Commitments and Contingencies | 15. Commitments and Contingencies The Company records amounts representing its probable estimated liabilities relating to claims, guarantees, litigation, audits and investigations. The Company relies in part on qualified actuaries to assist it in determining the level of reserves to establish for insurance-related claims that are known and have been asserted against it, and for insurance-related claims that are believed to have been incurred based on actuarial analysis, but have not yet been reported to the Company’s claims administrators as of the respective balance sheet dates. The Company includes any adjustments to such insurance reserves in its consolidated results of operations. The Company and its affiliates are involved in various investigations, audits, claims and lawsuits arising in the normal course of business. The Company is not always aware that it is under investigation, or of its status in such matters, but currently is aware of certain pending investigations, including the matters described below. In the opinion of management, based on current information and discussions with counsel, with the exception of matters noted below, the ultimate resolution of these matters is not expected to have a material adverse effect on the Company’s consolidated balance sheet or statements of income or cash flows. The Company is not always aware that it or its’ affiliates are under investigation, or of the status of such matters, but the Company is currently aware of certain pending investigations, including the matters described below. In some instances, the Company guarantees that a project, when complete, will achieve specified performance standards. If the project subsequently fails to meet guaranteed performance standards, the Company may either incur additional costs or be held responsible for the costs incurred by the client to achieve the required performance standards. At June 30, 2015, the Company was contingently liable in the amount of approximately $411.8 million under standby letters of credit issued primarily in connection with general and professional liability insurance programs and for payment and performance guarantees. In the ordinary course of business, the Company enters into various agreements providing financial or performance assurances to clients on behalf of certain unconsolidated partnerships, joint ventures and other jointly executed contracts. These agreements are entered into primarily to support the project execution commitments of these entities. In addition, in connection with the investment activities of AECOM Capital, we provide guarantees of certain obligations, including guarantees for completion of projects, repayment of debt, environmental indemnity obligations and acts of willful misconduct. The guarantees have various expiration dates. The maximum potential payment amount of an outstanding performance guarantee is the remaining cost of work to be performed by or on behalf of third parties. Generally, under joint venture arrangements, if a partner is financially unable to complete its share of the contract, the other partner(s) will be required to complete those activities. The Company does not expect that these guarantees will have a material adverse effect on its consolidated balance sheet or statements of income or cash flows. USAID Egyptian Projects In November 2004, the federal government filed a civil action in Idaho federal district court against Washington Group International, a Delaware company (WGI), an affiliate of URS, which the Company acquired on October 17, 2014, and two of WGI’s subcontractors, asserting violations under the Federal False Claims Act and Federal Foreign Assistance Act of 1961 for failure to comply with U.S. Agency for International Development (USAID) source, origin, and nationality regulations in connection with five USAID-financed Egyptian projects beginning in the early 1990s. The federal government seeks a refund of the approximately $373 million paid to WGI under the contracts for the five completed and fully operational projects as well as damages and civil penalties (including doubling and trebling of damages) for violation of the statutes. In March 2005, WGI filed motions in Idaho federal district court and the United States Bankruptcy Court in Nevada contending that the federal government’s Idaho federal district court action was barred under the plan of reorganization approved by the Bankruptcy Court in 2002 when WGI emerged from bankruptcy protection. In 2006, the Idaho federal district court action was stayed pending the bankruptcy-related proceedings. On April 24, 2012, the Bankruptcy Court ruled that the bulk of the federal government’s claims under the Federal False Claims and the Federal Foreign Assistance Acts are not barred. On November 7, 2012, WGI appealed the Bankruptcy Court’s decision to the Ninth Circuit Bankruptcy Appellate Panel. On August 2, 2013, the Appellate Panel affirmed the Bankruptcy Court’s decision. On September 26, 2013, WGI appealed the Appellate Panel’s decision to the United States Ninth Circuit Court of Appeals. WGI contests the federal government’s allegations and intends to continue to defend this matter vigorously; however, WGI cannot provide assurance that it will be successful in these efforts. DOE Deactivation, Demolition, and Removal Project Washington Group International, an Ohio company (WGI Ohio), an affiliate of URS, executed a cost-reimbursable task order with the Department of Energy (DOE) in 2007 to provide deactivation, demolition and removal services at a New York State project site that, during 2010, experienced contamination and performance issues and remains uncompleted. In February 2011, WGI Ohio and the DOE executed a Task Order Modification that changed some cost-reimbursable contract provisions to at-risk. The Task Order Modification, including subsequent amendments, requires the DOE to pay all project costs up to $106 million, requires WGI Ohio and the DOE to equally share in all project costs incurred from $106 million to $146 million, and requires WGI Ohio to pay all project costs exceeding $146 million. WGI Ohio has incurred total project costs of approximately $300 million. Due to unanticipated requirements and permitting delays by federal and state agencies, as well as delays and related ground stabilization activities caused by Hurricane Irene in 2011, WGI Ohio has been required to perform work outside the scope of the Task Order Modification. In December 2014, WGI Ohio submitted claims against the DOE pursuant to the Contracts Disputes Acts seeking recovery of $103 million, including additional fees on changed work scope. Due to significant delays and uncertainties about responsibilities for the scope of remaining work, final costs necessary to complete this project may exceed $100 million. WGI Ohio can provide no certainty that it will recover the DOE claims and fees submitted in December 2014, as well as any other project costs after December 2014 that WGI Ohio is obligated to incur including the remaining project completion costs, which could have a material adverse effect on the Company’s results of operations. Canadian Pipeline Contract In January 2010, a pipeline owner filed an action in the Court of Queen’s Bench of Alberta, Canada against Flint Energy Services Ltd. (Flint), an affiliate of URS, as well as against a number of other defendants, alleging that the defendants negligently provided pipe coating and insulation system services, engineering, design services, construction services, and other work, causing damage to and abandonment of the line. The pipeline owner alleges it has suffered approximately C$85 million in damages in connection with the abandonment and replacement of the pipeline. Flint was the construction contractor on the pipeline project. Other defendants were responsible for engineering and design-services and for specifying and providing the actual pipe, insulation and coating materials used in the line. In January 2011, the pipeline owner served a Statement of Claim on Flint and, in September 2011, Flint filed a Statement of Defense denying that the damages to the coating system of the pipeline were caused by any negligence or breach of contract of Flint. Flint disputes the pipeline owner’s claims and intends to continue to defend this matter vigorously; however, it cannot provide assurance that it will be successful, in whole or in part, in these efforts. Waste Isolation Pilot Plant Environmental Incidents URS is a member of Nuclear Waste Partnership, LLC, a joint venture that manages and operates the Waste Isolation Pilot Plant (WIPP), a DOE federal waste repository in New Mexico designed to dispose of low level transuranic (TRU) radioactive waste generated by federal facilities. On February 5, 2014, an underground vehicle fire suspended operations at WIPP. On February 14, 2014, in a separate and unrelated event, a TRU waste container that originated from Los Alamos National Laboratory breached and released low levels of radiological contaminants from the mine at WIPP into the atmosphere. On December 6, 2014, the DOE and Nuclear Waste Partnership received an administrative compliance order and civil penalty of $17.7 million from the New Mexico Environment Department alleging violations of the Resource Conservation and Recovery Act and the New Mexico Hazardous Waste Act due to WIPP’s failure to prevent the underground fire and the radiological release. In addition, disposal operations at WIPP have been suspended until a final recovery plan can be implemented. Nuclear Waste Partnership, DOE and the New Mexico Environmental Department have executed a General Principles of Agreement, which, if incorporated into a final settlement document, would provide for DOE funding for various projects in lieu of any penalty payments. Tishman Inquiry The U.S. Attorney’s Office for the Eastern District of New York (USAO) has informed the Company’s subsidiary Tishman Construction Corporation (TCC) that, in connection with a wage and hour investigation of several New York area contractors, the USAO is investigating potential improper overtime payments to union workers on projects managed by TCC and other contractors in New York dating back to 1999. TCC, which was acquired by the Company in 2010, has cooperated fully with the investigation and, as of this date, no actions have been filed. AECOM Australia In 2005 and 2006, the Company’s main Australian subsidiary, AECOM Australia Pty Ltd (AECOM Australia), performed a traffic forecast assignment for a client consortium as part of the client’s project to design, build, finance and operate a tolled motorway tunnel in Australia. To fund the motorway’s design and construction, the client formed certain special purpose vehicles (SPVs) that raised approximately $700 million Australian dollars through an initial public offering (IPO) of equity units in 2006 and approximately an additional $1.4 billion Australian dollars in long term bank loans. The SPVs went into insolvency administrations in February 2011. KordaMentha, the receivers for the SPVs (the RCM Applicants), caused a lawsuit to be filed against AECOM Australia by the RCM Applicants in the Federal Court of Australia on May 14, 2012. Portigon AG (formerly WestLB AG), one of the lending banks to the SPVs, filed a lawsuit in the Federal Court of Australia against AECOM Australia on May 18, 2012. Separately, a class action lawsuit, which has been amended to include approximately 770 of the IPO investors, was filed against AECOM Australia in the Federal Court of Australia on May 31, 2012. All of the lawsuits claim damages that purportedly resulted from AECOM Australia’s role in connection with the above described traffic forecast. The RCM Applicants have claimed damages of approximately $1.68 billion Australian dollars (including interest, as of March 31, 2014). The damages claimed by Portigon AG as of June 17, 2014 were also recently quantified at approximately $76 million Australian dollars (including interest). The Company believes this claim is duplicative of damages already included in the RCM Applicants’ claim to the extent Portigon receives a portion of the RCM Applicants’ recovery. The class action applicants claim that they represent investors who acquired approximately $155 million Australian dollars of securities. On July 10, 2015, AECOM Australia, the RCM Applicants and Portigon AG entered into a Deed of Release settling the respective lawsuits. AECOM Australia disputes the claimed entitlements to damages asserted by the remaining class action lawsuit and will continue to defend this matter vigorously; AECOM Australia cannot provide assurance that it will be successful in these efforts. The potential range of loss and the resolution of this matter cannot be determined at this time and could have a material adverse effect on AECOM Australia and the results of its operations. DOE Hanford Nuclear Reservation URS Energy and Construction, Washington River Protection Solutions LLC and Washington Closure Hanford LLC, affiliates of URS, perform services under multiple contracts (including under the Waste Treatment Plant contract, the Tank Farm contract and the River Corridor contract) at the DOE’s Hanford nuclear reservation that have been subject to various government investigations or litigation: · Waste Treatment Plant government investigation: The federal government is conducting an investigation into our affiliate, URS Energy & Construction, a subcontractor on the Waste Treatment Plant, regarding contractual compliance and various technical issues in the design, development and construction of the Waste Treatment Plant. · Tank Farms government investigation: The federal government is conducting an investigation regarding the time keeping of employees at our joint venture, Washington River Protection Solutions LLC, when the joint venture took over as the prime contractor from another federal contractor. · Tank Farms government investigation: The federal government is conducting an investigation into the circumstances surrounding the response of our joint venture, Washington River Protection Solutions LLC, to a leak within the tank farms of the Hanford nuclear reservation. · River Corridor litigation: The federal government has partially intervened in a false claims act complaint filed in the Eastern District of Washington on December 2013 challenging our joint venture, Washington Closure Hanford LLC, and its contracting procedures under the Small Business Act. · Waste Treatment Plant whistleblower and employment claims: Two former employees have each filed employment related claims against our affiliate, URS Energy & Construction, seeking restitution for alleged retaliation and wrongful termination. URS Energy and Construction, Washington River Protection Solutions LLC and Washington Closure Hanford LLC dispute these investigations and claims and intend to continue to defend these matters vigorously; however, URS Energy and Construction, Washington River Protection Solutions LLC and Washington Closure Hanford LLC cannot provide assurances that they will be successful in these efforts. The resolution of these matters cannot be determined at this time and could have a material adverse effect on the Company’s results of operations and cash flows. |