $ 395,732 $ 375,540 Non-controlling interests in power plants 91,382 105,566 Total non-controlling interests $ 487,114 $ 481,106

Segment Reporting (Tables)

Segment Reporting (Tables)	6 Months Ended
	Jun. 30, 2016
Segment Reporting [Abstract]
Schedule of Segment Reporting Information, by Segment	The following table reflects summarized financial information concerning the Company’s reportable segments for the three and six months ended June 30, 2016 and 2015 : Three Months Ended June 30, 2016 Three Months Ended June 30, 2015 (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Operating revenues, net $ 28,878 $ 27,552 $ — $ 56,430 22,017 3,664 — 25,681 Depreciation, accretion and amortization 6,509 6,516 — 13,025 3,738 (402 ) — 3,336 Other operating costs and expenses 4,703 5,899 15,503 26,105 7,990 4,085 12,510 24,586 Interest expense, net 10,372 (281 ) 18,884 28,975 12,863 725 14,598 28,186 Other non-operating (income) expenses 14,304 1,053 (34,774 ) (19,417 ) (6,640 ) (440 ) — (7,080 ) Income tax expense (benefit) — — 2,061 2,061 — — (668 ) (668 ) Net income (loss) (7,010 ) 14,365 (1,674 ) 5,681 4,066 (304 ) (26,440 ) (22,679 ) Six Months Ended June 30, 2016 Six Months Ended June 30, 2015 (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Operating revenues, net 57,617 46,499 — 104,116 39,823 3,664 — 43,487 Depreciation, accretion and amortization 12,381 15,216 — 27,597 6,473 (402 ) — 6,071 Other operating costs and expenses 11,273 13,328 31,925 56,526 9,312 4,085 19,963 33,361 Interest expense (income), net 22,634 (2,049 ) 42,053 62,638 23,247 725 21,036 45,007 Other non-operating (income) expenses 18,549 3,042 (66,588 ) (44,997 ) (7,058 ) (440 ) — (7,498 ) Income tax expense — — 2,919 2,919 — — 450 450 Net income (loss) (7,220 ) 16,962 (10,309 ) (567 ) 7,849 (304 ) (41,449 ) (33,904 )
Reconciliation of Assets from Segment to Consolidated	The following table reflects reportable segment assets as of June 30, 2016 , and December 31, 2015 : Balance Sheet As of June 30, 2016 As of December 31, 2015 (3) (In thousands) Solar Wind Corporate Total Solar Wind Corporate Total Total assets $ 671,131 $ 431,578 $ 1,553,076 $ 2,655,785 $ 764,475 $ 375,683 $ 1,547,008 $ 2,687,166 (1) Income tax benefit is not allocated to the Company’s Solar and Wind segments. (2) Corporate assets include cash and cash equivalents, intercompany accounts receivable, other current assets and other assets. (3) When power plants are sold to the Company after completion by SunEdison, the Company retroactively recasts its historical financial statements to present the construction activity as if it consolidated the facility at inception of the construction (see Note 2 - Transactions Between Entities Under Common Control ). Recasted values are included in the December 31, 2015 asset balances disclosed above.

Other Comprehensive Income (L44

Other Comprehensive Income (Loss) (Tables)	6 Months Ended
	Jun. 30, 2016
Equity [Abstract]
Schedule of Other Comprehensive Income (Loss)	The following table presents the changes in each component of accumulated other comprehensive loss: (In thousands) Foreign Currency Translation Adjustments Hedging Activities Accumulated Other Comprehensive Income (loss) Balance as of December 31, 2015 $ (12,819 ) $ 1,638 $ (11,181 ) Other comprehensive income (loss) 38,511 (17,116 ) 21,395 Less: other comprehensive income (loss) attributable to non-controlling interests 15,189 (11,456 ) 3,733 Balance as of June 30, 2016 10,503 (4,022 ) 6,481
Components of Accumulated Other Comprehensive Loss	The following tables present the changes in each component of accumulated other comprehensive loss and the related tax effects for the three and six months ended June 30, 2016 : Three Months Ended June 30, 2016 (In thousands) Before Tax Tax Effect Net of Tax Foreign currency translation adjustments $ 33,954 $ 271 $ 34,225 Unrealized (loss) gain on hedging instruments (2,653 ) 4,792 2,139 Net other comprehensive income (loss) $ 31,301 $ 5,063 $ 36,364 Less: Other comprehensive income attributable to non-controlling interests, net of tax 14,886 Other comprehensive income (loss) attributable to Class A stockholders $ 21,478 Six Months Ended June 30, 2016 (In thousands) Before Tax Tax Effect Net of Tax Foreign currency translation adjustments $ 38,511 $ 271 $ 38,782 Unrealized (loss) gain on hedging instruments (17,116 ) 4,792 (12,324 ) Net other comprehensive income (loss) $ 21,395 $ 5,063 $ 26,458 Less: Other comprehensive income attributable to non-controlling interests, net of tax 7,036 Other comprehensive income (loss) attributable to Class A stockholders $ 19,422

Nature of Operations - Narrativ

Nature of Operations - Narrative (Details) - USD ($) $ in Thousands	Dec. 22, 2016	May 31, 2016	Dec. 31, 2016	Jun. 30, 2016	Dec. 31, 2015
Debt Instrument [Line Items]
Debt issuance costs reclassified				$ 21,419	$ 23,610
Global Operating LLC Revolver | Subsequent event | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Debt covenant, minimum threshold percentage of ownership for acceleration	50.00%		50.00%
Global Operating LLC | Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Debt covenant, minimum threshold percentage of ownership for acceleration		25.00%
Global Operating LLC | Senior notes | Subsequent event | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Debt covenant, minimum threshold percentage of ownership for acceleration			25.00%
Long-term debt and financing lease obligation | Accounting Standards Update 2015-03
Debt Instrument [Line Items]
Debt issuance costs reclassified				21,419	23,610
Deferred financing costs, net | Accounting Standards Update 2015-03
Debt Instrument [Line Items]
Debt issuance costs reclassified				$ (21,419)	$ (23,610)

Transactions Between Entities46

Transactions Between Entities Under Common Control - Changes in Previously Reported Balance Sheet Details (Details) $ in Thousands	Jun. 30, 2016USD ($)	Feb. 24, 2016power_plantMW	Dec. 31, 2015USD ($)	Jun. 30, 2015USD ($)	Dec. 31, 2014USD ($)
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Cash and cash equivalents	$ 870,494		$ 922,318	$ 667,738	$ 150,146
Prepaid expenses and other current assets	117,841		139,335
Power plants, net	1,375,254		1,206,604
Restricted cash	18,003		22,682
Due from SunEdison, net			0
Other assets	40,211		51,809
Total assets	2,655,785		2,687,166
Accounts payable	23,555		8,491
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015	111,305		129,437
Due to Sun Edison, net	29,326		44,254
Less current portion of long-term debt	324,225		319,498
Long-term debt, less current portion	888,082		952,653
Total liabilities	1,438,886		1,503,899
Additional paid-in capital	935,492		923,740
Accumulated deficit	(215,664)		(212,129)
Accumulated other comprehensive loss	8,241		(11,181)
Non-controlling interests	487,114		481,106
Total TerraForm Global, Inc. stockholders’ equity	729,785		702,161
Debt issuance costs reclassified	$ (21,419)		(23,610)
Unadjusted
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Cash and cash equivalents			921,946
Prepaid expenses and other current assets			144,743
Power plants, net			1,148,350
Restricted cash			22,582
Due from SunEdison, net			10,110
Other assets			66,901
Accounts payable			8,034
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015			123,280
Due to Sun Edison, net			0
Less current portion of long-term debt			327,714
Long-term debt, less current portion			968,047
Additional paid-in capital			923,924
Accumulated deficit			(212,661)
Accumulated other comprehensive loss			(11,253)
Non-controlling interests			480,668
Recast Adjustments
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Cash and cash equivalents			372
Prepaid expenses and other current assets			(5,408)
Power plants, net			58,254
Restricted cash			100
Due from SunEdison, net			(10,110)
Other assets			(15,092)
Total assets			28,116
Accounts payable			457
Accrued expenses and other current liabilities, including consolidated variable interest entities of $46,773 in June 30, 2016 and $15,496 in December 31, 2015			6,157
Due to Sun Edison, net			44,254
Less current portion of long-term debt			(8,216)
Long-term debt, less current portion			(15,394)
Total liabilities			27,258
Additional paid-in capital			(184)
Accumulated deficit			532
Accumulated other comprehensive loss			72
Non-controlling interests			438
Total TerraForm Global, Inc. stockholders’ equity			858
NPS Star and WXA
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Number of projects acquired | power_plant		2
Capacity of acquired power plants | MW		35.6
Other current assets | Accounting Standards Update 2015-03
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Debt issuance costs reclassified			23,600
Long-term debt, less current portion | Accounting Standards Update 2015-03
Error Corrections and Prior Period Adjustments Restatement [Line Items]
Debt issuance costs reclassified			$ (23,600)

Acquisitions - 2016 and 2015 Ac

Acquisitions - 2016 and 2015 Acquisition Narrative (Details) $ / shares in Units, $ in Millions

Apr. 08, 2016USD ($)MW

Dec. 31, 2015USD ($)shares

Oct. 07, 2015USD ($)power_plantMW

Sep. 18, 2015USD ($)$ / sharesMWshares

Aug. 06, 2015USD ($)MW

Jun. 09, 2015USD ($)MW

May 14, 2015USD ($)wind_projectMW

Mar. 31, 2016shares

Jul. 31, 2015hydro_power_projectdirector

Jun. 30, 2016USD ($)shares

Jun. 30, 2016USD ($)

Apr. 30, 2016

Feb. 24, 2016power_plantMW

Jul. 31, 2015wind_project

Jul. 31, 2015MW

Renova Energia S.A.

Business Acquisition [Line Items]

Ownership interest threshold for board of directors appointment rights

28.00%

NPS Star and WXA

Business Acquisition [Line Items]

Percentage of voting interests acquired

49.00%

Number of projects acquired | power_plant

2

Capacity of acquired power plants | MW

35.6

NPS Star

Business Acquisition [Line Items]

Number of projects acquired | power_plant

3

Capacity of acquired power plants | MW

17.8

WXA

Business Acquisition [Line Items]

Number of projects acquired | power_plant

3

Capacity of acquired power plants | MW

17.8

Alto Cielo Preliminary

Business Acquisition [Line Items]

Percentage of voting interests acquired

100.00%

Capacity of acquired power plants | MW

26.4

Payments to acquire businesses

$ 32.3

Escrow deposits related to property sale

$ 1.8

$ 1.8

Certain India project

Business Acquisition [Line Items]

Percentage of voting interests acquired

51.00%

Honiton

Business Acquisition [Line Items]

Percentage of voting interests acquired

100.00%

Number of projects acquired | wind_project

3

Capacity of acquired power plants | MW

148.5

Payments to acquire businesses

$ 109.1

NSM 24

Business Acquisition [Line Items]

Percentage of voting interests acquired

51.00%

Capacity of acquired power plants | MW

24

Payments to acquire businesses

$ 9.1

Subsequent equity interest in acquisition, percent

49.00%

Equity interest in acquiree, fair value

$ 8.7

Remeasurement gain

$ 1.4

Witkop / Soutpan

Business Acquisition [Line Items]

Payments to acquire businesses

$ 38.7

Fair value of aggregate interest

$ 47.8

Witkop / Soutpan | SunEdison

Business Acquisition [Line Items]

Percentage of voting interests acquired

41.30%

Capacity of acquired power plants | MW

32.6

Equity interest prior to acquisition

9.70%

Renova (Salvador / Bahia)

Business Acquisition [Line Items]

Number of projects acquired | wind_project

2

Capacity of acquired power plants | MW

306.7

Payments to acquire businesses

$ 117.3

117.7

Acquisition agreement, number of projects to be acquired

1

2

Acquisition agreement, capacity of projects to be acquired (in MW) | MW

336.2

Acquisition purchase price

$ 321.3

$ 320.7

Common stock issued in acquisition (in shares) | shares

20,327,499

put / call arrangement transferred in acquisition

$ 20.4

Amount held in escrow pending lender release letter

$ 49.2

Renova (Salvador / Bahia) | SunEdison

Business Acquisition [Line Items]

put / call arrangement transferred in acquisition

20.4

FERSA Final

Business Acquisition [Line Items]

Number of projects acquired | power_plant

3

Capacity of acquired power plants | MW

101.6

Acquisition purchase price

$ 72.4

Repayments of long-term debt

$ 39

Common Stock | Renova (Salvador / Bahia)

Business Acquisition [Line Items]

Common stock issued in acquisition (in shares) | shares

20,327,499

20,223,581

Value assigned to equity acquisition

$ 183.6

$ 182.6

$ 182.6

Shares issued or issuable, value assigned (in usd per share) | $ / shares

$ 9.03

Omnibus agreement | Renova (Salvador / Bahia) | Renova

Business Acquisition [Line Items]

Payments on (proceeds from) previous acquisition

$ 5

Omnibus agreement | Renova (Salvador / Bahia) | Renova Energia S.A.

Business Acquisition [Line Items]

Number of board of director appointments | director

1

Counterparty ownership interest threshold, percentage of shares owned

100.00%

Common Class A | Omnibus agreement | Renova (Salvador / Bahia) | Global LLC

Business Acquisition [Line Items]

Common stock terminated in business acquisition (in shares) | shares

19,221,671

Acquisitions - Proforma (Detail

Acquisitions - Proforma (Details) - USD ($) $ in Thousands	6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015
FERSA Final
Business Combination, Pro Forma Information, Results of Acquiree since Acquisition Date, Actual [Abstract]
Net sales	$ 4,103
Net (loss) income	(582)
Net sales, pro forma	104,527	$ 48,435
Net income loss, pro forma	(373)	$ (34,131)
Alto Cielo Preliminary
Business Combination, Pro Forma Information, Results of Acquiree since Acquisition Date, Actual [Abstract]
Net sales	679
Net (loss) income	$ 266

Acquisitions - Schedule of Acqu

Acquisitions - Schedule of Acquisition Accounting (Details) $ in Thousands	Jun. 30, 2016USD ($)
FERSA Final
Business Acquisition [Line Items]
Cash and cash equivalents	$ 8,022
Restricted cash	0
Accounts receivable, net	4,220
Renewable energy facilities, net	55,312
Intangible assets	8,400
Other assets	1,182
Total assets acquired	77,136
Accrued expenses and other current liabilities	4,479
Deferred tax liabilities	1,518
Long term debt, including current portion	38,746
Total liabilities assumed	44,743
Fair value of net assets acquired	32,393
Alto Cielo Preliminary
Business Acquisition [Line Items]
Cash and cash equivalents	190
Restricted cash	1,923
Accounts receivable, net	311
Renewable energy facilities, net	35,530
Intangible assets	0
Other assets	2,738
Total assets acquired	40,692
Accrued expenses and other current liabilities	3,670
Deferred tax liabilities	673
Long term debt, including current portion	4,031
Total liabilities assumed	8,374
Fair value of net assets acquired	$ 32,318

Acquisitions - Subsequent Event

Acquisitions - Subsequent Events and Transfer of Balance of Equity Narrative (Details) - Subsequent event - USD ($) $ in Millions	1 Months Ended
	Oct. 31, 2016	Jan. 27, 2017	Nov. 30, 2016
Azure
Business Acquisition [Line Items]
Additional ownership interest acquired			26.00%
Millenium Solar Power
Business Acquisition [Line Items]
Additional ownership interest acquired		26.00%
Millenium Solar Power
Business Acquisition [Line Items]
Additional ownership interest acquired	11.00%
Payments to acquire additional interest in subsidiaries	$ 1
Focal Solar Power Plant
Business Acquisition [Line Items]
Percentage of voting interests acquired	51.00%
Payments to acquire businesses	$ 0.5

Acquisitions - Pending Acquisit

Acquisitions - Pending Acquisitions Narrative (Details) ZAR in Millions, $ in Millions	Jan. 31, 2017USD ($)	Jan. 31, 2017ZAR	Apr. 30, 2015power_plantMWshares	Dec. 22, 2016USD ($)	Jun. 30, 2016USD ($)shares	Mar. 31, 2017USD ($)	Mar. 31, 2017ZAR	Mar. 31, 2016USD ($)	Feb. 24, 2016power_plantMW	Aug. 31, 2015USD ($)power_plant	Aug. 04, 2015MW
BioTherm
Business Acquisition [Line Items]
Number of projects acquired | power_plant			3
Escrow deposit | $					$ 43.9					$ 65.6
NPS Star
Business Acquisition [Line Items]
Number of projects acquired | power_plant									3
Capacity of acquired power plants | MW									17.8
WXA
Business Acquisition [Line Items]
Number of projects acquired | power_plant									3
Capacity of acquired power plants | MW									17.8
Non-current restricted cash | BioTherm
Business Acquisition [Line Items]
Cash deposits held for acquisitions | $								$ 20.3
SunEdison | Del Litoral
Business Acquisition [Line Items]
Capacity of acquired power plants | MW											17.4
SunEdison | El Naranjal
Business Acquisition [Line Items]
Capacity of acquired power plants | MW											57.4
SunEdison | Bora Bora
Business Acquisition [Line Items]
Capacity of acquired power plants | MW											24.1
Scenario, forecast | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses | $	$ 8.9					$ 74.5
Scenario, forecast | Minority Interests in South African Acquisition [Member] | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses	5.9	ZAR 88.9
Scenario, forecast | USD | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses | $						67.6
Scenario, forecast | USD | BioTherm | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses | $	2
Scenario, forecast | ZAR | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses						$ 6.7	ZAR 100.4
Scenario, forecast | ZAR | BioTherm | BioTherm
Business Acquisition [Line Items]
Payments to acquire businesses	$ 0.8	ZAR 11.6
Common Stock | Deposits for acquisitions | BioTherm
Business Acquisition [Line Items]
Common stock issued in acquisition (in shares) | shares			544,055		544,055
Assets associated with third party sale | Subsequent event
Business Acquisition [Line Items]
Proceeds from Third Party Sale Transaction | $				$ 6.7
South Africa | BioTherm
Business Acquisition [Line Items]
Number of projects acquired | power_plant			3							3
Capacity of acquired power plants | MW			32.6

Acquisitions - Terminated Acqui

Acquisitions - Terminated Acquisitions Narrative (Details) $ in Millions	Dec. 13, 2016USD ($)	Mar. 29, 2016USD ($)	Jun. 30, 2015USD ($)power_plantMWshares	May 19, 2015MW
GME
Business Acquisition [Line Items]
Acquisition agreement, number of projects to be acquired | power_plant			4
Capacity of acquired power plants | MW			326
Payments to acquire businesses			$ 337.9
Interest rate on purchase price			15.00%
SunEdison | LAP
Business Acquisition [Line Items]
Acquisition agreement, capacity of projects to be acquired (in MW) | MW				72.5
SunEdison | GME
Business Acquisition [Line Items]
Company payments for solar plants			$ 46.9
Renova | ESPRA
Business Acquisition [Line Items]
Agreement termination fee		$ 10
Subsequent event | GME
Business Acquisition [Line Items]
Reimbursement of business acquisition, certain expenses	$ 0.4
Common Stock | GME
Business Acquisition [Line Items]
Common stock issued in acquisition (in shares) | shares			701,754

Power Plants - Schedule of Powe

Power Plants - Schedule of Power Plants, Net (Details) - USD ($) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015	Dec. 31, 2015
Renewable energy facility [Line Items]
Total power plants in service, at cost	$ 1,443,506		$ 1,443,506		$ 1,246,691
Less: accumulated depreciation	(69,180)		(69,180)		(40,600)
Total power plants in service, net	1,374,326		1,374,326		1,206,091
Power plants, net	1,375,254		1,375,254		1,206,604
Land
Renewable energy facility [Line Items]
Total power plants in service, at cost	11,225		11,225		9,749
Wind power plants
Renewable energy facility [Line Items]
Total power plants in service, at cost	773,869		773,869		562,086
Solar power plants
Renewable energy facility [Line Items]
Total power plants in service, at cost	658,412		658,412		674,856
Construction in progress - solar projects
Renewable energy facility [Line Items]
Power plants, net	928		928		513
Power plants
Renewable energy facility [Line Items]
Depreciation	12,100	$ 3,000	$ 25,800	$ 5,700
Solar Energy Corporation of India (SECI) | India PSA
Renewable energy facility [Line Items]
Solar generation, subsidy receipts, year one, percentage			10.00%
Solar generation, subsidy receipts, next twelve months, percentage			50.00%
Viability Gap Funding subsidies			$ 8,900
Solar Energy Corporation of India (SECI) | India PSA | Other current assets
Renewable energy facility [Line Items]
Solar generation, government subsidies receivable	1,800		1,800		10,700
Solar Energy Corporation of India (SECI) | India PSA | Other assets
Renewable energy facility [Line Items]
Solar generation, government subsidies receivable	$ 7,000		$ 7,000		$ 7,100

Deposits for Acquisitions - Sch

Deposits for Acquisitions - Schedule of Deposits for Acquisitions (Details) $ in Thousands	Apr. 12, 2016USD ($)	Apr. 30, 2015power_plantshares	Jun. 30, 2016USD ($)	Mar. 31, 2016USD ($)	Dec. 31, 2015USD ($)MW	Dec. 22, 2016USD ($)	Jun. 30, 2016USD ($)shares	Dec. 31, 2015USD ($)MW	Nov. 20, 2015power_plant	Aug. 31, 2015USD ($)
Business Combination, Separately Recognized Transactions [Line Items]
Deposits for acquisitions			$ 282,101		$ 282,101		$ 282,101	$ 282,101
Less: provision for contingent loss			231,000		231,000		231,000	231,000
Deposit for acquisitions, net			49,733		51,101		49,733	51,101
Escrow deposit			18,003		22,682		18,003	22,682
India PSA
Business Combination, Separately Recognized Transactions [Line Items]
Deposits for acquisitions			231,000		$ 231,000		231,000	$ 231,000
Less: provision for contingent loss			231,000				231,000
India PSA | India
Business Combination, Separately Recognized Transactions [Line Items]
Capacity of acquired power plants | MW					425			425
BioTherm
Business Combination, Separately Recognized Transactions [Line Items]
Deposits for acquisitions			51,101		$ 51,101		51,101	$ 51,101
Less: BioTherm distribution			0	$ (1,368)				$ 0
Number of projects acquired | power_plant		3
Escrow deposit			43,900				43,900			$ 65,600
Acquisition purchase price					$ 71,400
BioTherm | Non-current restricted cash
Business Combination, Separately Recognized Transactions [Line Items]
Escrow deposit			18,000				18,000
Non-current restricted cash				$ 20,300
SunEdison | India PSA | India
Business Combination, Separately Recognized Transactions [Line Items]
Deposits for acquisitions			231,000				$ 231,000
Number of projects acquired | power_plant									17
Aries and Kookoonsies | BioTherm
Business Combination, Separately Recognized Transactions [Line Items]
Less: BioTherm distribution			$ (2,300)
Subsequent event | Aries and Kookoonsies | BioTherm
Business Combination, Separately Recognized Transactions [Line Items]
Less: BioTherm distribution						$ (1,700)
Subsequent event | Klipheuwel | BioTherm
Business Combination, Separately Recognized Transactions [Line Items]
Less: BioTherm distribution						$ (1,100)
Pending litigation | TerraForm Global, Inc. v. SunEdison, Inc, et al. | India PSA
Business Combination, Separately Recognized Transactions [Line Items]
Amount sought through litigation	$ 231,000
Common Stock | BioTherm | Deposits for acquisitions
Business Combination, Separately Recognized Transactions [Line Items]
Common stock issued in acquisition (in shares) | shares		544,055					544,055

Intangible Assets - Schedule of

Intangible Assets - Schedule of Gross Carrying Amounts and Accumulated Amortization of Intangible Assets (Details) - USD ($) $ in Thousands	3 Months Ended	6 Months Ended	12 Months Ended
	Jun. 30, 2016	Jun. 30, 2016	Dec. 31, 2015
Finite-Lived Intangible Assets [Line Items]
Amortization expense	$ 1,000	$ 1,900
Revenue contract
Intangible Assets, Net (Excluding Goodwill) [Abstract]
Remaining Weighted Average Amortization Period (Years)		19 years	20 years
Gross Carrying Amount	84,643	$ 84,643	$ 84,643
Accumulated Amortization	(3,537)	(3,537)	(1,632)
Accumulated Currency Translation Adjustment	(11,052)	(11,052)	(12,381)
Net Book Value	70,054	$ 70,054	$ 70,630
Minimum | Revenue contract
Finite-Lived Intangible Assets [Line Items]
Weighted average remaining life of intangibles		20 years
Maximum | Revenue contract
Finite-Lived Intangible Assets [Line Items]
Weighted average remaining life of intangibles		25 years
Operating revenues, net
Finite-Lived Intangible Assets [Line Items]
Amortization expense	200	$ 400
Depreciation, accretion and amortization
Finite-Lived Intangible Assets [Line Items]
Amortization expense	$ 800	$ 1,500

Variable Interest Entities - Ca

Variable Interest Entities - Carry Amounts and Classification of Assets and Liabilities (Details) $ in Thousands	6 Months Ended
	Jun. 30, 2016USD ($)entity	Jun. 30, 2016USD ($)power_plant	Feb. 24, 2016power_plantMW	Dec. 31, 2015USD ($)
Variable interest entities
Variable Interest Entity [Line Items]
Number of variable interest entities, primary beneficiary	13	11
VIE, primary beneficiary
Variable Interest Entity [Line Items]
Total assets	$ 723,604	$ 723,604		$ 772,523
Total liabilities	459,149	459,149		431,712
VIE, primary beneficiary | Current assets
Variable Interest Entity [Line Items]
Total assets	194,980	194,980		212,295
VIE, primary beneficiary | Non-current assets
Variable Interest Entity [Line Items]
Total assets	528,624	528,624		560,228
VIE, primary beneficiary | Current liabilities
Variable Interest Entity [Line Items]
Total liabilities	397,705	397,705		351,554
VIE, primary beneficiary | Non-current liabilities
Variable Interest Entity [Line Items]
Total liabilities	$ 61,444	$ 61,444		$ 80,158
NPS Star and WXA
Variable Interest Entity [Line Items]
Percentage of voting interests acquired			49.00%
Number of projects acquired | power_plant			2
Capacity of acquired power plants | MW			35.6
NPS Star
Variable Interest Entity [Line Items]
Number of projects acquired | power_plant			3
Capacity of acquired power plants | MW			17.8
WXA
Variable Interest Entity [Line Items]
Number of projects acquired | power_plant			3
Capacity of acquired power plants | MW			17.8

Long-Term Debt - Schedule of Lo

Long-Term Debt - Schedule of Long-Term Debt (Details) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Debt Instrument [Line Items]
Long-term debt	$ 1,233,726	$ 1,295,761
Less: deferred financing costs, net	21,419	23,610
Less current portion of long-term debt	324,225	319,498
Long-term debt, less current portion	888,082	952,653
Amount of long-term debt reclassified to current due to non-compliance with certain debt covenants	319,900	319,000
Permanent financing
Debt Instrument [Line Items]
Long-term debt	346,281
Revolving credit facility | Global Operating LLC Revolver
Debt Instrument [Line Items]
Long-term debt	$ 135,000	135,000
Variable and blended interest rate	3.90%
Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Long-term debt	$ 752,445	791,826
Stated interest rate	9.80%
Term debt | Permanent financing
Debt Instrument [Line Items]
Long-term debt	$ 346,281	$ 368,935
Variable and blended interest rate	12.10%
Long-term debt, percentage of debt bearing fixed interest	11.30%
Long-term debt, percentage of debt bearing variable interest	88.70%

Long-Term Debt - Corporate Leve

Long-Term Debt - Corporate Level Long-Term Debt Narrative (Details)	Sep. 08, 2016	Sep. 02, 2016	May 31, 2016	May 06, 2016USD ($)requirement	Jun. 30, 2016USD ($)	Dec. 31, 2015USD ($)
Revolving credit facility | Global Operating LLC Revolver
Debt Instrument [Line Items]
Line of credit outstanding					$ 135,000,000	$ 135,000,000
Line of credit, borrowing capacity				$ 350,000,000
Revolving credit facility | Global Operating LLC Revolver | Global Operating LLC
Debt Instrument [Line Items]
Debt instrument, debt covenant, grace period for annual report				75 days
Debt covenant, number of requirements | requirement				3
Revolving credit facility | Global Operating LLC Revolver | Global Operating LLC | Alto Cielo Preliminary
Debt Instrument [Line Items]
Amount of letters of credit outstanding					$ 0	$ 500,000
Senior notes | 9.75% Senior Notes due 2022 | Global Operating LLC
Debt Instrument [Line Items]
Debt instrument, debt covenant, grace period for annual report			60 days
Senior notes | 9.75% Senior Notes due 2022 | Global Operating LLC | Subsequent event
Debt Instrument [Line Items]
Redemption price, percentage	101.00%	101.00%

Long-Term Debt - Senior Notes N

Long-Term Debt - Senior Notes Narrative (Details)	Dec. 22, 2016	Dec. 06, 2016	Sep. 08, 2016	Sep. 02, 2016	May 31, 2016	Dec. 31, 2016	Jun. 30, 2016USD ($)	Dec. 31, 2015USD ($)
Debt Instrument [Line Items]
Long-term debt							$ 1,233,726,000	$ 1,295,761,000
Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Notional amount of senior debt							$ 760,400,000
Stated interest rate							9.80%
Long-term debt							$ 752,445,000	$ 791,826,000
Global Operating LLC Revolver | 9.75% Senior Notes due 2022 | Subsequent event
Debt Instrument [Line Items]
Debt covenant, minimum threshold percentage of ownership for acceleration	50.00%					50.00%
Global Operating LLC | Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Amount of long term debt outstanding							$ 752,445,000
Debt instrument, debt covenant, grace period for annual report					60 days
Debt covenant, cure period					90 days
Debt covenant, minimum threshold percentage of ownership for acceleration					25.00%
Global Operating LLC | Senior notes | 9.75% Senior Notes due 2022 | Subsequent event
Debt Instrument [Line Items]
Debt covenant, minimum threshold percentage of ownership for acceleration						25.00%
Debt covenant, waiver fee per principal amount		0.0035		0.005
Stated interest rate				4.00%
Redemption price, percentage			101.00%	101.00%

Long-Term Debt - Project-level

Long-Term Debt - Project-level Debt Narrative (Details) $ in Thousands	Jun. 16, 2016	May 31, 2016	Apr. 21, 2016power_plant	Jan. 31, 2016USD ($)	Dec. 31, 2015USD ($)	Jan. 31, 2016USD ($)	Jun. 30, 2016USD ($)	Mar. 31, 2016USD ($)	Jun. 30, 2015USD ($)	Jun. 30, 2016USD ($)	Jun. 30, 2015USD ($)	Dec. 31, 2015USD ($)	Sep. 02, 2016
Debt Instrument [Line Items]
Project level debt					$ 1,295,761		$ 1,233,726			$ 1,233,726		$ 1,295,761
Repayments of senior debt										35,441	$ 0
Loss (gain) on the extinguishment of debt							526		$ 1,219	(5,735)	1,219
Interest income							900		$ 0	3,200	$ 0
India PSA
Debt Instrument [Line Items]
Acquisition of projects, number of projects with accelerated debt maturities | power_plant			2
South Africa projects
Debt Instrument [Line Items]
Acquisition of projects, number of projects with accelerated debt maturities | power_plant			3
Permanent financing
Debt Instrument [Line Items]
Project level debt							346,281			346,281
Term debt | Permanent financing
Debt Instrument [Line Items]
Project level debt					368,935		346,281			346,281		368,935
Term debt | Permanent financing | South Africa
Debt Instrument [Line Items]
Long-term debt, amount bearing fixed interest							10,500			10,500
Amount of long term debt outstanding							$ 125,600			$ 125,600
Term debt | Permanent financing | South Africa | Minimum
Debt Instrument [Line Items]
Long-term debt, variable interest debt, interest rate							12.30%			12.30%
Term debt | Permanent financing | South Africa | Maximum
Debt Instrument [Line Items]
Long-term debt, variable interest debt, interest rate							13.00%			13.00%
Term debt | Permanent financing | India
Debt Instrument [Line Items]
Long-term debt, amount bearing fixed interest							$ 20,500			$ 20,500
Term debt | Permanent financing | India | Matures in September 2026
Debt Instrument [Line Items]
Stated interest rate							4.54%			4.54%
Term debt | Permanent financing | India | Matures in December 2026
Debt Instrument [Line Items]
Stated interest rate							12.00%			12.00%
Term debt | Permanent financing | Boshof
Debt Instrument [Line Items]
Amount of long term debt outstanding							$ 181,600			$ 181,600
Term debt | Permanent financing | ESP Urja and Azure | India
Debt Instrument [Line Items]
Long-term debt, amount bearing fixed interest							$ 18,400			$ 18,400
Term debt | Permanent financing | ESP Urja and Azure | India | Matures in December 2026
Debt Instrument [Line Items]
Stated interest rate							4.70%			4.70%
Term debt | Permanent financing | India PSA
Debt Instrument [Line Items]
Repayments of project-level indebtedness of projects in equity method investment							$ 23,600
Loss (gain) on the extinguishment of debt							400
Term debt | Permanent financing | Three-month LIBOR And three-month Johannesburg Interbank agreed rate | South Africa
Debt Instrument [Line Items]
Long-term debt, amount bearing variable interest							307,300			$ 307,300
Term debt | Permanent financing | Kuala Lumpur Interbank offered rate | Malaysia
Debt Instrument [Line Items]
Long-term debt, amount bearing variable interest							$ 6,100			$ 6,100
Stated interest rate							4.00%			4.00%
Term debt | Investor | Permanent financing | Silver Star Pavilion and Fortune 11 | Malaysia
Debt Instrument [Line Items]
Long-term debt, amount bearing fixed interest							$ 1,200			$ 1,200
Stated interest rate							4.00%			4.00%
Senior notes
Debt Instrument [Line Items]
Extinguishment of debt, amount						$ 49,600
Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Project level debt					791,826		$ 752,445			$ 752,445		791,826
Stated interest rate							9.80%			9.80%
Debt repurchase program, authorized amount					40,000							40,000
Extinguishment of debt, amount				$ 41,000	8,600
Repayments of senior debt				33,200	6,800	40,000
Payments of debt extinguishment costs				$ 1,900	$ 400	$ 2,300
Loss (gain) on the extinguishment of debt								$ (6,300)
Global Operating LLC | Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Amount of long term debt outstanding							$ 752,445			$ 752,445
Debt instrument, debt covenant, grace period for annual report		60 days
Debt covenant, cure period		90 days
Global Operating LLC | Senior notes | Subsequent event | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Stated interest rate													4.00%
Unspecified foreign currency hedging counterparty
Debt Instrument [Line Items]
Debt instrument, debt covenant, grace period for annual report	120 days
Unspecified foreign currency hedging counterparty | Global Operating LLC
Debt Instrument [Line Items]
Debt covenant, cure period	30 days
Accounts payable | Senior notes | 9.75% Senior Notes due 2022
Debt Instrument [Line Items]
Repurchases completed, principal and interest due												$ 400

Long-Term Debt - Debt Maturitie

Long-Term Debt - Debt Maturities Table (Details) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Debt Instrument [Line Items]
Debt maturities, within 1 year	$ 12,617
Debt maturities, year 1 through year 2	8,145
Debt maturities, year 2 through year 3	10,176
Debt maturities, year 3 through year 4	149,613
Debt maturities, year 4 through year 5	17,221
Debt maturities, thereafter	1,035,954
Total long-term debt	1,233,726	$ 1,295,761
Corporate-level debt
Debt Instrument [Line Items]
Debt maturities, within 1 year	0
Debt maturities, year 1 through year 2	0
Debt maturities, year 2 through year 3	0
Debt maturities, year 3 through year 4	135,000
Debt maturities, year 4 through year 5	0
Debt maturities, thereafter	752,445
Total long-term debt	887,445
Permanent financing
Debt Instrument [Line Items]
Debt maturities, within 1 year	12,617
Debt maturities, year 1 through year 2	8,145
Debt maturities, year 2 through year 3	10,176
Debt maturities, year 3 through year 4	14,613
Debt maturities, year 4 through year 5	17,221
Debt maturities, thereafter	283,509
Total long-term debt	$ 346,281

Income Taxes - Schedule of Tax

Income Taxes - Schedule of Tax Provision (Details) - USD ($) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015
Income Tax Disclosure [Abstract]
Income (loss) before income tax expense	$ 7,742	$ (23,347)	$ 2,352	$ (33,454)
Income tax expense (benefit)	$ 2,061	$ (668)	$ 2,919	$ 450
Effective tax rate	26.60%	2.90%	124.10%	(1.30%)

Income Taxes - Narrative (Detai

Income Taxes - Narrative (Details)	6 Months Ended
	Jun. 30, 2016
Income Taxes [Line Items]
Income tax benefit at U.S. federal statutory rate	35.00%
Global LLC
Income Taxes [Line Items]
Ownership percentage by parent	64.80%
SunEdison
Income Taxes [Line Items]
Total non-controlling interests	35.20%

Derivatives - Summary of Activi

Derivatives - Summary of Activities Related to Derivative Instruments (Details) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Other assets (liabilities) | Designated as Hedging Instrument | Interest rate swaps
Derivatives, Fair Value [Line Items]
Derivative assets (liabilities) at fair value	$ (2,329)	$ 6,210
Other assets (liabilities) | Designated as Hedging Instrument | Cross currency swaps
Derivatives, Fair Value [Line Items]
Derivative assets (liabilities) at fair value	50,566	64,083
Other assets (liabilities) | Derivatives Not Designated as Hedging | Interest rate swaps
Derivatives, Fair Value [Line Items]
Derivative assets (liabilities) at fair value	412	5,194
Other assets (liabilities) | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives, Fair Value [Line Items]
Derivative assets (liabilities) at fair value	(9,549)	21,383
Accumulated other comprehensive loss (income) | Designated as Hedging Instrument | Interest rate swaps
Derivatives, Fair Value [Line Items]
Accumulated other comprehensive (income) loss, fair value	2,329	(6,210)
Accumulated other comprehensive loss (income) | Designated as Hedging Instrument | Cross currency swaps
Derivatives, Fair Value [Line Items]
Accumulated other comprehensive (income) loss, fair value	$ 9,779	$ 1,202

Derivatives - Schedule of Loss

Derivatives - Schedule of Loss (Gain) Derivatives Not Designated as Hedging (Details) - Derivatives Not Designated as Hedging - USD ($) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015
Interest (income) expense | Interest rate swaps
Derivatives [Line Items]
Loss (gain) on derivatives	$ (1,813)	$ (1,064)	$ (4,782)	$ (470)
Loss on foreign currency exchange | Foreign currency forward contracts
Derivatives [Line Items]
Loss (gain) on derivatives	$ 14,021	$ 0	$ 32,184	$ 0

Derivatives - Narrative (Detail

Derivatives - Narrative (Details) - USD ($)	3 Months Ended		6 Months Ended		12 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015	Dec. 31, 2014	Dec. 31, 2015
Derivative Instruments, Gain (Loss) [Line Items]
Derivative collateral received or pledged	$ 0		$ 0			$ 0
Fair value of outstanding contracts, net gain (loss)	9,000,000		9,000,000
Foreign currency forward contracts | Derivatives Not Designated as Hedging | Other long-term liabilities
Derivative Instruments, Gain (Loss) [Line Items]
Combined notional value	293,119,000		293,119,000
Loss on foreign currency exchange | Foreign currency forward contracts | Derivatives Not Designated as Hedging
Derivative Instruments, Gain (Loss) [Line Items]
Loss (gain) on derivatives	$ 14,021,000	$ 0	$ 32,184,000	$ 0
Accumulated net gain (loss) from cash flow hedges including portion attributable to non-controlling interest | Cross currency swaps
Derivative Instruments, Gain (Loss) [Line Items]
Reclassification from AOCI, before tax					$ 5,900,000

Derivatives - Summary of Notion

Derivatives - Summary of Notional Amounts (Details)	Jun. 30, 2016USD ($)
Designated as Hedging Instrument | Interest rate swaps
Derivatives [Line Items]
Notional amount	$ 121,213,000
Designated as Hedging Instrument | Cross currency swaps
Derivatives [Line Items]
Notional amount	121,213,000
Derivatives Not Designated as Hedging | Interest rate swaps
Derivatives [Line Items]
Notional amount	113,612,000
Derivatives Not Designated as Hedging | Other long-term liabilities | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	293,119,000
BRL | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	87,333,000
CNY | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	34,192,000
INR | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	85,904,000
MYR | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	7,940,000
THB | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	11,408,000
ZAR | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	38,691,000
USD | Derivatives Not Designated as Hedging | Foreign currency forward contracts
Derivatives [Line Items]
Notional amount	$ 27,651,000

Fair Value of Financial Instr68

Fair Value of Financial Instruments - Recurring Fair Value Measurements and Fair Value of Long-Term Debt (Details) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	$ 39,100	$ 96,870
Carrying Amount
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Long-term debt, including current portion	1,233,726	1,295,761
Fair Value
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Long-term debt, including current portion	1,148,307	1,125,124
Interest rate swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	(1,917)	11,404
Foreign currency forward contracts | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	(9,549)	21,383
Cross currency swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	50,566	64,083
Level 1 | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	(9,549)	21,383
Level 1 | Interest rate swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 1 | Foreign currency forward contracts | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	(9,549)	21,383
Level 1 | Cross currency swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 2 | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	48,649	75,487
Level 2 | Interest rate swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	(1,917)	11,404
Level 2 | Foreign currency forward contracts | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 2 | Cross currency swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	50,566	64,083
Level 3 | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 3 | Interest rate swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 3 | Foreign currency forward contracts | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	0	0
Level 3 | Cross currency swaps | Fair value, measurements, recurring
Fair Value, Assets and Liabilities Measured on Recurring and Nonrecurring Basis [Line Items]
Derivative assets (liabilities) at fair value	$ 0	$ 0

Stockholders' Equity - Narrativ

Stockholders' Equity - Narrative (Details) - $ / shares	Feb. 29, 2016	Jun. 30, 2016	Dec. 31, 2015
Common Class A
Class of Stock [Line Items]
Common stock, shares outstanding		113,101,162	114,630,318
Common stock dividends declared (in dollars per share)	$ 0.275
Common stock dividends declared, annualized (in dollars per share)	$ 1.10
Treasury Stock
Class of Stock [Line Items]
Common stock, shares outstanding			5,244
Treasury Stock | Common Class A
Class of Stock [Line Items]
Common stock, shares outstanding		5,244

Stockholders' Equity - Schedule

Stockholders' Equity - Schedule of Outstanding Equity Securities (Details) - shares	Jun. 30, 2016	Dec. 31, 2015
Class of Stock [Line Items]
Preferred stock outstanding (in shares)	0	0
Total shares outstanding (in shares)	174,444,216
Common Class A
Class of Stock [Line Items]
Common stock outstanding (in shares)	113,101,162	114,630,318
Common Class A | Multiple shareholders
Class of Stock [Line Items]
Common stock outstanding (in shares)	113,101,162
Common Class B
Class of Stock [Line Items]
Common stock outstanding (in shares)	61,343,054	61,343,054
Common Class B | SunEdison stock transaction
Class of Stock [Line Items]
Common stock outstanding (in shares)	61,343,054
Common Class B1
Class of Stock [Line Items]
Common stock outstanding (in shares)	0	0

Stock-Based Compensation - Narr

Stock-Based Compensation - Narrative (Details) $ / shares in Units, $ in Thousands	Dec. 23, 2015USD ($)shares	Aug. 05, 2015	Mar. 31, 2015shares	Sep. 26, 2014shares	Jun. 30, 2016USD ($)$ / sharesshares	Jun. 30, 2015USD ($)	Jun. 30, 2016USD ($)$ / sharesshares	Jun. 30, 2015USD ($)	Dec. 31, 2015$ / sharesshares	Jan. 30, 2017shares
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Maximum share-based compensation contractual term							10 years
Number of shares authorized under the incentive plan (in shares)					17,884,910		17,884,910
Number of shares available for future grant (in shares)					9,331,045		9,331,045
Stock-based compensation expense | $					$ 900	$ 0	$ 2,000	$ 0
Allocated stock-based compensation | $					15,965	$ 3,852	23,202	$ 6,819
Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Common stock, conversion ratio		178.8491
Unrecognized compensation costs | $					$ 1,500		$ 1,500
Period for unrecognized compensation cost recognition							3 years 2 months 12 days
Weighted average grant date fair value (in dollars per share) | $ / shares					$ 0.17		$ 0.17		$ 0.18
Restricted stock granted (in shares)							0
Expected volatility			40.00%
Awards outstanding					6,025,417		6,025,417		7,774,554
Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Unrecognized compensation costs | $					$ 17,600		$ 17,600
Period for unrecognized compensation cost recognition							2 years 3 months 18 days
Restricted stock granted (in shares)							403,737
Awards outstanding					2,515,947		2,515,947		2,846,049
Common Class C | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)			2,750	1,550
Common Class A | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)			491,835	277,216
Percentage of shares vesting									25.00%
Common Class A | Percentage vesting on the second anniversary of the grant date | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Common Class A | Percentage vesting on the second anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Common Class A | Percentage vesting on the third anniversary of the grant date | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Common Class A | Percentage vesting on the third anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Common Class A | Percentage vesting on the fourth anniversary of the grant date | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Common Class A | Percentage vesting on the fourth anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
Executive officers and management | Common Class A | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)	2,024,800
Total grant date fair value | $	$ 11,000
Requisite service period	3 years
Executive officers and management | Common Class A | Percentage vesting on the first anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting	25.00%
Executive officers and management | Common Class A | Percentage vesting on the second anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting	25.00%
Executive officers and management | Common Class A | Percentage vesting on the third anniversary of the grant date | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting	50.00%
2014 Incentive Plan | Common Class C | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Expected volatility				40.00%
2014 Incentive Plan | Common Class A | Percentage vesting on the first anniversary of the grant date | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Percentage of shares vesting							25.00%
September 26, 2014 | 2014 Incentive Plan | Common Class C | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)				31,350
Lack of marketability discount				10.00%
Time to liquidity event				7 months
Discount rate				13.00%
March 31, 2015 | 2014 Incentive Plan | Common Class C | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)			35,245
Lack of marketability discount			5.00%
Time to liquidity event			3 months
Discount rate			12.00%
Class C common stock converted to Class A common stock | September 26, 2014 | 2014 Incentive Plan | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)				5,606,918
Class C common stock converted to Class A common stock | March 31, 2015 | 2014 Incentive Plan | Restricted stock award (RSA)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Restricted stock granted (in shares)			6,303,519
Stock-based compensation | SunEdison
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Allocated stock-based compensation | $					$ 0		$ 0
SunEdison | Stock-based compensation
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Allocated stock-based compensation | $					$ 0		$ 0
Subsequent event | Restricted stock units (RSUs)
Share-based Compensation Arrangement by Share-based Payment Award [Line Items]
Awards outstanding										2,382,487

Stock-Based Compensation - Sche

Stock-Based Compensation - Schedule of Restricted Stock (Details) $ / shares in Units, $ in Millions	6 Months Ended
	Jun. 30, 2016USD ($)$ / sharesshares
Restricted stock award (RSA)
Number of Shares Outstanding [Roll Forward]
Beginning balance (in shares)	7,774,554
Granted (in shares)	0
Forfeited (in shares)	(1,749,137)
Ending balance (in shares)	6,025,417
Weighted Average Grant Date Fair Value Per Share
Weighted average grant date fair value (in dollars per share) | $ / shares	$ 0.18
Forfeited (in dollars per share) | $ / shares	0.18
Weighted average grant date fair value (in dollars per share) | $ / shares	$ 0.17
Outstanding, aggregate intrinsic value | $	$ 19.6
Restricted stock units (RSUs)
Number of Shares Outstanding [Roll Forward]
Beginning balance (in shares)	2,846,049
Granted (in shares)	403,737
Forfeited (in shares)	(733,839)
Ending balance (in shares)	2,515,947
Weighted Average Grant Date Fair Value Per Share
Outstanding, aggregate intrinsic value | $	$ 8.2
Outstanding, weighted average remaining contractual life	1 year 6 months 24 days

Earnings (Loss) Per Share - Sch

Earnings (Loss) Per Share - Schedule of Basic and Diluted Loss Per Share (Details) - USD ($) $ / shares in Units, $ in Thousands	3 Months Ended	6 Months Ended
	Jun. 30, 2016	Jun. 30, 2016
Earnings Per Share [Abstract]
Net income (loss) attributable to Class A common stockholders	$ 1,097	$ (3,535)
Less: dividends paid on Class A common stock and participating RSAs	0	30,674
Undistributed loss attributable to Class A stockholders	$ 1,097	$ (34,209)
Weighted-average shares outstanding (in shares)	106,856,000	106,856,000
Distributed earnings per share, basic (usd per share)	$ 0	$ 0.29
Undistributed loss per share, basic (usd per share)	0.01	(0.32)
Basic and diluted loss per share (in usd per share)	0.01	(0.03)
Distributed earnings per share, diluted (usd per share)	0	0.29
Undistributed loss per share, diluted (usd per share)	$ 0.02	$ (0.31)
Common Class B
Antidilutive Securities Excluded from Computation of Earnings Per Share [Line Items]
Antidilutive securities excluded from computation of EPS (in shares)		61,343,054
Restricted stock award (RSA)
Antidilutive Securities Excluded from Computation of Earnings Per Share [Line Items]
Antidilutive securities excluded from computation of EPS (in shares)		6,245,398
Restricted stock units (RSUs)
Antidilutive Securities Excluded from Computation of Earnings Per Share [Line Items]
Antidilutive securities excluded from computation of EPS (in shares)		2,515,947

Non-Controlling Interests - Sch

Non-Controlling Interests - Schedule of Non-controlling Interests by Entity in Stockholders' Equity (Details) - USD ($) $ in Thousands	Jun. 30, 2016	Dec. 31, 2015
Earnings Per Share, Basic, by Common Class, Including Two Class Method [Line Items]
Total non-controlling interests	$ 487,114	$ 481,106
Global LLC
Earnings Per Share, Basic, by Common Class, Including Two Class Method [Line Items]
Ownership percentage by parent	64.80%
SunEdison
Earnings Per Share, Basic, by Common Class, Including Two Class Method [Line Items]
Total non-controlling interests	35.20%
Investor | Non-controlling interests in power plants
Earnings Per Share, Basic, by Common Class, Including Two Class Method [Line Items]
Total non-controlling interests	$ 91,382	105,566
Investor | SunEdison | Global LLC
Earnings Per Share, Basic, by Common Class, Including Two Class Method [Line Items]
Total non-controlling interests	$ 395,732	$ 375,540

Commitments and Contingencies -

Commitments and Contingencies - Narrative (Details) $ / shares in Units, ¥ in Millions, shares in Millions

Jul. 31, 2018CNY (¥)

Jan. 31, 2017USD ($)

Jul. 14, 2016USD ($)$ / sharesshares

Jun. 03, 2016USD ($)

Jun. 03, 2016CNY (¥)

Apr. 12, 2016USD ($)director

Nov. 05, 2015claim

Jan. 31, 2016USD ($)

Jan. 04, 2016claim

Jun. 30, 2016CNY (¥)

Mar. 31, 2017USD ($)

Oct. 07, 2016USD ($)

Oct. 05, 2016claim

Jun. 30, 2016USD ($)

Jun. 30, 2016CNY (¥)

Dec. 31, 2015USD ($)

Aug. 31, 2015power_plant

Aug. 05, 2015$ / shares

Apr. 30, 2015power_plantMW

Other Commitments [Line Items]

Deposits for acquisitions

$ 282,101,000

$ 282,101,000

India PSA

Other Commitments [Line Items]

Deposits for acquisitions

231,000,000

231,000,000

BioTherm

Other Commitments [Line Items]

Deposits for acquisitions

51,101,000

$ 51,101,000

Number of projects acquired | power_plant

3

South Africa | BioTherm

Other Commitments [Line Items]

Capacity of acquired power plants | MW

32.6

Number of projects acquired | power_plant

3

3

Fraser v. Wuebbels, Iron Workers Mid-South Pension Fund, et al., Badri, and Patel v. TerraForm Global, Inc. et al

Other Commitments [Line Items]

Number of claims filed | claim

4

Beltran and Pyramid Holdings v. TerraForm Global, Inc. et al.

Other Commitments [Line Items]

Number of claims filed | claim

2

Kingdom Associates, VMT II LLC, and Canyon Capital Advisors LLC v. TerraForm Global, Inc. | Subsequent event

Other Commitments [Line Items]

Number fo claims pending | claim

3

Suzlon Energy (Tianjin) Limited (SETL)

Other Commitments [Line Items]

Payments for settlements award

$ 500,000

Suzlon Energy (Tianjin) Limited (SETL) | Beijing Aliyun Investment Consulting Co. Ltd (Aliyun)

Other Commitments [Line Items]

Payments for settlements award | ¥

¥ 45

Amount sought through litigation

$ (7,100,000)

¥ (47)

Settlement liability

$ 300,000

¥ 2

Renova arbitration

Other Commitments [Line Items]

Share price | $ / shares

$ 15

Renova arbitration | Subsequent event

Other Commitments [Line Items]

Share price | $ / shares

$ 3.38

Aldridge v. Blackmore

Other Commitments [Line Items]

Number of directors named in litigation | director

4

Scenario, forecast | BioTherm

Other Commitments [Line Items]

Payments to acquire businesses

$ 8,900,000

$ 74,500,000

Scenario, forecast | Suzlon Energy (Tianjin) Limited (SETL) | Beijing Aliyun Investment Consulting Co. Ltd (Aliyun)

Other Commitments [Line Items]

Payments for settlements award | ¥

¥ 2

Positive outcome of litigation | SunEdison Bankruptcy Case | Subsequent event

Other Commitments [Line Items]

Amount of damages sought

$ 2,000,000,000

Pending litigation | Renova arbitration | Subsequent event

Other Commitments [Line Items]

Loss contingency, number of shares in warranty agreement (in shares) | shares

7

Loss contingency, damages sought, value

$ 250,000,000

Loss contingency, damages sought, value based on number of shares (in shares) | shares

20

Pending litigation | TerraForm Global, Inc. v. SunEdison, Inc, et al. | India PSA

Other Commitments [Line Items]

Amount sought through litigation

$ (231,000,000)

Related Parties - Agreements Na

Related Parties - Agreements Narrative (Details)	2 Months Ended	3 Months Ended		6 Months Ended
	Jan. 31, 2016USD ($)	Jun. 30, 2016USD ($)	Jun. 30, 2015USD ($)	Jun. 30, 2016USD ($)	Jun. 30, 2015USD ($)	Feb. 24, 2016MW	Dec. 31, 2015USD ($)	Aug. 05, 2015USD ($)	Aug. 04, 2015USD ($)MW
Related Party Transaction [Line Items]
General and administrative - affiliate		$ 15,965,000	$ 3,852,000	$ 23,202,000	$ 6,819,000
Cost of operations - affiliate		4,683,000	1,369,000	9,713,000	2,333,000
Due to Sun Edison, net		$ 29,326,000		29,326,000			$ 44,254,000
Contributions of additional paid in capital				48,983,000	7,245,000
Senior notes
Related Party Transaction [Line Items]
Extinguishment of debt, amount	$ 49,600,000
Additional Paid-in-Capital | SunEdison
Related Party Transaction [Line Items]
Contributions of additional paid in capital				38,400,000	$ 67,900,000
Del Litoral | SunEdison
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW									17.4
El Naranjal | SunEdison
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW									57.4
Bora Bora | SunEdison
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW									24.1
NPS Star
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW						17.8
WXA
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW						17.8
Management services agreement | Maximum | SunEdison
Related Party Transaction [Line Items]
Management fee due to parent in 2015								$ 0
Management fee due to parent in 2016-2018 (in percent of Terra LLC's cash available for distribution)								2.50%
Corporate overhead allocation | SunEdison
Related Party Transaction [Line Items]
General and administrative - affiliate			$ 3,900,000	23,202,000
Interest payment agreement | SunEdison
Related Party Transaction [Line Items]
IPO terms, expected aggregate interest expense deduction due to debt extinguishment	$ 2,900,000
Interest payment agreement | Senior notes | Maximum | Global Operating LLC | SunEdison
Related Party Transaction [Line Items]
IPO terms, expected aggregate interest expense year one									$ 81,200,000
IPO terms, expected aggregate interest expense year two									40,000,000
IPO terms, expected aggregate interest expense year three									30,000,000
IPO terms, expected aggregate interest expense year four									20,000,000
IPO terms, expected aggregate interest expense year five									$ 10,000,000
Interest payments received on Senior notes				$ 41,200,000

Related Parties - Compulsorily

Related Parties - Compulsorily Convertible Debentures Narrative (Details) (Details)	Aug. 05, 2015USD ($)MW	Oct. 07, 2016USD ($)	Jun. 30, 2016USD ($)	Jun. 30, 2016INR (₨)
Compulsorily convertible debentures (CCD) | SunEdison
Related Party Transaction [Line Items]
Unsecured compulsorily convertible debentures			$ 9,600,000	₨ 650,000,000
Unnamed third party | Compulsorily convertible debentures (CCD)
Related Party Transaction [Line Items]
Unsecured compulsorily convertible debentures			$ 1,700,000	₨ 112,100,000
Call rights projects | SunEdison
Related Party Transaction [Line Items]
Capacity of acquired power plants | MW	1,600
Support agreement, additional power plant capacity | MW	4,200
Support agreement, right of first offer, contract time period	6 years
Global LLC | Call rights projects | SunEdison
Related Party Transaction [Line Items]
Support agreement, projected cash available for distributions, minimum | $	$ 1,400,000,000
Support agreement, projected cash available for distributions, minimum, term of commercial operation	12 months
SunEdison Bankruptcy Case | Positive outcome of litigation | Subsequent event
Related Party Transaction [Line Items]
Estimated un secured claims amount (in excess of $2.0 billion) | $		$ 2,000,000,000

Segment Reporting - Summary of

Segment Reporting - Summary of Financial Information for Reportable Segments (Details) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016USD ($)	Jun. 30, 2015USD ($)	Jun. 30, 2016USD ($)reportable_segment	Jun. 30, 2015USD ($)	Dec. 31, 2015USD ($)
Segment Reporting Information [Line Items]
Number of reportable segments | reportable_segment			2
Operating revenues, net	$ 56,430	$ 25,681	$ 104,116	$ 43,487
Depreciation, accretion and amortization	13,025	3,336	27,597	6,071
Other operating costs and expenses	26,105	24,586	56,526	33,361
Interest expense, net	28,975	28,186	62,638	45,007
Other non-operating (income) expenses	(19,417)	(7,080)	(44,997)	(7,498)
Income tax expense (benefit)	2,061	(668)	2,919	450
Net income (loss)	5,681	(22,679)	(567)	(33,904)
Total assets	2,655,785		2,655,785		$ 2,687,166
Operating segments | Solar
Segment Reporting Information [Line Items]
Operating revenues, net	28,878	22,017	57,617	39,823
Depreciation, accretion and amortization	6,509	3,738	12,381	6,473
Other operating costs and expenses	4,703	7,990	11,273	9,312
Interest expense, net	10,372	12,863	22,634	23,247
Other non-operating (income) expenses	14,304	(6,640)	18,549	(7,058)
Income tax expense (benefit)	0	0	0	0
Net income (loss)	(7,010)	4,066	(7,220)	7,849
Total assets	671,131		671,131		764,475
Operating segments | Wind
Segment Reporting Information [Line Items]
Operating revenues, net	27,552	3,664	46,499	3,664
Depreciation, accretion and amortization	6,516	(402)	15,216	(402)
Other operating costs and expenses	5,899	4,085	13,328	4,085
Interest expense, net	(281)	725	(2,049)	725
Other non-operating (income) expenses	1,053	(440)	3,042	(440)
Income tax expense (benefit)	0	0	0	0
Net income (loss)	14,365	(304)	16,962	(304)
Total assets	431,578		431,578		375,683
Corporate
Segment Reporting Information [Line Items]
Operating revenues, net	0	0	0	0
Depreciation, accretion and amortization	0	0	0	0
Other operating costs and expenses	15,503	12,510	31,925	19,963
Interest expense, net	18,884	14,598	42,053	21,036
Other non-operating (income) expenses	(34,774)	0	(66,588)	0
Income tax expense (benefit)	2,061	(668)	2,919	450
Net income (loss)	(1,674)	$ (26,440)	(10,309)	$ (41,449)
Total assets	$ 1,553,076		$ 1,553,076		$ 1,547,008

Other Comprehensive Income (L79

Other Comprehensive Income (Loss) - Schedule of Accumulated Other Comprehensive Income (Details) - USD ($) $ in Thousands	3 Months Ended	6 Months Ended
	Jun. 30, 2016	Jun. 30, 2016
Accumulated foreign currency adjustment attributable to Parent
AOCI Attributable to Parent, before Tax [Roll Forward]
Balance as of December 31, 2015		$ (12,819)
Balance as of June 30, 2016	$ 10,503	10,503
Accumulated net gain (loss) from cash flow hedges attributable to Parent
AOCI Attributable to Parent, before Tax [Roll Forward]
Balance as of December 31, 2015		1,638
Balance as of June 30, 2016	(4,022)	(4,022)
AOCI attributable to Parent
AOCI Attributable to Parent, before Tax [Roll Forward]
Balance as of December 31, 2015		(11,181)
Balance as of June 30, 2016	6,481	6,481
Accumulated foreign currency adjustment including portion attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Other comprehensive income (loss)	33,954	38,511
Accumulated net gain (loss) from cash flow hedges including portion attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Other comprehensive income (loss)	(2,653)	(17,116)
AOCI including portion attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Other comprehensive income (loss)	$ 31,301	21,395
Accumulated foreign currency adjustment attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Less: other comprehensive income (loss) attributable to non-controlling interests		15,189
Accumulated net gain (loss) from cash flow hedges attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Less: other comprehensive income (loss) attributable to non-controlling interests		(11,456)
AOCI attributable to non-controlling interest
AOCI Attributable to Parent, before Tax [Roll Forward]
Less: other comprehensive income (loss) attributable to non-controlling interests		$ 3,733

Other Comprehensive Income (L80

Other Comprehensive Income (Loss) - Schedule of Changes in Components of Accumulated Other Comprehensive Loss (Details) - USD ($) $ in Thousands	3 Months Ended		6 Months Ended
	Jun. 30, 2016	Jun. 30, 2015	Jun. 30, 2016	Jun. 30, 2015
AOCI Attributable to Parent, Net of Tax [Roll Forward]
Other comprehensive income (loss), net of tax	$ 36,364	$ (6,485)	$ 26,458	$ (2,111)
Other comprehensive income (loss), net of tax, parent	21,478	(6,485)	19,422	(2,111)
Accumulated foreign currency adjustment including portion attributable to non-controlling interest
AOCI Attributable to Parent, Net of Tax [Roll Forward]
Other comprehensive income (loss), before tax	33,954		38,511
Other comprehensive income tax	(271)		(271)
Other comprehensive income (loss), net of tax	34,225	(2,338)	38,782	2,139
Accumulated net gain (loss) from cash flow hedges including portion attributable to non-controlling interest
AOCI Attributable to Parent, Net of Tax [Roll Forward]
Other comprehensive income (loss), before tax	(2,653)		(17,116)
Other comprehensive income tax	(4,792)		(4,792)
Other comprehensive income (loss), net of tax	2,139	(4,147)	(12,324)	(4,250)
AOCI including portion attributable to non-controlling interest
AOCI Attributable to Parent, Net of Tax [Roll Forward]
Other comprehensive income (loss), before tax	31,301		21,395
Other comprehensive income tax	(5,063)		(5,063)
Other comprehensive income (loss), net of tax	36,364	(6,485)	26,458	(2,111)
AOCI attributable to non-controlling interest
AOCI Attributable to Parent, Net of Tax [Roll Forward]
Other comprehensive income (loss), net of tax	$ 14,886	$ 0	$ 7,036	$ 0

Subsequent Events - Narrative (

Subsequent Events - Narrative (Details)	Jun. 10, 2016	Jan. 29, 2017USD ($)	Jan. 27, 2017claim	Jan. 20, 2017scenario$ / shares	Jan. 13, 2017member	Jan. 10, 2017member
Subsequent Event [Line Items]
Extension period for 10-K filing compliance, number of calendar days	180 days
Subsequent event
Subsequent Event [Line Items]
Bankruptcy settlement agreements | claim			2
Number of business combination scenarios under exclusivity agreement | scenario				4
Conflicts Committee | Subsequent event
Subsequent Event [Line Items]
Number of directors | member					3
Audit Committee | Subsequent event
Subsequent Event [Line Items]
Number of directors | member						4
Compensation Committee | Subsequent event
Subsequent Event [Line Items]
Number of directors | member						3
Global LLC | Conflicts Committee | Subsequent event
Subsequent Event [Line Items]
Number of directors | member					3
SunEdison | SunEdison | Subsequent event
Subsequent Event [Line Items]
MOU, consideration to be transferred upon sale of entity | $		$ 0.250
SunEdison | SunEdison | TerraForm Power | Subsequent event
Subsequent Event [Line Items]
MOU, consideration to be transferred upon sale of entity | $		$ 0.369
Whole Company Transaction | Brookfield Asset Management Inc. | Subsequent event
Subsequent Event [Line Items]
Percentage of entity to be acquired under exclusivity agreement				100.00%
Share price offered (in usd per share)				$ 4.15
Whole GLBL with TERP Transaction | Brookfield Asset Management Inc. | Subsequent event
Subsequent Event [Line Items]
Percentage of entity to be acquired under exclusivity agreement				100.00%
Share price offered (in usd per share)				$ 4.35
Share price to be paid upon closing of transaction (in usd per share)				0.20
Share price to be paid immediately (in usd per share)				$ 4.15
Sponsorship Transaction | Brookfield Asset Management Inc. | Subsequent event
Subsequent Event [Line Items]
Percentage of entity to be acquired under exclusivity agreement				50.10%
Share price offered (in usd per share)				$ 4.15
Double Sponsorship Transaction | Brookfield Asset Management Inc. | Subsequent event
Subsequent Event [Line Items]
Share price offered (in usd per share)				$ 4.25
Maximum | Whole GLBL with TERP Transaction | Brookfield Asset Management Inc. | TerraForm Power | Subsequent event
Subsequent Event [Line Items]
Percentage of entity to be acquired under exclusivity agreement				100.00%
Minimum | Whole GLBL with TERP Transaction | Brookfield Asset Management Inc. | TerraForm Power | Subsequent event
Subsequent Event [Line Items]
Percentage of entity to be acquired under exclusivity agreement				50.10%